{ "article": { "LEGIARTI000050742674": { "META": { "META_SPEC": { "META_ARTICLE": { "NUM": "1", "TYPE": "ENTIEREMENT_MODIF", "DATE_FIN": "2999-01-01", "DATE_DEBUT": "2999-01-01" } }, "META_COMMUN": { "ID": "LEGIARTI000050742674", "URL": "article/LEGI/ARTI/00/00/50/74/26/LEGIARTI000050742674.xml", "NATURE": "Article", "ORIGINE": "LEGI" } }, "LIENS": { "LIEN": [ { "@id": "LEGIARTI000006847390", "@num": "2", "#text": "LOI n° 77-2 du 3 janvier 1977 - art. 2", "@sens": "source", "@cidtexte": "JORFTEXT000000522423", "@numtexte": "77-2", "@typelien": "CITATION", "@naturetexte": "LOI", "@datesignatexte": "1977-01-03" }, { "@id": "JORFARTI000042106701", "@num": "1", "#text": "Arrêté du 29 juin 2020 - art. 1", "@sens": "source", "@cidtexte": "JORFTEXT000042106692", "@nortexte": "ECOT2013713A", "@typelien": "CITATION", "@naturetexte": "ARRETE", "@datesignatexte": "2020-06-29" }, { "@id": "LEGIARTI000050745443", "@num": "1", "#text": "Arrêté du 29 juin 2020 - art. 1 (V)", "@sens": "source", "@cidtexte": "JORFTEXT000042106692", "@nortexte": "ECOT2013713A", "@typelien": "MODIFIE", "@naturetexte": "ARRETE", "@datesignatexte": "2020-06-29" }, { "@id": "LEGITEXT000006074096", "#text": "Code de la construction et de l'habitation.", "@sens": "source", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CITATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGISCTA000050175237", "#text": "Code de la construction et de l'habitation.", "@sens": "source", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CITATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000006824483", "@num": "L222-1", "#text": "Code de la construction et de l'habitation. - art. L222-1", "@sens": "source", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CITATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000006824508", "@num": "L231-1", "#text": "Code de la construction et de l'habitation. - art. L231-1", "@sens": "source", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CITATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000006824506", "@num": "L232-1", "#text": "Code de la construction et de l'habitation. - art. L232-1", "@sens": "source", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CITATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" } ] }, "CONTEXTE": { "TEXTE": { "@cid": "JORFTEXT000050731018", "@nor": "ECOT2430597A", "@nature": "ARRETE", "TITRE_TXT": [ { "@fin": "2999-01-01", "#text": "Arrêté du 3 décembre 2024 modifiant l'arrêté du 29 juin 2020 relatif aux modalités d'allongement du délai de réalisation des travaux dans le cadre d'un prêt réglementé", "@debut": "2999-01-01", "@id_txt": "JORFTEXT000050731018", "@c_titre_court": "Arrêté du 3 décembre 2024" }, { "@fin": "2999-01-01", "#text": "Arrêté du 3 décembre 2024 modifiant l'arrêté du 29 juin 2020 relatif aux modalités d'allongement du délai de réalisation des travaux dans le cadre d'un prêt réglementé", "@debut": "2024-12-06", "@id_txt": "LEGITEXT000050742642", "@c_titre_court": "Arrêté du 3 décembre 2024" } ], "@ministere": "Ministère de l'économie, des finances et de l'industrie", "@date_publi": "2024-12-05", "@date_signature": "2024-12-03", "@num_parution_jo": "0287" } }, "VERSIONS": { "VERSION": [ { "LIEN_ART": { "@id": "LEGIARTI000050742674", "@fin": "2999-01-01", "@num": "1", "@debut": "2999-01-01", "@origine": "LEGI" } }, { "LIEN_ART": { "@id": "JORFARTI000050731050", "@fin": "2999-01-01", "@num": "1", "@debut": "2999-01-01", "@origine": "JORF" } } ] }, "BLOC_TEXTUEL": { "CONTENU": "
A modifié les dispositions suivantes :

- Arrêté du 29 juin 2020
\n Art. 1\n
\n

\n
" } }, "LEGIARTI000006824483": { "META": { "META_SPEC": { "META_ARTICLE": { "NUM": "L222-1", "ETAT": "VIGUEUR", "TYPE": "AUTONOME", "DATE_FIN": "2999-01-01", "DATE_DEBUT": "1978-06-08" } }, "META_COMMUN": { "ID": "LEGIARTI000006824483", "URL": "article/LEGI/ARTI/00/00/06/82/44/LEGIARTI000006824483.xml", "NATURE": "Article", "ORIGINE": "LEGI", "ANCIEN_ID": "UCAXXXXXXXX1X222L001XXAA" } }, "LIENS": { "LIEN": [ { "@id": "JORFTEXT000000687668", "#text": "Loi 71-579 1971-07-16 art. 33 al. 1, al. 2", "@sens": "source", "@cidtexte": "JORFTEXT000000687668", "@numtexte": "71-579", "@typelien": "CONCORDANCE", "@naturetexte": "LOI", "@datesignatexte": "1971-07-16" }, { "@id": "LEGIARTI000006826369", "@num": "33", "#text": "Loi n°71-579 du 16 juillet 1971 - art. 33 (Ab)", "@sens": "cible", "@cidtexte": "JORFTEXT000000687668", "@numtexte": "71-579", "@typelien": "CONCORDE", "@naturetexte": "LOI", "@datesignatexte": "1971-07-16" }, { "@id": "JORFTEXT000000516442", "#text": "Décret 78-621 1978-05-31 JORF 8 juin 1978", "@sens": "source", "@cidtexte": "JORFTEXT000000516442", "@numtexte": "78-621", "@typelien": "CODIFICATION", "@naturetexte": "DECRET", "@datesignatexte": "1978-05-31" }, { "@id": "LEGIARTI000006847634", "@num": "4", "#text": "Loi n°85-704 du 12 juillet 1985 - art. 4 (M)", "@sens": "cible", "@cidtexte": "JORFTEXT000000693683", "@numtexte": "85-704", "@typelien": "CITATION", "@naturetexte": "LOI", "@datesignatexte": "1985-07-12" }, { "@id": "LEGIARTI000027550543", "@num": "7", "#text": "Arrêté du 30 décembre 2010 - art. 7 (Ab)", "@sens": "cible", "@cidtexte": "JORFTEXT000023332971", "@nortexte": "DEVL1026553A", "@typelien": "CITATION", "@naturetexte": "ARRETE", "@datesignatexte": "2010-12-30" }, { "@id": "LEGIARTI000050745443", "@num": "1", "#text": "Arrêté du 29 juin 2020 - art. 1 (V)", "@sens": "cible", "@cidtexte": "JORFTEXT000042106692", "@nortexte": "ECOT2013713A", "@typelien": "CITATION", "@naturetexte": "ARRETE", "@datesignatexte": "2020-06-29" }, { "@id": "LEGITEXT000050742642", "#text": "Arrêté du 3 décembre 2024 (V)", "@sens": "cible", "@cidtexte": "JORFTEXT000050731018", "@nortexte": "ECOT2430597A", "@typelien": "CITATION", "@naturetexte": "ARRETE", "@datesignatexte": "2024-12-03" }, { "@id": "LEGIARTI000050742674", "@num": "1", "#text": "Arrêté du 3 décembre 2024 - art. 1", "@sens": "cible", "@cidtexte": "JORFTEXT000050731018", "@nortexte": "ECOT2430597A", "@typelien": "CITATION", "@naturetexte": "ARRETE", "@datesignatexte": "2024-12-03" }, { "@id": "LEGIARTI000006443372", "@num": "1779", "#text": "Code civil - art. 1779 (V)", "@sens": "source", "@cidtexte": "LEGITEXT000006070721", "@typelien": "CITATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000006443996", "@num": "1831-1", "#text": "Code civil - art. 1831-1 (V)", "@sens": "source", "@cidtexte": "LEGITEXT000006070721", "@typelien": "CITATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000006824191", "@num": "L111-31", "#text": "Code de la construction et de l'habitation. - art. L111-31 (V)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CITATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000006824477", "@num": "L221-1", "#text": "Code de la construction et de l'habitation. - art. L221-1 (V)", "@sens": "source", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CITATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000006824485", "@num": "L222-2", "#text": "Code de la construction et de l'habitation. - art. L222-2 (V)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CITATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000006824536", "@num": "L242-1", "#text": "Code de la construction et de l'habitation. - art. L242-1 (V)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CITATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000025760489", "@num": "L281-1", "#text": "Code de la construction et de l'habitation. - art. L281-1 (V)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CITATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000039041825", "@num": "R222-1", "#text": "Code de la construction et de l'habitation. - art. R222-1 (VD)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CITATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000039041816", "@num": "R222-3", "#text": "Code de la construction et de l'habitation. - art. R222-3 (VD)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CITATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000006795916", "@num": "L242-2", "#text": "Code des assurances - art. L242-2 (V)", "@sens": "cible", "@cidtexte": "LEGITEXT000006073984", "@typelien": "CITATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" } ] }, "CONTEXTE": { "TEXTE": { "TM": { "TM": { "TM": { "TM": { "TITRE_TM": [ { "@id": "LEGISCTA000006159019", "@fin": "2999-01-01", "#text": "Chapitre II : Dispositions particulières au contrat de promotion immobilière pour la construction d'immeubles à usage d'habitation ou à usage professionnel et d'habitation.", "@debut": "1978-06-08" } ] }, "TITRE_TM": [ { "@id": "LEGISCTA000006143525", "@fin": "2999-01-01", "#text": "Titre II : Promotion immobilière.", "@debut": "1978-06-08" } ] }, "TITRE_TM": [ { "@id": "LEGISCTA000006128681", "@fin": "2999-01-01", "#text": "Livre II : Statut des constructeurs.", "@debut": "1978-06-08" } ] }, "TITRE_TM": [ { "@id": "LEGISCTA000006108136", "@fin": "2999-01-01", "#text": "Partie législative", "@debut": "1978-06-08" } ] }, "@cid": "LEGITEXT000006074096", "@nature": "CODE", "TITRE_TXT": [ { "@fin": "2999-01-01", "#text": "Code de la construction et de l'habitation", "@debut": "1977-03-10", "@id_txt": "LEGITEXT000006074096", "@c_titre_court": "Code de la construction et de l'habitation." } ], "@date_publi": "2999-01-01", "@date_signature": "2999-01-01" } }, "VERSIONS": { "VERSION": [ { "@etat": "VIGUEUR", "LIEN_ART": { "@id": "LEGIARTI000006824483", "@fin": "2999-01-01", "@num": "L222-1", "@etat": "VIGUEUR", "@debut": "1978-06-08", "@origine": "LEGI" } } ] }, "BLOC_TEXTUEL": { "CONTENU": "

Tout contrat par lequel une personne s'oblige envers le maître de l'ouvrage à faire procéder à la construction d'un immeuble d'habitation ou d'un immeuble à usage professionnel et d'habitation, en une qualité autre que celle de vendeur ou que celles qui sont indiquées au 3° de l'article 1779 du code civil, est soumis aux règles des articles 1831-1 à 1831-5 du même code, reproduits aux articles L. 221-1 à L. 221-5 du présent code, ainsi qu'à celles du présent chapitre.

\n
\n

Les dispositions du premier alinéa du présent article ne sont pas obligatoires lorsque le maître d'ouvrage est une personne qui construit un ou plusieurs immeubles en vue de la vente ou une société autre que celles mentionnées aux chapitres II et III du titre Ier du présent livre faisant construire plus de deux locaux à usage professionnel ou d'habitation.

