{ "article": { "LEGIARTI000039041705": { "META": { "META_SPEC": { "META_ARTICLE": { "NUM": "R231-13", "ETAT": "VIGUEUR", "TYPE": "AUTONOME", "DATE_FIN": "2999-01-01", "DATE_DEBUT": "2019-09-01" } }, "META_COMMUN": { "ID": "LEGIARTI000039041705", "URL": "article/LEGI/ARTI/00/00/39/04/17/LEGIARTI000039041705.xml", "NATURE": "Article", "ORIGINE": "LEGI" } }, "LIENS": { "LIEN": [ { "@id": "JORFTEXT000000879756", "#text": "Décret 72-1239 1972-12-29 art. 13", "@sens": "source", "@cidtexte": "JORFTEXT000000879756", "@numtexte": "72-1239", "@typelien": "CONCORDANCE", "@naturetexte": "DECRET", "@datesignatexte": "1972-12-29" }, { "@id": "JORFTEXT000000702963", "#text": "Décret n° 78-622 du 31 mai 1978", "@sens": "source", "@cidtexte": "JORFTEXT000000702963", "@numtexte": "78-622", "@typelien": "CODIFICATION", "@naturetexte": "DECRET", "@datesignatexte": "1978-05-31" }, { "@id": "LEGIARTI000038955628", "@num": "4", "#text": "Décret n°2019-873 du 21 août 2019 - art. 4", "@sens": "cible", "@cidtexte": "JORFTEXT000038947944", "@nortexte": "TERX1913732D", "@numtexte": "2019-873", "@typelien": "MODIFIE", "@naturetexte": "DECRET", "@datesignatexte": "2019-08-21" }, { "@id": "LEGIARTI000006824657", "@num": "L231-2", "#text": "Code de la construction et de l'habitation. - art. L231-2", "@sens": "source", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CITATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" } ] }, "CONTEXTE": { "TEXTE": { "TM": { "TM": { "TM": { "TM": { "TITRE_TM": [ { "@id": "LEGISCTA000006160668", "@fin": "2999-01-01", "#text": "Chapitre Ier : Construction d'une maison individuelle avec fourniture de plan.", "@debut": "1991-11-29" } ] }, "TITRE_TM": [ { "@id": "LEGISCTA000006145287", "@fin": "2999-01-01", "#text": "Titre III : Construction d'une maison individuelle.", "@debut": "1991-11-29" } ] }, "TITRE_TM": [ { "@id": "LEGISCTA000006132257", "@fin": "2999-01-01", "#text": "Livre II : Statut des constructeurs.", "@debut": "1978-06-08" } ] }, "TITRE_TM": [ { "@id": "LEGISCTA000006112857", "@fin": "2999-01-01", "#text": "Partie réglementaire", "@debut": "1977-03-10" } ] }, "@cid": "LEGITEXT000006074096", "@nature": "CODE", "TITRE_TXT": [ { "@fin": "2999-01-01", "#text": "Code de la construction et de l'habitation", "@debut": "1977-03-10", "@id_txt": "LEGITEXT000006074096", "@c_titre_court": "Code de la construction et de l'habitation." } ], "@date_publi": "2999-01-01", "@date_signature": "2999-01-01" } }, "VERSIONS": { "VERSION": [ { "@etat": "MODIFIE", "LIEN_ART": { "@id": "LEGIARTI000006896559", "@fin": "1991-11-29", "@num": "R*231-13", "@etat": "MODIFIE", "@debut": "1978-06-08", "@origine": "LEGI" } }, { "@etat": "MODIFIE", "LIEN_ART": { "@id": "LEGIARTI000006896560", "@fin": "2019-09-01", "@num": "R*231-13", "@etat": "MODIFIE", "@debut": "1991-11-29", "@origine": "LEGI" } }, { "@etat": "VIGUEUR", "LIEN_ART": { "@id": "LEGIARTI000039041705", "@fin": "2999-01-01", "@num": "R231-13", "@etat": "VIGUEUR", "@debut": "2019-09-01", "@origine": "LEGI" } } ] }, "BLOC_TEXTUEL": { "CONTENU": "
Sont approuvées les clauses types mentionnées au dernier alinéa de l'article L. 231-2 et figurant en annexe au présent code.
\n
" } }, "LEGIARTI000006824657": { "META": { "META_SPEC": { "META_ARTICLE": { "NUM": "L231-2", "ETAT": "MODIFIE", "TYPE": "AUTONOME", "DATE_FIN": "1979-07-14", "DATE_DEBUT": "1978-06-08" } }, "META_COMMUN": { "ID": "LEGIARTI000006824657", "URL": "article/LEGI/ARTI/00/00/06/82/46/LEGIARTI000006824657.xml", "NATURE": "Article", "ORIGINE": "LEGI", "ANCIEN_ID": "UCAXXXXXXXX1X231L002XXAA" } }, "LIENS": { "LIEN": [ { "@id": "JORFTEXT000000687668", "#text": "Loi 71-579 1971-07-16 art. 45 al. 2 à 6", "@sens": "source", "@cidtexte": "JORFTEXT000000687668", "@numtexte": "71-579", "@typelien": "CONCORDANCE", "@naturetexte": "LOI", "@datesignatexte": "1971-07-16" }, { "@id": "LEGIARTI000006826382", "@num": "45", "#text": "Loi n°71-579 du 16 juillet 1971 - art. 45 (Ab)", "@sens": "cible", "@cidtexte": "JORFTEXT000000687668", "@numtexte": "71-579", "@typelien": "CONCORDE", "@naturetexte": "LOI", "@datesignatexte": "1971-07-16" }, { "@id": "JORFTEXT000000516442", "#text": "Décret 78-621 1978-05-31 JORF 8 juin 1978", "@sens": "source", "@cidtexte": "JORFTEXT000000516442", "@numtexte": "78-621", "@typelien": "CODIFICATION", "@naturetexte": "DECRET", "@datesignatexte": "1978-05-31" }, { "@id": "LEGIARTI000006829601", "@num": "9", "#text": "Arrêté du 30 décembre 1988 - art. 9 (V)", "@sens": "cible", "@cidtexte": "JORFTEXT000000873773", "@nortexte": "EQUC8800886A", "@typelien": "CITATION", "@naturetexte": "ARRETE", "@datesignatexte": "1988-12-30" }, { "@id": "LEGIARTI000006739977", "@num": "1", "#text": "Décret n°99-776 du 8 septembre 1999 - art. 1 (Ab)", "@sens": "cible", "@cidtexte": "JORFTEXT000000396628", "@nortexte": "ECOT9914031D", "@numtexte": "99-776", "@typelien": "CITATION", "@naturetexte": "DECRET", "@datesignatexte": "1999-09-08" }, { "@id": "LEGITEXT000050742475", "#text": "Arrêté du 3 décembre 2024 (V)", "@sens": "cible", "@cidtexte": "JORFTEXT000050731883", "@nortexte": "LRUL2422852A", "@typelien": "CITATION", "@naturetexte": "ARRETE", "@datesignatexte": "2024-12-03" }, { "@id": "LEGIARTI000006443512", "@num": "1792-1", "#text": "Code civil - art. 1792-1 (V)", "@sens": "source", "@cidtexte": "LEGITEXT000006070721", "@typelien": "CITATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000006824160", "@num": "L111-14", "#text": "Code de la construction et de l'habitation. - art. L111-14 (V)", "@sens": "source", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CITATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000041586868", "@num": "L231-1", "#text": "Code de la construction et de l'habitation. - art. L231-1 (VD)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CITATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000006824510", "@num": "L231-1-1", "#text": "Code de la construction et de l'habitation. - art. L231-1-1 (Ab)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CITATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000006824501", "@num": "L231-10", "#text": "Code de la construction et de l'habitation. - art. L231-10 (V)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CITATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000038433486", "@num": "L231-6", "#text": "Code de la construction et de l'habitation. - art. L231-6 (VD)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CITATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000006824498", "@num": "L231-7", "#text": "Code de la construction et de l'habitation. - art. L231-7 (V)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CITATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000006824507", "@num": "L232-2", "#text": "Code de la construction et de l'habitation. - art. L232-2 (V)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CITATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000006824514", "@num": "L241-1", "#text": "Code de la construction et de l'habitation. - art. L241-1 (M)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CITATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000006824660", "@num": "L241-3", "#text": "Code de la construction et de l'habitation. - art. L241-3 (M)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CITATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000006824538", "@num": "L242-2", "#text": "Code de la construction et de l'habitation. - art. L242-2 (V)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CITATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000006896534", "@num": "R*231-1", "#text": "Code de la construction et de l'habitation. - art. R*231-1 (M)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CITATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000006896543", "@num": "R*231-7", "#text": "Code de la construction et de l'habitation. - art. R*231-7 (M)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CITATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000039041705", "@num": "R231-13", "#text": "Code de la construction et de l'habitation. - art. R231-13 (VD)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CITATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000039041701", "@num": "R231-14", "#text": "Code de la construction et de l'habitation. - art. R231-14 (VD)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CITATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000039041754", "@num": "R231-2", "#text": "Code de la construction et de l'habitation. - art. R231-2 (VD)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CITATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000039041749", "@num": "R231-3", "#text": "Code de la construction et de l'habitation. - art. R231-3 (VD)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CITATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000039041744", "@num": "R231-4", "#text": "Code de la construction et de l'habitation. - art. R231-4 (VD)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CITATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000039041740", "@num": "R231-5", "#text": "Code de la construction et de l'habitation. - art. R231-5 (VD)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CITATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000006821757", "@num": "R421-24-3", "#text": "Code des assurances - art. R421-24-3 (Ab)", "@sens": "cible", "@cidtexte": "LEGITEXT000006073984", "@typelien": "CITATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000033655931", "@num": "D313-26", "#text": "Code monétaire et financier - art. D313-26 (VD)", "@sens": "cible", "@cidtexte": "LEGITEXT000006072026", "@typelien": "CITATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" } ] }, "CONTEXTE": { "TEXTE": { "TM": { "TM": { "TM": { "TM": { "TITRE_TM": [ { "@id": "LEGISCTA000006159020", "@fin": "2999-01-01", "#text": "Chapitre Ier : Contrat de construction d'une maison individuelle avec fourniture du plan.", "@debut": "1991-12-01" } ] }, "TITRE_TM": [ { "@id": "LEGISCTA000006143526", "@fin": "2999-01-01", "#text": "Titre III : Construction d'une maison individuelle.", "@debut": "1991-12-01" } ] }, "TITRE_TM": [ { "@id": "LEGISCTA000006128681", "@fin": "2999-01-01", "#text": "Livre II : Statut des constructeurs.", "@debut": "1978-06-08" } ] }, "TITRE_TM": [ { "@id": "LEGISCTA000006108136", "@fin": "2999-01-01", "#text": "Partie législative", "@debut": "1978-06-08" } ] }, "@cid": "LEGITEXT000006074096", "@nature": "CODE", "TITRE_TXT": [ { "@fin": "2999-01-01", "#text": "Code de la construction et de l'habitation", "@debut": "1977-03-10", "@id_txt": "LEGITEXT000006074096", "@c_titre_court": "Code de la construction et de l'habitation." } ], "@date_publi": "2999-01-01", "@date_signature": "2999-01-01" } }, "VERSIONS": { "VERSION": [ { "@etat": "MODIFIE", "LIEN_ART": { "@id": "LEGIARTI000006824657", "@fin": "1979-07-14", "@num": "L231-2", "@etat": "MODIFIE", "@debut": "1978-06-08", "@origine": "LEGI" } }, { "@etat": "MODIFIE", "LIEN_ART": { "@id": "LEGIARTI000006824658", "@fin": "1991-12-01", "@num": "L231-2", "@etat": "MODIFIE", "@debut": "1979-07-14", "@origine": "LEGI" } }, { "@etat": "MODIFIE", "LIEN_ART": { "@id": "LEGIARTI000006824659", "@fin": "2018-11-25", "@num": "L231-2", "@etat": "MODIFIE", "@debut": "1991-12-01", "@origine": "LEGI" } }, { "@etat": "MODIFIE", "LIEN_ART": { "@id": "LEGIARTI000037667723", "@fin": "2020-02-01", "@num": "L231-2", "@etat": "MODIFIE", "@debut": "2018-11-25", "@origine": "LEGI" } }, { "@etat": "MODIFIE", "LIEN_ART": { "@id": "LEGIARTI000038433496", "@fin": "2021-07-01", "@num": "L231-2", "@etat": "MODIFIE", "@debut": "2020-02-01", "@origine": "LEGI" } }, { "@etat": "VIGUEUR", "LIEN_ART": { "@id": "LEGIARTI000041586856", "@fin": "2999-01-01", "@num": "L231-2", "@etat": "VIGUEUR", "@debut": "2021-07-01", "@origine": "LEGI" } } ] }, "BLOC_TEXTUEL": { "CONTENU": "

La personne mentionnée au premier alinéa de l'article L. 231-1 est tenue d'exécuter les travaux décrits et estimés conformément au g dudit article aux prix et conditions mentionnés au contrat si le maître de l'ouvrage en fait la demande dans le délai de trois mois à partir de la signature du contrat.

\n
\n

Lorsque cette personne a fait état dans sa publicité ou dans le contrat de prêts destinés au financement de la construction, le contrat est, nonobstant toute stipulation contraire, réputé conclu sous la condition résolutoire du refus des prêts sauf si le maître de l'ouvrage a expressément indiqué qu'il renonçait à ces prêts.

\n
\n

Le contrat est également réputé conclu sous la condition suspensive qu'il soit satisfait à toutes les formalités réglementaires préalables à la construction.

\n
\n

La personne mentionnée au premier alinéa de l'article L. 231-1 ne peut exiger ou accepter du maître de l'ouvrage aucun versement, aucun dépôt, aucune souscription ou acceptation d'effet de commerce avant la signature du contrat. Les sommes qui peuvent être exigées à la signature du contrat sont restituées à l'acquéreur dans le cas où la condition suspensive prévue à l'alinéa précédent ne se réaliserait pas.

\n
\n

Aucun paiement ne peut non plus être exigé ni accepté avant la date à laquelle la créance est exigible.

\n
\n

La personne mentionnée à l'article L. 231-1, alinéa 1er, est réputée constructeur de l'ouvrage au sens de l'article 1792-1 du code civil reproduit à l'article L. 111-14 du présent code.

\n
" } }, "LEGIARTI000006824658": { "META": { "META_SPEC": { "META_ARTICLE": { "NUM": "L231-2", "ETAT": "MODIFIE", "TYPE": "AUTONOME", "DATE_FIN": "1991-12-01", "DATE_DEBUT": "1979-07-14" } }, "META_COMMUN": { "ID": "LEGIARTI000006824658", "URL": "article/LEGI/ARTI/00/00/06/82/46/LEGIARTI000006824658.xml", "NATURE": "Article", "ORIGINE": "LEGI", "ANCIEN_ID": "UCAXXXXXXXX1X231L002XXAB" } }, "LIENS": { "LIEN": [ { "@id": "JORFTEXT000000687668", "#text": "Loi 71-579 1971-07-16 art. 45 al. 2 à 6", "@sens": "source", "@cidtexte": "JORFTEXT000000687668", "@numtexte": "71-579", "@typelien": "CONCORDANCE", "@naturetexte": "LOI", "@datesignatexte": "1971-07-16" }, { "@id": "LEGIARTI000006826382", "@num": "45", "#text": "Loi n°71-579 du 16 juillet 1971 - art. 45 (Ab)", "@sens": "cible", "@cidtexte": "JORFTEXT000000687668", "@numtexte": "71-579", "@typelien": "CONCORDE", "@naturetexte": "LOI", "@datesignatexte": "1971-07-16" }, { "@id": "JORFTEXT000000516442", "#text": "Décret 78-621 1978-05-31 JORF 8 juin 1978", "@sens": "source", "@cidtexte": "JORFTEXT000000516442", "@numtexte": "78-621", "@typelien": "CODIFICATION", "@naturetexte": "DECRET", "@datesignatexte": "1978-05-31" }, { "@id": "LEGIARTI000006273347", "@num": "39", "#text": "Loi n°79-596 du 13 juillet 1979 - art. 39 () JORF 14 juillet 1979", "@sens": "source", "@cidtexte": "JORFTEXT000000886678", "@numtexte": "79-596", "@typelien": "MODIFICATION", "@naturetexte": "LOI", "@datesignatexte": "1979-07-13" }, { "@id": "LEGIARTI000006829601", "@num": "9", "#text": "Arrêté du 30 décembre 1988 - art. 9 (V)", "@sens": "cible", "@cidtexte": "JORFTEXT000000873773", "@nortexte": "EQUC8800886A", "@typelien": "CITATION", "@naturetexte": "ARRETE", "@datesignatexte": "1988-12-30" }, { "@id": "LEGIARTI000006739977", "@num": "1", "#text": "Décret n°99-776 du 8 septembre 1999 - art. 1 (Ab)", "@sens": "cible", "@cidtexte": "JORFTEXT000000396628", "@nortexte": "ECOT9914031D", "@numtexte": "99-776", "@typelien": "CITATION", "@naturetexte": "DECRET", "@datesignatexte": "1999-09-08" }, { "@id": "LEGITEXT000050742475", "#text": "Arrêté du 3 décembre 2024 (V)", "@sens": "cible", "@cidtexte": "JORFTEXT000050731883", "@nortexte": "LRUL2422852A", "@typelien": "CITATION", "@naturetexte": "ARRETE", "@datesignatexte": "2024-12-03" }, { "@id": "LEGIARTI000006443512", "@num": "1792-1", "#text": "Code civil - art. 1792-1 (V)", "@sens": "source", "@cidtexte": "LEGITEXT000006070721", "@typelien": "CITATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000006824160", "@num": "L111-14", "#text": "Code de la construction et de l'habitation. - art. L111-14 (V)", "@sens": "source", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CITATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000041586868", "@num": "L231-1", "#text": "Code de la construction et de l'habitation. - art. L231-1 (VD)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CITATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000006824510", "@num": "L231-1-1", "#text": "Code de la construction et de l'habitation. - art. L231-1-1 (Ab)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CITATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000006824501", "@num": "L231-10", "#text": "Code de la construction et de l'habitation. - art. L231-10 (V)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CITATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000038433486", "@num": "L231-6", "#text": "Code de la construction et de l'habitation. - art. L231-6 (VD)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CITATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000006824498", "@num": "L231-7", "#text": "Code de la construction et de l'habitation. - art. L231-7 (V)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CITATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000006824507", "@num": "L232-2", "#text": "Code de la construction et de l'habitation. - art. L232-2 (V)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CITATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000006824514", "@num": "L241-1", "#text": "Code de la construction et de l'habitation. - art. L241-1 (M)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CITATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000006824660", "@num": "L241-3", "#text": "Code de la construction et de l'habitation. - art. L241-3 (M)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CITATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000006824538", "@num": "L242-2", "#text": "Code de la construction et de l'habitation. - art. L242-2 (V)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CITATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000006896534", "@num": "R*231-1", "#text": "Code de la construction et de l'habitation. - art. R*231-1 (M)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CITATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000006896543", "@num": "R*231-7", "#text": "Code de la construction et de l'habitation. - art. R*231-7 (M)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CITATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000039041705", "@num": "R231-13", "#text": "Code de la construction et de l'habitation. - art. R231-13 (VD)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CITATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000039041701", "@num": "R231-14", "#text": "Code de la construction et de l'habitation. - art. R231-14 (VD)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CITATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000039041754", "@num": "R231-2", "#text": "Code de la construction et de l'habitation. - art. R231-2 (VD)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CITATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000039041749", "@num": "R231-3", "#text": "Code de la construction et de l'habitation. - art. R231-3 (VD)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CITATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000039041744", "@num": "R231-4", "#text": "Code de la construction et de l'habitation. - art. R231-4 (VD)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CITATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000039041740", "@num": "R231-5", "#text": "Code de la construction et de l'habitation. - art. R231-5 (VD)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CITATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000006821757", "@num": "R421-24-3", "#text": "Code des assurances - art. R421-24-3 (Ab)", "@sens": "cible", "@cidtexte": "LEGITEXT000006073984", "@typelien": "CITATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000033655931", "@num": "D313-26", "#text": "Code monétaire et financier - art. D313-26 (VD)", "@sens": "cible", "@cidtexte": "LEGITEXT000006072026", "@typelien": "CITATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" } ] }, "CONTEXTE": { "TEXTE": { "TM": { "TM": { "TM": { "TM": { "TITRE_TM": [ { "@id": "LEGISCTA000006159020", "@fin": "2999-01-01", "#text": "Chapitre Ier : Contrat de construction d'une maison individuelle avec fourniture du plan.", "@debut": "1991-12-01" } ] }, "TITRE_TM": [ { "@id": "LEGISCTA000006143526", "@fin": "2999-01-01", "#text": "Titre III : Construction d'une maison individuelle.", "@debut": "1991-12-01" } ] }, "TITRE_TM": [ { "@id": "LEGISCTA000006128681", "@fin": "2999-01-01", "#text": "Livre II : Statut des constructeurs.", "@debut": "1978-06-08" } ] }, "TITRE_TM": [ { "@id": "LEGISCTA000006108136", "@fin": "2999-01-01", "#text": "Partie législative", "@debut": "1978-06-08" } ] }, "@cid": "LEGITEXT000006074096", "@nature": "CODE", "TITRE_TXT": [ { "@fin": "2999-01-01", "#text": "Code de la construction et de l'habitation", "@debut": "1977-03-10", "@id_txt": "LEGITEXT000006074096", "@c_titre_court": "Code de la construction et de l'habitation." } ], "@date_publi": "2999-01-01", "@date_signature": "2999-01-01" } }, "VERSIONS": { "VERSION": [ { "@etat": "MODIFIE", "LIEN_ART": { "@id": "LEGIARTI000006824657", "@fin": "1979-07-14", "@num": "L231-2", "@etat": "MODIFIE", "@debut": "1978-06-08", "@origine": "LEGI" } }, { "@etat": "MODIFIE", "LIEN_ART": { "@id": "LEGIARTI000006824658", "@fin": "1991-12-01", "@num": "L231-2", "@etat": "MODIFIE", "@debut": "1979-07-14", "@origine": "LEGI" } }, { "@etat": "MODIFIE", "LIEN_ART": { "@id": "LEGIARTI000006824659", "@fin": "2018-11-25", "@num": "L231-2", "@etat": "MODIFIE", "@debut": "1991-12-01", "@origine": "LEGI" } }, { "@etat": "MODIFIE", "LIEN_ART": { "@id": "LEGIARTI000037667723", "@fin": "2020-02-01", "@num": "L231-2", "@etat": "MODIFIE", "@debut": "2018-11-25", "@origine": "LEGI" } }, { "@etat": "MODIFIE", "LIEN_ART": { "@id": "LEGIARTI000038433496", "@fin": "2021-07-01", "@num": "L231-2", "@etat": "MODIFIE", "@debut": "2020-02-01", "@origine": "LEGI" } }, { "@etat": "VIGUEUR", "LIEN_ART": { "@id": "LEGIARTI000041586856", "@fin": "2999-01-01", "@num": "L231-2", "@etat": "VIGUEUR", "@debut": "2021-07-01", "@origine": "LEGI" } } ] }, "BLOC_TEXTUEL": { "CONTENU": "

Le contrat est réputé conclu sous la condition suspensive qu'il soit satisfait à toutes les formalités réglementaires préalables à la construction.

Aucun paiement ne peut non plus être exigé ni accepté avant la date à laquelle la créance est exigible.

La personne mentionnée à l'article L. 231-1, alinéa 1er, est réputée constructeur de l'ouvrage au sens de l'article 1792-1 du Code civil reproduit à l'article L. 111-14 du présent code.