\n
" } }, "LEGIARTI000006824506": { "META": { "META_SPEC": { "META_ARTICLE": { "NUM": "L232-1", "ETAT": "MODIFIE", "TYPE": "AUTONOME", "DATE_FIN": "2021-07-01", "DATE_DEBUT": "1991-12-01" } }, "META_COMMUN": { "ID": "LEGIARTI000006824506", "URL": "article/LEGI/ARTI/00/00/06/82/45/LEGIARTI000006824506.xml", "NATURE": "Article", "ORIGINE": "LEGI", "ANCIEN_ID": "UCAXXXXXXXX1X232L001XXAA" } }, "LIENS": { "LIEN": [ { "@id": "JORFTEXT000000522423", "#text": "Loi n° 77-2 du 3 janvier 1977 (V)", "@sens": "source", "@cidtexte": "JORFTEXT000000522423", "@numtexte": "77-2", "@typelien": "CITATION", "@naturetexte": "LOI", "@datesignatexte": "1977-01-03" }, { "@id": "JORFTEXT000000516442", "#text": "Décret 78-621 1978-05-31 JORF 8 JUIN 1978", "@sens": "source", "@cidtexte": "JORFTEXT000000516442", "@numtexte": "78-621", "@typelien": "CODIFICATION", "@naturetexte": "DECRET", "@datesignatexte": "1978-05-31" }, { "@id": "JORFTEXT000000709335", "#text": "Loi 90-1129 1990-12-19 art. 8", "@sens": "source", "@cidtexte": "JORFTEXT000000709335", "@nortexte": "EQUX9000054L", "@numtexte": "90-1129", "@typelien": "SPEC_APPLI", "@naturetexte": "LOI", "@datesignatexte": "1990-12-19" }, { "@id": "LEGIARTI000006826206", "@num": "1", "#text": "Loi n°90-1129 du 19 décembre 1990 - art. 1 () JORF 22 décembre 1990 en vigueur le 1er décembre 1991", "@sens": "source", "@cidtexte": "JORFTEXT000000709335", "@nortexte": "EQUX9000054L", "@numtexte": "90-1129", "@typelien": "CREATION", "@naturetexte": "LOI", "@datesignatexte": "1990-12-19" }, { "@id": "LEGIARTI000006830648", "@num": "3", "#text": "Arrêté du 27 novembre 1991 - art. 3 (V)", "@sens": "cible", "@cidtexte": "JORFTEXT000000526871", "@nortexte": "EQUC9101692A", "@typelien": "CITATION", "@naturetexte": "ARRETE", "@datesignatexte": "1991-11-27" }, { "@id": "LEGIARTI000021355420", "@num": "1", "#text": "Arrêté du 19 novembre 2009 - art. 1 (V)", "@sens": "cible", "@cidtexte": "JORFTEXT000021344622", "@nortexte": "DEVU0926808A", "@typelien": "CITATION", "@naturetexte": "ARRETE", "@datesignatexte": "2009-11-19" }, { "@id": "LEGIARTI000027550543", "@num": "7", "#text": "Arrêté du 30 décembre 2010 - art. 7 (Ab)", "@sens": "cible", "@cidtexte": "JORFTEXT000023332971", "@nortexte": "DEVL1026553A", "@typelien": "CITATION", "@naturetexte": "ARRETE", "@datesignatexte": "2010-12-30" }, { "@id": "LEGIARTI000045581767", "@num": "4-1", "#text": "Arrêté du 11 octobre 2011 - art. 4-1 (V)", "@sens": "cible", "@cidtexte": "JORFTEXT000024695233", "@nortexte": "DEVL1126896A", "@typelien": "CITATION", "@naturetexte": "ARRETE", "@datesignatexte": "2011-10-11" }, { "@id": "LEGIARTI000050745443", "@num": "1", "#text": "Arrêté du 29 juin 2020 - art. 1 (V)", "@sens": "cible", "@cidtexte": "JORFTEXT000042106692", "@nortexte": "ECOT2013713A", "@typelien": "CITATION", "@naturetexte": "ARRETE", "@datesignatexte": "2020-06-29" }, { "@id": "LEGIARTI000044503425", "@num": "10", "#text": "Arrêté du 9 décembre 2021 - art. 10", "@sens": "cible", "@cidtexte": "JORFTEXT000044501420", "@nortexte": "LOGL2114162A", "@typelien": "CITATION", "@naturetexte": "ARRETE", "@datesignatexte": "2021-12-09" }, { "@id": "LEGITEXT000050742475", "#text": "Arrêté du 3 décembre 2024 (V)", "@sens": "cible", "@cidtexte": "JORFTEXT000050731883", "@nortexte": "LRUL2422852A", "@typelien": "CITATION", "@naturetexte": "ARRETE", "@datesignatexte": "2024-12-03" }, { "@id": "LEGITEXT000050742642", "#text": "Arrêté du 3 décembre 2024 (V)", "@sens": "cible", "@cidtexte": "JORFTEXT000050731018", "@nortexte": "ECOT2430597A", "@typelien": "CITATION", "@naturetexte": "ARRETE", "@datesignatexte": "2024-12-03" }, { "@id": "LEGIARTI000050742674", "@num": "1", "#text": "Arrêté du 3 décembre 2024 - art. 1", "@sens": "cible", "@cidtexte": "JORFTEXT000050731018", "@nortexte": "ECOT2430597A", "@typelien": "CITATION", "@naturetexte": "ARRETE", "@datesignatexte": "2024-12-03" }, { "@id": "LEGIARTI000006795972", "@num": "L242-1", "#text": "Code des assurances - art. L242-1 (V)", "@sens": "source", "@cidtexte": "LEGITEXT000006073984", "@typelien": "CITATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000006824172", "@num": "L111-23", "#text": "Code de la construction et de l'habitation. - art. L111-23 (V)", "@sens": "source", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CITATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000006824508", "@num": "L231-1", "#text": "Code de la construction et de l'habitation. - art. L231-1 (V)", "@sens": "source", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CITATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000028806974", "@num": "L241-3", "#text": "Code de la construction et de l'habitation. - art. L241-3 (V)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CITATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000032235569", "@num": "L241-8", "#text": "Code de la construction et de l'habitation. - art. L241-8 (VD)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CITATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000038433476", "@num": "L242-2", "#text": "Code de la construction et de l'habitation. - art. L242-2 (VD)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CITATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000046680556", "@num": "R172-1", "#text": "Code de la construction et de l'habitation. - art. R172-1 (V)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CITATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000039041691", "@num": "R232-3", "#text": "Code de la construction et de l'habitation. - art. R232-3 (VD)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CITATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000039041682", "@num": "R232-5", "#text": "Code de la construction et de l'habitation. - art. R232-5 (VD)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CITATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000039041673", "@num": "R232-7", "#text": "Code de la construction et de l'habitation. - art. R232-7 (VD)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CITATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000033655931", "@num": "D313-26", "#text": "Code monétaire et financier - art. D313-26 (VD)", "@sens": "cible", "@cidtexte": "LEGITEXT000006072026", "@typelien": "CITATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" } ] }, "CONTEXTE": { "TEXTE": { "TM": { "TM": { "TM": { "TM": { "TITRE_TM": [ { "@id": "LEGISCTA000006159021", "@fin": "2999-01-01", "#text": "Chapitre II : Contrat de construction d'une maison individuelle sans fourniture du plan.", "@debut": "1991-12-01" } ] }, "TITRE_TM": [ { "@id": "LEGISCTA000006143526", "@fin": "2999-01-01", "#text": "Titre III : Construction d'une maison individuelle.", "@debut": "1991-12-01" } ] }, "TITRE_TM": [ { "@id": "LEGISCTA000006128681", "@fin": "2999-01-01", "#text": "Livre II : Statut des constructeurs.", "@debut": "1978-06-08" } ] }, "TITRE_TM": [ { "@id": "LEGISCTA000006108136", "@fin": "2999-01-01", "#text": "Partie législative", "@debut": "1978-06-08" } ] }, "@cid": "LEGITEXT000006074096", "@nature": "CODE", "TITRE_TXT": [ { "@fin": "2999-01-01", "#text": "Code de la construction et de l'habitation", "@debut": "1977-03-10", "@id_txt": "LEGITEXT000006074096", "@c_titre_court": "Code de la construction et de l'habitation." } ], "@date_publi": "2999-01-01", "@date_signature": "2999-01-01" } }, "VERSIONS": { "VERSION": [ { "@etat": "MODIFIE", "LIEN_ART": { "@id": "LEGIARTI000006824506", "@fin": "2021-07-01", "@num": "L232-1", "@etat": "MODIFIE", "@debut": "1991-12-01", "@origine": "LEGI" } }, { "@etat": "VIGUEUR", "LIEN_ART": { "@id": "LEGIARTI000041586842", "@fin": "2999-01-01", "@num": "L232-1", "@etat": "VIGUEUR", "@debut": "2021-07-01", "@origine": "LEGI" } } ] }, "BLOC_TEXTUEL": { "CONTENU": "
Le contrat de louage d'ouvrage n'entrant pas dans le champ d'application de l'article L. 231-1 et ayant au moins pour objet l'exécution des travaux de gros oeuvre, de mise hors d'eau et hors d'air d'un immeuble à usage d'habitation ou d'un immeuble à usage professionnel et d'habitation, ne comportant pas plus de deux logements destinés au même maître de l'ouvrage, doit être rédigé par écrit et préciser :
\n
a) La désignation du terrain ;
\n
b) La consistance et les caractéristiques techniques de l'ouvrage à réaliser ;
\n
c) Le prix convenu forfaitaire et définitif, sous réserve, s'il y a lieu, de sa révision dans les conditions et limites convenues, ainsi que les modalités de son règlement au fur et à mesure de l'exécution des travaux ;
\n
d) Le délai d'exécution des travaux et les pénalités applicables en cas de retard de livraison ;
\n
e) La référence de l'assurance de dommages souscrite par le maître de l'ouvrage en application de l'article L. 242-1 du code des assurances ;
\n
f) L'indication que le maître de l'ouvrage pourra se faire assister par un professionnel habilité en application de la loi n° 77-2 du 3 janvier 1977 précitée ou des articles L. 111-23 et suivants lors de la réception ou par tout autre professionnel de la construction titulaire d'un contrat d'assurance couvrant les responsabilités pour ce type de mission ;
\n
g) L'engagement de l'entrepreneur de fournir, au plus tard à la date d'ouverture du chantier, la justification de la garantie de livraison qu'il apporte au maître de l'ouvrage, l'attestation de cette garantie étant établie par le garant et annexée au contrat.
" } }, "LEGIARTI000006824508": { "META": { "META_SPEC": { "META_ARTICLE": { "NUM": "L231-1", "ETAT": "MODIFIE", "TYPE": "AUTONOME", "DATE_FIN": "1991-12-01", "DATE_DEBUT": "1978-06-08" } }, "META_COMMUN": { "ID": "LEGIARTI000006824508", "URL": "article/LEGI/ARTI/00/00/06/82/45/LEGIARTI000006824508.xml", "NATURE": "Article", "ORIGINE": "LEGI", "ANCIEN_ID": "UCAXXXXXXXX1X231L001XXAA" } }, "LIENS": { "LIEN": [ { "@id": "JORFTEXT000000687668", "#text": "Loi 71-579 1971-07-16 art. 45 al. 1", "@sens": "source", "@cidtexte": "JORFTEXT000000687668", "@numtexte": "71-579", "@typelien": "CONCORDANCE", "@naturetexte": "LOI", "@datesignatexte": "1971-07-16" }, { "@id": "LEGIARTI000006826382", "@num": "45", "#text": "Loi n°71-579 du 16 juillet 1971 - art. 45 (Ab)", "@sens": "cible", "@cidtexte": "JORFTEXT000000687668", "@numtexte": "71-579", "@typelien": "CONCORDE", "@naturetexte": "LOI", "@datesignatexte": "1971-07-16" }, { "@id": "JORFTEXT000000516442", "#text": "Décret 78-621 1978-05-31 JORF 8 juin 1978", "@sens": "source", "@cidtexte": "JORFTEXT000000516442", "@numtexte": "78-621", "@typelien": "CODIFICATION", "@naturetexte": "DECRET", "@datesignatexte": "1978-05-31" }, { "@id": "LEGIARTI000006829601", "@num": "9", "#text": "Arrêté du 30 décembre 1988 - art. 9 (V)", "@sens": "cible", "@cidtexte": "JORFTEXT000000873773", "@nortexte": "EQUC8800886A", "@typelien": "CITATION", "@naturetexte": "ARRETE", "@datesignatexte": "1988-12-30" }, { "@id": "LEGIARTI000006830647", "@num": "2", "#text": "Arrêté du 27 novembre 1991 - art. 2 (V)", "@sens": "cible", "@cidtexte": "JORFTEXT000000526871", "@nortexte": "EQUC9101692A", "@typelien": "CITATION", "@naturetexte": "ARRETE", "@datesignatexte": "1991-11-27" }, { "@id": "LEGIARTI000006739977", "@num": "1", "#text": "Décret n°99-776 du 8 septembre 1999 - art. 1 (Ab)", "@sens": "cible", "@cidtexte": "JORFTEXT000000396628", "@nortexte": "ECOT9914031D", "@numtexte": "99-776", "@typelien": "CITATION", "@naturetexte": "DECRET", "@datesignatexte": "1999-09-08" }, { "@id": "LEGIARTI000006227139", "@num": "3", "#text": "Arrêté du 18 décembre 2003 - art. 3 (V)", "@sens": "cible", "@cidtexte": "JORFTEXT000000612646", "@nortexte": "EQUU0301863A", "@typelien": "CITATION", "@naturetexte": "ARRETE", "@datesignatexte": "2003-12-18" }, { "@id": "LEGIARTI000006254037", "@num": "3", "#text": "Arrêté du 27 juillet 2006 - art. 3 (V)", "@sens": "cible", "@cidtexte": "JORFTEXT000000789055", "@nortexte": "SOCU0611686A", "@typelien": "CITATION", "@naturetexte": "ARRETE", "@datesignatexte": "2006-07-27" }, { "@id": "LEGIARTI000021510847", "@num": "5", "#text": "Arrêté du 8 mai 2007 - art. 5 (V)", "@sens": "cible", "@cidtexte": "JORFTEXT000000615939", "@nortexte": "SOCU0750649A", "@typelien": "CITATION", "@naturetexte": "ARRETE", "@datesignatexte": "2007-05-03" }, { "@id": "LEGIARTI000021355420", "@num": "1", "#text": "Arrêté du 19 novembre 2009 - art. 1 (V)", "@sens": "cible", "@cidtexte": "JORFTEXT000021344622", "@nortexte": "DEVU0926808A", "@typelien": "CITATION", "@naturetexte": "ARRETE", "@datesignatexte": "2009-11-19" }, { "@id": "LEGIARTI000027550543", "@num": "7", "#text": "Arrêté du 30 décembre 2010 - art. 7 (Ab)", "@sens": "cible", "@cidtexte": "JORFTEXT000023332971", "@nortexte": "DEVL1026553A", "@typelien": "CITATION", "@naturetexte": "ARRETE", "@datesignatexte": "2010-12-30" }, { "@id": "LEGIARTI000045581767", "@num": "4-1", "#text": "Arrêté du 11 octobre 2011 - art. 4-1 (V)", "@sens": "cible", "@cidtexte": "JORFTEXT000024695233", "@nortexte": "DEVL1126896A", "@typelien": "CITATION", "@naturetexte": "ARRETE", "@datesignatexte": "2011-10-11" }, { "@id": "LEGIARTI000033251105", "@num": "3", "#text": "Arrêté du 12 octobre 2016 - art. 3 (M)", "@sens": "cible", "@cidtexte": "JORFTEXT000033243759", "@nortexte": "LHAL1623033A", "@typelien": "CITATION", "@naturetexte": "ARRETE", "@datesignatexte": "2016-10-12" }, { "@id": "LEGIARTI000050745443", "@num": "1", "#text": "Arrêté du 29 juin 2020 - art. 1 (V)", "@sens": "cible", "@cidtexte": "JORFTEXT000042106692", "@nortexte": "ECOT2013713A", "@typelien": "CITATION", "@naturetexte": "ARRETE", "@datesignatexte": "2020-06-29" }, { "@id": "LEGIARTI000044503425", "@num": "10", "#text": "Arrêté du 9 décembre 2021 - art. 10", "@sens": "cible", "@cidtexte": "JORFTEXT000044501420", "@nortexte": "LOGL2114162A", "@typelien": "CITATION", "@naturetexte": "ARRETE", "@datesignatexte": "2021-12-09" }, { "@id": "LEGITEXT000050742642", "#text": "Arrêté du 3 décembre 2024 (V)", "@sens": "cible", "@cidtexte": "JORFTEXT000050731018", "@nortexte": "ECOT2430597A", "@typelien": "CITATION", "@naturetexte": "ARRETE", "@datesignatexte": "2024-12-03" }, { "@id": "LEGIARTI000050742674", "@num": "1", "#text": "Arrêté du 3 décembre 2024 - art. 1", "@sens": "cible", "@cidtexte": "JORFTEXT000050731018", "@nortexte": "ECOT2430597A", "@typelien": "CITATION", "@naturetexte": "ARRETE", "@datesignatexte": "2024-12-03" }, { "@id": "LEGIARTI000025430929", "@num": "R*442-18", "#text": "Code de l'urbanisme - art. *R442-18 (V)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074075", "@typelien": "CITATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000025100231", "@num": "R*112-2", "#text": "Code de l'urbanisme - art. R*112-2 (VT)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074075", "@typelien": "CITATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000031721274", "@num": "R111-22", "#text": "Code de l'urbanisme - art. R111-22 (V)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074075", "@typelien": "CITATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000025430951", "@num": "R*442-1", "#text": "Code de l'urbanisme - art. R442-1 (V)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074075", "@typelien": "CITATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000039049511", "@num": "Annexe à l'article R422-37", "#text": "Code de la construction et de l'habitation. - art. Annexe à l'article R422-37 (V)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CITATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000039049534", "@num": "Annexe à l'article R422-6", "#text": "Code de la construction et de l'habitation. - art. Annexe à l'article R422-6 (V)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CITATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000019030588", "@num": "Annexe à l'article R422-7", "#text": "Code de la construction et de l'habitation. - art. Annexe à l'article R422-7 (V)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CITATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000006824510", "@num": "L231-1-1", "#text": "Code de la construction et de l'habitation. - art. L231-1-1 (Ab)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CITATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000028574448", "@num": "L231-11", "#text": "Code de la construction et de l'habitation. - art. L231-11 (V)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CITATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000041586856", "@num": "L231-2", "#text": "Code de la construction et de l'habitation. - art. L231-2 (VD)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CITATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000038433492", "@num": "L231-3", "#text": "Code de la construction et de l'habitation. - art. L231-3 (VD)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CITATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000006824494", "@num": "L231-4", "#text": "Code de la construction et de l'habitation. - art. L231-4 (V)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CITATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000006824506", "@num": "L232-1", "#text": "Code de la construction et de l'habitation. - art. L232-1 (V)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CITATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000028806974", "@num": "L241-3", "#text": "Code de la construction et de l'habitation. - art. L241-3 (V)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CITATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000032235569", "@num": "L241-8", "#text": "Code de la construction et de l'habitation. - art. L241-8 (VD)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CITATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000038433476", "@num": "L242-2", "#text": "Code de la construction et de l'habitation. - art. L242-2 (VD)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CITATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000006896453", "@num": "R*231-4", "#text": "Code de la construction et de l'habitation. - art. R*231-4 (M)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CITATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000006896456", "@num": "R*231-5", "#text": "Code de la construction et de l'habitation. - art. R*231-5 (M)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CITATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000046680556", "@num": "R172-1", "#text": "Code de la construction et de l'habitation. - art. R172-1 (V)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CITATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000006811936", "@num": "R124-2", "#text": "Code des assurances - art. R124-2 (V)", "@sens": "cible", "@cidtexte": "LEGITEXT000006073984", "@typelien": "CITATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000006821757", "@num": "R421-24-3", "#text": "Code des assurances - art. R421-24-3 (Ab)", "@sens": "cible", "@cidtexte": "LEGITEXT000006073984", "@typelien": "CITATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" } ] }, "CONTEXTE": { "TEXTE": { "TM": { "TM": { "TM": { "TM": { "TITRE_TM": [ { "@id": "LEGISCTA000006159020", "@fin": "2999-01-01", "#text": "Chapitre Ier : Contrat de construction d'une maison individuelle avec fourniture du plan.", "@debut": "1991-12-01" } ] }, "TITRE_TM": [ { "@id": "LEGISCTA000006143526", "@fin": "2999-01-01", "#text": "Titre III : Construction d'une maison individuelle.", "@debut": "1991-12-01" } ] }, "TITRE_TM": [ { "@id": "LEGISCTA000006128681", "@fin": "2999-01-01", "#text": "Livre II : Statut des constructeurs.", "@debut": "1978-06-08" } ] }, "TITRE_TM": [ { "@id": "LEGISCTA000006108136", "@fin": "2999-01-01", "#text": "Partie législative", "@debut": "1978-06-08" } ] }, "@cid": "LEGITEXT000006074096", "@nature": "CODE", "TITRE_TXT": [ { "@fin": "2999-01-01", "#text": "Code de la construction et de l'habitation", "@debut": "1977-03-10", "@id_txt": "LEGITEXT000006074096", "@c_titre_court": "Code de la construction et de l'habitation." } ], "@date_publi": "2999-01-01", "@date_signature": "2999-01-01" } }, "VERSIONS": { "VERSION": [ { "@etat": "MODIFIE", "LIEN_ART": { "@id": "LEGIARTI000006824508", "@fin": "1991-12-01", "@num": "L231-1", "@etat": "MODIFIE", "@debut": "1978-06-08", "@origine": "LEGI" } }, { "@etat": "MODIFIE", "LIEN_ART": { "@id": "LEGIARTI000006824509", "@fin": "2021-07-01", "@num": "L231-1", "@etat": "MODIFIE", "@debut": "1991-12-01", "@origine": "LEGI" } }, { "@etat": "VIGUEUR", "LIEN_ART": { "@id": "LEGIARTI000041586868", "@fin": "2999-01-01", "@num": "L231-1", "@etat": "VIGUEUR", "@debut": "2021-07-01", "@origine": "LEGI" } } ] }, "BLOC_TEXTUEL": { "CONTENU": "
Tout contrat autre que celui mentionné au titre II du présent livre, par lequel une personne se charge de la construction d'un immeuble à usage d'habitation ou d'un immeuble à usage professionnel et d'habitation ne comportant qu'un seul logement d'après un plan qu'elle a proposé ou fait proposer au maître de l'ouvrage doit comporter les énonciations suivantes :
\n
a) L'affirmation de la conformité du projet aux règles de construction prescrites en application du présent code et, notamment, de son livre Ier ;
\n
b) La consistance et les caractéristiques techniques du bâtiment à construire ;
\n
c) Les devis descriptifs et les conditions d'exécution techniques des travaux ;
\n
d) Le prix convenu ainsi que les limites et conditions dans lesquelles la révision du prix peut intervenir ;
\n
e) Les modalités de règlement à mesure de l'avancement des travaux ;
\n
f) Le délai dans lequel le bâtiment doit être édifié ;
\n
g) La description et l'estimation du coût de ceux des travaux d'équipement intérieur ou extérieur qui sont indispensables à l'implantation et à l'utilisation ou à l'habitation de l'immeuble et qui ne sont pas compris dans le prix ;
\n
h) La garantie apportée par la personne qui s'est chargée de la construction pour la bonne exécution de sa mission.
" } }, "LEGIARTI000006824509": { "META": { "META_SPEC": { "META_ARTICLE": { "NUM": "L231-1", "ETAT": "MODIFIE", "TYPE": "AUTONOME", "DATE_FIN": "2021-07-01", "DATE_DEBUT": "1991-12-01" } }, "META_COMMUN": { "ID": "LEGIARTI000006824509", "URL": "article/LEGI/ARTI/00/00/06/82/45/LEGIARTI000006824509.xml", "NATURE": "Article", "ORIGINE": "LEGI", "ANCIEN_ID": "UCAXXXXXXXX1X231L001XXAB" } }, "LIENS": { "LIEN": [ { "@id": "JORFTEXT000000687668", "#text": "Loi 71-579 1971-07-16 art. 45 al. 1", "@sens": "source", "@cidtexte": "JORFTEXT000000687668", "@numtexte": "71-579", "@typelien": "CONCORDANCE", "@naturetexte": "LOI", "@datesignatexte": "1971-07-16" }, { "@id": "LEGIARTI000006826382", "@num": "45", "#text": "Loi n°71-579 du 16 juillet 1971 - art. 45 (Ab)", "@sens": "cible", "@cidtexte": "JORFTEXT000000687668", "@numtexte": "71-579", "@typelien": "CONCORDE", "@naturetexte": "LOI", "@datesignatexte": "1971-07-16" }, { "@id": "JORFTEXT000000516442", "#text": "Décret 78-621 1978-05-31 JORF 8 JUIN 1978", "@sens": "source", "@cidtexte": "JORFTEXT000000516442", "@numtexte": "78-621", "@typelien": "CODIFICATION", "@naturetexte": "DECRET", "@datesignatexte": "1978-05-31" }, { "@id": "LEGIARTI000006829601", "@num": "9", "#text": "Arrêté du 30 décembre 1988 - art. 9 (V)", "@sens": "cible", "@cidtexte": "JORFTEXT000000873773", "@nortexte": "EQUC8800886A", "@typelien": "CITATION", "@naturetexte": "ARRETE", "@datesignatexte": "1988-12-30" }, { "@id": "JORFTEXT000000709335", "#text": "Loi 90-1129 1990-12-19 art. 8", "@sens": "source", "@cidtexte": "JORFTEXT000000709335", "@nortexte": "EQUX9000054L", "@numtexte": "90-1129", "@typelien": "SPEC_APPLI", "@naturetexte": "LOI", "@datesignatexte": "1990-12-19" }, { "@id": "LEGIARTI000006826206", "@num": "1", "#text": "Loi n°90-1129 du 19 décembre 1990 - art. 1 () JORF 22 décembre 1990 en vigueur le 1er décembre 1991", "@sens": "source", "@cidtexte": "JORFTEXT000000709335", "@nortexte": "EQUX9000054L", "@numtexte": "90-1129", "@typelien": "MODIFICATION", "@naturetexte": "LOI", "@datesignatexte": "1990-12-19" }, { "@id": "LEGIARTI000006830647", "@num": "2", "#text": "Arrêté du 27 novembre 1991 - art. 2 (V)", "@sens": "cible", "@cidtexte": "JORFTEXT000000526871", "@nortexte": "EQUC9101692A", "@typelien": "CITATION", "@naturetexte": "ARRETE", "@datesignatexte": "1991-11-27" }, { "@id": "LEGIARTI000006739977", "@num": "1", "#text": "Décret n°99-776 du 8 septembre 1999 - art. 1 (Ab)", "@sens": "cible", "@cidtexte": "JORFTEXT000000396628", "@nortexte": "ECOT9914031D", "@numtexte": "99-776", "@typelien": "CITATION", "@naturetexte": "DECRET", "@datesignatexte": "1999-09-08" }, { "@id": "LEGIARTI000006227139", "@num": "3", "#text": "Arrêté du 18 décembre 2003 - art. 3 (V)", "@sens": "cible", "@cidtexte": "JORFTEXT000000612646", "@nortexte": "EQUU0301863A", "@typelien": "CITATION", "@naturetexte": "ARRETE", "@datesignatexte": "2003-12-18" }, { "@id": "LEGIARTI000006254037", "@num": "3", "#text": "Arrêté du 27 juillet 2006 - art. 3 (V)", "@sens": "cible", "@cidtexte": "JORFTEXT000000789055", "@nortexte": "SOCU0611686A", "@typelien": "CITATION", "@naturetexte": "ARRETE", "@datesignatexte": "2006-07-27" }, { "@id": "LEGIARTI000021510847", "@num": "5", "#text": "Arrêté du 8 mai 2007 - art. 5 (V)", "@sens": "cible", "@cidtexte": "JORFTEXT000000615939", "@nortexte": "SOCU0750649A", "@typelien": "CITATION", "@naturetexte": "ARRETE", "@datesignatexte": "2007-05-03" }, { "@id": "LEGIARTI000021355420", "@num": "1", "#text": "Arrêté du 19 novembre 2009 - art. 1 (V)", "@sens": "cible", "@cidtexte": "JORFTEXT000021344622", "@nortexte": "DEVU0926808A", "@typelien": "CITATION", "@naturetexte": "ARRETE", "@datesignatexte": "2009-11-19" }, { "@id": "LEGIARTI000027550543", "@num": "7", "#text": "Arrêté du 30 décembre 2010 - art. 7 (Ab)", "@sens": "cible", "@cidtexte": "JORFTEXT000023332971", "@nortexte": "DEVL1026553A", "@typelien": "CITATION", "@naturetexte": "ARRETE", "@datesignatexte": "2010-12-30" }, { "@id": "LEGIARTI000045581767", "@num": "4-1", "#text": "Arrêté du 11 octobre 2011 - art. 4-1 (V)", "@sens": "cible", "@cidtexte": "JORFTEXT000024695233", "@nortexte": "DEVL1126896A", "@typelien": "CITATION", "@naturetexte": "ARRETE", "@datesignatexte": "2011-10-11" }, { "@id": "LEGIARTI000033251105", "@num": "3", "#text": "Arrêté du 12 octobre 2016 - art. 3 (M)", "@sens": "cible", "@cidtexte": "JORFTEXT000033243759", "@nortexte": "LHAL1623033A", "@typelien": "CITATION", "@naturetexte": "ARRETE", "@datesignatexte": "2016-10-12" }, { "@id": "LEGIARTI000050745443", "@num": "1", "#text": "Arrêté du 29 juin 2020 - art. 1 (V)", "@sens": "cible", "@cidtexte": "JORFTEXT000042106692", "@nortexte": "ECOT2013713A", "@typelien": "CITATION", "@naturetexte": "ARRETE", "@datesignatexte": "2020-06-29" }, { "@id": "LEGIARTI000044503425", "@num": "10", "#text": "Arrêté du 9 décembre 2021 - art. 10", "@sens": "cible", "@cidtexte": "JORFTEXT000044501420", "@nortexte": "LOGL2114162A", "@typelien": "CITATION", "@naturetexte": "ARRETE", "@datesignatexte": "2021-12-09" }, { "@id": "LEGITEXT000050742642", "#text": "Arrêté du 3 décembre 2024 (V)", "@sens": "cible", "@cidtexte": "JORFTEXT000050731018", "@nortexte": "ECOT2430597A", "@typelien": "CITATION", "@naturetexte": "ARRETE", "@datesignatexte": "2024-12-03" }, { "@id": "LEGIARTI000050742674", "@num": "1", "#text": "Arrêté du 3 décembre 2024 - art. 1", "@sens": "cible", "@cidtexte": "JORFTEXT000050731018", "@nortexte": "ECOT2430597A", "@typelien": "CITATION", "@naturetexte": "ARRETE", "@datesignatexte": "2024-12-03" }, { "@id": "LEGIARTI000006443512", "@num": "1792-1", "#text": "Code civil - art. 1792-1 (V)", "@sens": "source", "@cidtexte": "LEGITEXT000006070721", "@typelien": "CITATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000025430929", "@num": "R*442-18", "#text": "Code de l'urbanisme - art. *R442-18 (V)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074075", "@typelien": "CITATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000025100231", "@num": "R*112-2", "#text": "Code de l'urbanisme - art. R*112-2 (VT)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074075", "@typelien": "CITATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000031721274", "@num": "R111-22", "#text": "Code