\n
" } }, "LEGIARTI000006824659": { "META": { "META_SPEC": { "META_ARTICLE": { "NUM": "L231-2", "ETAT": "MODIFIE", "TYPE": "AUTONOME", "DATE_FIN": "2018-11-25", "DATE_DEBUT": "1991-12-01" } }, "META_COMMUN": { "ID": "LEGIARTI000006824659", "URL": "article/LEGI/ARTI/00/00/06/82/46/LEGIARTI000006824659.xml", "NATURE": "Article", "ORIGINE": "LEGI", "ANCIEN_ID": "UCAXXXXXXXX1X231L002XXAC" } }, "LIENS": { "LIEN": [ { "@id": "JORFTEXT000000687668", "#text": "Loi 71-579 1971-07-16 art. 45 al. 2 à 6", "@sens": "source", "@cidtexte": "JORFTEXT000000687668", "@numtexte": "71-579", "@typelien": "CONCORDANCE", "@naturetexte": "LOI", "@datesignatexte": "1971-07-16" }, { "@id": "LEGIARTI000006826382", "@num": "45", "#text": "Loi n°71-579 du 16 juillet 1971 - art. 45 (Ab)", "@sens": "cible", "@cidtexte": "JORFTEXT000000687668", "@numtexte": "71-579", "@typelien": "CONCORDE", "@naturetexte": "LOI", "@datesignatexte": "1971-07-16" }, { "@id": "JORFTEXT000000522423", "#text": "Loi n° 77-2 du 3 janvier 1977 (V)", "@sens": "source", "@cidtexte": "JORFTEXT000000522423", "@numtexte": "77-2", "@typelien": "CITATION", "@naturetexte": "LOI", "@datesignatexte": "1977-01-03" }, { "@id": "JORFTEXT000000516442", "#text": "Décret 78-621 1978-05-31 JORF 8 JUIN 1978", "@sens": "source", "@cidtexte": "JORFTEXT000000516442", "@numtexte": "78-621", "@typelien": "CODIFICATION", "@naturetexte": "DECRET", "@datesignatexte": "1978-05-31" }, { "@id": "LEGIARTI000006829601", "@num": "9", "#text": "Arrêté du 30 décembre 1988 - art. 9 (V)", "@sens": "cible", "@cidtexte": "JORFTEXT000000873773", "@nortexte": "EQUC8800886A", "@typelien": "CITATION", "@naturetexte": "ARRETE", "@datesignatexte": "1988-12-30" }, { "@id": "JORFTEXT000000709335", "#text": "Loi 90-1129 1990-12-19 art. 8", "@sens": "source", "@cidtexte": "JORFTEXT000000709335", "@nortexte": "EQUX9000054L", "@numtexte": "90-1129", "@typelien": "SPEC_APPLI", "@naturetexte": "LOI", "@datesignatexte": "1990-12-19" }, { "@id": "LEGIARTI000006826206", "@num": "1", "#text": "Loi n°90-1129 du 19 décembre 1990 - art. 1 () JORF 22 décembre 1990 en vigueur le 1er décembre 1991", "@sens": "source", "@cidtexte": "JORFTEXT000000709335", "@nortexte": "EQUX9000054L", "@numtexte": "90-1129", "@typelien": "MODIFICATION", "@naturetexte": "LOI", "@datesignatexte": "1990-12-19" }, { "@id": "LEGIARTI000006739977", "@num": "1", "#text": "Décret n°99-776 du 8 septembre 1999 - art. 1 (Ab)", "@sens": "cible", "@cidtexte": "JORFTEXT000000396628", "@nortexte": "ECOT9914031D", "@numtexte": "99-776", "@typelien": "CITATION", "@naturetexte": "DECRET", "@datesignatexte": "1999-09-08" }, { "@id": "LEGITEXT000050742475", "#text": "Arrêté du 3 décembre 2024 (V)", "@sens": "cible", "@cidtexte": "JORFTEXT000050731883", "@nortexte": "LRUL2422852A", "@typelien": "CITATION", "@naturetexte": "ARRETE", "@datesignatexte": "2024-12-03" }, { "@id": "LEGIARTI000006795972", "@num": "L242-1", "#text": "Code des assurances - art. L242-1 (V)", "@sens": "source", "@cidtexte": "LEGITEXT000006073984", "@typelien": "CITATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000006824172", "@num": "L111-23", "#text": "Code de la construction et de l'habitation. - art. L111-23 (V)", "@sens": "source", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CITATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000041586868", "@num": "L231-1", "#text": "Code de la construction et de l'habitation. - art. L231-1 (VD)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CITATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000006824510", "@num": "L231-1-1", "#text": "Code de la construction et de l'habitation. - art. L231-1-1 (Ab)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CITATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000006824501", "@num": "L231-10", "#text": "Code de la construction et de l'habitation. - art. L231-10 (V)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CITATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000006824502", "@num": "L231-11", "#text": "Code de la construction et de l'habitation. - art. L231-11 (V)", "@sens": "source", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CITATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000038433486", "@num": "L231-6", "#text": "Code de la construction et de l'habitation. - art. L231-6 (VD)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CITATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000006824498", "@num": "L231-7", "#text": "Code de la construction et de l'habitation. - art. L231-7 (V)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CITATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000006824507", "@num": "L232-2", "#text": "Code de la construction et de l'habitation. - art. L232-2 (V)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CITATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000006824514", "@num": "L241-1", "#text": "Code de la construction et de l'habitation. - art. L241-1 (M)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CITATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000006824660", "@num": "L241-3", "#text": "Code de la construction et de l'habitation. - art. L241-3 (M)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CITATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000006824538", "@num": "L242-2", "#text": "Code de la construction et de l'habitation. - art. L242-2 (V)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CITATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000006896534", "@num": "R*231-1", "#text": "Code de la construction et de l'habitation. - art. R*231-1 (M)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CITATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000006896543", "@num": "R*231-7", "#text": "Code de la construction et de l'habitation. - art. R*231-7 (M)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CITATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000039041705", "@num": "R231-13", "#text": "Code de la construction et de l'habitation. - art. R231-13 (VD)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CITATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000039041701", "@num": "R231-14", "#text": "Code de la construction et de l'habitation. - art. R231-14 (VD)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CITATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000039041754", "@num": "R231-2", "#text": "Code de la construction et de l'habitation. - art. R231-2 (VD)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CITATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000039041749", "@num": "R231-3", "#text": "Code de la construction et de l'habitation. - art. R231-3 (VD)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CITATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000039041744", "@num": "R231-4", "#text": "Code de la construction et de l'habitation. - art. R231-4 (VD)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CITATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000039041740", "@num": "R231-5", "#text": "Code de la construction et de l'habitation. - art. R231-5 (VD)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CITATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000006821757", "@num": "R421-24-3", "#text": "Code des assurances - art. R421-24-3 (Ab)", "@sens": "cible", "@cidtexte": "LEGITEXT000006073984", "@typelien": "CITATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000033655931", "@num": "D313-26", "#text": "Code monétaire et financier - art. D313-26 (VD)", "@sens": "cible", "@cidtexte": "LEGITEXT000006072026", "@typelien": "CITATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" } ] }, "CONTEXTE": { "TEXTE": { "TM": { "TM": { "TM": { "TM": { "TITRE_TM": [ { "@id": "LEGISCTA000006159020", "@fin": "2999-01-01", "#text": "Chapitre Ier : Contrat de construction d'une maison individuelle avec fourniture du plan.", "@debut": "1991-12-01" } ] }, "TITRE_TM": [ { "@id": "LEGISCTA000006143526", "@fin": "2999-01-01", "#text": "Titre III : Construction d'une maison individuelle.", "@debut": "1991-12-01" } ] }, "TITRE_TM": [ { "@id": "LEGISCTA000006128681", "@fin": "2999-01-01", "#text": "Livre II : Statut des constructeurs.", "@debut": "1978-06-08" } ] }, "TITRE_TM": [ { "@id": "LEGISCTA000006108136", "@fin": "2999-01-01", "#text": "Partie législative", "@debut": "1978-06-08" } ] }, "@cid": "LEGITEXT000006074096", "@nature": "CODE", "TITRE_TXT": [ { "@fin": "2999-01-01", "#text": "Code de la construction et de l'habitation", "@debut": "1977-03-10", "@id_txt": "LEGITEXT000006074096", "@c_titre_court": "Code de la construction et de l'habitation." } ], "@date_publi": "2999-01-01", "@date_signature": "2999-01-01" } }, "VERSIONS": { "VERSION": [ { "@etat": "MODIFIE", "LIEN_ART": { "@id": "LEGIARTI000006824657", "@fin": "1979-07-14", "@num": "L231-2", "@etat": "MODIFIE", "@debut": "1978-06-08", "@origine": "LEGI" } }, { "@etat": "MODIFIE", "LIEN_ART": { "@id": "LEGIARTI000006824658", "@fin": "1991-12-01", "@num": "L231-2", "@etat": "MODIFIE", "@debut": "1979-07-14", "@origine": "LEGI" } }, { "@etat": "MODIFIE", "LIEN_ART": { "@id": "LEGIARTI000006824659", "@fin": "2018-11-25", "@num": "L231-2", "@etat": "MODIFIE", "@debut": "1991-12-01", "@origine": "LEGI" } }, { "@etat": "MODIFIE", "LIEN_ART": { "@id": "LEGIARTI000037667723", "@fin": "2020-02-01", "@num": "L231-2", "@etat": "MODIFIE", "@debut": "2018-11-25", "@origine": "LEGI" } }, { "@etat": "MODIFIE", "LIEN_ART": { "@id": "LEGIARTI000038433496", "@fin": "2021-07-01", "@num": "L231-2", "@etat": "MODIFIE", "@debut": "2020-02-01", "@origine": "LEGI" } }, { "@etat": "VIGUEUR", "LIEN_ART": { "@id": "LEGIARTI000041586856", "@fin": "2999-01-01", "@num": "L231-2", "@etat": "VIGUEUR", "@debut": "2021-07-01", "@origine": "LEGI" } } ] }, "BLOC_TEXTUEL": { "CONTENU": "
Le contrat visé à l'article L. 231-1 doit comporter les énonciations suivantes :
\n
a) La désignation du terrain destiné à l'implantation de la construction et la mention du titre de propriété du maître de l'ouvrage ou des droits réels lui permettant de construire ;
\n
b) L'affirmation de la conformité du projet aux règles de construction prescrites en application du présent code, notamment de son livre Ier, et du code de l'urbanisme ;
\n
c) La consistance et les caractéristiques techniques du bâtiment à construire comportant tous les travaux d'adaptation au sol, les raccordements aux réseaux divers et tous les travaux d'équipement intérieur ou extérieur indispensables à l'implantation et à l'utilisation de l'immeuble ;
\n
d) Le coût du bâtiment à construire, égal à la somme du prix convenu et, s'il y a lieu, du coût des travaux dont le maître de l'ouvrage se réserve l'exécution en précisant :
\n
-d'une part, le prix convenu qui est forfaitaire et définitif, sous réserve, s'il y a lieu, de sa révision dans les conditions et limites convenues conformément à l'article L. 231-11, et qui comporte la rémunération de tout ce qui est à la charge du constructeur, y compris le coût de la garantie de livraison ;
\n
-d'autre part, le coût des travaux dont le maître de l'ouvrage se réserve l'exécution, ceux-ci étant décrits et chiffrés par le constructeur et faisant l'objet, de la part du maître de l'ouvrage, d'une clause manuscrite spécifique et paraphée par laquelle il en accepte le coût et la charge ;
\n
e) Les modalités de règlement en fonction de l'état d'avancement des travaux ;
\n
f) L'indication que le maître de l'ouvrage pourra se faire assister par un professionnel habilité en application de la loi n° 77-2 du 3 janvier 1977 sur l'architecture ou des articles L. 111-23 et suivants lors de la réception ou par tout autre professionnel de la construction titulaire d'un contrat d'assurance couvrant les responsabilités pour ce type de mission ;
\n
g) L'indication de l'obtention du permis de construire et des autres autorisations administratives, dont une copie est annexée au contrat ;
\n
h) L'indication des modalités de financement, la nature et le montant des prêts obtenus et acceptés par le maître de l'ouvrage ;
\n
i) La date d'ouverture du chantier, le délai d'exécution des travaux et les pénalités prévues en cas de retard de livraison ;
\n
j) La référence de l'assurance de dommages souscrite par le maître de l'ouvrage, en application de l'article L. 242-1 du code des assurances ;
\n
k) Les justifications des garanties de remboursement et de livraison apportées par le constructeur, les attestations de ces garanties étant établies par le garant et annexées au contrat.
\n
Les stipulations du contrat, notamment celles relatives aux travaux à la charge du constructeur, au prix convenu, au délai d'exécution des travaux et aux pénalités applicables en cas de retard d'exécution peuvent se référer à des clauses types approuvées par décret en Conseil d'Etat.
" } }, "LEGIARTI000037667723": { "META": { "META_SPEC": { "META_ARTICLE": { "NUM": "L231-2", "ETAT": "MODIFIE", "TYPE": "AUTONOME", "DATE_FIN": "2020-02-01", "DATE_DEBUT": "2018-11-25" } }, "META_COMMUN": { "ID": "LEGIARTI000037667723", "URL": "article/LEGI/ARTI/00/00/37/66/77/LEGIARTI000037667723.xml", "NATURE": "Article", "ORIGINE": "LEGI" } }, "LIENS": { "LIEN": [ { "@id": "JORFTEXT000000687668", "#text": "Loi 71-579 1971-07-16 art. 45 al. 2 à 6", "@sens": "source", "@cidtexte": "JORFTEXT000000687668", "@numtexte": "71-579", "@typelien": "CONCORDANCE", "@naturetexte": "LOI", "@datesignatexte": "1971-07-16" }, { "@id": "LEGIARTI000006826382", "@num": "45", "#text": "Loi n°71-579 du 16 juillet 1971 - art. 45 (Ab)", "@sens": "cible", "@cidtexte": "JORFTEXT000000687668", "@numtexte": "71-579", "@typelien": "CONCORDE", "@naturetexte": "LOI", "@datesignatexte": "1971-07-16" }, { "@id": "JORFTEXT000000522423", "#text": "LOI n° 77-2 du 3 janvier 1977", "@sens": "source", "@cidtexte": "JORFTEXT000000522423", "@numtexte": "77-2", "@typelien": "CITATION", "@naturetexte": "LOI", "@datesignatexte": "1977-01-03" }, { "@id": "JORFTEXT000000516442", "#text": "Décret n° 78-621 du 31 mai 1978", "@sens": "source", "@cidtexte": "JORFTEXT000000516442", "@numtexte": "78-621", "@typelien": "CODIFICATION", "@naturetexte": "DECRET", "@datesignatexte": "1978-05-31" }, { "@id": "LEGIARTI000006829601", "@num": "9", "#text": "Arrêté du 30 décembre 1988 - art. 9 (V)", "@sens": "cible", "@cidtexte": "JORFTEXT000000873773", "@nortexte": "EQUC8800886A", "@typelien": "CITATION", "@naturetexte": "ARRETE", "@datesignatexte": "1988-12-30" }, { "@id": "LEGIARTI000006739977", "@num": "1", "#text": "Décret n°99-776 du 8 septembre 1999 - art. 1 (Ab)", "@sens": "cible", "@cidtexte": "JORFTEXT000000396628", "@nortexte": "ECOT9914031D", "@numtexte": "99-776", "@typelien": "CITATION", "@naturetexte": "DECRET", "@datesignatexte": "1999-09-08" }, { "@id": "LEGIARTI000037642281", "@num": "68", "#text": "LOI n°2018-1021 du 23 novembre 2018 - art. 68", "@sens": "cible", "@cidtexte": "JORFTEXT000037639478", "@nortexte": "TERL1805474L", "@numtexte": "2018-1021", "@typelien": "MODIFIE", "@naturetexte": "LOI", "@datesignatexte": "2018-11-23" }, { "@id": "LEGITEXT000050742475", "#text": "Arrêté du 3 décembre 2024 (V)", "@sens": "cible", "@cidtexte": "JORFTEXT000050731883", "@nortexte": "LRUL2422852A", "@typelien": "CITATION", "@naturetexte": "ARRETE", "@datesignatexte": "2024-12-03" }, { "@id": "LEGIARTI000006795972", "@num": "L242-1", "#text": "Code des assurances - art. L242-1", "@sens": "source", "@cidtexte": "LEGITEXT000006073984", "@typelien": "CITATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000006824172", "@num": "L111-23", "#text": "Code de la construction et de l'habitation. - art. L111-23", "@sens": "source", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CITATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000041586868", "@num": "L231-1", "#text": "Code de la construction et de l'habitation. - art. L231-1 (VD)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CITATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000006824510", "@num": "L231-1-1", "#text": "Code de la construction et de l'habitation. - art. L231-1-1 (Ab)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CITATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000006824501", "@num": "L231-10", "#text": "Code de la construction et de l'habitation. - art. L231-10 (V)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CITATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000006824502", "@num": "L231-11", "#text": "Code de la construction et de l'habitation. - art. L231-11", "@sens": "source", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CITATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000038433486", "@num": "L231-6", "#text": "Code de la construction et de l'habitation. - art. L231-6 (VD)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CITATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000006824498", "@num": "L231-7", "#text": "Code de la construction et de l'habitation. - art. L231-7 (V)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CITATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000006824507", "@num": "L232-2", "#text": "Code de la construction et de l'habitation. - art. L232-2 (V)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CITATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000006824514", "@num": "L241-1", "#text": "Code de la construction et de l'habitation. - art. L241-1 (M)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CITATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000006824660", "@num": "L241-3", "#text": "Code de la construction et de l'habitation. - art. L241-3 (M)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CITATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000006824538", "@num": "L242-2", "#text": "Code de la construction et de l'habitation. - art. L242-2 (V)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CITATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000006896534", "@num": "R*231-1", "#text": "Code de la construction et de l'habitation. - art. R*231-1 (M)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CITATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000006896543", "@num": "R*231-7", "#text": "Code de la construction et de l'habitation. - art. R*231-7 (M)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CITATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000039041705", "@num": "R231-13", "#text": "Code de la construction et de l'habitation. - art. R231-13 (VD)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CITATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000039041701", "@num": "R231-14", "#text": "Code de la construction et de l'habitation. - art. R231-14 (VD)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CITATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000039041754", "@num": "R231-2", "#text": "Code de la construction et de l'habitation. - art. R231-2 (VD)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CITATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000039041749", "@num": "R231-3", "#text": "Code de la construction et de l'habitation. - art. R231-3 (VD)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CITATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000039041744", "@num": "R231-4", "#text": "Code de la construction et de l'habitation. - art. R231-4 (VD)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CITATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000039041740", "@num": "R231-5", "#text": "Code de la construction et de l'habitation. - art. R231-5 (VD)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CITATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000006821757", "@num": "R421-24-3", "#text": "Code des assurances - art. R421-24-3 (Ab)", "@sens": "cible", "@cidtexte": "LEGITEXT000006073984", "@typelien": "CITATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000033655931", "@num": "D313-26", "#text": "Code monétaire et financier - art. D313-26 (VD)", "@sens": "cible", "@cidtexte": "LEGITEXT000006072026", "@typelien": "CITATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" } ] }, "CONTEXTE": { "TEXTE": { "TM": { "TM": { "TM": { "TM": { "TITRE_TM": [ { "@id": "LEGISCTA000006159020", "@fin": "2999-01-01", "#text": "Chapitre Ier : Contrat de construction d'une maison individuelle avec fourniture du plan.", "@debut": "1991-12-01" } ] }, "TITRE_TM": [ { "@id": "LEGISCTA000006143526", "@fin": "2999-01-01", "#text": "Titre III : Construction d'une maison individuelle.", "@debut": "1991-12-01" } ] }, "TITRE_TM": [ { "@id": "LEGISCTA000006128681", "@fin": "2999-01-01", "#text": "Livre II : Statut des constructeurs.", "@debut": "1978-06-08" } ] }, "TITRE_TM": [ { "@id": "LEGISCTA000006108136", "@fin": "2999-01-01", "#text": "Partie législative", "@debut": "1978-06-08" } ] }, "@cid": "LEGITEXT000006074096", "@nature": "CODE", "TITRE_TXT": [ { "@fin": "2999-01-01", "#text": "Code de la construction et de l'habitation", "@debut": "1977-03-10", "@id_txt": "LEGITEXT000006074096", "@c_titre_court": "Code de la construction et de l'habitation." } ], "@date_publi": "2999-01-01", "@date_signature": "2999-01-01" } }, "VERSIONS": { "VERSION": [ { "@etat": "MODIFIE", "LIEN_ART": { "@id": "LEGIARTI000006824657", "@fin": "1979-07-14", "@num": "L231-2", "@etat": "MODIFIE", "@debut": "1978-06-08", "@origine": "LEGI" } }, { "@etat": "MODIFIE", "LIEN_ART": { "@id": "LEGIARTI000006824658", "@fin": "1991-12-01", "@num": "L231-2", "@etat": "MODIFIE", "@debut": "1979-07-14", "@origine": "LEGI" } }, { "@etat": "MODIFIE", "LIEN_ART": { "@id": "LEGIARTI000006824659", "@fin": "2018-11-25", "@num": "L231-2", "@etat": "MODIFIE", "@debut": "1991-12-01", "@origine": "LEGI" } }, { "@etat": "MODIFIE", "LIEN_ART": { "@id": "LEGIARTI000037667723", "@fin": "2020-02-01", "@num": "L231-2", "@etat": "MODIFIE", "@debut": "2018-11-25", "@origine": "LEGI" } }, { "@etat": "MODIFIE", "LIEN_ART": { "@id": "LEGIARTI000038433496", "@fin": "2021-07-01", "@num": "L231-2", "@etat": "MODIFIE", "@debut": "2020-02-01", "@origine": "LEGI" } }, { "@etat": "VIGUEUR", "LIEN_ART": { "@id": "LEGIARTI000041586856", "@fin": "2999-01-01", "@num": "L231-2", "@etat": "VIGUEUR", "@debut": "2021-07-01", "@origine": "LEGI" } } ] }, "BLOC_TEXTUEL": { "CONTENU": "

Le contrat visé à l'article L. 231-1 doit comporter les énonciations suivantes :

a) La désignation du terrain destiné à l'implantation de la construction et la mention du titre de propriété du maître de l'ouvrage ou des droits réels lui permettant de construire ;

b) L'affirmation de la conformité du projet aux règles de construction prescrites en application du présent code, notamment de son livre Ier, et du code de l'urbanisme ;

c) La consistance et les caractéristiques techniques du bâtiment à construire comportant :

-tous les travaux d'adaptation au sol, notamment, le cas échéant, ceux rendus nécessaires par l'étude géotechnique mentionnée aux articles L. 112-22 et L. 112-23 du présent code, dont une copie est annexée au contrat ;
\n-les raccordements aux réseaux divers ;
\n-tous les travaux d'équipement intérieur ou extérieur indispensables à l'implantation et à l'utilisation de l'immeuble ;

d) Le coût du bâtiment à construire, égal à la somme du prix convenu et, s'il y a lieu, du coût des travaux dont le maître de l'ouvrage se réserve l'exécution en précisant :

-d'une part, le prix convenu qui est forfaitaire et définitif, sous réserve, s'il y a lieu, de sa révision dans les conditions et limites convenues conformément à l'article L. 231-11, et qui comporte la rémunération de tout ce qui est à la charge du constructeur, y compris le coût de la garantie de livraison ;

-d'autre part, le coût des travaux dont le maître de l'ouvrage se réserve l'exécution, ceux-ci étant décrits et chiffrés par le constructeur et faisant l'objet, de la part du maître de l'ouvrage, d'une clause manuscrite spécifique et paraphée par laquelle il en accepte le coût et la charge ;

e) Les modalités de règlement en fonction de l'état d'avancement des travaux ;

f) L'indication que le maître de l'ouvrage pourra se faire assister par un professionnel habilité en application de la loi n° 77-2 du 3 janvier 1977 sur l'architecture ou des articles L. 111-23 et suivants lors de la réception ou par tout autre professionnel de la construction titulaire d'un contrat d'assurance couvrant les responsabilités pour ce type de mission ;

g) L'indication de l'obtention du permis de construire et des autres autorisations administratives, dont une copie est annexée au contrat ;

h) L'indication des modalités de financement, la nature et le montant des prêts obtenus et acceptés par le maître de l'ouvrage ;

i) La date d'ouverture du chantier, le délai d'exécution des travaux et les pénalités prévues en cas de retard de livraison ;

j) La référence de l'assurance de dommages souscrite par le maître de l'ouvrage, en application de l'article L. 242-1 du code des assurances ;

k) Les justifications des garanties de remboursement et de livraison apportées par le constructeur, les attestations de ces garanties étant établies par le garant et annexées au contrat.

" } }, "LEGIARTI000038433496": { "META": { "META_SPEC": { "META_ARTICLE": { "NUM": "L231-2", "ETAT": "MODIFIE", "TYPE": "AUTONOME", "DATE_FIN": "2021-07-01", "DATE_DEBUT": "2020-02-01" } }, "META_COMMUN": { "ID": "LEGIARTI000038433496", "URL": "article/LEGI/ARTI/00/00/38/43/34/LEGIARTI000038433496.xml", "NATURE": "Article", "ORIGINE": "LEGI" } }, "NOTA": { "CONTENU": "

Conformément à l'article 2 de l'ordonnance n° 2019-395 du 30 avril 2019, les présentes dispositions s'appliquent aux contrats conclus à compter du premier jour du troisième mois suivant la publication du décret prévu à l'article L. 242-2 du code de la construction et de l'habitation, dans sa rédaction issue du 4° de l'article 1er de la présente ordonnance et au plus tard à compter du premier jour du neuvième mois suivant celui de la publication de la présente ordonnance au Journal officiel de la République française.

" }, "LIENS": { "LIEN": [ { "@id": "JORFTEXT000000687668", "#text": "Loi 71-579 1971-07-16 art. 45 al. 2 à 6", "@sens": "source", "@cidtexte": "JORFTEXT000000687668", "@numtexte": "71-579", "@typelien": "CONCORDANCE", "@naturetexte": "LOI", "@datesignatexte": "1971-07-16" }, { "@id": "LEGIARTI000006826382", "@num": "45", "#text": "Loi n°71-579 du 16 juillet 1971 - art. 45 (Ab)", "@sens": "cible", "@cidtexte": "JORFTEXT000000687668", "@numtexte": "71-579", "@typelien": "CONCORDE", "@naturetexte": "LOI", "@datesignatexte": "1971-07-16" }, { "@id": "JORFTEXT000000522423", "#text": "LOI n° 77-2 du 3 janvier 1977", "@sens": "source", "@cidtexte": "JORFTEXT000000522423", "@numtexte": "77-2", "@typelien": "CITATION", "@naturetexte": "LOI", "@datesignatexte": "1977-01-03" }, { "@id": "JORFTEXT000000516442", "#text": "Décret n° 78-621 du 31 mai 1978", "@sens": "source", "@cidtexte": "JORFTEXT000000516442", "@numtexte": "78-621", "@typelien": "CODIFICATION", "@naturetexte": "DECRET", "@datesignatexte": "1978-05-31" }, { "@id": "LEGIARTI000006829601", "@num": "9", "#text": "Arrêté du 30 décembre 1988 - art. 9 (V)", "@sens": "cible", "@cidtexte": "JORFTEXT000000873773", "@nortexte": "EQUC8800886A", "@typelien": "CITATION", "@naturetexte": "ARRETE", "@datesignatexte": "1988-12-30" }, { "@id": "LEGIARTI000006739977", "@num": "1", "#text": "Décret n°99-776 du 8 septembre 1999 - art. 1 (Ab)", "@sens": "cible", "@cidtexte": "JORFTEXT000000396628", "@nortexte": "ECOT9914031D", "@numtexte": "99-776", "@typelien": "CITATION", "@naturetexte": "DECRET", "@datesignatexte": "1999-09-08" }, { "@id": "LEGIARTI000038432548", "@num": "1", "#text": "Ordonnance n° 2019-395 du 30 avril 2019 - art. 1", "@sens": "cible", "@cidtexte": "JORFTEXT000038431584", "@nortexte": "TERL1908590R", "@numtexte": "2019-395", "@typelien": "MODIFIE", "@naturetexte": "ORDONNANCE", "@datesignatexte": "2019-04-30" }, { "@id": "LEGITEXT000050742475", "#text": "Arrêté du 3 décembre 2024 (V)", "@sens": "cible", "@cidtexte": "JORFTEXT000050731883", "@nortexte": "LRUL2422852A", "@typelien": "CITATION", "@naturetexte": "ARRETE", "@datesignatexte": "2024-12-03" }, { "@id": "LEGIARTI000006795972", "@num": "L242-1", "#text": "Code des assurances - art. L242-1", "@sens": "source", "@cidtexte": "LEGITEXT000006073984", "@typelien": "CITATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000037644962", "@num": "L111-1-1", "#text": "Code de la construction et de l'habitation. - art. L111-1-1", "@sens": "source", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CITATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000006824172", "@num": "L111-23", "#text": "Code de la construction et de l'habitation. - art. L111-23", "@sens": "source", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CITATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000037645136", "@num": "L112-22", "#text": "Code de la construction et de l'habitation. - art. L112-22", "@sens": "source", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CITATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000041586868", "@num": "L231-1", "#text": "Code de la construction et de l'habitation. - art. L231-1 (VD)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CITATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000006824510", "@num": "L231-1-1", "#text": "Code de la construction et de l'habitation. - art. L231-1-1 (Ab)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CITATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000006824501", "@num": "L231-10", "#text": "Code de la construction et de l'habitation. - art. L231-10 (V)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CITATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000006824502", "@num": "L231-11", "#text": "Code de la construction et de l'habitation. - art. L231-11", "@sens": "source", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CITATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000038433486", "@num": "L231-6", "#text": "Code de la construction et de l'habitation. - art. L231-6 (VD)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CITATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000006824498", "@num": "L231-7", "#text": "Code de la construction et de l'habitation. - art. L231-7 (V)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CITATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000006824507", "@num": "L232-2", "#text": "Code de la construction et de l'habitation. - art. L232-2 (V)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CITATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000006824514", "@num": "L241-1", "#text": "Code de la construction et de l'habitation. - art. L241-1 (M)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CITATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000006824660", "@num": "L241-3", "#text": "Code de la construction et de l'habitation. - art. L241-3 (M)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CITATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000038433476", "@num": "L242-2", "#text": "Code de la construction et de l'habitation. - art. L242-2 (VD)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CITATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000006896534", "@num": "R*231-1", "#text": "Code de la construction et de l'habitation. - art. R*231-1 (M)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CITATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000006896543", "@num": "R*231-7", "#text": "Code de la construction et de l'habitation. - art. R*231-7 (M)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CITATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000039041705", "@num": "R231-13", "#text": "Code de la construction et de l'habitation. - art. R231-13 (VD)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CITATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000039041701", "@num": "R231-14", "#text": "Code de la construction et de l'habitation. - art. R231-14 (VD)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CITATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000039041754", "@num": "R231-2", "#text": "Code de la construction et de l'habitation. - art. R231-2 (VD)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CITATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000039041749", "@num": "R231-3", "#text": "Code de la construction et de l'habitation. - art. R231-3 (VD)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CITATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000039041744", "@num": "R231-4", "#text": "Code de la construction et de l'habitation. - art. R231-4 (VD)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CITATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000039041740", "@num": "R231-5", "#text": "Code de la construction et de l'habitation. - art. R231-5 (VD)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CITATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000006821757", "@num": "R421-24-3", "#text": "Code des assurances - art. R421-24-3 (Ab)", "@sens": "cible", "@cidtexte": "LEGITEXT000006073984", "@typelien": "CITATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000033655931", "@num": "D313-26", "#text": "Code monétaire et financier - art. D313-26 (VD)", "@sens": "cible", "@cidtexte": "LEGITEXT000006072026", "@typelien": "CITATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" } ] }, "CONTEXTE": { "TEXTE": { "TM": { "TM": { "TM": { "TM": { "TITRE_TM": [ { "@id": "LEGISCTA000006159020", "@fin": "2999-01-01", "#text": "Chapitre Ier : Contrat de construction d'une maison individuelle avec fourniture du plan.", "@debut": "1991-12-01" } ] }, "TITRE_TM": [ { "@id": "LEGISCTA000006143526", "@fin": "2999-01-01", "#text": "Titre III : Construction d'une maison individuelle.", "@debut": "1991-12-01" } ] }, "TITRE_TM": [ { "@id": "LEGISCTA000006128681", "@fin": "2999-01-01", "#text": "Livre II : Statut des constructeurs.", "@debut": "1978-06-08" } ] }, "TITRE_TM": [ { "@id": "LEGISCTA000006108136", "@fin": "2999-01-01", "#text": "Partie législative", "@debut": "1978-06-08" } ] }, "@cid": "LEGITEXT000006074096", "@nature": "CODE", "TITRE_TXT": [ { "@fin": "2999-01-01", "#text": "Code de la construction et de l'habitation", "@debut": "1977-03-10", "@id_txt": "LEGITEXT000006074096", "@c_titre_court": "Code de la construction et de l'habitation." } ], "@date_publi": "2999-01-01", "@date_signature": "2999-01-01" } }, "VERSIONS": { "VERSION": [ { "@etat": "MODIFIE", "LIEN_ART": { "@id": "LEGIARTI000006824657", "@fin": "1979-07-14", "@num": "L231-2", "@etat": "MODIFIE", "@debut": "1978-06-08", "@origine": "LEGI" } }, { "@etat": "MODIFIE", "LIEN_ART": { "@id": "LEGIARTI000006824658", "@fin": "1991-12-01", "@num": "L231-2", "@etat": "MODIFIE", "@debut": "1979-07-14", "@origine": "LEGI" } }, { "@etat": "MODIFIE", "LIEN_ART": { "@id": "LEGIARTI000006824659", "@fin": "2018-11-25", "@num": "L231-2", "@etat": "MODIFIE", "@debut": "1991-12-01", "@origine": "LEGI" } }, { "@etat": "MODIFIE", "LIEN_ART": { "@id": "LEGIARTI000037667723", "@fin": "2020-02-01", "@num": "L231-2", "@etat": "MODIFIE", "@debut": "2018-11-25", "@origine": "LEGI" } }, { "@etat": "MODIFIE", "LIEN_ART": { "@id": "LEGIARTI000038433496", "@fin": "2021-07-01", "@num": "L231-2", "@etat": "MODIFIE", "@debut": "2020-02-01", "@origine": "LEGI" } }, { "@etat": "VIGUEUR", "LIEN_ART": { "@id": "LEGIARTI000041586856", "@fin": "2999-01-01", "@num": "L231-2", "@etat": "VIGUEUR", "@debut": "2021-07-01", "@origine": "LEGI" } } ] }, "BLOC_TEXTUEL": { "CONTENU": "

Le contrat visé à l'article L. 231-1 doit comporter les énonciations suivantes :

a) La désignation du terrain destiné à l'implantation de la construction et la mention du titre de propriété du maître de l'ouvrage ou des droits réels lui permettant de construire ;

b) L'affirmation de la conformité du projet aux règles de construction prescrites en application du présent code, notamment de son livre Ier, et du code de l'urbanisme ;

c) La consistance et les caractéristiques techniques du bâtiment à construire comportant :

-tous les travaux d'adaptation au sol, notamment, le cas échéant, ceux rendus nécessaires par l'étude géotechnique mentionnée aux articles L. 112-22 et L. 112-23 du présent code, dont une copie est annexée au contrat ;
-les raccordements aux réseaux divers ;
-tous les travaux d'équipement intérieur ou extérieur indispensables à l'implantation et à l'utilisation de l'immeuble ;

d) Le coût du bâtiment à construire, égal à la somme du prix convenu et, s'il y a lieu, du coût des travaux dont le maître de l'ouvrage se réserve l'exécution en précisant :

e) Les modalités de règlement en fonction de l'état d'avancement des travaux ;

g) L'indication de l'obtention du permis de construire et des autres autorisations administratives, dont une copie est annexée au contrat ;

h) L'indication des modalités de financement, la nature et le montant des prêts obtenus et acceptés par le maître de l'ouvrage ;

i) La date d'ouverture du chantier, le délai d'exécution des travaux et les pénalités prévues en cas de retard de livraison ;

j) La référence de l'assurance de dommages souscrite par le maître de l'ouvrage, en application de l'article L. 242-1 du code des assurances ;

k) Les justifications des garanties de remboursement et de livraison apportées par le constructeur, les attestations de ces garanties étant établies par le garant et annexées au contrat.

Lorsque le constructeur assure la fabrication, la pose et l'assemblage sur le chantier d'éléments préfabriqués dans les conditions définies à l'article L. 111-1-1, le contrat précise en outre la description et les caractéristiques des éléments préfabriqués, ainsi que les modalités selon lesquelles le maître de l'ouvrage est informé de l'achèvement et de la bonne exécution de la fabrication de ces éléments.

Dans le cas prévu au précédent alinéa, les modalités de règlement mentionnées au contrat, en vertu du e de l'article L. 231-2, tiennent compte de l'état d'avancement des travaux de construction et de l'achèvement de la fabrication des éléments préfabriqués.

Les stipulations du contrat, notamment celles relatives aux travaux à la charge du constructeur, au prix convenu, au délai d'exécution des travaux et aux pénalités applicables en cas de retard d'exécution, ainsi que celles relatives aux modalités selon lesquelles le maître de l'ouvrage est informé de l'achèvement et de la bonne exécution de la fabrication des éléments préfabriqués, peuvent se référer à des clauses types approuvées par décret en Conseil d'Etat.