de l'urbanisme - art. R111-22 (V)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074075", "@typelien": "CITATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000025430951", "@num": "R*442-1", "#text": "Code de l'urbanisme - art. R442-1 (V)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074075", "@typelien": "CITATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000039049511", "@num": "Annexe à l'article R422-37", "#text": "Code de la construction et de l'habitation. - art. Annexe à l'article R422-37 (V)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CITATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000039049534", "@num": "Annexe à l'article R422-6", "#text": "Code de la construction et de l'habitation. - art. Annexe à l'article R422-6 (V)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CITATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000019030588", "@num": "Annexe à l'article R422-7", "#text": "Code de la construction et de l'habitation. - art. Annexe à l'article R422-7 (V)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CITATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000006824160", "@num": "L111-14", "#text": "Code de la construction et de l'habitation. - art. L111-14 (V)", "@sens": "source", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CITATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000006824510", "@num": "L231-1-1", "#text": "Code de la construction et de l'habitation. - art. L231-1-1 (Ab)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CITATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000028574448", "@num": "L231-11", "#text": "Code de la construction et de l'habitation. - art. L231-11 (V)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CITATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000041586856", "@num": "L231-2", "#text": "Code de la construction et de l'habitation. - art. L231-2 (VD)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CITATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000038433492", "@num": "L231-3", "#text": "Code de la construction et de l'habitation. - art. L231-3 (VD)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CITATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000006824494", "@num": "L231-4", "#text": "Code de la construction et de l'habitation. - art. L231-4 (V)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CITATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000006824506", "@num": "L232-1", "#text": "Code de la construction et de l'habitation. - art. L232-1 (V)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CITATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000028806974", "@num": "L241-3", "#text": "Code de la construction et de l'habitation. - art. L241-3 (V)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CITATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000032235569", "@num": "L241-8", "#text": "Code de la construction et de l'habitation. - art. L241-8 (VD)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CITATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000038433476", "@num": "L242-2", "#text": "Code de la construction et de l'habitation. - art. L242-2 (VD)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CITATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000006896453", "@num": "R*231-4", "#text": "Code de la construction et de l'habitation. - art. R*231-4 (M)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CITATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000006896456", "@num": "R*231-5", "#text": "Code de la construction et de l'habitation. - art. R*231-5 (M)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CITATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000046680556", "@num": "R172-1", "#text": "Code de la construction et de l'habitation. - art. R172-1 (V)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CITATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000006811936", "@num": "R124-2", "#text": "Code des assurances - art. R124-2 (V)", "@sens": "cible", "@cidtexte": "LEGITEXT000006073984", "@typelien": "CITATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000006821757", "@num": "R421-24-3", "#text": "Code des assurances - art. R421-24-3 (Ab)", "@sens": "cible", "@cidtexte": "LEGITEXT000006073984", "@typelien": "CITATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" } ] }, "CONTEXTE": { "TEXTE": { "TM": { "TM": { "TM": { "TM": { "TITRE_TM": [ { "@id": "LEGISCTA000006159020", "@fin": "2999-01-01", "#text": "Chapitre Ier : Contrat de construction d'une maison individuelle avec fourniture du plan.", "@debut": "1991-12-01" } ] }, "TITRE_TM": [ { "@id": "LEGISCTA000006143526", "@fin": "2999-01-01", "#text": "Titre III : Construction d'une maison individuelle.", "@debut": "1991-12-01" } ] }, "TITRE_TM": [ { "@id": "LEGISCTA000006128681", "@fin": "2999-01-01", "#text": "Livre II : Statut des constructeurs.", "@debut": "1978-06-08" } ] }, "TITRE_TM": [ { "@id": "LEGISCTA000006108136", "@fin": "2999-01-01", "#text": "Partie législative", "@debut": "1978-06-08" } ] }, "@cid": "LEGITEXT000006074096", "@nature": "CODE", "TITRE_TXT": [ { "@fin": "2999-01-01", "#text": "Code de la construction et de l'habitation", "@debut": "1977-03-10", "@id_txt": "LEGITEXT000006074096", "@c_titre_court": "Code de la construction et de l'habitation." } ], "@date_publi": "2999-01-01", "@date_signature": "2999-01-01" } }, "VERSIONS": { "VERSION": [ { "@etat": "MODIFIE", "LIEN_ART": { "@id": "LEGIARTI000006824508", "@fin": "1991-12-01", "@num": "L231-1", "@etat": "MODIFIE", "@debut": "1978-06-08", "@origine": "LEGI" } }, { "@etat": "MODIFIE", "LIEN_ART": { "@id": "LEGIARTI000006824509", "@fin": "2021-07-01", "@num": "L231-1", "@etat": "MODIFIE", "@debut": "1991-12-01", "@origine": "LEGI" } }, { "@etat": "VIGUEUR", "LIEN_ART": { "@id": "LEGIARTI000041586868", "@fin": "2999-01-01", "@num": "L231-1", "@etat": "VIGUEUR", "@debut": "2021-07-01", "@origine": "LEGI" } } ] }, "BLOC_TEXTUEL": { "CONTENU": "
Toute personne qui se charge de la construction d'un immeuble à usage d'habitation ou d'un immeuble à usage professionnel et d'habitation ne comportant pas plus de deux logements destinés au même maître de l'ouvrage d'après un plan qu'elle a proposé ou fait proposer doit conclure avec le maître de l'ouvrage un contrat soumis aux dispositions de l'article L. 231-2.
\n
Cette obligation est également imposée :
\n
a) A toute personne qui se charge de la construction d'un tel immeuble à partir d'un plan fourni par un tiers à la suite d'un démarchage à domicile ou d'une publicité faits pour le compte de cette personne ;
\n
b) A toute personne qui réalise une partie des travaux de construction d'un tel immeuble dès lors que le plan de celui-ci a été fourni par cette personne ou, pour son compte, au moyen des procédés visés à l'alinéa précédent.
\n
Cette personne est dénommée constructeur au sens du présent chapitre et réputée constructeur de l'ouvrage au sens de l'article 1792-1 du code civil reproduit à l'article L. 111-14.
" } }, "LEGIARTI000006847390": { "META": { "META_SPEC": { "META_ARTICLE": { "NUM": "2", "ETAT": "MODIFIE", "TYPE": "AUTONOME", "DATE_FIN": "2005-08-27", "DATE_DEBUT": "1977-01-04" } }, "META_COMMUN": { "ID": "LEGIARTI000006847390", "URL": "article/LEGI/ARTI/00/00/06/84/73/LEGIARTI000006847390.xml", "NATURE": "Article", "ORIGINE": "LEGI", "ANCIEN_ID": "UPECQXXXXXX002AAXXXXXXAA" } }, "LIENS": { "LIEN": [ { "@id": "LEGIARTI000041587293", "@num": "10-1", "#text": "Loi n° 75-1351 du 31 décembre 1975 - art. 10-1 (VD)", "@sens": "cible", "@cidtexte": "JORFTEXT000000889243", "@numtexte": "75-1351", "@typelien": "CITATION", "@naturetexte": "LOI", "@datesignatexte": "1975-12-31" }, { "@id": "JORFTEXT000000522423", "#text": "LOI 77-2 1977-01-03 ART. 10, ART. 11, ART. 12, ART. 13, ART. 37", "@sens": "source", "@cidtexte": "JORFTEXT000000522423", "@numtexte": "77-2", "@typelien": "CITATION", "@naturetexte": "LOI", "@datesignatexte": "1977-01-03" }, { "@id": "JORFTEXT000000522423", "#text": "LOI 77-2 1977-01-03 JORF 4 JANVIER 1977 Rectificatif JORF 5 et 21 JANVIER 1977", "@sens": "source", "@cidtexte": "JORFTEXT000000522423", "@numtexte": "77-2", "@typelien": "CREATION", "@naturetexte": "LOI", "@datesignatexte": "1977-01-03" }, { "@id": "LEGIARTI000006847403", "@num": "10", "#text": "Loi n°77-2 du 3 janvier 1977 - art. 10 (M)", "@sens": "source", "@cidtexte": "JORFTEXT000000522423", "@numtexte": "77-2", "@typelien": "CITATION", "@naturetexte": "LOI", "@datesignatexte": "1977-01-03" }, { "@id": "LEGIARTI000006847406", "@num": "11", "#text": "Loi n°77-2 du 3 janvier 1977 - art. 11 (V)", "@sens": "source", "@cidtexte": "JORFTEXT000000522423", "@numtexte": "77-2", "@typelien": "CITATION", "@naturetexte": "LOI", "@datesignatexte": "1977-01-03" }, { "@id": "LEGIARTI000006325212", "@num": "1", "#text": "Décret n°84-57 du 25 janvier 1984 - art. 1 (V)", "@sens": "cible", "@cidtexte": "JORFTEXT000000885338", "@numtexte": "84-57", "@typelien": "CITATION", "@naturetexte": "DECRET", "@datesignatexte": "1984-01-25" }, { "@id": "LEGIARTI000032612972", "@num": "1", "#text": "Décret n°2016-711 du 30 mai 2016 - art. 1", "@sens": "cible", "@cidtexte": "JORFTEXT000032611310", "@nortexte": "LHAX1613394D", "@numtexte": "2016-711", "@typelien": "CITATION", "@naturetexte": "DECRET", "@datesignatexte": "2016-05-30" }, { "@id": "LEGIARTI000049785078", "@num": "1", "#text": "Décret n°2018-416 du 30 mai 2018 - art. 1 (V)", "@sens": "cible", "@cidtexte": "JORFTEXT000036964133", "@nortexte": "TERL1802835D", "@numtexte": "2018-416", "@typelien": "CITATION", "@naturetexte": "DECRET", "@datesignatexte": "2018-05-30" }, { "@id": "LEGIARTI000039742618", "@num": "14", "#text": "Décret n°2019-1478 du 26 décembre 2019 - art. 14 (V)", "@sens": "cible", "@cidtexte": "JORFTEXT000039683543", "@nortexte": "LOGL1923206D", "@numtexte": "2019-1478", "@typelien": "CITATION", "@naturetexte": "DECRET", "@datesignatexte": "2019-12-26" }, { "@id": "LEGIARTI000045682036", "@num": "8", "#text": "Arrêté du 10 avril 2020 - art. 8 (V)", "@sens": "cible", "@cidtexte": "JORFTEXT000041842389", "@nortexte": "LOGL2005904A", "@typelien": "CITATION", "@naturetexte": "ARRETE", "@datesignatexte": "2020-04-10" }, { "@id": "LEGIARTI000050745443", "@num": "1", "#text": "Arrêté du 29 juin 2020 - art. 1 (V)", "@sens": "cible", "@cidtexte": "JORFTEXT000042106692", "@nortexte": "ECOT2013713A", "@typelien": "CITATION", "@naturetexte": "ARRETE", "@datesignatexte": "2020-06-29" }, { "@id": "LEGIARTI000044100071", "@num": "1", "#text": "Décret n°2021-1227 du 23 septembre 2021 - art. 1", "@sens": "cible", "@cidtexte": "JORFTEXT000044097895", "@nortexte": "LOGL2005552D", "@numtexte": "2021-1227", "@typelien": "CITATION", "@naturetexte": "DECRET", "@datesignatexte": "2021-09-23" }, { "@id": "LEGITEXT000046084823", "#text": "Décret n°2022-1035 du 22 juillet 2022 (V)", "@sens": "cible", "@cidtexte": "JORFTEXT000046081405", "@nortexte": "TRER2208329D", "@numtexte": "2022-1035", "@typelien": "CITATION", "@naturetexte": "DECRET", "@datesignatexte": "2022-07-22" }, { "@id": "LEGIARTI000046084850", "@num": "1", "#text": "Décret n°2022-1035 du 22 juillet 2022 - art. 1", "@sens": "cible", "@cidtexte": "JORFTEXT000046081405", "@nortexte": "TRER2208329D", "@numtexte": "2022-1035", "@typelien": "CITATION", "@naturetexte": "DECRET", "@datesignatexte": "2022-07-22" }, { "@id": "LEGITEXT000046818907", "#text": "Arrêté du 21 décembre 2022 (V)", "@sens": "cible", "@cidtexte": "JORFTEXT000046807068", "@nortexte": "ENER2236172A", "@typelien": "CITATION", "@naturetexte": "ARRETE", "@datesignatexte": "2022-12-21" }, { "@id": "LEGIARTI000048561895", "@num": "1", "#text": "Décret n°2023-1175 du 12 décembre 2023 - art. 1", "@sens": "cible", "@cidtexte": "JORFTEXT000048560412", "@nortexte": "TREL2318911D", "@numtexte": "2023-1175", "@typelien": "CITATION", "@naturetexte": "DECRET", "@datesignatexte": "2023-12-12" }, { "@id": "LEGITEXT000050742642", "#text": "Arrêté du 3 décembre 2024 (V)", "@sens": "cible", "@cidtexte": "JORFTEXT000050731018", "@nortexte": "ECOT2430597A", "@typelien": "CITATION", "@naturetexte": "ARRETE", "@datesignatexte": "2024-12-03" }, { "@id": "LEGIARTI000050742674", "@num": "1", "#text": "Arrêté du 3 décembre 2024 - art. 1", "@sens": "cible", "@cidtexte": "JORFTEXT000050731018", "@nortexte": "ECOT2430597A", "@typelien": "CITATION", "@naturetexte": "ARRETE", "@datesignatexte": "2024-12-03" }, { "@id": "LEGIARTI000050476283", "@num": "R232-5", "#text": "Code de l'énergie - art. R232-5 (V)", "@sens": "cible", "@cidtexte": "LEGITEXT000023983208", "@typelien": "CITATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000039636138", "@num": "D111-19-46", "#text": "Code de la construction et de l'habitation. - art. D111-19-46 (Ab)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CITATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000043976954", "@num": "L111-1", "#text": "Code de la construction et de l'habitation. - art. L111-1 (V)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CITATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000036568642", "@num": "L111-10-2", "#text": "Code de la construction et de l'habitation. - art. L111-10-2 (VT)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CITATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000037671229", "@num": "L111-9-1", "#text": "Code de la construction et de l'habitation. - art. L111-9-1 (VT)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CITATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000041590629", "@num": "L152-1", "#text": "Code de la construction et de l'habitation. - art. L152-1 (VD)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CITATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000006895963", "@num": "R*111-19-22", "#text": "Code de la construction et de l'habitation. - art. R*111-19-22 (M)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CITATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000006895971", "@num": "R111-19-27", "#text": "Code de la construction et de l'habitation. - art. R111-19-27 (Ab)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CITATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000036568935", "@num": "R111-20-4", "#text": "Code de la construction et de l'habitation. - art. R111-20-4 (Ab)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CITATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000024097911", "@num": "R111-4-3", "#text": "Code de la construction et de l'habitation. - art. R111-4-3 (Ab)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CITATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000048562939", "@num": "R122-30", "#text": "Code de la construction et de l'habitation. - art. R122-30 (VD)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CITATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000048562930", "@num": "R122-32", "#text": "Code de la construction et de l'habitation. - art. R122-32 (VD)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CITATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000036572288", "@num": "R131-28-4", "#text": "Code de la construction et de l'habitation. - art. R131-28-4 (Ab)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CITATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000034671992", "@num": "R131-28-9", "#text": "Code de la construction et de l'habitation. - art. R131-28-9 (Ab)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CITATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000043819355", "@num": "R165-17", "#text": "Code de la construction et de l'habitation. - art. R165-17 (V)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CITATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000043819425", "@num": "R173-6", "#text": "Code de la construction et de l'habitation. - art. R173-6 (V)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CITATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" } ] }, "CONTEXTE": { "TEXTE": { "@cid": "JORFTEXT000000522423", "@num": "77-2", "@nature": "LOI", "TITRE_TXT": [ { "@fin": "2999-01-01", "#text": "LOI n° 77-2 du 3 janvier 1977 sur l'architecture", "@debut": "2999-01-01", "@id_txt": "JORFTEXT000000522423", "@c_titre_court": "LOI n° 77-2 du 3 janvier 1977" }, { "@fin": "2999-01-01", "#text": "Loi n° 77-2 du 3 janvier 1977 sur l'architecture", "@debut": "1977-01-04", "@id_txt": "LEGITEXT000006068580", "@c_titre_court": "Loi n° 77-2 du 3 janvier 1977" } ], "@date_publi": "1977-01-04", "@date_signature": "1977-01-03" } }, "VERSIONS": { "VERSION": [ { "@etat": "MODIFIE", "LIEN_ART": { "@id": "LEGIARTI000006847390", "@fin": "2005-08-27", "@num": "2", "@etat": "MODIFIE", "@debut": "1977-01-04", "@origine": "LEGI" } }, { "@etat": "VIGUEUR", "LIEN_ART": { "@id": "LEGIARTI000006847391", "@fin": "2999-01-01", "@num": "2", "@etat": "VIGUEUR", "@debut": "2005-08-27", "@origine": "LEGI" } } ] }, "BLOC_TEXTUEL": { "CONTENU": "
Sont considérées comme architectes pour l'application de la présente loi les personnes physiques énumérées aux articles 10 et 11, les sociétés définies à l'article 12 ainsi que les personnes physiques admises à porter le titre d'agréé en architecture en application de l'article 37 ci-après.
\n
" } }, "LEGIARTI000006847391": { "META": { "META_SPEC": { "META_ARTICLE": { "NUM": "2", "ETAT": "VIGUEUR", "TYPE": "AUTONOME", "DATE_FIN": "2999-01-01", "DATE_DEBUT": "2005-08-27" } }, "META_COMMUN": { "ID": "LEGIARTI000006847391", "URL": "article/LEGI/ARTI/00/00/06/84/73/LEGIARTI000006847391.xml", "NATURE": "Article", "ORIGINE": "LEGI", "ANCIEN_ID": "UPECQXXXXXX002AAXXXXXXAB" } }, "LIENS": { "LIEN": [ { "@id": "LEGIARTI000041587293", "@num": "10-1", "#text": "Loi n° 75-1351 du 31 décembre 1975 - art. 10-1 (VD)", "@sens": "cible", "@cidtexte": "JORFTEXT000000889243", "@numtexte": "75-1351", "@typelien": "CITATION", "@naturetexte": "LOI", "@datesignatexte": "1975-12-31" }, { "@id": "JORFTEXT000000522423", "#text": "Loi 77-2 1977-01-03 art. 10, art. 11, art. 12, art. 37", "@sens": "source", "@cidtexte": "JORFTEXT000000522423", "@numtexte": "77-2", "@typelien": "CITATION", "@naturetexte": "LOI", "@datesignatexte": "1977-01-03" }, { "@id": "LEGIARTI000006847403", "@num": "10", "#text": "Loi n°77-2 du 3 janvier 1977 - art. 10 (M)", "@sens": "source", "@cidtexte": "JORFTEXT000000522423", "@numtexte": "77-2", "@typelien": "CITATION", "@naturetexte": "LOI", "@datesignatexte": "1977-01-03" }, { "@id": "LEGIARTI000006847406", "@num": "11", "#text": "Loi n°77-2 du 3 janvier 1977 - art. 11 (V)", "@sens": "source", "@cidtexte": "JORFTEXT000000522423", "@numtexte": "77-2", "@typelien": "CITATION", "@naturetexte": "LOI", "@datesignatexte": "1977-01-03" }, { "@id": "LEGIARTI000006325212", "@num": "1", "#text": "Décret n°84-57 du 25 janvier 1984 - art. 1 (V)", "@sens": "cible", "@cidtexte": "JORFTEXT000000885338", "@numtexte": "84-57", "@typelien": "CITATION", "@naturetexte": "DECRET", "@datesignatexte": "1984-01-25" }, { "@id": "LEGIARTI000006244391", "@num": "2", "#text": "Ordonnance n°2005-1044 du 26 août 2005 - art. 2 () JORF 27 août 2005", "@sens": "source", "@cidtexte": "JORFTEXT000000812004", "@nortexte": "MCCX0500148R", "@numtexte": "2005-1044", "@typelien": "MODIFICATION", "@naturetexte": "ORDONNANCE", "@datesignatexte": "2005-08-26" }, { "@id": "LEGIARTI000032612972", "@num": "1", "#text": "Décret n°2016-711 du 30 mai 2016 - art. 1", "@sens": "cible", "@cidtexte": "JORFTEXT000032611310", "@nortexte": "LHAX1613394D", "@numtexte": "2016-711", "@typelien": "CITATION", "@naturetexte": "DECRET", "@datesignatexte": "2016-05-30" }, { "@id": "LEGIARTI000049785078", "@num": "1", "#text": "Décret n°2018-416 du 30 mai 2018 - art. 1 (V)", "@sens": "cible", "@cidtexte": "JORFTEXT000036964133", "@nortexte": "TERL1802835D", "@numtexte": "2018-416", "@typelien": "CITATION", "@naturetexte": "DECRET", "@datesignatexte": "2018-05-30" }, { "@id": "LEGIARTI000039742618", "@num": "14", "#text": "Décret n°2019-1478 du 26 décembre 2019 - art. 14 (V)", "@sens": "cible", "@cidtexte": "JORFTEXT000039683543", "@nortexte": "LOGL1923206D", "@numtexte": "2019-1478", "@typelien": "CITATION", "@naturetexte": "DECRET", "@datesignatexte": "2019-12-26" }, { "@id": "LEGIARTI000045682036", "@num": "8", "#text": "Arrêté du 10 avril 2020 - art. 8 (V)", "@sens": "cible", "@cidtexte": "JORFTEXT000041842389", "@nortexte": "LOGL2005904A", "@typelien": "CITATION", "@naturetexte": "ARRETE", "@datesignatexte": "2020-04-10" }, { "@id": "LEGIARTI000050745443", "@num": "1", "#text": "Arrêté du 29 juin 2020 - art. 1 (V)", "@sens": "cible", "@cidtexte": "JORFTEXT000042106692", "@nortexte": "ECOT2013713A", "@typelien": "CITATION", "@naturetexte": "ARRETE", "@datesignatexte": "2020-06-29" }, { "@id": "LEGIARTI000044100071", "@num": "1", "#text": "Décret n°2021-1227 du 23 septembre 2021 - art. 1", "@sens": "cible", "@cidtexte": "JORFTEXT000044097895", "@nortexte": "LOGL2005552D", "@numtexte": "2021-1227", "@typelien": "CITATION", "@naturetexte": "DECRET", "@datesignatexte": "2021-09-23" }, { "@id": "LEGITEXT000046084823", "#text": "Décret n°2022-1035 du 22 juillet 2022 (V)", "@sens": "cible", "@cidtexte": "JORFTEXT000046081405", "@nortexte": "TRER2208329D", "@numtexte": "2022-1035", "@typelien": "CITATION", "@naturetexte": "DECRET", "@datesignatexte": "2022-07-22" }, { "@id": "LEGIARTI000046084850", "@num": "1", "#text": "Décret n°2022-1035 du 22 juillet 2022 - art. 1", "@sens": "cible", "@cidtexte": "JORFTEXT000046081405", "@nortexte": "TRER2208329D", "@numtexte": "2022-1035", "@typelien": "CITATION", "@naturetexte": "DECRET", "@datesignatexte": "2022-07-22" }, { "@id": "LEGITEXT000046818907", "#text": "Arrêté du 21 décembre 2022 (V)", "@sens": "cible", "@cidtexte": "JORFTEXT000046807068", "@nortexte": "ENER2236172A", "@typelien": "CITATION", "@naturetexte": "ARRETE", "@datesignatexte": "2022-12-21" }, { "@id": "LEGIARTI000048561895", "@num": "1", "#text": "Décret n°2023-1175 du 12 décembre 2023 - art. 1", "@sens": "cible", "@cidtexte": "JORFTEXT000048560412", "@nortexte": "TREL2318911D", "@numtexte": "2023-1175", "@typelien": "CITATION", "@naturetexte": "DECRET", "@datesignatexte": "2023-12-12" }, { "@id": "LEGITEXT000050742642", "#text": "Arrêté du 3 décembre 2024 (V)", "@sens": "cible", "@cidtexte": "JORFTEXT000050731018", "@nortexte": "ECOT2430597A", "@typelien": "CITATION", "@naturetexte": "ARRETE", "@datesignatexte": "2024-12-03" }, { "@id": "LEGIARTI000050742674", "@num": "1", "#text": "Arrêté du 3 décembre 2024 - art. 1", "@sens": "cible", "@cidtexte": "JORFTEXT000050731018", "@nortexte": "ECOT2430597A", "@typelien": "CITATION", "@naturetexte": "ARRETE", "@datesignatexte": "2024-12-03" }, { "@id": "LEGIARTI000050476283", "@num": "R232-5", "#text": "Code de l'énergie - art. R232-5 (V)", "@sens": "cible", "@cidtexte": "LEGITEXT000023983208", "@typelien": "CITATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000039636138", "@num": "D111-19-46", "#text": "Code de la construction et de l'habitation. - art. D111-19-46 (Ab)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CITATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000043976954", "@num": "L111-1", "#text": "Code de la construction et de l'habitation. - art. L111-1 (V)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CITATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000036568642", "@num": "L111-10-2", "#text": "Code de la construction et de l'habitation. - art. L111-10-2 (VT)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CITATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000037671229", "@num": "L111-9-1", "#text": "Code de la construction et de l'habitation. - art. L111-9-1 (VT)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CITATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000041590629", "@num": "L152-1", "#text": "Code de la construction et de l'habitation. - art. L152-1 (VD)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CITATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000006895963", "@num": "R*111-19-22", "#text": "Code de la construction et de l'habitation. - art. R*111-19-22 (M)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CITATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000006895971", "@num": "R111-19-27", "#text": "Code de la construction et de l'habitation. - art. R111-19-27 (Ab)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CITATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000036568935", "@num": "R111-20-4", "#text": "Code de la construction et de l'habitation. - art. R111-20-4 (Ab)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CITATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000024097911", "@num": "R111-4-3", "#text": "Code de la construction et de l'habitation. - art. R111-4-3 (Ab)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CITATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000048562939", "@num": "R122-30", "#text": "Code de la construction et de l'habitation. - art. R122-30 (VD)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CITATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000048562930", "@num": "R122-32", "#text": "Code de la construction et de l'habitation. - art. R122-32 (VD)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CITATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000036572288", "@num": "R131-28-4", "#text": "Code de la construction et de l'habitation. - art. R131-28-4 (Ab)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CITATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000034671992", "@num": "R131-28-9", "#text": "Code de la construction et de l'habitation. - art. R131-28-9 (Ab)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CITATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000043819355", "@num": "R165-17", "#text": "Code de la construction et de l'habitation. - art. R165-17 (V)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CITATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000043819425", "@num": "R173-6", "#text": "Code de la construction et de l'habitation. - art. R173-6 (V)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CITATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" } ] }, "CONTEXTE": { "TEXTE": { "@cid": "JORFTEXT000000522423", "@num": "77-2", "@nature": "LOI", "TITRE_TXT": [ { "@fin": "2999-01-01", "#text": "LOI n° 77-2 du 3 janvier 1977 sur l'architecture", "@debut": "2999-01-01", "@id_txt": "JORFTEXT000000522423", "@c_titre_court": "LOI n° 77-2 du 3 janvier 1977" }, { "@fin": "2999-01-01", "#text": "Loi n° 77-2 du 3 janvier 1977 sur l'architecture", "@debut": "1977-01-04", "@id_txt": "LEGITEXT000006068580", "@c_titre_court": "Loi n° 77-2 du 3 janvier 1977" } ], "@date_publi": "1977-01-04", "@date_signature": "1977-01-03" } }, "VERSIONS": { "VERSION": [ { "@etat": "MODIFIE", "LIEN_ART": { "@id": "LEGIARTI000006847390", "@fin": "2005-08-27", "@num": "2", "@etat": "MODIFIE", "@debut": "1977-01-04", "@origine": "LEGI" } }, { "@etat": "VIGUEUR", "LIEN_ART": { "@id": "LEGIARTI000006847391", "@fin": "2999-01-01", "@num": "2", "@etat": "VIGUEUR", "@debut": "2005-08-27", "@origine": "LEGI" } } ] }, "BLOC_TEXTUEL": { "CONTENU": "
Sont considérées comme architectes pour l'application de la présente loi les personnes physiques énumérées aux articles 10 et 11, les sociétés définies à l'article 12, ainsi que les personnes physiques admises à porter le titre d'agréé en architecture ou celui de détenteur de récépissé en application de l'article 37 et inscrites à un tableau régional d'architectes ou à son annexe.
\n
" } }, "LEGIARTI000041586842": { "META": { "META_SPEC": { "META_ARTICLE": { "NUM": "L232-1", "ETAT": "VIGUEUR", "TYPE": "AUTONOME", "DATE_FIN": "2999-01-01", "DATE_DEBUT": "2021-07-01" } }, "META_COMMUN": { "ID": "LEGIARTI000041586842", "URL": "article/LEGI/ARTI/00/00/41/58/68/LEGIARTI000041586842.xml", "NATURE": "Article", "ORIGINE": "LEGI" } }, "NOTA": { "CONTENU": "