" } }, "LEGIARTI000038955628": { "META": { "META_SPEC": { "META_ARTICLE": { "NUM": "4", "TYPE": "ENTIEREMENT_MODIF", "DATE_FIN": "2999-01-01", "DATE_DEBUT": "2999-01-01" } }, "META_COMMUN": { "ID": "LEGIARTI000038955628", "URL": "article/LEGI/ARTI/00/00/38/95/56/LEGIARTI000038955628.xml", "NATURE": "Article", "ORIGINE": "LEGI" } }, "LIENS": { "LIEN": [ { "@id": "LEGIARTI000039040680", "@num": "D361-4", "#text": "Code de la construction et de l'habitation. - art. D361-4 (VD)", "@sens": "source", "@cidtexte": "LEGITEXT000006074096", "@typelien": "MODIFIE", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000039040680", "@num": "D361-4", "#text": "Code de la construction et de l'habitation. - art. D361-4 (VD)", "@sens": "source", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CREE", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000039040680", "@num": "D361-4", "#text": "Code de la construction et de l'habitation. - art. D361-4 (VD)", "@sens": "source", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CONCORDE", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000037775650", "@num": "D481-5-8", "#text": "Code de la construction et de l'habitation. - art. D481-5-8 (T)", "@sens": "source", "@cidtexte": "LEGITEXT000006074096", "@typelien": "TRANSFERE", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000034354480", "@num": "D511-13-1", "#text": "Code de la construction et de l'habitation. - art. D511-13-1 (T)", "@sens": "source", "@cidtexte": "LEGITEXT000006074096", "@typelien": "TRANSFERE", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000039043475", "@num": "D522-1", "#text": "Code de la construction et de l'habitation. - art. D522-1 (VD)", "@sens": "source", "@cidtexte": "LEGITEXT000006074096", "@typelien": "MODIFIE", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000039043473", "@num": "D522-2", "#text": "Code de la construction et de l'habitation. - art. D522-2 (VD)", "@sens": "source", "@cidtexte": "LEGITEXT000006074096", "@typelien": "MODIFIE", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000039043471", "@num": "D522-3", "#text": "Code de la construction et de l'habitation. - art. D522-3 (VD)", "@sens": "source", "@cidtexte": "LEGITEXT000006074096", "@typelien": "MODIFIE", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000039043469", "@num": "D522-5", "#text": "Code de la construction et de l'habitation. - art. D522-5 (VD)", "@sens": "source", "@cidtexte": "LEGITEXT000006074096", "@typelien": "MODIFIE", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000039041461", "@num": "R111-1-1", "#text": "Code de la construction et de l'habitation. - art. R111-1-1 (Ab)", "@sens": "source", "@cidtexte": "LEGITEXT000006074096", "@typelien": "MODIFIE", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000039041419", "@num": "R111-10", "#text": "Code de la construction et de l'habitation. - art. R111-10 (Ab)", "@sens": "source", "@cidtexte": "LEGITEXT000006074096", "@typelien": "MODIFIE", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000039041413", "@num": "R111-11", "#text": "Code de la construction et de l'habitation. - art. R111-11 (Ab)", "@sens": "source", "@cidtexte": "LEGITEXT000006074096", "@typelien": "MODIFIE", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000039041407", "@num": "R111-12", "#text": "Code de la construction et de l'habitation. - art. R111-12 (Ab)", "@sens": "source", "@cidtexte": "LEGITEXT000006074096", "@typelien": "MODIFIE", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000039041401", "@num": "R111-13", "#text": "Code de la construction et de l'habitation. - art. R111-13 (Ab)", "@sens": "source", "@cidtexte": "LEGITEXT000006074096", "@typelien": "MODIFIE", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000039041396", "@num": "R111-14-1", "#text": "Code de la construction et de l'habitation. - art. R111-14-1 (Ab)", "@sens": "source", "@cidtexte": "LEGITEXT000006074096", "@typelien": "MODIFIE", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000039041391", "@num": "R111-15", "#text": "Code de la construction et de l'habitation. - art. R111-15 (Ab)", "@sens": "source", "@cidtexte": "LEGITEXT000006074096", "@typelien": "MODIFIE", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000039041376", "@num": "R111-16", "#text": "Code de la construction et de l'habitation. - art. R111-16 (Ab)", "@sens": "source", "@cidtexte": "LEGITEXT000006074096", "@typelien": "MODIFIE", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000039041369", "@num": "R111-17", "#text": "Code de la construction et de l'habitation. - art. R111-17 (Ab)", "@sens": "source", "@cidtexte": "LEGITEXT000006074096", "@typelien": "MODIFIE", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000039041363", "@num": "R111-18", "#text": "Code de la construction et de l'habitation. - art. R111-18 (Ab)", "@sens": "source", "@cidtexte": "LEGITEXT000006074096", "@typelien": "MODIFIE", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000039041357", "@num": "R111-18-1", "#text": "Code de la construction et de l'habitation. - art. R111-18-1 (Ab)", "@sens": "source", "@cidtexte": "LEGITEXT000006074096", "@typelien": "MODIFIE", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000039041273", "@num": "R111-18-10", "#text": "Code de la construction et de l'habitation. - art. R111-18-10 (Ab)", "@sens": "source", "@cidtexte": "LEGITEXT000006074096", "@typelien": "MODIFIE", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000039041260", "@num": "R111-18-11", "#text": "Code de la construction et de l'habitation. - art. R111-18-11 (Ab)", "@sens": "source", "@cidtexte": "LEGITEXT000006074096", "@typelien": "MODIFIE", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000039041344", "@num": "R111-18-2", "#text": "Code de la construction et de l'habitation. - art. R111-18-2 (Ab)", "@sens": "source", "@cidtexte": "LEGITEXT000006074096", "@typelien": "MODIFIE", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000039041337", "@num": "R111-18-3", "#text": "Code de la construction et de l'habitation. - art. R111-18-3 (Ab)", "@sens": "source", "@cidtexte": "LEGITEXT000006074096", "@typelien": "MODIFIE", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000039041331", "@num": "R111-18-4", "#text": "Code de la construction et de l'habitation. - art. R111-18-4 (Ab)", "@sens": "source", "@cidtexte": "LEGITEXT000006074096", "@typelien": "MODIFIE", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000039041325", "@num": "R111-18-5", "#text": "Code de la construction et de l'habitation. - art. R111-18-5 (Ab)", "@sens": "source", "@cidtexte": "LEGITEXT000006074096", "@typelien": "MODIFIE", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000039041316", "@num": "R111-18-6", "#text": "Code de la construction et de l'habitation. - art. R111-18-6 (Ab)", "@sens": "source", "@cidtexte": "LEGITEXT000006074096", "@typelien": "MODIFIE", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000039041313", "@num": "R111-18-7", "#text": "Code de la construction et de l'habitation. - art. R111-18-7 (Ab)", "@sens": "source", "@cidtexte": "LEGITEXT000006074096", "@typelien": "MODIFIE", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000039041305", "@num": "R111-18-8", "#text": "Code de la construction et de l'habitation. - art. R111-18-8 (Ab)", "@sens": "source", "@cidtexte": "LEGITEXT000006074096", "@typelien": "MODIFIE", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000039041293", "@num": "R111-18-9", "#text": "Code de la construction et de l'habitation. - art. R111-18-9 (Ab)", "@sens": "source", "@cidtexte": "LEGITEXT000006074096", "@typelien": "MODIFIE", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000039041256", "@num": "R111-19-1", "#text": "Code de la construction et de l'habitation. - art. R111-19-1 (VD)", "@sens": "source", "@cidtexte": "LEGITEXT000006074096", "@typelien": "MODIFIE", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000039041228", "@num": "R111-19-11", "#text": "Code de la construction et de l'habitation. - art. R111-19-11 (VD)", "@sens": "source", "@cidtexte": "LEGITEXT000006074096", "@typelien": "MODIFIE", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000039041225", "@num": "R111-19-12", "#text": "Code de la construction et de l'habitation. - art. R111-19-12 (VD)", "@sens": "source", "@cidtexte": "LEGITEXT000006074096", "@typelien": "MODIFIE", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000039041220", "@num": "R111-19-13", "#text": "Code de la construction et de l'habitation. - art. R111-19-13 (VD)", "@sens": "source", "@cidtexte": "LEGITEXT000006074096", "@typelien": "MODIFIE", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000039041215", "@num": "R111-19-14", "#text": "Code de la construction et de l'habitation. - art. R111-19-14 (VD)", "@sens": "source", "@cidtexte": "LEGITEXT000006074096", "@typelien": "MODIFIE", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000039041209", "@num": "R111-19-15", "#text": "Code de la construction et de l'habitation. - art. R111-19-15 (VD)", "@sens": "source", "@cidtexte": "LEGITEXT000006074096", "@typelien": "MODIFIE", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000039041206", "@num": "R111-19-16", "#text": "Code de la construction et de l'habitation. - art. R111-19-16 (VD)", "@sens": "source", "@cidtexte": "LEGITEXT000006074096", "@typelien": "MODIFIE", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000039041202", "@num": "R111-19-19", "#text": "Code de la construction et de l'habitation. - art. R111-19-19 (VD)", "@sens": "source", "@cidtexte": "LEGITEXT000006074096", "@typelien": "MODIFIE", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000039041253", "@num": "R111-19-2", "#text": "Code de la construction et de l'habitation. - art. R111-19-2 (VD)", "@sens": "source", "@cidtexte": "LEGITEXT000006074096", "@typelien": "MODIFIE", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000039041198", "@num": "R111-19-20", "#text": "Code de la construction et de l'habitation. - art. R111-19-20 (VD)", "@sens": "source", "@cidtexte": "LEGITEXT000006074096", "@typelien": "MODIFIE", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000039041195", "@num": "R111-19-21", "#text": "Code de la construction et de l'habitation. - art. R111-19-21 (VD)", "@sens": "source", "@cidtexte": "LEGITEXT000006074096", "@typelien": "MODIFIE", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000039041192", "@num": "R111-19-22", "#text": "Code de la construction et de l'habitation. - art. R111-19-22 (VD)", "@sens": "source", "@cidtexte": "LEGITEXT000006074096", "@typelien": "MODIFIE", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000039041250", "@num": "R111-19-3", "#text": "Code de la construction et de l'habitation. - art. R111-19-3 (VD)", "@sens": "source", "@cidtexte": "LEGITEXT000006074096", "@typelien": "MODIFIE", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000039041247", "@num": "R111-19-4", "#text": "Code de la construction et de l'habitation. - art. R111-19-4 (VD)", "@sens": "source", "@cidtexte": "LEGITEXT000006074096", "@typelien": "MODIFIE", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000039041244", "@num": "R111-19-5", "#text": "Code de la construction et de l'habitation. - art. R111-19-5 (VD)", "@sens": "source", "@cidtexte": "LEGITEXT000006074096", "@typelien": "MODIFIE", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000039041237", "@num": "R111-19-8", "#text": "Code de la construction et de l'habitation. - art. R111-19-8 (VD)", "@sens": "source", "@cidtexte": "LEGITEXT000006074096", "@typelien": "MODIFIE", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000039041232", "@num": "R111-19-9", "#text": "Code de la construction et de l'habitation. - art. R111-19-9 (VD)", "@sens": "source", "@cidtexte": "LEGITEXT000006074096", "@typelien": "MODIFIE", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000039041453", "@num": "R111-2", "#text": "Code de la construction et de l'habitation. - art. R111-2 (Ab)", "@sens": "source", "@cidtexte": "LEGITEXT000006074096", "@typelien": "MODIFIE", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000039041187", "@num": "R111-24", "#text": "Code de la construction et de l'habitation. - art. R111-24 (VD)", "@sens": "source", "@cidtexte": "LEGITEXT000006074096", "@typelien": "MODIFIE", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000039041182", "@num": "R111-25", "#text": "Code de la construction et de l'habitation. - art. R111-25 (VD)", "@sens": "source", "@cidtexte": "LEGITEXT000006074096", "@typelien": "MODIFIE", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000039041179", "@num": "R111-26", "#text": "Code de la construction et de l'habitation. - art. R111-26 (VD)", "@sens": "source", "@cidtexte": "LEGITEXT000006074096", "@typelien": "MODIFIE", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000039041176", "@num": "R111-27", "#text": "Code de la construction et de l'habitation. - art. R111-27 (VD)", "@sens": "source", "@cidtexte": "LEGITEXT000006074096", "@typelien": "MODIFIE", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000039041173", "@num": "R111-28", "#text": "Code de la construction et de l'habitation. - art. R111-28 (VD)", "@sens": "source", "@cidtexte": "LEGITEXT000006074096", "@typelien": "MODIFIE", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000039041168", "@num": "R111-29", "#text": "Code de la construction et de l'habitation. - art. R111-29 (VD)", "@sens": "source", "@cidtexte": "LEGITEXT000006074096", "@typelien": "MODIFIE", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000039041158", "@num": "R111-29-1", "#text": "Code de la construction et de l'habitation. - art. R111-29-1 (Ab)", "@sens": "source", "@cidtexte": "LEGITEXT000006074096", "@typelien": "MODIFIE", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000039041447", "@num": "R111-3", "#text": "Code de la construction et de l'habitation. - art. R111-3 (Ab)", "@sens": "source", "@cidtexte": "LEGITEXT000006074096", "@typelien": "MODIFIE", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000039041155", "@num": "R111-30", "#text": "Code de la construction et de l'habitation. - art. R111-30 (VD)", "@sens": "source", "@cidtexte": "LEGITEXT000006074096", "@typelien": "MODIFIE", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000039041151", "@num": "R111-31", "#text": "Code de la construction et de l'habitation. - art. R111-31 (VD)", "@sens": "source", "@cidtexte": "LEGITEXT000006074096", "@typelien": "MODIFIE", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000039041143", "@num": "R111-32", "#text": "Code de la construction et de l'habitation. - art. R111-32 (Ab)", "@sens": "source", "@cidtexte": "LEGITEXT000006074096", "@typelien": "MODIFIE", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000039041133", "@num": "R111-32-1", "#text": "Code de la construction et de l'habitation. - art. R111-32-1 (Ab)", "@sens": "source", "@cidtexte": "LEGITEXT000006074096", "@typelien": "MODIFIE", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000039041130", "@num": "R111-32-2", "#text": "Code de la construction et de l'habitation. - art. R111-32-2 (VD)", "@sens": "source", "@cidtexte": "LEGITEXT000006074096", "@typelien": "MODIFIE", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000039041127", "@num": "R111-32-3", "#text": "Code de la construction et de l'habitation. - art. R111-32-3 (VD)", "@sens": "source", "@cidtexte": "LEGITEXT000006074096", "@typelien": "MODIFIE", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000039041122", "@num": "R111-33", "#text": "Code de la construction et de l'habitation. - art. R111-33 (VD)", "@sens": "source", "@cidtexte": "LEGITEXT000006074096", "@typelien": "MODIFIE", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000039041114", "@num": "R111-33-1", "#text": "Code de la construction et de l'habitation. - art. R111-33-1 (Ab)", "@sens": "source", "@cidtexte": "LEGITEXT000006074096", "@typelien": "MODIFIE", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000039041112", "@num": "R111-34", "#text": "Code de la construction et de l'habitation. - art. R111-34 (VD)", "@sens": "source", "@cidtexte": "LEGITEXT000006074096", "@typelien": "MODIFIE", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000039041109", "@num": "R111-35", "#text": "Code de la construction et de l'habitation. - art. R111-35 (VD)", "@sens": "source", "@cidtexte": "LEGITEXT000006074096", "@typelien": "MODIFIE", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000039041106", "@num": "R111-36", "#text": "Code de la construction et de l'habitation. - art. R111-36 (VD)", "@sens": "source", "@cidtexte": "LEGITEXT000006074096", "@typelien": "MODIFIE", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000039041101", "@num": "R111-37", "#text": "Code de la construction et de l'habitation. - art. R111-37 (VD)", "@sens": "source", "@cidtexte": "LEGITEXT000006074096", "@typelien": "MODIFIE", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000039041098", "@num": "R111-39", "#text": "Code de la construction et de l'habitation. - art. R111-39 (VD)", "@sens": "source", "@cidtexte": "LEGITEXT000006074096", "@typelien": "MODIFIE", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000039041442", "@num": "R111-4", "#text": "Code de la construction et de l'habitation. - art. R111-4 (Ab)", "@sens": "source", "@cidtexte": "LEGITEXT000006074096", "@typelien": "MODIFIE", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000039041094", "@num": "R111-40", "#text": "Code de la construction et de l'habitation. - art. R111-40 (VD)", "@sens": "source", "@cidtexte": "LEGITEXT000006074096", "@typelien": "MODIFIE", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000039041091", "@num": "R111-41", "#text": "Code de la construction et de l'habitation. - art. R111-41 (VD)", "@sens": "source", "@cidtexte": "LEGITEXT000006074096", "@typelien": "MODIFIE", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000039041088", "@num": "R111-42", "#text": "Code de la construction et de l'habitation. - art. R111-42 (VD)", "@sens": "source", "@cidtexte": "LEGITEXT000006074096", "@typelien": "MODIFIE", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000039041436", "@num": "R111-5", "#text": "Code de la construction et de l'habitation. - art. R111-5 (Ab)", "@sens": "source", "@cidtexte": "LEGITEXT000006074096", "@typelien": "MODIFIE", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000039041431", "@num": "R111-8", "#text": "Code de la construction et de l'habitation. - art. R111-8 (Ab)", "@sens": "source", "@cidtexte": "LEGITEXT000006074096", "@typelien": "MODIFIE", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000039041425", "@num": "R111-9", "#text": "Code de la construction et de l'habitation. - art. R111-9 (Ab)", "@sens": "source", "@cidtexte": "LEGITEXT000006074096", "@typelien": "MODIFIE", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000039041084", "@num": "R123-1", "#text": "Code de la construction et de l'habitation. - art. R123-1 (VD)", "@sens": "source", "@cidtexte": "LEGITEXT000006074096", "@typelien": "MODIFIE", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000039041056", "@num": "R123-10", "#text": "Code de la construction et de l'habitation. - art. R123-10 (VD)", "@sens": "source", "@cidtexte": "LEGITEXT000006074096", "@typelien": "MODIFIE", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000039041051", "@num": "R123-11", "#text": "Code de la construction et de l'habitation. - art. R123-11 (VD)", "@sens": "source", "@cidtexte": "LEGITEXT000006074096", "@typelien": "MODIFIE", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000039041047", "@num": "R123-12", "#text": "Code de la construction et de l'habitation. - art. R123-12 (VD)", "@sens": "source", "@cidtexte": "LEGITEXT000006074096", "@typelien": "MODIFIE", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000039041042", "@num": "R123-13", "#text": "Code de la construction et de l'habitation. - art. R123-13 (VD)", "@sens": "source", "@cidtexte": "LEGITEXT000006074096", "@typelien": "MODIFIE", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000039041033", "@num": "R123-14", "#text": "Code de la construction et de l'habitation. - art. R123-14 (VD)", "@sens": "source", "@cidtexte": "LEGITEXT000006074096", "@typelien": "MODIFIE", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000039041028", "@num": "R123-15", "#text": "Code de la construction et de l'habitation. - art. R123-15 (VD)", "@sens": "source", "@cidtexte": "LEGITEXT000006074096", "@typelien": "MODIFIE", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000039041026", "@num": "R123-16", "#text": "Code de la construction et de l'habitation. - art. R123-16 (VD)", "@sens": "source", "@cidtexte": "LEGITEXT000006074096", "@typelien": "MODIFIE", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000039041023", "@num": "R123-17", "#text": "Code de la construction et de l'habitation. - art. R123-17 (VD)", "@sens": "source", "@cidtexte": "LEGITEXT000006074096", "@typelien": "MODIFIE", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000039041019", "@num": "R123-18", "#text": "Code de la construction et de l'habitation. - art. R123-18 (VD)", "@sens": "source", "@cidtexte": "LEGITEXT000006074096", "@typelien": "MODIFIE", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000039041014", "@num": "R123-19", "#text": "Code de la construction et de l'habitation. - art. R123-19 (VD)", "@sens": "source", "@cidtexte": "LEGITEXT000006074096", "@typelien": "MODIFIE", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000039041081", "@num": "R123-2", "#text": "Code de la construction et de l'habitation. - art. R123-2 (VD)", "@sens": "source", "@cidtexte": "LEGITEXT000006074096", "@typelien": "MODIFIE", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000039041011", "@num": "R123-20", "#text": "Code de la construction et de l'habitation. - art. R123-20 (VD)", "@sens": "source", "@cidtexte": "LEGITEXT000006074096", "@typelien": "MODIFIE", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000039041007", "@num": "R123-21", "#text": "Code de la construction et de l'habitation. - art. R123-21 (VD)", "@sens": "source", "@cidtexte": "LEGITEXT000006074096", "@typelien": "MODIFIE", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000039041003", "@num": "R123-27", "#text": "Code de la construction et de l'habitation. - art. R123-27 (VD)", "@sens": "source", "@cidtexte": "LEGITEXT000006074096", "@typelien": "MODIFIE", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000039041000", "@num": "R123-28", "#text": "Code de la construction et de l'habitation. - art. R123-28 (VD)", "@sens": "source", "@cidtexte": "LEGITEXT000006074096", "@typelien": "MODIFIE", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000039040997", "@num": "R123-29", "#text": "Code de la construction et de l'habitation. - art. R123-29 (VD)", "@sens": "source", "@cidtexte": "LEGITEXT000006074096", "@typelien": "MODIFIE", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000039041078", "@num": "R123-3", "#text": "Code de la construction et de l'habitation. - art. R123-3 (VD)", "@sens": "source", "@cidtexte": "LEGITEXT000006074096", "@typelien": "MODIFIE", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000039040994", "@num": "R123-30", "#text": "Code de la construction et de l'habitation. - art. R123-30 (VD)", "@sens": "source", "@cidtexte": "LEGITEXT000006074096", "@typelien": "MODIFIE", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000039040990", "@num": "R123-31", "#text": "Code de la construction et de l'habitation. - art. R123-31 (VD)", "@sens": "source", "@cidtexte": "LEGITEXT000006074096", "@typelien": "MODIFIE", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000039040987", "@num": "R123-32", "#text": "Code de la construction et de l'habitation. - art. R123-32 (VD)", "@sens": "source", "@cidtexte": "LEGITEXT000006074096", "@typelien": "MODIFIE", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000039040984", "@num": "R123-33", "#text": "Code de la construction et de l'habitation. - art. R123-33 (VD)", "@sens": "source", "@cidtexte": "LEGITEXT000006074096", "@typelien": "MODIFIE", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000039040979", "@num": "R123-34", "#text": "Code de la construction et de l'habitation. - art. R123-34 (VD)", "@sens": "source", "@cidtexte": "LEGITEXT000006074096", "@typelien": "MODIFIE", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000039040974", "@num": "R123-35", "#text": "Code de la construction et de l'habitation. - art. R123-35 (VD)", "@sens": "source", "@cidtexte": "LEGITEXT000006074096", "@typelien": "MODIFIE", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000039040969", "@num": "R123-36", "#text": "Code de la construction et de l'habitation. - art. R123-36 (VD)", "@sens": "source", "@cidtexte": "LEGITEXT000006074096", "@typelien": "MODIFIE", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000039040966", "@num": "R123-37", "#text": "Code de la construction et de l'habitation. - art. R123-37 (VD)", "@sens": "source", "@cidtexte": "LEGITEXT000006074096", "@typelien": "MODIFIE", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000039040962", "@num": "R123-38", "#text": "Code de la construction et de l'habitation. - art. R123-38 (VD)", "@sens": "source", "@cidtexte": "LEGITEXT000006074096", "@typelien": "MODIFIE", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000039040957", "@num": "R123-39", "#text": "Code de la construction et de l'habitation. - art. R123-39 (VD)", "@sens": "source", "@cidtexte": "LEGITEXT000006074096", "@typelien": "MODIFIE", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000039041076", "@num": "R123-4", "#text": "Code de la construction et de l'habitation. - art. R123-4 (VD)", "@sens": "source", "@cidtexte": "LEGITEXT000006074096", "@typelien": "MODIFIE", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000039040954", "@num": "R123-40", "#text": "Code de la construction et de l'habitation. - art. R123-40 (VD)", "@sens": "source", "@cidtexte": "LEGITEXT000006074096", "@typelien": "MODIFIE", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000039040951", "@num": "R123-41", "#text": "Code de la construction et de l'habitation. - art. R123-41 (VD)", "@sens": "source", "@cidtexte": "LEGITEXT000006074096", "@typelien": "MODIFIE", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000039040948", "@num": "R123-42", "#text": "Code de la construction et de l'habitation. - art. R123-42 (VD)", "@sens": "source", "@cidtexte": "LEGITEXT000006074096", "@typelien": "MODIFIE", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000039040650", "@num": "R123-43", "#text": "Code de la construction et de l'habitation. - art. R123-43 (VD)", "@sens": "source", "@cidtexte": "LEGITEXT000006074096", "@typelien": "MODIFIE", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000039040945", "@num": "R123-44", "#text": "Code de la construction et de l'habitation. - art. R123-44 (VD)", "@sens": "source", "@cidtexte": "LEGITEXT000006074096", "@typelien": "MODIFIE", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000039040939", "@num": "R123-45", "#text": "Code de la construction et de l'habitation. - art. R123-45 (VD)", "@sens": "source", "@cidtexte": "LEGITEXT000006074096", "@typelien": "MODIFIE", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000039040935", "@num": "R123-46", "#text": "Code de la construction et de l'habitation. - art. R123-46 (VD)", "@sens": "source", "@cidtexte": "LEGITEXT000006074096", "@typelien": "MODIFIE", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000039040932", "@num": "R123-47", "#text": "Code de la construction et de l'habitation. - art. R123-47 (VD)", "@sens": "source", "@cidtexte": "LEGITEXT000006074096", "@typelien": "MODIFIE", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000039040928", "@num": "R123-48", "#text": "Code de la construction et de l'habitation. - art. R123-48 (VD)", "@sens": "source", "@cidtexte": "LEGITEXT000006074096", "@typelien": "MODIFIE", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000039040924", "@num": "R123-49", "#text": "Code de la construction et de l'habitation. - art. R123-49 (VD)", "@sens": "source", "@cidtexte": "LEGITEXT000006074096", "@typelien": "MODIFIE", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000039041073", "@num": "R123-5", "#text": "Code de la construction et de l'habitation. - art. R123-5 (VD)", "@sens": "source", "@cidtexte": "LEGITEXT000006074096", "@typelien": "MODIFIE", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000039040921", "@num": "R123-50", "#text": "Code de la construction et de l'habitation. - art. R123-50 (VD)", "@sens": "source", "@cidtexte": "LEGITEXT000006074096", "@typelien": "MODIFIE", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000039040918", "@num": "R123-51", "#text": "Code de la construction et de l'habitation. - art. R123-51 (VD)", "@sens": "source", "@cidtexte": "LEGITEXT000006074096", "@typelien": "MODIFIE", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000039040914", "@num": "R123-52", "#text": "Code de la construction et de l'habitation. - art. R123-52 (VD)", "@sens": "source", "@cidtexte": "LEGITEXT000006074096", "@typelien": "MODIFIE", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000039040911", "@num": "R123-53", "#text": "Code de la construction et de l'habitation. - art. R123-53 (VD)", "@sens": "source", "@cidtexte": "LEGITEXT000006074096", "@typelien": "MODIFIE", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000039040907", "@num": "R123-54", "#text": "Code de la construction et de l'habitation. - art. R123-54 (VD)", "@sens": "source", "@cidtexte": "LEGITEXT000006074096", "@typelien": "MODIFIE", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000039040904", "@num": "R123-55", "#text": "Code de la construction et de l'habitation. - art. R123-55 (VD)", "@sens": "source", "@cidtexte": "LEGITEXT000006074096", "@typelien": "MODIFIE", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000039041070", "@num": "R123-6", "#text": "Code de la construction et de l'habitation. - art. R123-6 (VD)", "@sens": "source", "@cidtexte": "LEGITEXT000006074096", "@typelien": "MODIFIE", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000039041067", "@num": "R123-7", "#text": "Code de la construction et de l'habitation. - art. R123-7 (VD)", "@sens": "source", "@cidtexte": "LEGITEXT000006074096", "@typelien": "MODIFIE", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000039041063", "@num": "R123-8", "#text": "Code de la construction et de l'habitation. - art. R123-8 (VD)", "@sens": "source", "@cidtexte": "LEGITEXT000006074096", "@typelien": "MODIFIE", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000039041059", "@num": "R123-9", "#text": "Code de la construction et de l'habitation. - art. R123-9 (VD)", "@sens": "source", "@cidtexte": "LEGITEXT000006074096", "@typelien": "MODIFIE", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000039040901", "@num": "R127-1", "#text": "Code de la construction et de l'habitation. - art. R127-1 (VD)", "@sens": "source", "@cidtexte": "LEGITEXT000006074096", "@typelien": "MODIFIE", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000039040897", "@num": "R127-8", "#text": "Code de la construction et de l'habitation. - art. R127-8 (VD)", "@sens": "source", "@cidtexte": "LEGITEXT000006074096", "@typelien": "MODIFIE", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000039040893", "@num": "R129-1", "#text": "Code de la construction et de l'habitation. - art. R129-1 (VD)", "@sens": "source", "@cidtexte": "LEGITEXT000006074096", "@typelien": "MODIFIE", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000039040853", "@num": "R129-10", "#text": "Code de la construction et de l'habitation. - art. R129-10 (VD)", "@sens": "source", "@cidtexte": "LEGITEXT000006074096", "@typelien": "MODIFIE", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000039040848", "@num": "R129-11", "#text": "Code de la construction et de l'habitation. - art. R129-11 (VD)", "@sens": "source", "@cidtexte": "LEGITEXT000006074096", "@typelien": "MODIFIE", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000039040888", "@num": "R129-2", "#text": "Code de la construction et de l'habitation. - art. R129-2 (VD)", "@sens": "source", "@cidtexte": "LEGITEXT000006074096", "@typelien": "MODIFIE", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000039040884", "@num": "R129-3", "#text": "Code de la construction et de l'habitation. - art. R129-3 (VD)", "@sens": "source", "@cidtexte": "LEGITEXT000006074096", "@typelien": "MODIFIE", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000039040879", "@num": "R129-4", "#text": "Code de la construction et de l'habitation. - art. R129-4 (VD)", "@sens": "source", "@cidtexte": "LEGITEXT000006074096", "@typelien": "MODIFIE", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000039040873", "@num": "R129-5", "#text": "Code de la construction et de l'habitation. - art. R129-5 (VD)", "@sens": "source", "@cidtexte": "LEGITEXT000006074096", "@typelien": "MODIFIE", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000039040869", "@num": "R129-6", "#text": "Code de la construction et de l'habitation. - art. R129-6 (VD)", "@sens": "source", "@cidtexte": "LEGITEXT000006074096", "@typelien": "MODIFIE", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000039040865", "@num": "R129-7", "#text": "Code de la construction et de l'habitation. - art. R129-7 (VD)", "@sens": "source", "@cidtexte": "LEGITEXT000006074096", "@typelien": "MODIFIE", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000039040862", "@num": "R129-8", "#text": "Code de la construction et de l'habitation. - art. R129-8 (VD)", "@sens": "source", "@cidtexte": "LEGITEXT000006074096", "@typelien": "MODIFIE", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000039040859", "@num": "R129-9", "#text": "Code de la construction et de l'habitation. - art. R129-9 (VD)", "@sens": "source", "@cidtexte": "LEGITEXT000006074096", "@typelien": "MODIFIE", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000039040845", "@num": "R131-1", "#text": "Code de la construction et de l'habitation. - art. R131-1 (VD)", "@sens": "source", "@cidtexte": "LEGITEXT000006074096", "@typelien": "MODIFIE", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000039040841", "@num": "R131-2", "#text": "Code de la construction et de l'habitation. - art. R131-2 (VD)", "@sens": "source", "@cidtexte": "LEGITEXT000006074096", "@typelien": "MODIFIE", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000039040828", "@num": "R131-28-1", "#text": "Code de la construction et de l'habitation. - art. R131-28-1 (VD)", "@sens": "source", "@cidtexte": "LEGITEXT000006074096", "@typelien": "MODIFIE", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000039040835", "@num": "R131-3", "#text": "Code de la construction et de l'habitation. - art. R131-3 (VD)", "@sens": "source", "@cidtexte": "LEGITEXT000006074096", "@typelien": "MODIFIE", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000039040830", "@num": "R131-4", "#text": "Code de la construction et de l'habitation. - art. R131-4 (VD)", "@sens": "source", "@cidtexte": "LEGITEXT000006074096", "@typelien": "MODIFIE", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000039040824", "@num": "R132-1", "#text": "Code de la construction et de l'habitation. - art. R132-1 (VD)", "@sens": "source", "@cidtexte": "LEGITEXT000006074096", "@typelien": "MODIFIE", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000039040818", "@num": "R133-1", "#text": "Code de la construction et de l'habitation. - art. R133-1 (VD)", "@sens": "source", "@cidtexte": "LEGITEXT000006074096", "@typelien": "MODIFIE", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000039040813", "@num": "R133-2", "#text": "Code de la construction et de l'habitation. - art. R133-2 (VD)", "@sens": "source", "@cidtexte": "LEGITEXT000006074096", "@typelien": "MODIFIE", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000039040773", "@num": "R134-10", "#text": "Code de la construction et de l'habitation. - art. R134-10 (VD)", "@sens": "source", "@cidtexte": "LEGITEXT000006074096", "@typelien": "MODIFIE", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000039040771", "@num": "R134-11", "#text": "Code de la construction et de l'habitation. - art. R134-11 (VD)", "@sens": "source", "@cidtexte": "LEGITEXT000006074096", "@typelien": "MODIFIE", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000039040768", "@num": "R134-12", "#text": "Code de la construction et de l'habitation. - art. R134-12 (VD)", "@sens": "source", "@cidtexte": "LEGITEXT000006074096", "@typelien": "MODIFIE", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000039040764", "@num": "R134-13", "#text": "Code de la construction et de l'habitation. - art. R134-13 (VD)", "@sens": "source", "@cidtexte": "LEGITEXT000006074096", "@typelien": "MODIFIE", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000039040810", "@num": "R134-5-1", "#text": "Code de la construction et de l'habitation. - art. R134-5-1 (VD)", "@sens": "source", "@cidtexte": "LEGITEXT000006074096", "@typelien": "MODIFIE", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000039040807", "@num": "R134-5-2", "#text": "Code de la construction et de l'habitation. - art. R134-5-2 (VD)", "@sens": "source", "@cidtexte": "LEGITEXT000006074096", "@typelien": "MODIFIE", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000039040804", "@num": "R134-5-3", "#text": "Code de la construction et de l'habitation. - art. R134-5-3 (VD)", "@sens": "source", "@cidtexte": "LEGITEXT000006074096", "@typelien": "MODIFIE", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000039040801", "@num": "R134-5-4", "#text": "Code de la construction et de l'habitation. - art. R134-5-4 (VD)", "@sens": "source", "@cidtexte": "LEGITEXT000006074096", "@typelien": "MODIFIE", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000039040795", "@num": "R134-5-5", "#text": "Code de la construction et de l'habitation. - art. R134-5-5 (VD)", "@sens": "source", "@cidtexte": "LEGITEXT000006074096", "@typelien": "MODIFIE", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000039040792", "@num": "R134-5-6", "#text": "Code de la construction et de l'habitation. - art. R134-5-6 (VD)", "@sens": "source", "@cidtexte": "LEGITEXT000006074096", "@typelien": "MODIFIE", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000039040788", "@num": "R134-6", "#text": "Code de la construction et de l'habitation. - art. R134-6 (VD)", "@sens": "source", "@cidtexte": "LEGITEXT000006074096", "@typelien": "MODIFIE", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000039040785", "@num": "R134-7", "#text": "Code de la construction et de l'habitation. - art. R134-7 (VD)", "@sens": "source", "@cidtexte": "LEGITEXT000006074096", "@typelien": "MODIFIE", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000039040781", "@num": "R134-8", "#text": "Code de la construction et de l'habitation. - art. R134-8 (VD)", "@sens": "source", "@cidtexte": "LEGITEXT000006074096", "@typelien": "MODIFIE", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000039040776", "@num": "R134-9", "#text": "Code de la construction et de l'habitation. - art. R134-9 (VD)", "@sens": "source", "@cidtexte": "LEGITEXT000006074096", "@typelien": "MODIFIE", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000039040760", "@num": "R141-1", "#text": "Code de la construction et de l'habitation. - art. R141-1 (VD)", "@sens": "source", "@cidtexte": "LEGITEXT000006074096", "@typelien": "MODIFIE", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000039040756", "@num": "R141-2", "#text": "Code de la construction et de l'habitation. - art. R141-2 (VD)", "@sens": "source", "@cidtexte": "LEGITEXT000006074096", "@typelien": "MODIFIE", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000039040725", "@num": "R152-11", "#text": "Code de la construction et de l'habitation. - art. R152-11 (VD)", "@sens": "source", "@cidtexte": "LEGITEXT000006074096", "@typelien": "MODIFIE", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000039040742", "@num": "R152-6", "#text": "Code de la construction et de l'habitation. - art. R152-6 (VD)", "@sens": "source", "@cidtexte": "LEGITEXT000006074096", "@typelien": "MODIFIE", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000039040733", "@num": "R152-7", "#text": "Code de la construction et de l'habitation. - art. R152-7 (VD)", "@sens": "source", "@cidtexte": "LEGITEXT000006074096", "@typelien": "MODIFIE", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000039040728", "@num": "R152-8", "#text": "Code de la construction et de l'habitation. - art. R152-8 (VD)", "@sens": "source", "@cidtexte": "LEGITEXT000006074096", "@typelien": "MODIFIE", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000039040721", "@num": "R161-1", "#text": "Code de la construction et de l'habitation. - art. R161-1 (VD)", "@sens": "source", "@cidtexte": "LEGITEXT000006074096", "@typelien": "MODIFIE", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000039040719", "@num": "R161-2", "#text": "Code de la construction et de l'habitation. - art. R161-2 (VD)", "@sens": "source", "@cidtexte": "LEGITEXT000006074096", "@typelien": "MODIFIE", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000039040717", "@num": "R161-3", "#text": "Code de la construction et de l'habitation. - art. R161-3 (VD)", "@sens": "source", "@cidtexte": "LEGITEXT000006074096", "@typelien": "MODIFIE", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000039040710", "@num": "R161-4", "#text": "Code de la construction et de l'habitation. - art. R161-4 (Ab)", "@sens": "source", "@cidtexte": "LEGITEXT000006074096", "@typelien": "MODIFIE", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000039040708", "@num": "R162-1", "#text": "Code de la construction et de l'habitation. - art. R162-1 (VD)", "@sens": "source", "@cidtexte": "LEGITEXT000006074096", "@typelien": "MODIFIE", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000039040705", "@num": "R162-2", "#text": "Code de la construction et de l'habitation. - art. R162-2 (VD)", "@sens": "source", "@cidtexte": "LEGITEXT000006074096", "@typelien": "MODIFIE", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000039040702", "@num": "R162-3", "#text": "Code de la construction et de l'habitation. - art. R162-3 (VD)", "@sens": "source", "@cidtexte": "LEGITEXT000006074096", "@typelien": "MODIFIE", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000039040699", "@num": "R162-4", "#text": "Code de la construction et de l'habitation. - art. R162-4 (VD)", "@sens": "source", "@cidtexte": "LEGITEXT000006074096", "@typelien": "MODIFIE", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000039042056", "@num": "R211-1", "#text": "Code de la construction et de l'habitation. - art. R211-1 (VD)", "@sens": "source", "@cidtexte": "LEGITEXT000006074096", "@typelien": "MODIFIE", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000039042052", "@num": "R211-2", "#text": "Code de la construction et de l'habitation. - art. R211-2 (VD)", "@sens": "source", "@cidtexte": "LEGITEXT000006074096", "@typelien": "MODIFIE", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000039042047", "@num": "R211-3", "#text": "Code de la construction et de l'habitation. - art. R211-3 (VD)", "@sens": "source", "@cidtexte": "LEGITEXT000006074096", "@typelien": "MODIFIE", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000039042043", "@num": "R211-4", "#text": "Code de la construction et de l'habitation. - art. R211-4 (VD)", "@sens": "source", "@cidtexte": "LEGITEXT000006074096", "@typelien": "MODIFIE", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000039042040", "@num": "R211-5", "#text": "Code de la construction et de l'habitation. - art. R211-5 (VD)", "@sens": "source", "@cidtexte": "LEGITEXT000006074096", "@typelien": "MODIFIE", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000039042035", "@num": "R211-6", "#text": "Code de la construction et de l'habitation. - art. R211-6 (VD)", "@sens": "source", "@cidtexte": "LEGITEXT000006074096", "@typelien": "MODIFIE", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000039042030", "@num": "R212-1", "#text": "Code de la construction et de l'habitation. - art. R212-1 (VD)", "@sens": "source", "@cidtexte": "LEGITEXT000006074096", "@typelien": "MODIFIE", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000039041990", "@num": "R212-10", "#text": "Code de la construction et de l'habitation. - art. R212-10 (VD)", "@sens": "source", "@cidtexte": "LEGITEXT000006074096", "@typelien": "MODIFIE", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000039041984", "@num": "R212-11", "#text": "Code de la construction et de l'habitation. - art. R212-11 (VD)", "@sens": "source", "@cidtexte": "LEGITEXT000006074096", "@typelien": "MODIFIE", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000039041979", "@num": "R212-12", "#text": "Code de la construction et de l'habitation. - art. R212-12 (VD)", "@sens": "source", "@cidtexte": "LEGITEXT000006074096", "@typelien": "MODIFIE", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000039041974", "@num": "R212-13", "#text": "Code de la construction et de l'habitation. - art. R212-13 (VD)", "@sens": "source", "@cidtexte": "LEGITEXT000006074096", "@typelien": "MODIFIE", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000039041968", "@num": "R212-14", "#text": "Code de la construction et de l'habitation. - art. R212-14 (VD)", "@sens": "source", "@cidtexte": "LEGITEXT000006074096", "@typelien": "MODIFIE", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000039041965", "@num": "R212-15", "#text": "Code de la construction et de l'habitation. - art. R212-15 (VD)", "@sens": "source", "@cidtexte": "LEGITEXT000006074096", "@typelien": "MODIFIE", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000039041962", "@num": "R212-16", "#text": "Code de la construction et de l'habitation. - art. R212-16 (VD)", "@sens": "source", "@cidtexte": "LEGITEXT000006074096", "@typelien": "MODIFIE", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000039041944", "@num": "R212-17", "#text": "Code de la construction et de l'habitation. - art. R212-17 (VD)", "@sens": "source", "@cidtexte": "LEGITEXT000006074096", "@typelien": "MODIFIE", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000039041938", "@num": "R212-18", "#text": "Code de la construction et de l'habitation. - art. R212-18 (VD)", "@sens": "source", "@cidtexte": "LEGITEXT000006074096", "@typelien": "MODIFIE", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000039042026", "@num": "R212-2", "#text": "Code de la construction et de l'habitation. - art. R212-2 (VD)", "@sens": "source", "@cidtexte": "LEGITEXT000006074096", "@typelien": "MODIFIE", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000039042021", "@num": "R212-3", "#text": "Code de la construction et de l'habitation. - art. R212-3 (VD)", "@sens": "source", "@cidtexte": "LEGITEXT000006074096", "@typelien": "MODIFIE", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000039042017", "@num": "R212-4", "#text": "Code de la construction et de l'habitation. - art. R212-4 (VD)", "@sens": "source", "@cidtexte": "LEGITEXT000006074096", "@typelien": "MODIFIE", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000039042014", "@num": "R212-5", "#text": "Code de la construction et de l'habitation. - art. R212-5 (VD)", "@sens": "source", "@cidtexte": "LEGITEXT000006074096", "@typelien": "MODIFIE", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000039042009", "@num": "R212-6", "#text": "Code de la construction et de l'habitation. - art. R212-6 (VD)", "@sens": "source", "@cidtexte": "LEGITEXT000006074096", "@typelien": "MODIFIE", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000039042003", "@num": "R212-7", "#text": "Code de la construction et de l'habitation. - art. R212-7 (VD)", "@sens": "source", "@cidtexte": "LEGITEXT000006074096", "@typelien": "MODIFIE", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000039041998", "@num": "R212-8", "#text": "Code de la construction et de l'habitation. - art. R212-8 (VD)", "@sens": "source", "@cidtexte": "LEGITEXT000006074096", "@typelien": "MODIFIE", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000039041994", "@num": "R212-9", "#text": "Code de la construction et de l'habitation. - art. R212-9 (VD)", "@sens": "source", "@cidtexte": "LEGITEXT000006074096", "@typelien": "MODIFIE", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000039041935", "@num": "R213-1", "#text": "Code de la construction et de l'habitation. - art. R213-1 (VD)", "@sens": "source", "@cidtexte": "LEGITEXT000006074096", "@typelien": "MODIFIE", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000039041893", "@num": "R213-10", "#text": "Code de la construction et de l'habitation. - art. R213-10 (VD)", "@sens": "source", "@cidtexte": "LEGITEXT000006074096", "@typelien": "MODIFIE", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000039041888", "@num": "R213-11", "#text": "Code de la construction et de l'habitation. - art. R213-11 (VD)", "@sens": "source", "@cidtexte": "LEGITEXT000006074096", "@typelien": "MODIFIE", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000039041883", "@num": "R213-12", "#text": "Code de la construction et de l'habitation. - art. R213-12 (VD)", "@sens": "source", "@cidtexte": "LEGITEXT000006074096", "@typelien": "MODIFIE", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000039041879", "@num": "R213-13", "#text": "Code de la construction et de l'habitation. - art. R213-13 (VD)", "@sens": "source", "@cidtexte": "LEGITEXT000006074096", "@typelien": "MODIFIE", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000039041874", "@num": "R213-14", "#text": "Code de la construction et de l'habitation. - art. R213-14 (VD)", "@sens": "source", "@cidtexte": "LEGITEXT000006074096", "@typelien": "MODIFIE", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000039041870", "@num": "R213-15", "#text": "Code de la construction et de l'habitation. - art. R213-15 (VD)", "@sens": "source", "@cidtexte": "LEGITEXT000006074096", "@typelien": "MODIFIE", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000039041866", "@num": "R213-16", "#text": "Code de la construction et de l'habitation. - art. R213-16 (VD)", "@sens": "source", "@cidtexte": "LEGITEXT000006074096", "@typelien": "MODIFIE", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000039041862", "@num": "R213-17", "#text": "Code de la construction et de l'habitation. - art. R213-17 (VD)", "@sens": "source", "@cidtexte": "LEGITEXT000006074096", "@typelien": "MODIFIE", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000039041858", "@num": "R213-17-1", "#text": "Code de la construction et de l'habitation. - art. R213-17-1 (VD)", "@sens": "source", "@cidtexte": "LEGITEXT000006074096", "@typelien": "MODIFIE", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000039041853", "@num": "R213-17-2", "#text": "Code de la construction et de l'habitation. - art. R213-17-2 (VD)", "@sens": "source", "@cidtexte": "LEGITEXT000006074096", "@typelien": "MODIFIE", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000039041850", "@num": "R213-17-3", "#text": "Code de la construction et de l'habitation. - art. R213-17-3 (VD)", "@sens": "source", "@cidtexte": "LEGITEXT000006074096", "@typelien": "MODIFIE", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000039041931", "@num": "R213-2", "#text": "Code de la construction et de l'habitation. - art. R213-2 (VD)", "@sens": "source", "@cidtexte": "LEGITEXT000006074096", "@typelien": "MODIFIE", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000039041927", "@num": "R213-3", "#text": "Code de la construction et de l'habitation. - art. R213-3 (VD)", "@sens": "source", "@cidtexte": "LEGITEXT000006074096", "@typelien": "MODIFIE", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000039041922", "@num": "R213-4", "#text": "Code de la construction et de l'habitation. - art. R213-4 (VD)", "@sens": "source", "@cidtexte": "LEGITEXT000006074096", "@typelien": "MODIFIE", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000039041917", "@num": "R213-5", "#text": "Code de la construction et de l'habitation. - art. R213-5 (VD)", "@sens": "source", "@cidtexte": "LEGITEXT000006074096", "@typelien": "MODIFIE", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000039041912", "@num": "R213-6", "#text": "Code de la construction et de l'habitation. - art. R213-6 (VD)", "@sens": "source", "@cidtexte": "LEGITEXT000006074096", "@typelien": "MODIFIE", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000039041908", "@num": "R213-7", "#text": "Code de la construction et de l'habitation. - art. R213-7 (VD)", "@sens": "source", "@cidtexte": "LEGITEXT000006074096", "@typelien": "MODIFIE", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000039041903", "@num": "R213-8", "#text": "Code de la construction et de l'habitation. - art. R213-8 (VD)", "@sens": "source", "@cidtexte": "LEGITEXT000006074096", "@typelien": "MODIFIE", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000039041898", "@num": "R213-9", "#text": "Code de la construction et de l'habitation. - art. R213-9 (VD)", "@sens": "source", "@cidtexte": "LEGITEXT000006074096", "@typelien": "MODIFIE", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000039041844", "@num": "R215-1", "#text": "Code de la construction et de l'habitation. - art. R215-1 (VD)", "@sens": "source", "@cidtexte": "LEGITEXT000006074096", "@typelien": "MODIFIE", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000039041839", "@num": "R215-2", "#text": "Code de la construction et de l'habitation. - art. R215-2 (VD)", "@sens": "source", "@cidtexte": "LEGITEXT000006074096", "@typelien": "MODIFIE", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000039041835", "@num": "R215-3", "#text": "Code de la construction et de l'habitation. - art. R215-3 (VD)", "@sens": "source", "@cidtexte": "LEGITEXT000006074096", "@typelien": "MODIFIE", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000039041829", "@num": "R215-4", "#text": "Code de la construction et de l'habitation. - art. R215-4 (VD)", "@sens": "source", "@cidtexte": "LEGITEXT000006074096", "@typelien": "MODIFIE", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000039041825", "@num": "R222-1", "#text": "Code de la construction et de l'habitation. - art. R222-1 (VD)", "@sens": "source", "@cidtexte": "LEGITEXT000006074096", "@typelien": "MODIFIE", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000039041782", "@num": "R222-10", "#text": "Code de la construction et de l'habitation. - art. R222-10 (VD)", "@sens": "source", "@cidtexte": "LEGITEXT000006074096", "@typelien": "MODIFIE", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000039041776", "@num": "R222-11", "#text": "Code de la construction et de l'habitation. - art. R222-11 (VD)", "@sens": "source", "@cidtexte": "LEGITEXT000006074096", "@typelien": "MODIFIE", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000039041771", "@num": "R222-12", "#text": "Code de la construction et de l'habitation. - art. R222-12 (VD)", "@sens": "source", "@cidtexte": "LEGITEXT000006074096", "@typelien": "MODIFIE", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000039041767", "@num": "R222-13", "#text": "Code de la construction et de l'habitation. - art. R222-13 (VD)", "@sens": "source", "@cidtexte": "LEGITEXT000006074096", "@typelien": "MODIFIE", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000039041761", "@num": "R222-14", "#text": "Code de la construction et de l'habitation. - art. R222-14 (VD)", "@sens": "source", "@cidtexte": "LEGITEXT000006074096", "@typelien": "MODIFIE", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000039041821", "@num": "R222-2", "#text": "Code de la construction et de l'habitation. - art. R222-2 (VD)", "@sens": "source", "@cidtexte": "LEGITEXT000006074096", "@typelien": "MODIFIE", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000039041816", "@num": "R222-3", "#text": "Code de la construction et de l'habitation. - art. R222-3 (VD)", "@sens": "source", "@cidtexte": "LEGITEXT000006074096", "@typelien": "MODIFIE", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000039041812", "@num": "R222-4", "#text": "Code de la construction et de l'habitation. - art. R222-4 (VD)", "@sens": "source", "@cidtexte": "LEGITEXT000006074096", "@typelien": "MODIFIE", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000039041808", "@num": "R222-5", "#text": "Code de la construction et de l'habitation. - art. R222-5 (VD)", "@sens": "source", "@cidtexte": "LEGITEXT000006074096", "@typelien": "MODIFIE", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000039041804", "@num": "R222-6", "#text": "Code de la construction et de l'habitation. - art. R222-6 (VD)", "@sens": "source", "@cidtexte": "LEGITEXT000006074096", "@typelien": "MODIFIE", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000039041800", "@num": "R222-7", "#text": "Code de la construction et de l'habitation. - art. R222-7 (VD)", "@sens": "source", "@cidtexte": "LEGITEXT000006074096", "@typelien": "MODIFIE", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000039041794", "@num": "R222-8", "#text": "Code de la construction et de l'habitation. - art. R222-8 (VD)", "@sens": "source", "@cidtexte": "LEGITEXT000006074096", "@typelien": "MODIFIE", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000039041785", "@num": "R222-9", "#text": "Code de la construction et de l'habitation. - art. R222-9 (VD)", "@sens": "source", "@cidtexte": "LEGITEXT000006074096", "@typelien": "MODIFIE", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000039041758", "@num": "R231-1", "#text": "Code de la construction et de l'habitation. - art. R231-1 (VD)", "@sens": "source", "@cidtexte": "LEGITEXT000006074096", "@typelien": "MODIFIE", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000039041717", "@num": "R231-10", "#text": "Code de la construction et de l'habitation. - art. R231-10 (VD)", "@sens": "source", "@cidtexte": "LEGITEXT000006074096", "@typelien": "MODIFIE", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000039041713", "@num": "R231-11", "#text": "Code de la construction et de l'habitation. - art. R231-11 (VD)", "@sens": "source", "@cidtexte": "LEGITEXT000006074096", "@typelien": "MODIFIE", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000039041709", "@num": "R231-12", "#text": "Code de la construction et de l'habitation. - art. R231-12 (VD)", "@sens": "source", "@cidtexte": "LEGITEXT000006074096", "@typelien": "MODIFIE", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000039041705", "@num": "R231-13", "#text": "Code de la construction et de l'habitation. - art. R231-13 (VD)", "@sens": "source", "@cidtexte": "LEGITEXT000006074096", "@typelien": "MODIFIE", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000039041701", "@num": "R231-14", "#text": "Code de la construction et de l'habitation. - art. R231-14 (VD)", "@sens": "source", "@cidtexte": "LEGITEXT000006074096", "@typelien": "MODIFIE", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000039041754", "@num": "R231-2", "#text": "Code de la construction et de l'habitation. - art. R231-2 (VD)", "@sens": "source", "@cidtexte": "LEGITEXT000006074096", "@typelien": "MODIFIE", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000039041749", "@num": "R231-3", "#text": "Code de la construction et de l'habitation. - art. R231-3 (VD)", "@sens": "source", "@cidtexte": "LEGITEXT000006074096", "@typelien": "MODIFIE", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000039041744", "@num": "R231-4", "#text": "Code de la construction et de l'habitation. - art. R231-4 (VD)", "@sens": "source", "@cidtexte": "LEGITEXT000006074096", "@typelien": "MODIFIE", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000039041740", "@num": "R231-5", "#text": "Code de la construction et de l'habitation. - art. R231-5 (VD)", "@sens": "source", "@cidtexte": "LEGITEXT000006074096", "@typelien": "MODIFIE", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000039041736", "@num": "R231-6", "#text": "Code de la construction et de l'habitation. - art. R231-6 (VD)", "@sens": "source", "@cidtexte": "LEGITEXT000006074096", "@typelien": "MODIFIE", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000039041730", "@num": "R231-7", "#text": "Code de la construction et de l'habitation. - art. R231-7 (VD)", "@sens": "source", "@cidtexte": "LEGITEXT000006074096", "@typelien": "MODIFIE", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000039041725", "@num": "R231-8", "#text": "Code de la construction et de l'habitation. - art. R231-8 (VD)", "@sens": "source", "@cidtexte": "LEGITEXT000006074096", "@typelien": "MODIFIE", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000039041721", "@num": "R231-9", "#text": "Code de la construction et de l'habitation. - art. R231-9 (VD)", "@sens": "source", "@cidtexte": "LEGITEXT000006074096", "@typelien": "MODIFIE", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000039041698", "@num": "R232-1", "#text": "Code de la construction et de l'habitation. - art. R232-1 (VD)", "@sens": "source", "@cidtexte": "LEGITEXT000006074096", "@typelien": "MODIFIE", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000039041695", "@num": "R232-2", "#text": "Code de la construction et de l'habitation. - art. R232-2 (VD)", "@sens": "source", "@cidtexte": "LEGITEXT000006074096", "@typelien": "MODIFIE", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000039041691", "@num": "R232-3", "#text": "Code de la construction et de l'habitation. - art. R232-3 (VD)", "@sens": "source", "@cidtexte": "LEGITEXT000006074096", "@typelien": "MODIFIE", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000039041687", "@num": "R232-4", "#text": "Code de la construction et de l'habitation. - art. R232-4 (VD)", "@sens": "source", "@cidtexte": "LEGITEXT000006074096", "@typelien": "MODIFIE", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000039041682", "@num": "R232-5", "#text": "Code de la construction et de l'habitation. - art. R232-5 (VD)", "@sens": "source", "@cidtexte": "LEGITEXT000006074096", "@typelien": "MODIFIE", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000039041677", "@num": "R232-6", "#text": "Code de la construction et de l'habitation. - art. R232-6 (VD)", "@sens": "source", "@cidtexte": "LEGITEXT000006074096", "@typelien": "MODIFIE", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000039041673", "@num": "R232-7", "#text": "Code de la construction et de l'habitation. - art. R232-7 (VD)", "@sens": "source", "@cidtexte": "LEGITEXT000006074096", "@typelien": "MODIFIE", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000039041664", "@num": "R261-1", "#text": "Code de la construction et de l'habitation. - art. R261-1 (VD)", "@sens": "source", "@cidtexte": "LEGITEXT000006074096", "@typelien": "MODIFIE", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000039041621", "@num": "R261-10", "#text": "Code de la construction et de l'habitation. - art. R261-10 (VD)", "@sens": "source", "@cidtexte": "LEGITEXT000006074096", "@typelien": "MODIFIE", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000039041617", "@num": "R261-11", "#text": "Code de la construction et de l'habitation. - art. R261-11 (VD)", "@sens": "source", "@cidtexte": "LEGITEXT000006074096", "@typelien": "MODIFIE", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000039041613", "@num": "R261-12", "#text": "Code de la construction et de l'habitation. - art. R261-12 (VD)", "@sens": "source", "@cidtexte": "LEGITEXT000006074096", "@typelien": "MODIFIE", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000039041609", "@num": "R261-13", "#text": "Code de la construction et de l'habitation. - art. R261-13 (VD)", "@sens": "source", "@cidtexte": "LEGITEXT000006074096", "@typelien": "MODIFIE", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000039041606", "@num": "R261-14", "#text": "Code de la construction et de l'habitation. - art. R261-14 (VD)", "@sens": "source", "@cidtexte": "LEGITEXT000006074096", "@typelien": "MODIFIE", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000039041601", "@num": "R261-15", "#text": "Code de la construction et de l'habitation. - art. R261-15 (VD)", "@sens": "source", "@cidtexte": "LEGITEXT000006074096", "@typelien": "MODIFIE", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000039041597", "@num": "R261-16", "#text": "Code de la construction et de l'habitation. - art. R261-16 (VD)", "@sens": "source", "@cidtexte": "LEGITEXT000006074096", "@typelien": "MODIFIE", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000039041592", "@num": "R261-17", "#text": "Code de la construction et de l'habitation. - art. R261-17 (VD)", "@sens": "source", "@cidtexte": "LEGITEXT000006074096", "@typelien": "MODIFIE", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000039041660", "@num": "R261-2", "#text": "Code de la construction et de l'habitation. - art. R261-2 (VD)", "@sens": "source", "@cidtexte": "LEGITEXT000006074096", "@typelien": "MODIFIE", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000039041587", "@num": "R261-21", "#text": "Code de la construction et de l'habitation. - art. R261-21 (VD)", "@sens": "source", "@cidtexte": "LEGITEXT000006074096", "@typelien": "MODIFIE", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000039041584", "@num": "R261-22", "#text": "Code de la construction et de l'habitation. - art. R261-22 (VD)", "@sens": "source", "@cidtexte": "LEGITEXT000006074096", "@typelien": "MODIFIE", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000039041580", "@num": "R261-23", "#text": "Code de la construction et de l'habitation. - art. R261-23 (VD)", "@sens": "source", "@cidtexte": "LEGITEXT000006074096", "@typelien": "MODIFIE", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000039041575", "@num": "R261-24", "#text": "Code de la construction et de l'habitation. - art. R261-24 (V)", "@sens": "source", "@cidtexte": "LEGITEXT000006074096", "@typelien": "MODIFIE", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000039041570", "@num": "R261-24-1", "#text": "Code de la construction et de l'habitation. - art. R261-24-1 (VD)", "@sens": "source", "@cidtexte": "LEGITEXT000006074096", "@typelien": "MODIFIE", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000039041567", "@num": "R261-25", "#text": "Code de la construction et de l'habitation. - art. R261-25 (VD)", "@sens": "source", "@cidtexte": "LEGITEXT000006074096", "@typelien": "MODIFIE", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000039041562", "@num": "R261-26", "#text": "Code de la construction et de l'habitation. - art. R261-26 (VD)", "@sens": "source", "@cidtexte": "LEGITEXT000006074096", "@typelien": "MODIFIE", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000039041558", "@num": "R261-27", "#text": "Code de la construction et de l'habitation. - art. R261-27 (VD)", "@sens": "source", "@cidtexte": "LEGITEXT000006074096", "@typelien": "MODIFIE", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000039041555", "@num": "R261-28", "#text": "Code de la construction et de l'habitation. - art. R261-28 (VD)", "@sens": "source", "@cidtexte": "LEGITEXT000006074096", "@typelien": "MODIFIE", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000039041552", "@num": "R261-29", "#text": "Code de la construction et de l'habitation. - art. R261-29 (VD)", "@sens": "source", "@cidtexte": "LEGITEXT000006074096", "@typelien": "MODIFIE", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000039041657", "@num": "R261-3", "#text": "Code de la construction et de l'habitation. - art. R261-3 (VD)", "@sens": "source", "@cidtexte": "LEGITEXT000006074096", "@typelien": "MODIFIE", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000039041549", "@num": "R261-30", "#text": "Code de la construction et de l'habitation. - art. R261-30 (VD)", "@sens": "source", "@cidtexte": "LEGITEXT000006074096", "@typelien": "MODIFIE", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000039041546", "@num": "R261-31", "#text": "Code de la construction et de l'habitation. - art. R261-31 (VD)", "@sens": "source", "@cidtexte": "LEGITEXT000006074096", "@typelien": "MODIFIE", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000039041540", "@num": "R261-32", "#text": "Code de la construction et de l'habitation. - art. R261-32 (VD)", "@sens": "source", "@cidtexte": "LEGITEXT000006074096", "@typelien": "MODIFIE", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000039041536", "@num": "R261-33", "#text": "Code de la construction et de l'habitation. - art. R261-33 (VD)", "@sens": "source", "@cidtexte": "LEGITEXT000006074096", "@typelien": "MODIFIE", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000039041654", "@num": "R261-4", "#text": "Code de la construction et de l'habitation. - art. R261-4 (VD)", "@sens": "source", "@cidtexte": "LEGITEXT000006074096", "@typelien": "MODIFIE", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000039041651", "@num": "R261-5", "#text": "Code de la construction et de l'habitation. - art. R261-5 (VD)", "@sens": "source", "@cidtexte": "LEGITEXT000006074096", "@typelien": "MODIFIE", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000039041648", "@num": "R261-6", "#text": "Code de la construction et de l'habitation. - art. R261-6 (VD)", "@sens": "source", "@cidtexte": "LEGITEXT000006074096", "@typelien": "MODIFIE", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000039041642", "@num": "R261-7", "#text": "Code de la construction et de l'habitation. - art. R261-7 (VD)", "@sens": "source", "@cidtexte": "LEGITEXT000006074096", "@typelien": "MODIFIE", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000039041634", "@num": "R261-8", "#text": "Code de la construction et de l'habitation. - art. R261-8 (VD)", "@sens": "source", "@cidtexte": "LEGITEXT000006074096", "@typelien": "MODIFIE", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000039041628", "@num": "R261-9", "#text": "Code de la construction et de l'habitation. - art. R261-9 (VD)", "@sens": "source", "@cidtexte": "LEGITEXT000006074096", "@typelien": "MODIFIE", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000039041533", "@num": "R262-1", "#text": "Code de la construction et de l'habitation. - art. R262-1 (VD)", "@sens": "source", "@cidtexte": "LEGITEXT000006074096", "@typelien": "MODIFIE", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000039041490", "@num": "R262-10", "#text": "Code de la construction et de l'habitation. - art. R262-10 (VD)", "@sens": "source", "@cidtexte": "LEGITEXT000006074096", "@typelien": "MODIFIE", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000039041485", "@num": "R262-11", "#text": "Code de la construction et de l'habitation. - art. R262-11 (VD)", "@sens": "source", "@cidtexte": "LEGITEXT000006074096", "@typelien": "MODIFIE", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000039041482", "@num": "R262-12", "#text": "Code de la construction et de l'habitation. - art. R262-12 (VD)", "@sens": "source", "@cidtexte": "LEGITEXT000006074096", "@typelien": "MODIFIE", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000039041479", "@num": "R262-13", "#text": "Code de la construction et de l'habitation. - art. R262-13 (VD)", "@sens": "source", "@cidtexte": "LEGITEXT000006074096", "@typelien": "MODIFIE", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000039041474", "@num": "R262-14", "#text": "Code de la construction et de l'habitation. - art. R262-14 (VD)", "@sens": "source", "@cidtexte": "LEGITEXT000006074096", "@typelien": "MODIFIE", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000039041469", "@num": "R262-15", "#text": "Code de la construction et de l'habitation. - art. R262-15 (VD)", "@sens": "source", "@cidtexte": "LEGITEXT000006074096", "@typelien": "MODIFIE", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000039041531", "@num": "R262-2", "#text": "Code de la construction et de l'habitation. - art. R262-2 (VD)", "@sens": "source", "@cidtexte": "LEGITEXT000006074096", "@typelien": "MODIFIE", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000039041528", "@num": "R262-3", "#text": "Code de la construction et de l'habitation. - art. R262-3 (VD)", "@sens": "source", "@cidtexte": "LEGITEXT000006074096", "@typelien": "MODIFIE", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000039041521", "@num": "R262-4", "#text": "Code de la construction et de l'habitation. - art. R262-4 (VD)", "@sens": "source", "@cidtexte": "LEGITEXT000006074096", "@typelien": "MODIFIE", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000039041516", "@num": "R262-5", "#text": "Code de la construction et de l'habitation. - art. R262-5 (VD)", "@sens": "source", "@cidtexte": "LEGITEXT000006074096", "@typelien": "MODIFIE", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000039041511", "@num": "R262-6", "#text": "Code de la construction et de l'habitation. - art. R262-6 (VD)", "@sens": "source", "@cidtexte": "LEGITEXT000006074096", "@typelien": "MODIFIE", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000039041505", "@num": "R262-7", "#text": "Code de la construction et de l'habitation. - art. R262-7 (VD)", "@sens": "source", "@cidtexte": "LEGITEXT000006074096", "@typelien": "MODIFIE", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000039041501", "@num": "R262-8", "#text": "Code de la construction et de l'habitation. - art. R262-8 (VD)", "@sens": "source", "@cidtexte": "LEGITEXT000006074096", "@typelien": "MODIFIE", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000039041496", "@num": "R262-9", "#text": "Code de la construction et de l'habitation. - art. R262-9 (VD)", "@sens": "source", "@cidtexte": "LEGITEXT000006074096", "@typelien": "MODIFIE", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000039042771", "@num": "R311-1", "#text": "Code de la construction et de l'habitation. - art. R311-1 (VD)", "@sens": "source", "@cidtexte": "LEGITEXT000006074096", "@typelien": "MODIFIE", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000039042741", "@num": "R311-10", "#text": "Code de la construction et de l'habitation. - art. R311-10 (VD)", "@sens": "source", "@cidtexte": "LEGITEXT000006074096", "@typelien": "MODIFIE", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000039042737", "@num": "R311-11", "#text": "Code de la construction et de l'habitation. - art. R311-11 (VD)", "@sens": "source", "@cidtexte": "LEGITEXT000006074096", "@typelien": "MODIFIE", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000039042734", "@num": "R311-12", "#text": "Code de la construction et de l'habitation. - art. R311-12 (VD)", "@sens": "source", "@cidtexte": "LEGITEXT000006074096", "@typelien": "MODIFIE", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000039042731", "@num": "R311-13", "#text": "Code de la construction et de l'habitation. - art. R311-13 (VD)", "@sens": "source", "@cidtexte": "LEGITEXT000006074096", "@typelien": "MODIFIE", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000039042728", "@num": "R311-14", "#text": "Code de la construction et de l'habitation. - art. R311-14 (VD)", "@sens": "source", "@cidtexte": "LEGITEXT000006074096", "@typelien": "MODIFIE", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000039042724", "@num": "R311-15", "#text": "Code de la construction et de l'habitation. - art. R311-15 (VD)", "@sens": "source", "@cidtexte": "LEGITEXT000006074096", "@typelien": "MODIFIE", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000039042718", "@num": "R311-17", "#text": "Code de la construction et de l'habitation. - art. R311-17 (VD)", "@sens": "source", "@cidtexte": "LEGITEXT000006074096", "@typelien": "MODIFIE", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000039042711", "@num": "R311-18", "#text": "Code de la construction et de l'habitation. - art. R311-18 (VD)", "@sens": "source", "@cidtexte": "LEGITEXT000006074096", "@typelien": "MODIFIE", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000039042708", "@num": "R311-19", "#text": "Code de la construction et de l'habitation. - art. R311-19 (VD)", "@sens": "source", "@cidtexte": "LEGITEXT000006074096", "@typelien": "MODIFIE", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000039042766", "@num": "R311-2", "#text": "Code de la construction et de l'habitation. - art. R311-2 (VD)", "@sens": "source", "@cidtexte": "LEGITEXT000006074096", "@typelien": "MODIFIE", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000039042703", "@num": "R311-20", "#text": "Code de la construction et de l'habitation. - art. R311-20 (VD)", "@sens": "source", "@cidtexte": "LEGITEXT000006074096", "@typelien": "MODIFIE", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000039042699", "@num": "R311-21", "#text": "Code de la construction et de l'habitation. - art. R311-21 (VD)", "@sens": "source", "@cidtexte": "LEGITEXT000006074096", "@typelien": "MODIFIE", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000039042695", "@num": "R311-22", "#text": "Code de la construction et de l'habitation. - art. R311-22 (VD)", "@sens": "source", "@cidtexte": "LEGITEXT000006074096", "@typelien": "MODIFIE", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000039042691", "@num": "R311-23", "#text": "Code de la construction et de l'habitation. - art. R311-23 (VD)", "@sens": "source", "@cidtexte": "LEGITEXT000006074096", "@typelien": "MODIFIE", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000039042686", "@num": "R311-24", "#text": "Code de la construction et de l'habitation. - art. R311-24 (VD)", "@sens": "source", "@cidtexte": "LEGITEXT000006074096", "@typelien": "MODIFIE", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000039042682", "@num": "R311-25", "#text": "Code de la construction et de l'habitation. - art. R311-25 (VD)", "@sens": "source", "@cidtexte": "LEGITEXT000006074096", "@typelien": "MODIFIE", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000039042678", "@num": "R311-26", "#text": "Code de la construction et de l'habitation. - art. R311-26 (VD)", "@sens": "source", "@cidtexte": "LEGITEXT000006074096", "@typelien": "MODIFIE", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000039042675", "@num": "R311-27", "#text": "Code de la construction et de l'habitation. - art. R311-27 (VD)", "@sens": "source", "@cidtexte": "LEGITEXT000006074096", "@typelien": "MODIFIE", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000039042672", "@num": "R311-28", "#text": "Code de la construction et de l'habitation. - art. R311-28 (VD)", "@sens": "source", "@cidtexte": "LEGITEXT000006074096", "@typelien": "MODIFIE", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000039042667", "@num": "R311-29", "#text": "Code de la construction et de l'habitation. - art. R311-29 (VD)", "@sens": "source", "@cidtexte": "LEGITEXT000006074096", "@typelien": "MODIFIE", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000039042661", "@num": "R311-30", "#text": "Code de la construction et de l'habitation. - art. R311-30 (VD)", "@sens": "source", "@cidtexte": "LEGITEXT000006074096", "@typelien": "MODIFIE", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000039042657", "@num": "R311-31", "#text": "Code de la construction et de l'habitation. - art. R311-31 (VD)", "@sens": "source", "@cidtexte": "LEGITEXT000006074096", "@typelien": "MODIFIE", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000039042651", "@num": "R311-32", "#text": "Code de la construction et de l'habitation. - art. R311-32 (VD)", "@sens": "source", "@cidtexte": "LEGITEXT000006074096", "@typelien": "MODIFIE", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000039042646", "@num": "R311-33", "#text": "Code de la construction et de l'habitation. - art. R311-33 (VD)", "@sens": "source", "@cidtexte": "LEGITEXT000006074096", "@typelien": "MODIFIE", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000039042642", "@num": "R311-34", "#text": "Code de la construction et de l'habitation. - art. R311-34 (VD)", "@sens": "source", "@cidtexte": "LEGITEXT000006074096", "@typelien": "MODIFIE", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000039042637", "@num": "R311-35", "#text": "Code de la construction et de l'habitation. - art. R311-35 (VD)", "@sens": "source", "@cidtexte": "LEGITEXT000006074096", "@typelien": "MODIFIE", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000039042634", "@num": "R311-36", "#text": "Code de la construction et de l'habitation. - art. R311-36 (VD)", "@sens": "source", "@cidtexte": "LEGITEXT000006074096", "@typelien": "MODIFIE", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000039042628", "@num": "R311-37", "#text": "Code de la construction et de l'habitation. - art. R311-37 (VD)", "@sens": "source", "@cidtexte": "LEGITEXT000006074096", "@typelien": "MODIFIE", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000039042622", "@num": "R311-38", "#text": "Code de la construction et de l'habitation. - art. R311-38 (VD)", "@sens": "source", "@cidtexte": "LEGITEXT000006074096", "@typelien": "MODIFIE", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000039042619", "@num": "R311-39", "#text": "Code de la construction et de l'habitation. - art. R311-39 (VD)", "@sens": "source", "@cidtexte": "LEGITEXT000006074096", "@typelien": "MODIFIE", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000039042613", "@num": "R311-40", "#text": "Code de la construction et de l'habitation. - art. R311-40 (VD)", "@sens": "source", "@cidtexte": "LEGITEXT000006074096", "@typelien": "MODIFIE", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000039042607", "@num": "R311-41", "#text": "Code de la construction et de l'habitation. - art. R311-41 (VD)", "@sens": "source", "@cidtexte": "LEGITEXT000006074096", "@typelien": "MODIFIE", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000039042602", "@num": "R311-42", "#text": "Code de la construction et de l'habitation. - art. R311-42 (VD)", "@sens": "source", "@cidtexte": "LEGITEXT000006074096", "@typelien": "MODIFIE", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000039042596", "@num": "R311-43", "#text": "Code de la construction et de l'habitation. - art. R311-43 (VD)", "@sens": "source", "@cidtexte": "LEGITEXT000006074096", "@typelien": "MODIFIE", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000039042589", "@num": "R311-44", "#text": "Code de la construction et de l'habitation. - art. R311-44 (VD)", "@sens": "source", "@cidtexte": "LEGITEXT000006074096", "@typelien": "MODIFIE", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000039042583", "@num": "R311-45", "#text": "Code de la construction et de l'habitation. - art. R311-45 (VD)", "@sens": "source", "@cidtexte": "LEGITEXT000006074096", "@typelien": "MODIFIE", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000039042578", "@num": "R311-46", "#text": "Code de la construction et de l'habitation. - art. R311-46 (VD)", "@sens": "source", "@cidtexte": "LEGITEXT000006074096", "@typelien": "MODIFIE", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000039042570", "@num": "R311-47", "#text": "Code de la construction et de l'habitation. - art. R311-47 (VD)", "@sens": "source", "@cidtexte": "LEGITEXT000006074096", "@typelien": "MODIFIE", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000039042565", "@num": "R311-48", "#text": "Code de la construction et de l'habitation. - art. R311-48 (VD)", "@sens": "source", "@cidtexte": "LEGITEXT000006074096", "@typelien": "MODIFIE", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000039042560", "@num": "R311-49", "#text": "Code de la construction et de l'habitation. - art. R311-49 (VD)", "@sens": "source", "@cidtexte": "LEGITEXT000006074096", "@typelien": "MODIFIE", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000039042761", "@num": "R311-5", "#text": "Code de la construction et de l'habitation. - art. R311-5 (VD)", "@sens": "source", "@cidtexte": "LEGITEXT000006074096", "@typelien": "MODIFIE", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000039042557", "@num": "R311-50", "#text": "Code de la construction et de l'habitation. - art. R311-50 (VD)", "@sens": "source", "@cidtexte": "LEGITEXT000006074096", "@typelien": "MODIFIE", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000039042552", "@num": "R311-51", "#text": "Code de la construction et de l'habitation. - art. R311-51 (VD)", "@sens": "source", "@cidtexte": "LEGITEXT000006074096", "@typelien": "MODIFIE", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000039042547", "@num": "R311-52", "#text": "Code de la construction et de l'habitation. - art. R311-52 (VD)", "@sens": "source", "@cidtexte": "LEGITEXT000006074096", "@typelien": "MODIFIE", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000039042543", "@num": "R311-53", "#text": "Code de la construction et de l'habitation. - art. R311-53 (VD)", "@sens": "source", "@cidtexte": "LEGITEXT000006074096", "@typelien": "MODIFIE", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000039042539", "@num": "R311-54", "#text": "Code de la construction et de l'habitation. - art. R311-54 (VD)", "@sens": "source", "@cidtexte": "LEGITEXT000006074096", "@typelien": "MODIFIE", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000039042534", "@num": "R311-55", "#text": "Code de la construction et de l'habitation. - art. R311-55 (VD)", "@sens": "source", "@cidtexte": "LEGITEXT000006074096", "@typelien": "MODIFIE", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000039042529", "@num": "R311-56", "#text": "Code de la construction et de l'habitation. - art. R311-56 (VD)", "@sens": "source", "@cidtexte": "LEGITEXT000006074096", "@typelien": "MODIFIE", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000039042526", "@num": "R311-57", "#text": "Code de la construction et de l'habitation. - art. R311-57 (VD)", "@sens": "source", "@cidtexte": "LEGITEXT000006074096", "@typelien": "MODIFIE", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000039042521", "@num": "R311-58", "#text": "Code de la construction et de l'habitation. - art. R311-58 (VD)", "@sens": "source", "@cidtexte": "LEGITEXT000006074096", "@typelien": "MODIFIE", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000039042517", "@num": "R311-59", "#text": "Code de la construction et de l'habitation. - art. R311-59 (VD)", "@sens": "source", "@cidtexte": "LEGITEXT000006074096", "@typelien": "MODIFIE", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000039042756", "@num": "R311-6", "#text": "Code de la construction et de l'habitation. - art. R311-6 (VD)", "@sens": "source", "@cidtexte": "LEGITEXT000006074096", "@typelien": "MODIFIE", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000039042509", "@num": "R311-60", "#text": "Code de la construction et de l'habitation. - art. R311-60 (VD)", "@sens": "source", "@cidtexte": "LEGITEXT000006074096", "@typelien": "MODIFIE", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000039042503", "@num": "R311-61", "#text": "Code de la construction et de l'habitation. - art. R311-61 (VD)", "@sens": "source", "@cidtexte": "LEGITEXT000006074096", "@typelien": "MODIFIE", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000039042496", "@num": "R311-62", "#text": "Code de la construction et de l'habitation. - art. R311-62 (VD)", "@sens": "source", "@cidtexte": "LEGITEXT000006074096", "@typelien": "MODIFIE", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000039042491", "@num": "R311-63", "#text": "Code de la construction et de l'habitation. - art. R311-63 (VD)", "@sens": "source", "@cidtexte": "LEGITEXT000006074096", "@typelien": "MODIFIE", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000039042486", "@num": "R311-64", "#text": "Code de la construction et de l'habitation. - art. R311-64 (VD)", "@sens": "source", "@cidtexte": "LEGITEXT000006074096", "@typelien": "MODIFIE", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000039042483", "@num": "R311-65", "#text": "Code de la construction et de l'habitation. - art. R311-65 (VD)", "@sens": "source", "@cidtexte": "LEGITEXT000006074096", "@typelien": "MODIFIE", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000039042479", "@num": "R311-66", "#text": "Code de la construction et de l'habitation. - art. R311-66 (VD)", "@sens": "source", "@cidtexte": "LEGITEXT000006074096", "@typelien": "MODIFIE", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000039042752", "@num": "R311-7", "#text": "Code de la construction et de l'habitation. - art. R311-7 (VD)", "@sens": "source", "@cidtexte": "LEGITEXT000006074096", "@typelien": "MODIFIE", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000039042747", "@num": "R311-8", "#text": "Code de la construction et de l'habitation. - art. R311-8 (VD)", "@sens": "source", "@cidtexte": "LEGITEXT000006074096", "@typelien": "MODIFIE", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000039042744", "@num": "R311-9", "#text": "Code de la construction et de l'habitation. - art. R311-9 (VD)", "@sens": "source", "@cidtexte": "LEGITEXT000006074096", "@typelien": "MODIFIE", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000039042433", "@num": "R312-7-10", "#text": "Code de la construction et de l'habitation. - art. R312-7-10 (M)", "@sens": "source", "@cidtexte": "LEGITEXT000006074096", "@typelien": "MODIFIE", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000039042476", "@num": "R312-7-3", "#text": "Code de la construction et de l'habitation. - art. R312-7-3 (VD)", "@sens": "source", "@cidtexte": "LEGITEXT000006074096", "@typelien": "MODIFIE", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000039042473", "@num": "R312-7-4", "#text": "Code de la construction et de l'habitation. - art. R312-7-4 (VD)", "@sens": "source", "@cidtexte": "LEGITEXT000006074096", "@typelien": "MODIFIE", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000039042464", "@num": "R312-7-5", "#text": "Code de la construction et de l'habitation. - art. R312-7-5 (M)", "@sens": "source", "@cidtexte": "LEGITEXT000006074096", "@typelien": "MODIFIE", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000039042460", "@num": "R312-7-6", "#text": "Code de la construction et de l'habitation. - art. R312-7-6 (VD)", "@sens": "source", "@cidtexte": "LEGITEXT000006074096", "@typelien": "MODIFIE", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000039042457", "@num": "R312-7-7", "#text": "Code de la construction et de l'habitation. - art. R312-7-7 (VD)", "@sens": "source", "@cidtexte": "LEGITEXT000006074096", "@typelien": "MODIFIE", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000039042449", "@num": "R312-7-8", "#text": "Code de la construction et de l'habitation. - art. R312-7-8 (M)", "@sens": "source", "@cidtexte": "LEGITEXT000006074096", "@typelien": "MODIFIE", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000039042445", "@num": "R312-7-9", "#text": "Code de la construction et de l'habitation. - art. R312-7-9 (VD)", "@sens": "source", "@cidtexte": "LEGITEXT000006074096", "@typelien": "MODIFIE", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000039042428", "@num": "R313-1", "#text": "Code de la construction et de l'habitation. - art. R313-1 (VD)", "@sens": "source", "@cidtexte": "LEGITEXT000006074096", "@typelien": "MODIFIE", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000039042424", "@num": "R315-1", "#text": "Code de la construction et de l'habitation. - art. R315-1 (VD)", "@sens": "source", "@cidtexte": "LEGITEXT000006074096", "@typelien": "MODIFIE", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000039042388", "@num": "R315-10", "#text": "Code de la construction et de l'habitation. - art. R315-10 (VD)", "@sens": "source", "@cidtexte": "LEGITEXT000006074096", "@typelien": "MODIFIE", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000039042384", "@num": "R315-11", "#text": "Code de la construction et de l'habitation. - art. R315-11 (VD)", "@sens": "source", "@cidtexte": "LEGITEXT000006074096", "@typelien": "MODIFIE", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000039042380", "@num": "R315-12", "#text": "Code de la construction et de l'habitation. - art. R315-12 (VD)", "@sens": "source", "@cidtexte": "LEGITEXT000006074096", "@typelien": "MODIFIE", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000039042376", "@num": "R315-13", "#text": "Code de la construction et de l'habitation. - art. R315-13 (VD)", "@sens": "source", "@cidtexte": "LEGITEXT000006074096", "@typelien": "MODIFIE", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000039042373", "@num": "R315-14", "#text": "Code de la construction et de l'habitation. - art. R315-14 (VD)", "@sens": "source", "@cidtexte": "LEGITEXT000006074096", "@typelien": "MODIFIE", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000039042370", "@num": "R315-15", "#text": "Code de la construction et de l'habitation. - art. R315-15 (VD)", "@sens": "source", "@cidtexte": "LEGITEXT000006074096", "@typelien": "MODIFIE", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000039042366", "@num": "R315-16", "#text": "Code de la construction et de l'habitation. - art. R315-16 (VD)", "@sens": "source", "@cidtexte": "LEGITEXT000006074096", "@typelien": "MODIFIE", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000039042361", "@num": "R315-17", "#text": "Code de la construction et de l'habitation. - art. R315-17 (VD)", "@sens": "source", "@cidtexte": "LEGITEXT000006074096", "@typelien": "MODIFIE", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000039042358", "@num": "R315-18", "#text": "Code de la construction et de l'habitation. - art. R315-18 (VD)", "@sens": "source", "@cidtexte": "LEGITEXT000006074096", "@typelien": "MODIFIE", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000039042354", "@num": "R315-19", "#text": "Code de la construction et de l'habitation. - art. R315-19 (VD)", "@sens": "source", "@cidtexte": "LEGITEXT000006074096", "@typelien": "MODIFIE", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000039042421", "@num": "R315-2", "#text": "Code de la construction et de l'habitation. - art. R315-2 (VD)", "@sens": "source", "@cidtexte": "LEGITEXT000006074096", "@typelien": "MODIFIE", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000039042350", "@num": "R315-20", "#text": "Code de la construction et de l'habitation. - art. R315-20 (VD)", "@sens": "source", "@cidtexte": "LEGITEXT000006074096", "@typelien": "MODIFIE", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000039042346", "@num": "R315-21", "#text": "Code de la construction et de l'habitation. - art. R315-21 (VD)", "@sens": "source", "@cidtexte": "LEGITEXT000006074096", "@typelien": "MODIFIE", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000039042343", "@num": "R315-22", "#text": "Code de la construction et de l'habitation. - art. R315-22 (VD)", "@sens": "source", "@cidtexte": "LEGITEXT000006074096", "@typelien": "MODIFIE", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000039042340", "@num": "R315-24", "#text": "Code de la construction et de l'habitation. - art. R315-24 (VD)", "@sens": "source", "@cidtexte": "LEGITEXT000006074096", "@typelien": "MODIFIE", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000039042336", "@num": "R315-25", "#text": "Code de la construction et de l'habitation. - art. R315-25 (VD)", "@sens": "source", "@cidtexte": "LEGITEXT000006074096", "@typelien": "MODIFIE", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000039042333", "@num": "R315-26", "#text": "Code de la construction et de l'habitation. - art. R315-26 (VD)", "@sens": "source", "@cidtexte": "LEGITEXT000006074096", "@typelien": "MODIFIE", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000039042328", "@num": "R315-27", "#text": "Code de la construction et de l'habitation. - art. R315-27 (VD)", "@sens": "source", "@cidtexte": "LEGITEXT000006074096", "@typelien": "MODIFIE", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000039042324", "@num": "R315-28", "#text": "Code de la construction et de l'habitation. - art. R315-28 (VD)", "@sens": "source", "@cidtexte": "LEGITEXT000006074096", "@typelien": "MODIFIE", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000039042319", "@num": "R315-29", "#text": "Code de la construction et de l'habitation. - art. R315-29 (VD)", "@sens": "source", "@cidtexte": "LEGITEXT000006074096", "@typelien": "MODIFIE", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000039042418", "@num": "R315-3", "#text": "Code de la construction et de l'habitation. - art. R315-3 (VD)", "@sens": "source", "@cidtexte": "LEGITEXT000006074096", "@typelien": "MODIFIE", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000039042316", "@num": "R315-30", "#text": "Code de la construction et de l'habitation. - art. R315-30 (VD)", "@sens": "source", "@cidtexte": "LEGITEXT000006074096", "@typelien": "MODIFIE", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000039042311", "@num": "R315-31", "#text": "Code de la construction et de l'habitation. - art. R315-31 (VD)", "@sens": "source", "@cidtexte": "LEGITEXT000006074096", "@typelien": "MODIFIE", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000039042305", "@num": "R315-32", "#text": "Code de la construction et de l'habitation. - art. R315-32 (VD)", "@sens": "source", "@cidtexte": "LEGITEXT000006074096", "@typelien": "MODIFIE", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000039042300", "@num": "R315-33", "#text": "Code de la construction et de l'habitation. - art. R315-33 (VD)", "@sens": "source", "@cidtexte": "LEGITEXT000006074096", "@typelien": "MODIFIE", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000039042285", "@num": "R315-34", "#text": "Code de la construction et de l'habitation. - art. R315-34 (V)", "@sens": "source", "@cidtexte": "LEGITEXT000006074096", "@typelien": "MODIFIE", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000039042281", "@num": "R315-35", "#text": "Code de la construction et de l'habitation. - art. R315-35 (VD)", "@sens": "source", "@cidtexte": "LEGITEXT000006074096", "@typelien": "MODIFIE", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000039042278", "@num": "R315-36", "#text": "Code de la construction et de l'habitation. - art. R315-36 (VD)", "@sens": "source", "@cidtexte": "LEGITEXT000006074096", "@typelien": "MODIFIE", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000039042274", "@num": "R315-37", "#text": "Code de la construction et de l'habitation. - art. R315-37 (VD)", "@sens": "source", "@cidtexte": "LEGITEXT000006074096", "@typelien": "MODIFIE", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000039042269", "@num": "R315-38", "#text": "Code de la construction et de l'habitation. - art. R315-38 (VD)", "@sens": "source", "@cidtexte": "LEGITEXT000006074096", "@typelien": "MODIFIE", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000039042257", "@num": "R315-39", "#text": "Code de la construction et de l'habitation. - art. R315-39 (V)", "@sens": "source", "@cidtexte": "LEGITEXT000006074096", "@typelien": "MODIFIE", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000039042414", "@num": "R315-4", "#text": "Code de la construction et de l'habitation. - art. R315-4 (VD)", "@sens": "source", "@cidtexte": "LEGITEXT000006074096", "@typelien": "MODIFIE", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000039042253", "@num": "R315-40", "#text": "Code de la construction et de l'habitation. - art. R315-40 (VD)", "@sens": "source", "@cidtexte": "LEGITEXT000006074096", "@typelien": "MODIFIE", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000039042250", "@num": "R315-40-1", "#text": "Code de la construction et de l'habitation. - art. R315-40-1 (VD)", "@sens": "source", "@cidtexte": "LEGITEXT000006074096", "@typelien": "MODIFIE", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000039042247", "@num": "R315-41", "#text": "Code de la construction et de l'habitation. - art. R315-41 (VD)", "@sens": "source", "@cidtexte": "LEGITEXT000006074096", "@typelien": "MODIFIE", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000039042244", "@num": "R315-41-1", "#text": "Code de la construction et de l'habitation. - art. R315-41-1 (VD)", "@sens": "source", "@cidtexte": "LEGITEXT000006074096", "@typelien": "MODIFIE", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000039042241", "@num": "R315-42", "#text": "Code de la construction et de l'habitation. - art. R315-42 (VD)", "@sens": "source", "@cidtexte": "LEGITEXT000006074096", "@typelien": "MODIFIE", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000039042411", "@num": "R315-5", "#text": "Code de la construction et de l'habitation. - art. R315-5 (VD)", "@sens": "source", "@cidtexte": "LEGITEXT000006074096", "@typelien": "MODIFIE", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000039042408", "@num": "R315-6", "#text": "Code de la construction et de l'habitation. - art. R315-6 (VD)", "@sens": "source", "@cidtexte": "LEGITEXT000006074096", "@typelien": "MODIFIE", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000039042401", "@num": "R315-7", "#text": "Code de la construction et de l'habitation. - art. R315-7 (VD)", "@sens": "source", "@cidtexte": "LEGITEXT000006074096", "@typelien": "MODIFIE", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000039042396", "@num": "R315-8", "#text": "Code de la construction et de l'habitation. - art. R315-8 (VD)", "@sens": "source", "@cidtexte": "LEGITEXT000006074096", "@typelien": "MODIFIE", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000039042392", "@num": "R315-9", "#text": "Code de la construction et de l'habitation. - art. R315-9 (VD)", "@sens": "source", "@cidtexte": "LEGITEXT000006074096", "@typelien": "MODIFIE", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000039042226", "@num": "R318-10", "#text": "Code de la construction et de l'habitation. - art. R318-10 (V)", "@sens": "source", "@cidtexte": "LEGITEXT000006074096", "@typelien": "MODIFIE", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000039042221", "@num": "R318-10-1", "#text": "Code de la construction et de l'habitation. - art. R318-10-1 (VD)", "@sens": "source", "@cidtexte": "LEGITEXT000006074096", "@typelien": "MODIFIE", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000039042217", "@num": "R318-12", "#text": "Code de la construction et de l'habitation. - art. R318-12 (VD)", "@sens": "source", "@cidtexte": "LEGITEXT000006074096", "@typelien": "MODIFIE", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000039042214", "@num": "R318-15", "#text": "Code de la construction et de l'habitation. - art. R318-15 (VD)", "@sens": "source", "@cidtexte": "LEGITEXT000006074096", "@typelien": "MODIFIE", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000039042238", "@num": "R318-9", "#text": "Code de la construction et de l'habitation. - art. R318-9 (VD)", "@sens": "source", "@cidtexte": "LEGITEXT000006074096", "@typelien": "MODIFIE", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000039042196", "@num": "R321-10-1", "#text": "Code de la construction et de l'habitation. - art. R321-10-1 (VD)", "@sens": "source", "@cidtexte": "LEGITEXT000006074096", "@typelien": "MODIFIE", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000039042121", "@num": "R321-12", "#text": "Code de la construction et de l'habitation. - art. R321-12 (M)", "@sens": "source", "@cidtexte": "LEGITEXT000006074096", "@typelien": "MODIFIE", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000039042206", "@num": "R321-8", "#text": "Code de la construction et de l'habitation. - art. R321-8 (VD)", "@sens": "source", "@cidtexte": "LEGITEXT000006074096", "@typelien": "MODIFIE", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000039042204", "@num": "R321-9", "#text": "Code de la construction et de l'habitation. - art. R321-9 (VD)", "@sens": "source", "@cidtexte": "LEGITEXT000006074096", "@typelien": "MODIFIE", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000039042115", "@num": "R325-1", "#text": "Code de la construction et de l'habitation. - art. R325-1 (VD)", "@sens": "source", "@cidtexte": "LEGITEXT000006074096", "@typelien": "MODIFIE", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000039042112", "@num": "R325-2", "#text": "Code de la construction et de l'habitation. - art. R325-2 (VD)", "@sens": "source", "@cidtexte": "LEGITEXT000006074096", "@typelien": "MODIFIE", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000039042107", "@num": "R325-3", "#text": "Code de la construction et de l'habitation. - art. R325-3 (VD)", "@sens": "source", "@cidtexte": "LEGITEXT000006074096", "@typelien": "MODIFIE", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000039042102", "@num": "R325-4", "#text": "Code de la construction et de l'habitation. - art. R325-4 (VD)", "@sens": "source", "@cidtexte": "LEGITEXT000006074096", "@typelien": "MODIFIE", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000039042094", "@num": "R325-5", "#text": "Code de la construction et de l'habitation. - art. R325-5 (VD)", "@sens": "source", "@cidtexte": "LEGITEXT000006074096", "@typelien": "MODIFIE", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000039042091", "@num": "R325-6", "#text": "Code de la construction et de l'habitation. - art. R325-6 (VD)", "@sens": "source", "@cidtexte": "LEGITEXT000006074096", "@typelien": "MODIFIE", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000039042087", "@num": "R327-1", "#text": "Code de la construction et de l'habitation. - art. R327-1 (VD)", "@sens": "source", "@cidtexte": "LEGITEXT000006074096", "@typelien": "MODIFIE", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000038959667", "@num": "R361-4-1", "#text": "Code de la construction et de l'habitation. - art. R361-4-1 (V)", "@sens": "source", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CREE", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000039042083", "@num": "R366-1", "#text": "Code de la construction et de l'habitation. - art. R366-1 (VD)", "@sens": "source", "@cidtexte": "LEGITEXT000006074096", "@typelien": "MODIFIE", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000039042080", "@num": "R366-2", "#text": "Code de la construction et de l'habitation. - art. R366-2 (VD)", "@sens": "source", "@cidtexte": "LEGITEXT000006074096", "@typelien": "MODIFIE", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000039042077", "@num": "R366-3", "#text": "Code de la construction et de l'habitation. - art. R366-3 (VD)", "@sens": "source", "@cidtexte": "LEGITEXT000006074096", "@typelien": "MODIFIE", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000039042074", "@num": "R366-4", "#text": "Code de la construction et de l'habitation. - art. R366-4 (VD)", "@sens": "source", "@cidtexte": "LEGITEXT000006074096", "@typelien": "MODIFIE", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000039042070", "@num": "R366-5", "#text": "Code de la construction et de l'habitation. - art. R366-5 (VD)", "@sens": "source", "@cidtexte": "LEGITEXT000006074096", "@typelien": "MODIFIE", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000039042067", "@num": "R366-6", "#text": "Code de la construction et de l'habitation. - art. R366-6 (VD)", "@sens": "source", "@cidtexte": "LEGITEXT000006074096", "@typelien": "MODIFIE", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000039042063", "@num": "R366-7", "#text": "Code de la construction et de l'habitation. - art. R366-7 (VD)", "@sens": "source", "@cidtexte": "LEGITEXT000006074096", "@typelien": "MODIFIE", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000039042060", "@num": "R366-8", "#text": "Code de la construction et de l'habitation. - art. R366-8 (VD)", "@sens": "source", "@cidtexte": "LEGITEXT000006074096", "@typelien": "MODIFIE", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000039043464", "@num": "R421-1", "#text": "Code de la construction et de l'habitation. - art. R421-1 (VD)", "@sens": "source", "@cidtexte": "LEGITEXT000006074096", "@typelien": "MODIFIE", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000039043403", "@num": "R421-10", "#text": "Code de la construction et de l'habitation. - art. R421-10 (VD)", "@sens": "source", "@cidtexte": "LEGITEXT000006074096", "@typelien": "MODIFIE", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000039043400", "@num": "R421-11", "#text": "Code de la construction et de l'habitation. - art. R421-11 (VD)", "@sens": "source", "@cidtexte": "LEGITEXT000006074096", "@typelien": "MODIFIE", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000039043396", "@num": "R421-12", "#text": "Code de la construction et de l'habitation. - art. R421-12 (VD)", "@sens": "source", "@cidtexte": "LEGITEXT000006074096", "@typelien": "MODIFIE", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000039043394", "@num": "R421-14", "#text": "Code de la construction et de l'habitation. - art. R421-14 (VD)", "@sens": "source", "@cidtexte": "LEGITEXT000006074096", "@typelien": "MODIFIE", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000039043390", "@num": "R421-15", "#text": "Code de la construction et de l'habitation. - art. R421-15 (VD)", "@sens": "source", "@cidtexte": "LEGITEXT000006074096", "@typelien": "MODIFIE", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000039043384", "@num": "R421-16", "#text": "Code de la construction et de l'habitation. - art. R421-16 (VD)", "@sens": "source", "@cidtexte": "LEGITEXT000006074096", "@typelien": "MODIFIE", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000039043381", "@num": "R421-17", "#text": "Code de la construction et de l'habitation. - art. R421-17 (VD)", "@sens": "source", "@cidtexte": "LEGITEXT000006074096", "@typelien": "MODIFIE", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000039043378", "@num": "R421-18", "#text": "Code de la construction et de l'habitation. - art. R421-18 (VD)", "@sens": "source", "@cidtexte": "LEGITEXT000006074096", "@typelien": "MODIFIE", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000039043453", "@num": "R421-2", "#text": "Code de la construction et de l'habitation. - art. R421-2 (VD)", "@sens": "source", "@cidtexte": "LEGITEXT000006074096", "@typelien": "MODIFIE", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000039043376", "@num": "R421-21", "#text": "Code de la construction et de l'habitation. - art. R421-21 (VD)", "@sens": "source", "@cidtexte": "LEGITEXT000006074096", "@typelien": "MODIFIE", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000039043371", "@num": "R421-22", "#text": "Code de la construction et de l'habitation. - art. R421-22 (VD)", "@sens": "source", "@cidtexte": "LEGITEXT000006074096", "@typelien": "MODIFIE", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000039043439", "@num": "R421-3", "#text": "Code de la construction et de l'habitation. - art. R421-3 (V)", "@sens": "source", "@cidtexte": "LEGITEXT000006074096", "@typelien": "MODIFIE", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000039043436", "@num": "R421-4", "#text": "Code de la construction et de l'habitation. - art. R421-4 (VD)", "@sens": "source", "@cidtexte": "LEGITEXT000006074096", "@typelien": "MODIFIE", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000039043433", "@num": "R421-5", "#text": "Code de la construction et de l'habitation. - art. R421-5 (VD)", "@sens": "source", "@cidtexte": "LEGITEXT000006074096", "@typelien": "MODIFIE", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000039043430", "@num": "R421-6", "#text": "Code de la construction et de l'habitation. - art. R421-6 (VD)", "@sens": "source", "@cidtexte": "LEGITEXT000006074096", "@typelien": "MODIFIE", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000039043422", "@num": "R421-7", "#text": "Code de la construction et de l'habitation. - art. R421-7 (VD)", "@sens": "source", "@cidtexte": "LEGITEXT000006074096", "@typelien": "MODIFIE", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000039043411", "@num": "R421-8", "#text": "Code de la construction et de l'habitation. - art. R421-8 (VD)", "@sens": "source", "@cidtexte": "LEGITEXT000006074096", "@typelien": "MODIFIE", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000039043408", "@num": "R421-9", "#text": "Code de la construction et de l'habitation. - art. R421-9 (VD)", "@sens": "source", "@cidtexte": "LEGITEXT000006074096", "@typelien": "MODIFIE", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000039043368", "@num": "R422-1", "#text": "Code de la construction et de l'habitation. - art. R422-1 (VD)", "@sens": "source", "@cidtexte": "LEGITEXT000006074096", "@typelien": "MODIFIE", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000039043364", "@num": "R422-1-1", "#text": "Code de la construction et de l'habitation. - art. R422-1-1 (VD)", "@sens": "source", "@cidtexte": "LEGITEXT000006074096", "@typelien": "MODIFIE", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000039043360", "@num": "R422-1-2", "#text": "Code de la construction et de l'habitation. - art. R422-1-2 (VD)", "@sens": "source", "@cidtexte": "LEGITEXT000006074096", "@typelien": "MODIFIE", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000039043322", "@num": "R422-16-1", "#text": "Code de la construction et de l'habitation. - art. R422-16-1 (VD)", "@sens": "source", "@cidtexte": "LEGITEXT000006074096", "@typelien": "MODIFIE", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000039043317", "@num": "R422-18", "#text": "Code de la construction et de l'habitation. - art. R422-18 (VD)", "@sens": "source", "@cidtexte": "LEGITEXT000006074096", "@typelien": "MODIFIE", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000039043314", "@num": "R422-19", "#text": "Code de la construction et de l'habitation. - art. R422-19 (VD)", "@sens": "source", "@cidtexte": "LEGITEXT000006074096", "@typelien": "MODIFIE", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000039043355", "@num": "R422-2", "#text": "Code de la construction et de l'habitation. - art. R422-2 (VD)", "@sens": "source", "@cidtexte": "LEGITEXT000006074096", "@typelien": "MODIFIE", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000039043310", "@num": "R422-20", "#text": "Code de la construction et de l'habitation. - art. R422-20 (VD)", "@sens": "source", "@cidtexte": "LEGITEXT000006074096", "@typelien": "MODIFIE", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000039043305", "@num": "R422-21", "#text": "Code de la construction et de l'habitation. - art. R422-21 (VD)", "@sens": "source", "@cidtexte": "LEGITEXT000006074096", "@typelien": "MODIFIE", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000039043301", "@num": "R422-22", "#text": "Code de la construction et de l'habitation. - art. R422-22 (VD)", "@sens": "source", "@cidtexte": "LEGITEXT000006074096", "@typelien": "MODIFIE", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000039043298", "@num": "R422-23", "#text": "Code de la construction et de l'habitation. - art. R422-23 (VD)", "@sens": "source", "@cidtexte": "LEGITEXT000006074096", "@typelien": "MODIFIE", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000039043295", "@num": "R422-24", "#text": "Code de la construction et de l'habitation. - art. R422-24 (VD)", "@sens": "source", "@cidtexte": "LEGITEXT000006074096", "@typelien": "MODIFIE", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000039043292", "@num": "R422-25", "#text": "Code de la construction et de l'habitation. - art. R422-25 (VD)", "@sens": "source", "@cidtexte": "LEGITEXT000006074096", "@typelien": "MODIFIE", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000039043289", "@num": "R422-26", "#text": "Code de la construction et de l'habitation. - art. R422-26 (VD)", "@sens": "source", "@cidtexte": "LEGITEXT000006074096", "@typelien": "MODIFIE", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000039043286", "@num": "R422-27", "#text": "Code de la construction et de l'habitation. - art. R422-27 (VD)", "@sens": "source", "@cidtexte": "LEGITEXT000006074096", "@typelien": "MODIFIE", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000039043283", "@num": "R422-28", "#text": "Code de la construction et de l'habitation. - art. R422-28 (VD)", "@sens": "source", "@cidtexte": "LEGITEXT000006074096", "@typelien": "MODIFIE", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000039043280", "@num": "R422-29", "#text": "Code de la construction et de l'habitation. - art. R422-29 (VD)", "@sens": "source", "@cidtexte": "LEGITEXT000006074096", "@typelien": "MODIFIE", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000039043350", "@num": "R422-3", "#text": "Code de la construction et de l'habitation. - art. R422-3 (VD)", "@sens": "source", "@cidtexte": "LEGITEXT000006074096", "@typelien": "MODIFIE", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000039043276", "@num": "R422-30", "#text": "Code de la construction et de l'habitation. - art. R422-30 (VD)", "@sens": "source", "@cidtexte": "LEGITEXT000006074096", "@typelien": "MODIFIE", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000039043272", "@num": "R422-33", "#text": "Code de la construction et de l'habitation. - art. R422-33 (VD)", "@sens": "source", "@cidtexte": "LEGITEXT000006074096", "@typelien": "MODIFIE", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000039043269", "@num": "R422-38", "#text": "Code de la construction et de l'habitation. - art. R422-38 (VD)", "@sens": "source", "@cidtexte": "LEGITEXT000006074096", "@typelien": "MODIFIE", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000039043345", "@num": "R422-4", "#text": "Code de la construction et de l'habitation. - art. R422-4 (VD)", "@sens": "source", "@cidtexte": "LEGITEXT000006074096", "@typelien": "MODIFIE", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000039043341", "@num": "R422-5", "#text": "Code de la construction et de l'habitation. - art. R422-5 (VD)", "@sens": "source", "@cidtexte": "LEGITEXT000006074096", "@typelien": "MODIFIE", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000039043338", "@num": "R422-6", "#text": "Code de la construction et de l'habitation. - art. R422-6 (VD)", "@sens": "source", "@cidtexte": "LEGITEXT000006074096", "@typelien": "MODIFIE", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000039043335", "@num": "R422-7", "#text": "Code de la construction et de l'habitation. - art. R422-7 (VD)", "@sens": "source", "@cidtexte": "LEGITEXT000006074096", "@typelien": "MODIFIE", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000039043331", "@num": "R422-8", "#text": "Code de la construction et de l'habitation. - art. R422-8 (VD)", "@sens": "source", "@cidtexte": "LEGITEXT000006074096", "@typelien": "MODIFIE", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000039043327", "@num": "R422-8-1", "#text": "Code de la construction et de l'habitation. - art. R422-8-1 (VD)", "@sens": "source", "@cidtexte": "LEGITEXT000006074096", "@typelien": "MODIFIE", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000039043265", "@num": "R423-1", "#text": "Code de la construction et de l'habitation. - art. R423-1 (VD)", "@sens": "source", "@cidtexte": "LEGITEXT000006074096", "@typelien": "MODIFIE", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000039043261", "@num": "R423-1-4", "#text": "Code de la construction et de l'habitation. - art. R423-1-4 (VD)", "@sens": "source", "@cidtexte": "LEGITEXT000006074096", "@typelien": "MODIFIE", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000039043228", "@num": "R423-11", "#text": "Code de la construction et de l'habitation. - art. R423-11 (VD)", "@sens": "source", "@cidtexte": "LEGITEXT000006074096", "@typelien": "MODIFIE", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000039043224", "@num": "R423-12", "#text": "Code de la construction et de l'habitation. - art. R423-12 (VD)", "@sens": "source", "@cidtexte": "LEGITEXT000006074096", "@typelien": "MODIFIE", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000039043218", "@num": "R423-12-1", "#text": "Code de la construction et de l'habitation. - art. R423-12-1 (V)", "@sens": "source", "@cidtexte": "LEGITEXT000006074096", "@typelien": "MODIFIE", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000039043215", "@num": "R423-13", "#text": "Code de la construction et de l'habitation. - art. R423-13 (VD)", "@sens": "source", "@cidtexte": "LEGITEXT000006074096", "@typelien": "MODIFIE", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000039043212", "@num": "R423-14", "#text": "Code de la construction et de l'habitation. - art. R423-14 (VD)", "@sens": "source", "@cidtexte": "LEGITEXT000006074096", "@typelien": "MODIFIE", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000039043206", "@num": "R423-15", "#text": "Code de la construction et de l'habitation. - art. R423-15 (V)", "@sens": "source", "@cidtexte": "LEGITEXT000006074096", "@typelien": "MODIFIE", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000039043198", "@num": "R423-16", "#text": "Code de la construction et de l'habitation. - art. R423-16 (V)", "@sens": "source", "@cidtexte": "LEGITEXT000006074096", "@typelien": "MODIFIE", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000039043195", "@num": "R423-17", "#text": "Code de la construction et de l'habitation. - art. R423-17 (VD)", "@sens": "source", "@cidtexte": "LEGITEXT000006074096", "@typelien": "MODIFIE", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000039043189", "@num": "R423-17-1", "#text": "Code de la construction et de l'habitation. - art. R423-17-1 (V)", "@sens": "source", "@cidtexte": "LEGITEXT000006074096", "@typelien": "MODIFIE", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000039043186", "@num": "R423-18", "#text": "Code de la construction et de l'habitation. - art. R423-18 (VD)", "@sens": "source", "@cidtexte": "LEGITEXT000006074096", "@typelien": "MODIFIE", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000039043183", "@num": "R423-19", "#text": "Code de la construction et de l'habitation. - art. R423-19 (VD)", "@sens": "source", "@cidtexte": "LEGITEXT000006074096", "@typelien": "MODIFIE", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000039043257", "@num": "R423-2", "#text": "Code de la construction et de l'habitation. - art. R423-2 (VD)", "@sens": "source", "@cidtexte": "LEGITEXT000006074096", "@typelien": "MODIFIE", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000039043181", "@num": "R423-20", "#text": "Code de la construction et de l'habitation. - art. R423-20 (VD)", "@sens": "source", "@cidtexte": "LEGITEXT000006074096", "@typelien": "MODIFIE", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000039043178", "@num": "R423-21", "#text": "Code de la construction et de l'habitation. - art. R423-21 (VD)", "@sens": "source", "@cidtexte": "LEGITEXT000006074096", "@typelien": "MODIFIE", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000039043175", "@num": "R423-22", "#text": "Code de la construction et de l'habitation. - art. R423-22 (VD)", "@sens": "source", "@cidtexte": "LEGITEXT000006074096", "@typelien": "MODIFIE", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000039043173", "@num": "R423-23", "#text": "Code de la construction et de l'habitation. - art. R423-23 (VD)", "@sens": "source", "@cidtexte": "LEGITEXT000006074096", "@typelien": "MODIFIE", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000039043170", "@num": "R423-24", "#text": "Code de la construction et de l'habitation. - art. R423-24 (VD)", "@sens": "source", "@cidtexte": "LEGITEXT000006074096", "@typelien": "MODIFIE", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000039043166", "@num": "R423-25", "#text": "Code de la construction et de l'habitation. - art. R423-25 (VD)", "@sens": "source", "@cidtexte": "LEGITEXT000006074096", "@typelien": "MODIFIE", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000039043163", "@num": "R423-26", "#text": "Code de la construction et de l'habitation. - art. R423-26 (VD)", "@sens": "source", "@cidtexte": "LEGITEXT000006074096", "@typelien": "MODIFIE", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000039043160", "@num": "R423-27", "#text": "Code de la construction et de l'habitation. - art. R423-27 (VD)", "@sens": "source", "@cidtexte": "LEGITEXT000006074096", "@typelien": "MODIFIE", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000039043157", "@num": "R423-28", "#text": "Code de la construction et de l'habitation. - art. R423-28 (VD)", "@sens": "source", "@cidtexte": "LEGITEXT000006074096", "@typelien": "MODIFIE", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000039043155", "@num": "R423-29", "#text": "Code de la construction et de l'habitation. - art. R423-29 (VD)", "@sens": "source", "@cidtexte": "LEGITEXT000006074096", "@typelien": "MODIFIE", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000039043247", "@num": "R423-3", "#text": "Code de la construction et de l'habitation. - art. R423-3 (V)", "@sens": "source", "@cidtexte": "LEGITEXT000006074096", "@typelien": "MODIFIE", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000039043245", "@num": "R423-4", "#text": "Code de la construction et de l'habitation. - art. R423-4 (VD)", "@sens": "source", "@cidtexte": "LEGITEXT000006074096", "@typelien": "MODIFIE", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000039043243", "@num": "R423-5", "#text": "Code de la construction et de l'habitation. - art. R423-5 (VD)", "@sens": "source", "@cidtexte": "LEGITEXT000006074096", "@typelien": "MODIFIE", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000039043241", "@num": "R423-6", "#text": "Code de la construction et de l'habitation. - art. R423-6 (VD)", "@sens": "source", "@cidtexte": "LEGITEXT000006074096", "@typelien": "MODIFIE", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000039043152", "@num": "R423-68", "#text": "Code de la construction et de l'habitation. - art. R423-68 (VD)", "@sens": "source", "@cidtexte": "LEGITEXT000006074096", "@typelien": "MODIFIE", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000039043238", "@num": "R423-7", "#text": "Code de la construction et de l'habitation. - art. R423-7 (VD)", "@sens": "source", "@cidtexte": "LEGITEXT000006074096", "@typelien": "MODIFIE", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000039043149", "@num": "R423-72", "#text": "Code de la construction et de l'habitation. - art. R423-72 (VD)", "@sens": "source", "@cidtexte": "LEGITEXT000006074096", "@typelien": "MODIFIE", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000039043146", "@num": "R423-74", "#text": "Code de la construction et de l'habitation. - art. R423-74 (VD)", "@sens": "source", "@cidtexte": "LEGITEXT000006074096", "@typelien": "MODIFIE", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000039043141", "@num": "R423-75-1", "#text": "Code de la construction et de l'habitation. - art. R423-75-1 (VD)", "@sens": "source", "@cidtexte": "LEGITEXT000006074096", "@typelien": "MODIFIE", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000039043138", "@num": "R423-78", "#text": "Code de la construction et de l'habitation. - art. R423-78 (VD)", "@sens": "source", "@cidtexte": "LEGITEXT000006074096", "@typelien": "MODIFIE", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000039043135", "@num": "R423-84", "#text": "Code de la construction et de l'habitation. - art. R423-84 (VD)", "@sens": "source", "@cidtexte": "LEGITEXT000006074096", "@typelien": "MODIFIE", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000039043230", "@num": "R423-9", "#text": "Code de la construction et de l'habitation. - art. R423-9 (V)", "@sens": "source", "@cidtexte": "LEGITEXT000006074096", "@typelien": "MODIFIE", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000039043127", "@num": "R431-7", "#text": "Code de la construction et de l'habitation. - art. R431-7 (VD)", "@sens": "source", "@cidtexte": "LEGITEXT000006074096", "@typelien": "MODIFIE", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000039043123", "@num": "R432-1", "#text": "Code de la construction et de l'habitation. - art. R432-1 (VD)", "@sens": "source", "@cidtexte": "LEGITEXT000006074096", "@typelien": "MODIFIE", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000039043118", "@num": "R432-2", "#text": "Code de la construction et de l'habitation. - art. R432-2 (VD)", "@sens": "source", "@cidtexte": "LEGITEXT000006074096", "@typelien": "MODIFIE", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000039043098", "@num": "R441-12", "#text": "Code de la construction et de l'habitation. - art. R441-12 (VD)", "@sens": "source", "@cidtexte": "LEGITEXT000006074096", "@typelien": "MODIFIE", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000039043085", "@num": "R441-13", "#text": "Code de la construction et de l'habitation. - art. R441-13 (VD)", "@sens": "source", "@cidtexte": "LEGITEXT000006074096", "@typelien": "MODIFIE", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000039043080", "@num": "R441-13-1", "#text": "Code de la construction et de l'habitation. - art. R441-13-1 (VD)", "@sens": "source", "@cidtexte": "LEGITEXT000006074096", "@typelien": "MODIFIE", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000039043075", "@num": "R441-14", "#text": "Code de la construction et de l'habitation. - art. R441-14 (VD)", "@sens": "source", "@cidtexte": "LEGITEXT000006074096", "@typelien": "MODIFIE", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000039065806", "@num": "R441-14-1", "#text": "Code de la construction et de l'habitation. - art. R441-14-1 (V)", "@sens": "source", "@cidtexte": "LEGITEXT000006074096", "@typelien": "MODIFIE", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000039043065", "@num": "R441-16", "#text": "Code de la construction et de l'habitation. - art. R441-16 (VD)", "@sens": "source", "@cidtexte": "LEGITEXT000006074096", "@typelien": "MODIFIE", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000039043061", "@num": "R441-16-2", "#text": "Code de la construction et de l'habitation. - art. R441-16-2 (VD)", "@sens": "source", "@cidtexte": "LEGITEXT000006074096", "@typelien": "MODIFIE", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000039043058", "@num": "R441-16-3", "#text": "Code de la construction et de l'habitation. - art. R441-16-3 (VD)", "@sens": "source", "@cidtexte": "LEGITEXT000006074096", "@typelien": "MODIFIE", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000039043053", "@num": "R441-16-4", "#text": "Code de la construction et de l'habitation. - art. R441-16-4 (VD)", "@sens": "source", "@cidtexte": "LEGITEXT000006074096", "@typelien": "MODIFIE", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000039043049", "@num": "R441-18-1", "#text": "Code de la construction et de l'habitation. - art. R441-18-1 (VD)", "@sens": "source", "@cidtexte": "LEGITEXT000006074096", "@typelien": "MODIFIE", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000039043043", "@num": "R441-18-2", "#text": "Code de la construction et de l'habitation. - art. R441-18-2 (VD)", "@sens": "source", "@cidtexte": "LEGITEXT000006074096", "@typelien": "MODIFIE", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000039043040", "@num": "R441-18-3", "#text": "Code de la construction et de l'habitation. - art. R441-18-3 (VD)", "@sens": "source", "@cidtexte": "LEGITEXT000006074096", "@typelien": "MODIFIE", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000039043038", "@num": "R441-18-4", "#text": "Code de la construction et de l'habitation. - art. R441-18-4 (VD)", "@sens": "source", "@cidtexte": "LEGITEXT000006074096", "@typelien": "MODIFIE", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000039043035", "@num": "R441-18-5", "#text": "Code de la construction et de l'habitation. - art. R441-18-5 (VD)", "@sens": "source", "@cidtexte": "LEGITEXT000006074096", "@typelien": "MODIFIE", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000039043032", "@num": "R441-20", "#text": "Code de la construction et de l'habitation. - art. R441-20 (VD)", "@sens": "source", "@cidtexte": "LEGITEXT000006074096", "@typelien": "MODIFIE", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000039043028", "@num": "R441-21", "#text": "Code de la construction et de l'habitation. - art. R441-21 (VD)", "@sens": "source", "@cidtexte": "LEGITEXT000006074096", "@typelien": "MODIFIE", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000039043017", "@num": "R441-23", "#text": "Code de la construction et de l'habitation. - art. R441-23 (VD)", "@sens": "source", "@cidtexte": "LEGITEXT000006074096", "@typelien": "MODIFIE", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000039043014", "@num": "R441-26", "#text": "Code de la construction et de l'habitation. - art. R441-26 (VD)", "@sens": "source", "@cidtexte": "LEGITEXT000006074096", "@typelien": "MODIFIE", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000039043115", "@num": "R441-3-1", "#text": "Code de la construction et de l'habitation. - art. R441-3-1 (VD)", "@sens": "source", "@cidtexte": "LEGITEXT000006074096", "@typelien": "MODIFIE", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000039043010", "@num": "R441-31", "#text": "Code de la construction et de l'habitation. - art. R441-31 (VD)", "@sens": "source", "@cidtexte": "LEGITEXT000006074096", "@typelien": "MODIFIE", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000039043108", "@num": "R441-5", "#text": "Code de la construction et de l'habitation. - art. R441-5 (VD)", "@sens": "source", "@cidtexte": "LEGITEXT000006074096", "@typelien": "MODIFIE", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000039043106", "@num": "R441-6", "#text": "Code de la construction et de l'habitation. - art. R441-6 (VD)", "@sens": "source", "@cidtexte": "LEGITEXT000006074096", "@typelien": "MODIFIE", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000039043002", "@num": "R442-13", "#text": "Code de la construction et de l'habitation. - art. R442-13 (VD)", "@sens": "source", "@cidtexte": "LEGITEXT000006074096", "@typelien": "MODIFIE", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000039065707", "@num": "R442-14", "#text": "Code de la construction et de l'habitation. - art. R442-14 (V)", "@sens": "source", "@cidtexte": "LEGITEXT000006074096", "@typelien": "MODIFIE", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000039042991", "@num": "R442-23", "#text": "Code de la construction et de l'habitation. - art. R442-23 (VD)", "@sens": "source", "@cidtexte": "LEGITEXT000006074096", "@typelien": "MODIFIE", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000039042989", "@num": "R442-24", "#text": "Code de la construction et de l'habitation. - art. R442-24 (VD)", "@sens": "source", "@cidtexte": "LEGITEXT000006074096", "@typelien": "MODIFIE", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000039042987", "@num": "R442-25", "#text": "Code de la construction et de l'habitation. - art. R442-25 (VD)", "@sens": "source", "@cidtexte": "LEGITEXT000006074096", "@typelien": "MODIFIE", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000039042985", "@num": "R442-26", "#text": "Code de la construction et de l'habitation. - art. R442-26 (VD)", "@sens": "source", "@cidtexte": "LEGITEXT000006074096", "@typelien": "MODIFIE", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000039042981", "@num": "R442-27", "#text": "Code de la construction et de l'habitation. - art. R442-27 (VD)", "@sens": "source", "@cidtexte": "LEGITEXT000006074096", "@typelien": "MODIFIE", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000039042979", "@num": "R442-28", "#text": "Code de la construction et de l'habitation. - art. R442-28 (VD)", "@sens": "source", "@cidtexte": "LEGITEXT000006074096", "@typelien": "MODIFIE", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000039042976", "@num": "R442-29", "#text": "Code de la construction et de l'habitation. - art. R442-29 (VD)", "@sens": "source", "@cidtexte": "LEGITEXT000006074096", "@typelien": "MODIFIE", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000039043006", "@num": "R442-3", "#text": "Code de la construction et de l'habitation. - art. R442-3 (VD)", "@sens": "source", "@cidtexte": "LEGITEXT000006074096", "@typelien": "MODIFIE", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000039042973", "@num": "R442-30", "#text": "Code de la construction et de l'habitation. - art. R442-30 (VD)", "@sens": "source", "@cidtexte": "LEGITEXT000006074096", "@typelien": "MODIFIE", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000039042934", "@num": "R443-12-1", "#text": "Code de la construction et de l'habitation. - art. R443-12-1 (VD)", "@sens": "source", "@cidtexte": "LEGITEXT000006074096", "@typelien": "MODIFIE", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000039042954", "@num": "R443-2", "#text": "Code de la construction et de l'habitation. - art. R443-2 (V)", "@sens": "source", "@cidtexte": "LEGITEXT000006074096", "@typelien": "MODIFIE", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000039042950", "@num": "R443-4", "#text": "Code de la construction et de l'habitation. - art. R443-4 (VD)", "@sens": "source", "@cidtexte": "LEGITEXT000006074096", "@typelien": "MODIFIE", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000039042947", "@num": "R443-9-1", "#text": "Code de la construction et de l'habitation. - art. R443-9-1 (VD)", "@sens": "source", "@cidtexte": "LEGITEXT000006074096", "@typelien": "MODIFIE", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000039042945", "@num": "R443-9-2", "#text": "Code de la construction et de l'habitation. - art. R443-9-2 (VD)", "@sens": "source", "@cidtexte": "LEGITEXT000006074096", "@typelien": "MODIFIE", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000039042943", "@num": "R443-9-3", "#text": "Code de la construction et de l'habitation. - art. R443-9-3 (VD)", "@sens": "source", "@cidtexte": "LEGITEXT000006074096", "@typelien": "MODIFIE", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000039042939", "@num": "R443-9-4", "#text": "Code de la construction et de l'habitation. - art. R443-9-4 (VD)", "@sens": "source", "@cidtexte": "LEGITEXT000006074096", "@typelien": "MODIFIE", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000039042893", "@num": "R445-10", "#text": "Code de la construction et de l'habitation. - art. R445-10 (VD)", "@sens": "source", "@cidtexte": "LEGITEXT000006074096", "@typelien": "MODIFIE", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000039042929", "@num": "R445-2", "#text": "Code de la construction et de l'habitation. - art. R445-2 (VD)", "@sens": "source", "@cidtexte": "LEGITEXT000006074096", "@typelien": "MODIFIE", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000039042925", "@num": "R445-2-2", "#text": "Code de la construction et de l'habitation. - art. R445-2-2 (VD)", "@sens": "source", "@cidtexte": "LEGITEXT000006074096", "@typelien": "MODIFIE", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000039042922", "@num": "R445-2-3", "#text": "Code de la construction et de l'habitation. - art. R445-2-3 (VD)", "@sens": "source", "@cidtexte": "LEGITEXT000006074096", "@typelien": "MODIFIE", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000039042917", "@num": "R445-2-4", "#text": "Code de la construction et de l'habitation. - art. R445-2-4 (VD)", "@sens": "source", "@cidtexte": "LEGITEXT000006074096", "@typelien": "MODIFIE", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000039042913", "@num": "R445-2-5", "#text": "Code de la construction et de l'habitation. - art. R445-2-5 (VD)", "@sens": "source", "@cidtexte": "LEGITEXT000006074096", "@typelien": "MODIFIE", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000039042911", "@num": "R445-2-6", "#text": "Code de la construction et de l'habitation. - art. R445-2-6 (VD)", "@sens": "source", "@cidtexte": "LEGITEXT000006074096", "@typelien": "MODIFIE", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000039042909", "@num": "R445-2-7", "#text": "Code de la construction et de l'habitation. - art. R445-2-7 (VD)", "@sens": "source", "@cidtexte": "LEGITEXT000006074096", "@typelien": "MODIFIE", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000039042904", "@num": "R445-2-8", "#text": "Code de la construction et de l'habitation. - art. R445-2-8 (VD)", "@sens": "source", "@cidtexte": "LEGITEXT000006074096", "@typelien": "MODIFIE", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000039066062", "@num": "R445-24", "#text": "Code de la construction et de l'habitation. - art. R445-24 (V)", "@sens": "source", "@cidtexte": "LEGITEXT000006074096", "@typelien": "MODIFIE", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000039042884", "@num": "R445-25", "#text": "Code de la construction et de l'habitation. - art. R445-25 (VD)", "@sens": "source", "@cidtexte": "LEGITEXT000006074096", "@typelien": "MODIFIE", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000039042881", "@num": "R445-30", "#text": "Code de la construction et de l'habitation. - art. R445-30 (VD)", "@sens": "source", "@cidtexte": "LEGITEXT000006074096", "@typelien": "MODIFIE", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000039042876", "@num": "R445-31", "#text": "Code de la construction et de l'habitation. - art. R445-31 (VD)", "@sens": "source", "@cidtexte": "LEGITEXT000006074096", "@typelien": "MODIFIE", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000039042872", "@num": "R445-32", "#text": "Code de la construction et de l'habitation. - art. R445-32 (VD)", "@sens": "source", "@cidtexte": "LEGITEXT000006074096", "@typelien": "MODIFIE", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000039042870", "@num": "R445-33", "#text": "Code de la construction et de l'habitation. - art. R445-33 (VD)", "@sens": "source", "@cidtexte": "LEGITEXT000006074096", "@typelien": "MODIFIE", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000039042865", "@num": "R445-34", "#text": "Code de la construction et de l'habitation. - art. R445-34 (VD)", "@sens": "source", "@cidtexte": "LEGITEXT000006074096", "@typelien": "MODIFIE", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000039042897", "@num": "R445-6", "#text": "Code de la construction et de l'habitation. - art. R445-6 (VD)", "@sens": "source", "@cidtexte": "LEGITEXT000006074096", "@typelien": "MODIFIE", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000039042861", "@num": "R451-10", "#text": "Code de la construction et de l'habitation. - art. R451-10 (VD)", "@sens": "source", "@cidtexte": "LEGITEXT000006074096", "@typelien": "MODIFIE", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000039042858", "@num": "R461-1", "#text": "Code de la construction et de l'habitation. - art. R461-1 (VD)", "@sens": "source", "@cidtexte": "LEGITEXT000006074096", "@typelien": "MODIFIE", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000039042855", "@num": "R472-2-1", "#text": "Code de la construction et de l'habitation. - art. R472-2-1 (VD)", "@sens": "source", "@cidtexte": "LEGITEXT000006074096", "@typelien": "MODIFIE", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000039042842", "@num": "R472-3", "#text": "Code de la construction et de l'habitation. - art. R472-3 (V)", "@sens": "source", "@cidtexte": "LEGITEXT000006074096", "@typelien": "MODIFIE", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000039042810", "@num": "R481-11", "#text": "Code de la construction et de l'habitation. - art. R481-11 (V)", "@sens": "source", "@cidtexte": "LEGITEXT000006074096", "@typelien": "MODIFIE", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000039042807", "@num": "R481-12", "#text": "Code de la construction et de l'habitation. - art. R481-12 (VD)", "@sens": "source", "@cidtexte": "LEGITEXT000006074096", "@typelien": "MODIFIE", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000039042839", "@num": "R481-2", "#text": "Code de la construction et de l'habitation. - art. R481-2 (VD)", "@sens": "source", "@cidtexte": "LEGITEXT000006074096", "@typelien": "MODIFIE", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000039042835", "@num": "R481-3", "#text": "Code de la construction et de l'habitation. - art. R481-3 (VD)", "@sens": "source", "@cidtexte": "LEGITEXT000006074096", "@typelien": "MODIFIE", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000039042829", "@num": "R481-5-1", "#text": "Code de la construction et de l'habitation. - art. R481-5-1 (VD)", "@sens": "source", "@cidtexte": "LEGITEXT000006074096", "@typelien": "MODIFIE", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000038959717", "@num": "R481-5-8", "#text": "Code de la construction et de l'habitation. - art. R481-5-8 (V)", "@sens": "source", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CREE", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000039042824", "@num": "R481-6", "#text": "Code de la construction et de l'habitation. - art. R481-6 (VD)", "@sens": "source", "@cidtexte": "LEGITEXT000006074096", "@typelien": "MODIFIE", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000039042820", "@num": "R481-7", "#text": "Code de la construction et de l'habitation. - art. R481-7 (VD)", "@sens": "source", "@cidtexte": "LEGITEXT000006074096", "@typelien": "MODIFIE", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000039042818", "@num": "R481-8", "#text": "Code de la construction et de l'habitation. - art. R481-8 (VD)", "@sens": "source", "@cidtexte": "LEGITEXT000006074096", "@typelien": "MODIFIE", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000039042803", "@num": "R491-1", "#text": "Code de la construction et de l'habitation. - art. R491-1 (VD)", "@sens": "source", "@cidtexte": "LEGITEXT000006074096", "@typelien": "MODIFIE", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000039042797", "@num": "R491-2", "#text": "Code de la construction et de l'habitation. - art. R491-2 (VD)", "@sens": "source", "@cidtexte": "LEGITEXT000006074096", "@typelien": "MODIFIE", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000039042792", "@num": "R491-3", "#text": "Code de la construction et de l'habitation. - art. R491-3 (VD)", "@sens": "source", "@cidtexte": "LEGITEXT000006074096", "@typelien": "MODIFIE", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000039042786", "@num": "R491-4", "#text": "Code de la construction et de l'habitation. - art. R491-4 (VD)", "@sens": "source", "@cidtexte": "LEGITEXT000006074096", "@typelien": "MODIFIE", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000039042781", "@num": "R491-5", "#text": "Code de la construction et de l'habitation. - art. R491-5 (VD)", "@sens": "source", "@cidtexte": "LEGITEXT000006074096", "@typelien": "MODIFIE", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000039042775", "@num": "R491-6", "#text": "Code de la construction et de l'habitation. - art. R491-6 (VD)", "@sens": "source", "@cidtexte": "LEGITEXT000006074096", "@typelien": "MODIFIE", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000038959727", "@num": "R511-13-1", "#text": "Code de la construction et de l'habitation. - art. R511-13-1 (Ab)", "@sens": "source", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CREE", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000039043501", "@num": "R521-1", "#text": "Code de la construction et de l'habitation. - art. R521-1 (VD)", "@sens": "source", "@cidtexte": "LEGITEXT000006074096", "@typelien": "MODIFIE", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000039043498", "@num": "R521-2", "#text": "Code de la construction et de l'habitation. - art. R521-2 (VD)", "@sens": "source", "@cidtexte": "LEGITEXT000006074096", "@typelien": "MODIFIE", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000039043494", "@num": "R521-3", "#text": "Code de la construction et de l'habitation. - art. R521-3 (VD)", "@sens": "source", "@cidtexte": "LEGITEXT000006074096", "@typelien": "MODIFIE", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000039043491", "@num": "R521-4", "#text": "Code de la construction et de l'habitation. - art. R521-4 (VD)", "@sens": "source", "@cidtexte": "LEGITEXT000006074096", "@typelien": "MODIFIE", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000039043486", "@num": "R521-5", "#text": "Code de la construction et de l'habitation. - art. R521-5 (VD)", "@sens": "source", "@cidtexte": "LEGITEXT000006074096", "@typelien": "MODIFIE", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000039043482", "@num": "R521-6", "#text": "Code de la construction et de l'habitation. - art. R521-6 (VD)", "@sens": "source", "@cidtexte": "LEGITEXT000006074096", "@typelien": "MODIFIE", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000039043478", "@num": "R521-7", "#text": "Code de la construction et de l'habitation. - art. R521-7 (VD)", "@sens": "source", "@cidtexte": "LEGITEXT000006074096", "@typelien": "MODIFIE", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000039043656", "@num": "R631-10", "#text": "Code de la construction et de l'habitation. - art. R631-10 (VD)", "@sens": "source", "@cidtexte": "LEGITEXT000006074096", "@typelien": "MODIFIE", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000039043651", "@num": "R631-11", "#text": "Code de la construction et de l'habitation. - art. R631-11 (VD)", "@sens": "source", "@cidtexte": "LEGITEXT000006074096", "@typelien": "MODIFIE", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000039043644", "@num": "R631-12", "#text": "Code de la construction et de l'habitation. - art. R631-12 (VD)", "@sens": "source", "@cidtexte": "LEGITEXT000006074096", "@typelien": "MODIFIE", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000039043639", "@num": "R631-13", "#text": "Code de la construction et de l'habitation. - art. R631-13 (VD)", "@sens": "source", "@cidtexte": "LEGITEXT000006074096", "@typelien": "MODIFIE", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000039043635", "@num": "R631-14", "#text": "Code de la construction et de l'habitation. - art. R631-14 (VD)", "@sens": "source", "@cidtexte": "LEGITEXT000006074096", "@typelien": "MODIFIE", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000039040643", "@num": "R631-15", "#text": "Code de la construction et de l'habitation. - art. R631-15 (VD)", "@sens": "source", "@cidtexte": "LEGITEXT000006074096", "@typelien": "MODIFIE", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000039043629", "@num": "R631-17", "#text": "Code de la construction et de l'habitation. - art. R631-17 (VD)", "@sens": "source", "@cidtexte": "LEGITEXT000006074096", "@typelien": "MODIFIE", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000039043623", "@num": "R631-18", "#text": "Code de la construction et de l'habitation. - art. R631-18 (VD)", "@sens": "source", "@cidtexte": "LEGITEXT000006074096", "@typelien": "MODIFIE", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000039043617", "@num": "R631-19", "#text": "Code de la construction et de l'habitation. - art. R631-19 (VD)", "@sens": "source", "@cidtexte": "LEGITEXT000006074096", "@typelien": "MODIFIE", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000039043600", "@num": "R631-20", "#text": "Code de la construction et de l'habitation. - art. R631-20 (VD)", "@sens": "source", "@cidtexte": "LEGITEXT000006074096", "@typelien": "MODIFIE", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000039043591", "@num": "R631-21", "#text": "Code de la construction et de l'habitation. - art. R631-21 (VD)", "@sens": "source", "@cidtexte": "LEGITEXT000006074096", "@typelien": "MODIFIE", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000039043584", "@num": "R631-22", "#text": "Code de la construction et de l'habitation. - art. R631-22 (VD)", "@sens": "source", "@cidtexte": "LEGITEXT000006074096", "@typelien": "MODIFIE", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000039043573", "@num": "R631-23", "#text": "Code de la construction et de l'habitation. - art. R631-23 (V)", "@sens": "source", "@cidtexte": "LEGITEXT000006074096", "@typelien": "MODIFIE", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000039043569", "@num": "R631-24", "#text": "Code de la construction et de l'habitation. - art. R631-24 (VD)", "@sens": "source", "@cidtexte": "LEGITEXT000006074096", "@typelien": "MODIFIE", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000039043563", "@num": "R631-25", "#text": "Code de la construction et de l'habitation. - art. R631-25 (VD)", "@sens": "source", "@cidtexte": "LEGITEXT000006074096", "@typelien": "MODIFIE", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000039043558", "@num": "R631-26", "#text": "Code de la construction et de l'habitation. - art. R631-26 (VD)", "@sens": "source", "@cidtexte": "LEGITEXT000006074096", "@typelien": "MODIFIE", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000039043663", "@num": "R631-9", "#text": "Code de la construction et de l'habitation. - art. R631-9 (VD)", "@sens": "source", "@cidtexte": "LEGITEXT000006074096", "@typelien": "MODIFIE", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000039043552", "@num": "R642-1", "#text": "Code de la construction et de l'habitation. - art. R642-1 (VD)", "@sens": "source", "@cidtexte": "LEGITEXT000006074096", "@typelien": "MODIFIE", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000039043507", "@num": "R642-10", "#text": "Code de la construction et de l'habitation. - art. R642-10 (VD)", "@sens": "source", "@cidtexte": "LEGITEXT000006074096", "@typelien": "MODIFIE", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000039043546", "@num": "R642-2", "#text": "Code de la construction et de l'habitation. - art. R642-2 (VD)", "@sens": "source", "@cidtexte": "LEGITEXT000006074096", "@typelien": "MODIFIE", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000039043542", "@num": "R642-3", "#text": "Code de la construction et de l'habitation. - art. R642-3 (VD)", "@sens": "source", "@cidtexte": "LEGITEXT000006074096", "@typelien": "MODIFIE", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000039043537", "@num": "R642-4", "#text": "Code de la construction et de l'habitation. - art. R642-4 (VD)", "@sens": "source", "@cidtexte": "LEGITEXT000006074096", "@typelien": "MODIFIE", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000039043532", "@num": "R642-5", "#text": "Code de la construction et de l'habitation. - art. R642-5 (VD)", "@sens": "source", "@cidtexte": "LEGITEXT000006074096", "@typelien": "MODIFIE", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000039043527", "@num": "R642-6", "#text": "Code de la construction et de l'habitation. - art. R642-6 (VD)", "@sens": "source", "@cidtexte": "LEGITEXT000006074096", "@typelien": "MODIFIE", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000039043522", "@num": "R642-7", "#text": "Code de la construction et de l'habitation. - art. R642-7 (VD)", "@sens": "source", "@cidtexte": "LEGITEXT000006074096", "@typelien": "MODIFIE", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000039043517", "@num": "R642-8", "#text": "Code de la construction et de l'habitation. - art. R642-8 (VD)", "@sens": "source", "@cidtexte": "LEGITEXT000006074096", "@typelien": "MODIFIE", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000039043511", "@num": "R642-9", "#text": "Code de la construction et de l'habitation. - art. R642-9 (VD)", "@sens": "source", "@cidtexte": "LEGITEXT000006074096", "@typelien": "MODIFIE", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" } ] }, "CONTEXTE": { "TEXTE": { "@cid": "JORFTEXT000038947944", "@nor": "TERX1913732D", "@num": "2019-873", "@nature": "DECRET", "TITRE_TXT": [ { "@fin": "2999-01-01", "#text": "Décret n° 2019-873 du 21 août 2019 relatif à la partie réglementaire du code de la construction et de l'habitation", "@debut": "2999-01-01", "@id_txt": "JORFTEXT000038947944", "@c_titre_court": "Décret n°2019-873 du 21 août 2019" }, { "@fin": "2999-01-01", "#text": "Décret n° 2019-873 du 21 août 2019 relatif à la partie réglementaire du code de la construction et de l'habitation", "@debut": "2019-09-01", "@id_txt": "LEGITEXT000038955621", "@c_titre_court": "Décret n°2019-873 du 21 août 2019" } ], "@ministere": "Ministère de la cohésion des territoires et des relations avec les collectivités territoriales", "@date_publi": "2019-08-23", "@date_signature": "2019-08-21", "@num_parution_jo": "0195" } }, "VERSIONS": { "VERSION": [ { "LIEN_ART": { "@id": "LEGIARTI000038955628", "@fin": "2999-01-01", "@num": "4", "@debut": "2999-01-01", "@origine": "LEGI" } }, { "LIEN_ART": { "@id": "JORFARTI000038947948", "@fin": "2999-01-01", "@num": "4", "@debut": "2999-01-01", "@origine": "JORF" } } ] }, "BLOC_TEXTUEL": { "CONTENU": "
A modifié les dispositions suivantes :