Conformément à l'article 8 de l'ordonnance 2020-71 du 29 janvier 2020, ces dispositions entrent en vigueur à une date fixée par décret en Conseil d'Etat, et au plus tard le 1er juillet 2021.

" }, "LIENS": { "LIEN": [ { "@id": "JORFTEXT000000522423", "#text": "LOI n° 77-2 du 3 janvier 1977", "@sens": "source", "@cidtexte": "JORFTEXT000000522423", "@numtexte": "77-2", "@typelien": "CITATION", "@naturetexte": "LOI", "@datesignatexte": "1977-01-03" }, { "@id": "JORFTEXT000000516442", "#text": "Décret n° 78-621 du 31 mai 1978", "@sens": "source", "@cidtexte": "JORFTEXT000000516442", "@numtexte": "78-621", "@typelien": "CODIFICATION", "@naturetexte": "DECRET", "@datesignatexte": "1978-05-31" }, { "@id": "LEGIARTI000006830648", "@num": "3", "#text": "Arrêté du 27 novembre 1991 - art. 3 (V)", "@sens": "cible", "@cidtexte": "JORFTEXT000000526871", "@nortexte": "EQUC9101692A", "@typelien": "CITATION", "@naturetexte": "ARRETE", "@datesignatexte": "1991-11-27" }, { "@id": "LEGIARTI000021355420", "@num": "1", "#text": "Arrêté du 19 novembre 2009 - art. 1 (V)", "@sens": "cible", "@cidtexte": "JORFTEXT000021344622", "@nortexte": "DEVU0926808A", "@typelien": "CITATION", "@naturetexte": "ARRETE", "@datesignatexte": "2009-11-19" }, { "@id": "LEGIARTI000027550543", "@num": "7", "#text": "Arrêté du 30 décembre 2010 - art. 7 (Ab)", "@sens": "cible", "@cidtexte": "JORFTEXT000023332971", "@nortexte": "DEVL1026553A", "@typelien": "CITATION", "@naturetexte": "ARRETE", "@datesignatexte": "2010-12-30" }, { "@id": "LEGIARTI000045581767", "@num": "4-1", "#text": "Arrêté du 11 octobre 2011 - art. 4-1 (V)", "@sens": "cible", "@cidtexte": "JORFTEXT000024695233", "@nortexte": "DEVL1126896A", "@typelien": "CITATION", "@naturetexte": "ARRETE", "@datesignatexte": "2011-10-11" }, { "@id": "LEGIARTI000041562499", "@num": "4", "#text": "Ordonnance n° 2020-71 du 29 janvier 2020 - art. 4", "@sens": "cible", "@cidtexte": "JORFTEXT000041506557", "@nortexte": "LOGL1933297R", "@numtexte": "2020-71", "@typelien": "MODIFIE", "@naturetexte": "ORDONNANCE", "@datesignatexte": "2020-01-29" }, { "@id": "LEGIARTI000050745443", "@num": "1", "#text": "Arrêté du 29 juin 2020 - art. 1 (V)", "@sens": "cible", "@cidtexte": "JORFTEXT000042106692", "@nortexte": "ECOT2013713A", "@typelien": "CITATION", "@naturetexte": "ARRETE", "@datesignatexte": "2020-06-29" }, { "@id": "LEGIARTI000044503425", "@num": "10", "#text": "Arrêté du 9 décembre 2021 - art. 10", "@sens": "cible", "@cidtexte": "JORFTEXT000044501420", "@nortexte": "LOGL2114162A", "@typelien": "CITATION", "@naturetexte": "ARRETE", "@datesignatexte": "2021-12-09" }, { "@id": "LEGITEXT000050742475", "#text": "Arrêté du 3 décembre 2024 (V)", "@sens": "cible", "@cidtexte": "JORFTEXT000050731883", "@nortexte": "LRUL2422852A", "@typelien": "CITATION", "@naturetexte": "ARRETE", "@datesignatexte": "2024-12-03" }, { "@id": "LEGITEXT000050742642", "#text": "Arrêté du 3 décembre 2024 (V)", "@sens": "cible", "@cidtexte": "JORFTEXT000050731018", "@nortexte": "ECOT2430597A", "@typelien": "CITATION", "@naturetexte": "ARRETE", "@datesignatexte": "2024-12-03" }, { "@id": "LEGIARTI000050742674", "@num": "1", "#text": "Arrêté du 3 décembre 2024 - art. 1", "@sens": "cible", "@cidtexte": "JORFTEXT000050731018", "@nortexte": "ECOT2430597A", "@typelien": "CITATION", "@naturetexte": "ARRETE", "@datesignatexte": "2024-12-03" }, { "@id": "LEGIARTI000006795972", "@num": "L242-1", "#text": "Code des assurances - art. L242-1", "@sens": "source", "@cidtexte": "LEGITEXT000006073984", "@typelien": "CITATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000006824172", "@num": "L111-23", "#text": "Code de la construction et de l'habitation. - art. L111-23", "@sens": "source", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CITATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000041586868", "@num": "L231-1", "#text": "Code de la construction et de l'habitation. - art. L231-1 (VD)", "@sens": "source", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CITATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000028806974", "@num": "L241-3", "#text": "Code de la construction et de l'habitation. - art. L241-3 (V)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CITATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000032235569", "@num": "L241-8", "#text": "Code de la construction et de l'habitation. - art. L241-8 (VD)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CITATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000038433476", "@num": "L242-2", "#text": "Code de la construction et de l'habitation. - art. L242-2 (VD)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CITATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000046680556", "@num": "R172-1", "#text": "Code de la construction et de l'habitation. - art. R172-1 (V)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CITATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000039041691", "@num": "R232-3", "#text": "Code de la construction et de l'habitation. - art. R232-3 (VD)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CITATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000039041682", "@num": "R232-5", "#text": "Code de la construction et de l'habitation. - art. R232-5 (VD)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CITATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000039041673", "@num": "R232-7", "#text": "Code de la construction et de l'habitation. - art. R232-7 (VD)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CITATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000033655931", "@num": "D313-26", "#text": "Code monétaire et financier - art. D313-26 (VD)", "@sens": "cible", "@cidtexte": "LEGITEXT000006072026", "@typelien": "CITATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" } ] }, "CONTEXTE": { "TEXTE": { "TM": { "TM": { "TM": { "TM": { "TITRE_TM": [ { "@id": "LEGISCTA000006159021", "@fin": "2999-01-01", "#text": "Chapitre II : Contrat de construction d'une maison individuelle sans fourniture du plan.", "@debut": "1991-12-01" } ] }, "TITRE_TM": [ { "@id": "LEGISCTA000006143526", "@fin": "2999-01-01", "#text": "Titre III : Construction d'une maison individuelle.", "@debut": "1991-12-01" } ] }, "TITRE_TM": [ { "@id": "LEGISCTA000006128681", "@fin": "2999-01-01", "#text": "Livre II : Statut des constructeurs.", "@debut": "1978-06-08" } ] }, "TITRE_TM": [ { "@id": "LEGISCTA000006108136", "@fin": "2999-01-01", "#text": "Partie législative", "@debut": "1978-06-08" } ] }, "@cid": "LEGITEXT000006074096", "@nature": "CODE", "TITRE_TXT": [ { "@fin": "2999-01-01", "#text": "Code de la construction et de l'habitation", "@debut": "1977-03-10", "@id_txt": "LEGITEXT000006074096", "@c_titre_court": "Code de la construction et de l'habitation." } ], "@date_publi": "2999-01-01", "@date_signature": "2999-01-01" } }, "VERSIONS": { "VERSION": [ { "@etat": "MODIFIE", "LIEN_ART": { "@id": "LEGIARTI000006824506", "@fin": "2021-07-01", "@num": "L232-1", "@etat": "MODIFIE", "@debut": "1991-12-01", "@origine": "LEGI" } }, { "@etat": "VIGUEUR", "LIEN_ART": { "@id": "LEGIARTI000041586842", "@fin": "2999-01-01", "@num": "L232-1", "@etat": "VIGUEUR", "@debut": "2021-07-01", "@origine": "LEGI" } } ] }, "BLOC_TEXTUEL": { "CONTENU": "

Le contrat de louage d'ouvrage n'entrant pas dans le champ d'application de l'article L. 231-1 et ayant au moins pour objet l'exécution des travaux de gros oeuvre, de mise hors d'eau et hors d'air d'un immeuble à usage d'habitation ou d'un immeuble à usage professionnel et d'habitation, ne comportant pas plus de deux logements destinés au même maître de l'ouvrage, doit être rédigé par écrit et préciser :

a) La désignation du terrain ;

b) La consistance et les caractéristiques techniques de l'ouvrage à réaliser ;

c) Le prix convenu forfaitaire et définitif, sous réserve, s'il y a lieu, de sa révision dans les conditions et limites convenues, ainsi que les modalités de son règlement au fur et à mesure de l'exécution des travaux ;

d) Le délai d'exécution des travaux et les pénalités applicables en cas de retard de livraison ;

e) La référence de l'assurance de dommages souscrite par le maître de l'ouvrage en application de l'article L. 242-1 du code des assurances ;

f) L'indication que le maître de l'ouvrage pourra se faire assister par un professionnel habilité en application de la loi n° 77-2 du 3 janvier 1977 précitée ou des articles L. 125-1 et suivants lors de la réception ou par tout autre professionnel de la construction titulaire d'un contrat d'assurance couvrant les responsabilités pour ce type de mission ;

g) L'engagement de l'entrepreneur de fournir, au plus tard à la date d'ouverture du chantier, la justification de la garantie de livraison qu'il apporte au maître de l'ouvrage, l'attestation de cette garantie étant établie par le garant et annexée au contrat.

" } }, "LEGIARTI000041586868": { "META": { "META_SPEC": { "META_ARTICLE": { "NUM": "L231-1", "ETAT": "VIGUEUR", "TYPE": "AUTONOME", "DATE_FIN": "2999-01-01", "DATE_DEBUT": "2021-07-01" } }, "META_COMMUN": { "ID": "LEGIARTI000041586868", "URL": "article/LEGI/ARTI/00/00/41/58/68/LEGIARTI000041586868.xml", "NATURE": "Article", "ORIGINE": "LEGI" } }, "NOTA": { "CONTENU": "

Conformément à l'article 8 de l'ordonnance 2020-71 du 29 janvier 2020, ces dispositions entrent en vigueur à une date fixée par décret en Conseil d'Etat, et au plus tard le 1er juillet 2021.

" }, "LIENS": { "LIEN": [ { "@id": "JORFTEXT000000687668", "#text": "Loi 71-579 1971-07-16 art. 45 al. 1", "@sens": "source", "@cidtexte": "JORFTEXT000000687668", "@numtexte": "71-579", "@typelien": "CONCORDANCE", "@naturetexte": "LOI", "@datesignatexte": "1971-07-16" }, { "@id": "LEGIARTI000006826382", "@num": "45", "#text": "Loi n°71-579 du 16 juillet 1971 - art. 45 (Ab)", "@sens": "cible", "@cidtexte": "JORFTEXT000000687668", "@numtexte": "71-579", "@typelien": "CONCORDE", "@naturetexte": "LOI", "@datesignatexte": "1971-07-16" }, { "@id": "JORFTEXT000000516442", "#text": "Décret n° 78-621 du 31 mai 1978", "@sens": "source", "@cidtexte": "JORFTEXT000000516442", "@numtexte": "78-621", "@typelien": "CODIFICATION", "@naturetexte": "DECRET", "@datesignatexte": "1978-05-31" }, { "@id": "LEGIARTI000006829601", "@num": "9", "#text": "Arrêté du 30 décembre 1988 - art. 9 (V)", "@sens": "cible", "@cidtexte": "JORFTEXT000000873773", "@nortexte": "EQUC8800886A", "@typelien": "CITATION", "@naturetexte": "ARRETE", "@datesignatexte": "1988-12-30" }, { "@id": "LEGIARTI000006830647", "@num": "2", "#text": "Arrêté du 27 novembre 1991 - art. 2 (V)", "@sens": "cible", "@cidtexte": "JORFTEXT000000526871", "@nortexte": "EQUC9101692A", "@typelien": "CITATION", "@naturetexte": "ARRETE", "@datesignatexte": "1991-11-27" }, { "@id": "LEGIARTI000006739977", "@num": "1", "#text": "Décret n°99-776 du 8 septembre 1999 - art. 1 (Ab)", "@sens": "cible", "@cidtexte": "JORFTEXT000000396628", "@nortexte": "ECOT9914031D", "@numtexte": "99-776", "@typelien": "CITATION", "@naturetexte": "DECRET", "@datesignatexte": "1999-09-08" }, { "@id": "LEGIARTI000006227139", "@num": "3", "#text": "Arrêté du 18 décembre 2003 - art. 3 (V)", "@sens": "cible", "@cidtexte": "JORFTEXT000000612646", "@nortexte": "EQUU0301863A", "@typelien": "CITATION", "@naturetexte": "ARRETE", "@datesignatexte": "2003-12-18" }, { "@id": "LEGIARTI000006254037", "@num": "3", "#text": "Arrêté du 27 juillet 2006 - art. 3 (V)", "@sens": "cible", "@cidtexte": "JORFTEXT000000789055", "@nortexte": "SOCU0611686A", "@typelien": "CITATION", "@naturetexte": "ARRETE", "@datesignatexte": "2006-07-27" }, { "@id": "LEGIARTI000021510847", "@num": "5", "#text": "Arrêté du 8 mai 2007 - art. 5 (V)", "@sens": "cible", "@cidtexte": "JORFTEXT000000615939", "@nortexte": "SOCU0750649A", "@typelien": "CITATION", "@naturetexte": "ARRETE", "@datesignatexte": "2007-05-03" }, { "@id": "LEGIARTI000021355420", "@num": "1", "#text": "Arrêté du 19 novembre 2009 - art. 1 (V)", "@sens": "cible", "@cidtexte": "JORFTEXT000021344622", "@nortexte": "DEVU0926808A", "@typelien": "CITATION", "@naturetexte": "ARRETE", "@datesignatexte": "2009-11-19" }, { "@id": "LEGIARTI000027550543", "@num": "7", "#text": "Arrêté du 30 décembre 2010 - art. 7 (Ab)", "@sens": "cible", "@cidtexte": "JORFTEXT000023332971", "@nortexte": "DEVL1026553A", "@typelien": "CITATION", "@naturetexte": "ARRETE", "@datesignatexte": "2010-12-30" }, { "@id": "LEGIARTI000045581767", "@num": "4-1", "#text": "Arrêté du 11 octobre 2011 - art. 4-1 (V)", "@sens": "cible", "@cidtexte": "JORFTEXT000024695233", "@nortexte": "DEVL1126896A", "@typelien": "CITATION", "@naturetexte": "ARRETE", "@datesignatexte": "2011-10-11" }, { "@id": "LEGIARTI000033251105", "@num": "3", "#text": "Arrêté du 12 octobre 2016 - art. 3 (M)", "@sens": "cible", "@cidtexte": "JORFTEXT000033243759", "@nortexte": "LHAL1623033A", "@typelien": "CITATION", "@naturetexte": "ARRETE", "@datesignatexte": "2016-10-12" }, { "@id": "LEGIARTI000041562499", "@num": "4", "#text": "Ordonnance n° 2020-71 du 29 janvier 2020 - art. 4", "@sens": "cible", "@cidtexte": "JORFTEXT000041506557", "@nortexte": "LOGL1933297R", "@numtexte": "2020-71", "@typelien": "MODIFIE", "@naturetexte": "ORDONNANCE", "@datesignatexte": "2020-01-29" }, { "@id": "LEGIARTI000050745443", "@num": "1", "#text": "Arrêté du 29 juin 2020 - art. 1 (V)", "@sens": "cible", "@cidtexte": "JORFTEXT000042106692", "@nortexte": "ECOT2013713A", "@typelien": "CITATION", "@naturetexte": "ARRETE", "@datesignatexte": "2020-06-29" }, { "@id": "LEGIARTI000044503425", "@num": "10", "#text": "Arrêté du 9 décembre 2021 - art. 10", "@sens": "cible", "@cidtexte": "JORFTEXT000044501420", "@nortexte": "LOGL2114162A", "@typelien": "CITATION", "@naturetexte": "ARRETE", "@datesignatexte": "2021-12-09" }, { "@id": "LEGITEXT000050742642", "#text": "Arrêté du 3 décembre 2024 (V)", "@sens": "cible", "@cidtexte": "JORFTEXT000050731018", "@nortexte": "ECOT2430597A", "@typelien": "CITATION", "@naturetexte": "ARRETE", "@datesignatexte": "2024-12-03" }, { "@id": "LEGIARTI000050742674", "@num": "1", "#text": "Arrêté du 3 décembre 2024 - art. 1", "@sens": "cible", "@cidtexte": "JORFTEXT000050731018", "@nortexte": "ECOT2430597A", "@typelien": "CITATION", "@naturetexte": "ARRETE", "@datesignatexte": "2024-12-03" }, { "@id": "LEGIARTI000006443512", "@num": "1792-1", "#text": "Code civil - art. 1792-1", "@sens": "source", "@cidtexte": "LEGITEXT000006070721", "@typelien": "CITATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000025430929", "@num": "R*442-18", "#text": "Code de l'urbanisme - art. *R442-18 (V)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074075", "@typelien": "CITATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000025100231", "@num": "R*112-2", "#text": "Code de l'urbanisme - art. R*112-2 (VT)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074075", "@typelien": "CITATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000031721274", "@num": "R111-22", "#text": "Code de l'urbanisme - art. R111-22 (V)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074075", "@typelien": "CITATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000025430951", "@num": "R*442-1", "#text": "Code de l'urbanisme - art. R442-1 (V)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074075", "@typelien": "CITATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000039049511", "@num": "Annexe à l'article R422-37", "#text": "Code de la construction et de l'habitation. - art. Annexe à l'article R422-37 (V)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CITATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000039049534", "@num": "Annexe à l'article R422-6", "#text": "Code de la construction et de l'habitation. - art. Annexe à l'article R422-6 (V)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CITATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000019030588", "@num": "Annexe à l'article R422-7", "#text": "Code de la construction et de l'habitation. - art. Annexe à l'article R422-7 (V)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CITATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000006824510", "@num": "L231-1-1", "#text": "Code de la construction et de l'habitation. - art. L231-1-1 (Ab)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CITATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000028574448", "@num": "L231-11", "#text": "Code de la construction et de l'habitation. - art. L231-11 (V)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CITATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000041586856", "@num": "L231-2", "#text": "Code de la construction et de l'habitation. - art. L231-2 (VD)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CITATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000038433492", "@num": "L231-3", "#text": "Code de la construction et de l'habitation. - art. L231-3 (VD)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CITATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000006824494", "@num": "L231-4", "#text": "Code de la construction et de l'habitation. - art. L231-4 (V)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CITATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000041586842", "@num": "L232-1", "#text": "Code de la construction et de l'habitation. - art. L232-1 (VD)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CITATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000028806974", "@num": "L241-3", "#text": "Code de la construction et de l'habitation. - art. L241-3 (V)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CITATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000032235569", "@num": "L241-8", "#text": "Code de la construction et de l'habitation. - art. L241-8 (VD)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CITATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000038433476", "@num": "L242-2", "#text": "Code de la construction et de l'habitation. - art. L242-2 (VD)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CITATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000006896453", "@num": "R*231-4", "#text": "Code de la construction et de l'habitation. - art. R*231-4 (M)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CITATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000006896456", "@num": "R*231-5", "#text": "Code de la construction et de l'habitation. - art. R*231-5 (M)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CITATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000046680556", "@num": "R172-1", "#text": "Code de la construction et de l'habitation. - art. R172-1 (V)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CITATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000006811936", "@num": "R124-2", "#text": "Code des assurances - art. R124-2 (V)", "@sens": "cible", "@cidtexte": "LEGITEXT000006073984", "@typelien": "CITATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000006821757", "@num": "R421-24-3", "#text": "Code des assurances - art. R421-24-3 (Ab)", "@sens": "cible", "@cidtexte": "LEGITEXT000006073984", "@typelien": "CITATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" } ] }, "CONTEXTE": { "TEXTE": { "TM": { "TM": { "TM": { "TM": { "TITRE_TM": [ { "@id": "LEGISCTA000006159020", "@fin": "2999-01-01", "#text": "Chapitre Ier : Contrat de construction d'une maison individuelle avec fourniture du plan.", "@debut": "1991-12-01" } ] }, "TITRE_TM": [ { "@id": "LEGISCTA000006143526", "@fin": "2999-01-01", "#text": "Titre III : Construction d'une maison individuelle.", "@debut": "1991-12-01" } ] }, "TITRE_TM": [ { "@id": "LEGISCTA000006128681", "@fin": "2999-01-01", "#text": "Livre II : Statut des constructeurs.", "@debut": "1978-06-08" } ] }, "TITRE_TM": [ { "@id": "LEGISCTA000006108136", "@fin": "2999-01-01", "#text": "Partie législative", "@debut": "1978-06-08" } ] }, "@cid": "LEGITEXT000006074096", "@nature": "CODE", "TITRE_TXT": [ { "@fin": "2999-01-01", "#text": "Code de la construction et de l'habitation", "@debut": "1977-03-10", "@id_txt": "LEGITEXT000006074096", "@c_titre_court": "Code de la construction et de l'habitation." } ], "@date_publi": "2999-01-01", "@date_signature": "2999-01-01" } }, "VERSIONS": { "VERSION": [ { "@etat": "MODIFIE", "LIEN_ART": { "@id": "LEGIARTI000006824508", "@fin": "1991-12-01", "@num": "L231-1", "@etat": "MODIFIE", "@debut": "1978-06-08", "@origine": "LEGI" } }, { "@etat": "MODIFIE", "LIEN_ART": { "@id": "LEGIARTI000006824509", "@fin": "2021-07-01", "@num": "L231-1", "@etat": "MODIFIE", "@debut": "1991-12-01", "@origine": "LEGI" } }, { "@etat": "VIGUEUR", "LIEN_ART": { "@id": "LEGIARTI000041586868", "@fin": "2999-01-01", "@num": "L231-1", "@etat": "VIGUEUR", "@debut": "2021-07-01", "@origine": "LEGI" } } ] }, "BLOC_TEXTUEL": { "CONTENU": "