-Code de la construction et de l'habitation.
\nArt. R111-1-1, Art. R111-2, Art. R111-3, Art. R111-4, Art. R111-5, Art. R111-8, Art. R111-9, Art. R111-10, Art. R111-11, Art. R111-12, Art. R111-13, Art. R111-14-1, Art. R111-15, Art. R111-16, Art. R111-17, Art. R111-18, Art. R111-18-1, Art. R111-18-2, Art. R111-18-3, Art. R111-18-4, Art. R111-18-5, Art. R111-18-6, Art. R111-18-7, Art. R111-18-8, Art. R111-18-9, Art. R111-18-10, Art. R111-18-11, Art. R111-19-1, Art. R111-19-2, Art. R111-19-3, Art. R111-19-4, Art. R111-19-5, Art. R111-19-8, Art. R111-19-9, Art. R111-19-11, Art. R111-19-12, Art. R111-19-13, Art. R111-19-14, Art. R111-19-15, Art. R111-19-16, Art. R111-19-19, Art. R111-19-20, Art. R111-19-21, Art. R111-19-22, Art. R111-24, Art. R111-25, Art. R111-26, Art. R111-27, Art. R111-28, Art. R111-29, Art. R111-29-1, Art. R111-30, Art. R111-31, Art. R111-32, Art. R111-32-1, Art. R111-32-2, Art. R111-32-3, Art. R111-33, Art. R111-33-1, Art. R111-34, Art. R111-35, Art. R111-36, Art. R111-37, Art. R111-39, Art. R111-40, Art. R111-41, Art. R111-42, Art. R123-1, Art. R123-2, Art. R123-3, Art. R123-4, Art. R123-5, Art. R123-6, Art. R123-7, Art. R123-8, Art. R123-9, Art. R123-10, Art. R123-11, Art. R123-12, Art. R123-13, Art. R123-14, Art. R123-15, Art. R123-16, Art. R123-17, Art. R123-18, Art. R123-19, Art. R123-20, Art. R123-21, Art. R123-27, Art. R123-28, Art. R123-29, Art. R123-30, Art. R123-31, Art. R123-32, Art. R123-33, Art. R123-34, Art. R123-35, Art. R123-36, Art. R123-37, Art. R123-38, Art. R123-39, Art. R123-40, Art. R123-41, Art. R123-42, Art. R123-43, Art. R123-44, Art. R123-45, Art. R123-46, Art. R123-47, Art. R123-48, Art. R123-49, Art. R123-50, Art. R123-51, Art. R123-52, Art. R123-53, Art. R123-54, Art. R123-55, Art. R127-1, Art. R127-8, Art. R129-1, Art. R129-2, Art. R129-3, Art. R129-4, Art. R129-5, Art. R129-6, Art. R129-7, Art. R129-8, Art. R129-9, Art. R129-10, Art. R129-11, Art. R131-1, Art. R131-2, Art. R131-3, Art. R131-4, Art. R131-28-1, Art. R132-1, Art. R133-1, Art. R133-2, Art. R134-5-1, Art. R134-5-2, Art. R134-5-3, Art. R134-5-4, Art. R134-5-5, Art. R134-5-6, Art. R134-6, Art. R134-7, Art. R134-8, Art. R134-9, Art. R134-10, Art. R134-11, Art. R134-12, Art. R134-13, Art. R141-1, Art. R141-2, Art. R152-6, Art. R152-7, Art. R152-8, Art. R152-11, Art. R161-1, Art. R161-2, Art. R161-3, Art. R161-4, Art. R162-1, Art. R162-2, Art. R162-3, Art. R162-4 \n
\n

Article R231-13 AUTONOME VIGUEUR, en vigueur depuis le 01/09/2019 (Code de la construction et de l'habitation)