Toute personne qui se charge de la construction d'un immeuble à usage d'habitation ou d'un immeuble à usage professionnel et d'habitation ne comportant pas plus de deux logements destinés au même maître de l'ouvrage d'après un plan qu'elle a proposé ou fait proposer doit conclure avec le maître de l'ouvrage un contrat soumis aux dispositions de l'article L. 231-2.

Cette obligation est également imposée :

a) A toute personne qui se charge de la construction d'un tel immeuble à partir d'un plan fourni par un tiers à la suite d'un démarchage à domicile ou d'une publicité faits pour le compte de cette personne ;

b) A toute personne qui réalise une partie des travaux de construction d'un tel immeuble dès lors que le plan de celui-ci a été fourni par cette personne ou, pour son compte, au moyen des procédés visés à l'alinéa précédent.

Cette personne est dénommée constructeur au sens du présent chapitre et réputée constructeur de l'ouvrage au sens de l'article 1792-1 du code civil.

" } }, "LEGIARTI000050745443": { "META": { "META_SPEC": { "META_ARTICLE": { "NUM": "1", "ETAT": "VIGUEUR", "TYPE": "AUTONOME", "DATE_FIN": "2999-01-01", "DATE_DEBUT": "2024-12-06" } }, "META_COMMUN": { "ID": "LEGIARTI000050745443", "URL": "article/LEGI/ARTI/00/00/50/74/54/LEGIARTI000050745443.xml", "NATURE": "Article", "ORIGINE": "LEGI" } }, "LIENS": { "LIEN": [ { "@id": "LEGIARTI000006847390", "@num": "2", "#text": "LOI n° 77-2 du 3 janvier 1977 - art. 2", "@sens": "source", "@cidtexte": "JORFTEXT000000522423", "@numtexte": "77-2", "@typelien": "CITATION", "@naturetexte": "LOI", "@datesignatexte": "1977-01-03" }, { "@id": "LEGIARTI000050742674", "@num": "1", "#text": "Arrêté du 3 décembre 2024 - art. 1", "@sens": "cible", "@cidtexte": "JORFTEXT000050731018", "@nortexte": "ECOT2430597A", "@typelien": "MODIFIE", "@naturetexte": "ARRETE", "@datesignatexte": "2024-12-03" }, { "@id": "LEGITEXT000006069577", "#text": "Code général des impôts, CGI.", "@sens": "source", "@cidtexte": "LEGITEXT000006069577", "@typelien": "CITATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000020025258", "@num": "244 quater U", "#text": "Code général des impôts, CGI. - art. 244 quater U", "@sens": "source", "@cidtexte": "LEGITEXT000006069577", "@typelien": "CITATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGITEXT000006074096", "#text": "Code de la construction et de l'habitation.", "@sens": "source", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CITATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGISCTA000006177822", "#text": "Code de la construction et de l'habitation.", "@sens": "source", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CITATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGISCTA000020460919", "#text": "Code de la construction et de l'habitation.", "@sens": "source", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CITATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGISCTA000050175237", "#text": "Code de la construction et de l'habitation.", "@sens": "source", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CITATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000006824483", "@num": "L222-1", "#text": "Code de la construction et de l'habitation. - art. L222-1", "@sens": "source", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CITATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000006824508", "@num": "L231-1", "#text": "Code de la construction et de l'habitation. - art. L231-1", "@sens": "source", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CITATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000006824506", "@num": "L232-1", "#text": "Code de la construction et de l'habitation. - art. L232-1", "@sens": "source", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CITATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000006824582", "@num": "L261-3", "#text": "Code de la construction et de l'habitation. - art. L261-3", "@sens": "source", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CITATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000006824622", "@num": "L262-1", "#text": "Code de la construction et de l'habitation. - art. L262-1", "@sens": "source", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CITATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000023356560", "@num": "L31-10-1", "#text": "Code de la construction et de l'habitation. - art. L31-10-1", "@sens": "source", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CITATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000031367619", "@num": "L231-4", "#text": "Code des relations entre le public et l'administration - art. L231-4", "@sens": "source", "@cidtexte": "LEGITEXT000031366350", "@typelien": "CITATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" } ] }, "CONTEXTE": { "TEXTE": { "@cid": "JORFTEXT000042106692", "@nor": "ECOT2013713A", "@nature": "ARRETE", "TITRE_TXT": [ { "@fin": "2999-01-01", "#text": "Arrêté du 29 juin 2020 relatif aux modalités d'allongement du délai de réalisation des travaux dans le cadre d'un prêt réglementé", "@debut": "2999-01-01", "@id_txt": "JORFTEXT000042106692", "@c_titre_court": "Arrêté du 29 juin 2020" }, { "@fin": "2999-01-01", "#text": "Arrêté du 29 juin 2020 relatif aux modalités d'allongement du délai de réalisation des travaux dans le cadre d'un prêt réglementé", "@debut": "2020-07-13", "@id_txt": "LEGITEXT000042109160", "@c_titre_court": "Arrêté du 29 juin 2020" } ], "@ministere": "Ministère de l'économie, des finances et de la relance", "@date_publi": "2020-07-12", "@date_signature": "2020-06-29", "@num_parution_jo": "0171" } }, "VERSIONS": { "VERSION": [ { "@etat": "MODIFIE", "LIEN_ART": { "@id": "LEGIARTI000042109168", "@fin": "2024-12-06", "@num": "1", "@etat": "MODIFIE", "@debut": "2020-07-13", "@origine": "LEGI" } }, { "@etat": "VIGUEUR", "LIEN_ART": { "@id": "LEGIARTI000050745443", "@fin": "2999-01-01", "@num": "1", "@etat": "VIGUEUR", "@debut": "2024-12-06", "@origine": "LEGI" } }, { "LIEN_ART": { "@id": "JORFARTI000042106701", "@fin": "2999-01-01", "@num": "1", "@debut": "2999-01-01", "@origine": "JORF" } } ] }, "BLOC_TEXTUEL": { "CONTENU": "

I.-L'emprunteur qui bénéficie d'un prêt ne portant pas intérêt consenti pour financer la primo-accession à la propriété mentionné aux articles 244 quater V du code général des impôts et L. 31-10-1 et suivants du code de la construction et de l'habitation, d'un prêt conventionné mentionné aux articles D. 331-63 et suivants du code de la construction et de l'habitation, d'une avance remboursable ne portant pas intérêt pour le financement de travaux d'amélioration de la performance énergétique des logements anciens mentionnée à l'article 244 quater U du code général des impôts et aux articles D. 319-1 et suivants du code de la construction et de l'habitation ou d'un prêt avance mutation ne portant pas intérêt mentionné à l'article 244 quater T du code général des impôts et aux articles D. 31-11-1 et suivants du code de la construction et de l'habitation, peut solliciter, au plus tard trois mois avant son expiration, un allongement du délai de réalisation des travaux par une demande motivée déposée auprès de l'établissement de crédit, de la société de financement ou, s'agissant de l'avance remboursable ne portant pas intérêt pour le financement de travaux d'amélioration de la performance énergétique des logements anciens ou du prêt avance mutation ne portant pas intérêt, de la société de tiers-financement, dans l'un des quatre cas suivants :

1° En cas de force majeure :

a) Ayant une incidence sur la réalisation de l'opération pour laquelle l'emprunteur a conclu un contrat prévu aux articles L. 222-1, L. 231-1 ou L. 232-1 du code de la construction et de l'habitation ou une vente prévue aux articles L. 261-3 ou L. 262-1 du même code, ou se fait assister par un architecte au sens de l'article 2 de la loi n° 77-2 du 3 janvier 1977 sur l'architecture ;

b) Ayant une incidence sur la réalisation de l'opération et ne relevant pas du a) ;

2° En cas de maladie ou d'accident de l'emprunteur ayant entraîné une incapacité temporaire de travail d'une durée de trois mois minimum ou en cas de décès de l'emprunteur ;

3° En cas de procédure contentieuse liée à la réalisation de l'opération ;

4° En cas de reconnaissance de l'état de catastrophe naturelle ou de catastrophe technologique.

II.-Dans les cas prévus aux a du 1° et 2° à 4° du I du présent article, après deux premiers allongements accordés selon les modalités prévues à l'article 3, tout allongement supplémentaire est accordé par la direction générale du Trésor, selon la procédure prévue à l'article 2.

III.-Conformément au 3° de l'article L. 231-4 du code des relations entre le public et l'administration, à défaut de réponse dans les deux mois suivant la transmission de la demande motivée et des pièces, y compris celles complémentaires demandées par le prêteur, la demande d'allongement du délai est réputée rejetée, et les avantages financiers du prêt réglementé sont perdus pour les opérations non terminées à la date d'achèvement prévue.

\n
" } } }, "article_lien": [ { "article_id": "LEGIARTI000006847391", "cible": true, "cidtexte": "JORFTEXT000050731018", "id": "LEGIARTI000050742674", "typelien": "CITATION" }, { "article_id": "LEGIARTI000006824483", "cible": true, "cidtexte": "JORFTEXT000050731018", "id": "LEGIARTI000050742674", "typelien": "CITATION" }, { "article_id": "LEGIARTI000050745443", "cible": true, "cidtexte": "JORFTEXT000050731018", "id": "LEGIARTI000050742674", "typelien": "MODIFIE" }, { "article_id": "LEGIARTI000006824506", "cible": true, "cidtexte": "JORFTEXT000050731018", "id": "LEGIARTI000050742674", "typelien": "CITATION" }, { "article_id": "LEGIARTI000041586868", "cible": true, "cidtexte": "JORFTEXT000050731018", "id": "LEGIARTI000050742674", "typelien": "CITATION" }, { "article_id": "LEGIARTI000006824508", "cible": true, "cidtexte": "JORFTEXT000050731018", "id": "LEGIARTI000050742674", "typelien": "CITATION" }, { "article_id": "LEGIARTI000041586842", "cible": true, "cidtexte": "JORFTEXT000050731018", "id": "LEGIARTI000050742674", "typelien": "CITATION" }, { "article_id": "LEGIARTI000006824509", "cible": true, "cidtexte": "JORFTEXT000050731018", "id": "LEGIARTI000050742674", "typelien": "CITATION" }, { "article_id": "LEGIARTI000006847390", "cible": true, "cidtexte": "JORFTEXT000050731018", "id": "LEGIARTI000050742674", "typelien": "CITATION" } ], "follow": [ "LIENS.LIEN[@sens=cible,@typelien=CREATION].@id" ], "id": "LEGIARTI000050742674", "liens_entrants": true }

Article 1 ENTIEREMENT_MODIF (Arrêté du 3 décembre 2024 modifiant l'arrêté du 29 juin 2020 relatif aux modalités d'allongement du délai de réalisation des travaux dans le cadre d'un prêt réglementé)