{ "article": { "LEGIARTI000006824507": { "META": { "META_SPEC": { "META_ARTICLE": { "NUM": "L232-2", "ETAT": "VIGUEUR", "TYPE": "AUTONOME", "DATE_FIN": "2999-01-01", "DATE_DEBUT": "1991-12-01" } }, "META_COMMUN": { "ID": "LEGIARTI000006824507", "URL": "article/LEGI/ARTI/00/00/06/82/45/LEGIARTI000006824507.xml", "NATURE": "Article", "ORIGINE": "LEGI", "ANCIEN_ID": "UCAXXXXXXXX1X232L002XXAA" } }, "LIENS": { "LIEN": [ { "@id": "JORFTEXT000000516442", "#text": "Décret 78-621 1978-05-31 JORF 8 JUIN 1978", "@sens": "source", "@cidtexte": "JORFTEXT000000516442", "@numtexte": "78-621", "@typelien": "CODIFICATION", "@naturetexte": "DECRET", "@datesignatexte": "1978-05-31" }, { "@id": "JORFTEXT000000709335", "#text": "Loi 90-1129 1990-12-19 art. 8", "@sens": "source", "@cidtexte": "JORFTEXT000000709335", "@nortexte": "EQUX9000054L", "@numtexte": "90-1129", "@typelien": "SPEC_APPLI", "@naturetexte": "LOI", "@datesignatexte": "1990-12-19" }, { "@id": "LEGIARTI000006826206", "@num": "1", "#text": "Loi n°90-1129 du 19 décembre 1990 - art. 1 () JORF 22 décembre 1990 en vigueur le 1er décembre 1991", "@sens": "source", "@cidtexte": "JORFTEXT000000709335", "@nortexte": "EQUX9000054L", "@numtexte": "90-1129", "@typelien": "CREATION", "@naturetexte": "LOI", "@datesignatexte": "1990-12-19" }, { "@id": "LEGIARTI000006824504", "@num": "L231-13", "#text": "Code de la construction et de l'habitation. - art. L231-13 (VT)", "@sens": "source", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CITATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000006824657", "@num": "L231-2", "#text": "Code de la construction et de l'habitation. - art. L231-2 (V)", "@sens": "source", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CITATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000006824494", "@num": "L231-4", "#text": "Code de la construction et de l'habitation. - art. L231-4 (V)", "@sens": "source", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CITATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000006824496", "@num": "L231-6", "#text": "Code de la construction et de l'habitation. - art. L231-6 (VT)", "@sens": "source", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CITATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000006824499", "@num": "L231-8", "#text": "Code de la construction et de l'habitation. - art. L231-8 (V)", "@sens": "source", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CITATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000006824500", "@num": "L231-9", "#text": "Code de la construction et de l'habitation. - art. L231-9 (V)", "@sens": "source", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CITATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" } ] }, "CONTEXTE": { "TEXTE": { "TM": { "TM": { "TM": { "TM": { "TITRE_TM": [ { "@id": "LEGISCTA000006159021", "@fin": "2999-01-01", "#text": "Chapitre II : Contrat de construction d'une maison individuelle sans fourniture du plan.", "@debut": "1991-12-01" } ] }, "TITRE_TM": [ { "@id": "LEGISCTA000006143526", "@fin": "2999-01-01", "#text": "Titre III : Construction d'une maison individuelle.", "@debut": "1991-12-01" } ] }, "TITRE_TM": [ { "@id": "LEGISCTA000006128681", "@fin": "2999-01-01", "#text": "Livre II : Statut des constructeurs.", "@debut": "1978-06-08" } ] }, "TITRE_TM": [ { "@id": "LEGISCTA000006108136", "@fin": "2999-01-01", "#text": "Partie législative", "@debut": "1978-06-08" } ] }, "@cid": "LEGITEXT000006074096", "@nature": "CODE", "TITRE_TXT": [ { "@fin": "2999-01-01", "#text": "Code de la construction et de l'habitation", "@debut": "1977-03-10", "@id_txt": "LEGITEXT000006074096", "@c_titre_court": "Code de la construction et de l'habitation." } ], "@date_publi": "2999-01-01", "@date_signature": "2999-01-01" } }, "VERSIONS": { "VERSION": [ { "@etat": "VIGUEUR", "LIEN_ART": { "@id": "LEGIARTI000006824507", "@fin": "2999-01-01", "@num": "L232-2", "@etat": "VIGUEUR", "@debut": "1991-12-01", "@origine": "LEGI" } } ] }, "BLOC_TEXTUEL": { "CONTENU": "
Les dispositions du dernier alinéa de l'article L. 231-2, de l'article L. 231-6, du paragraphe II de l'article L. 231-4, des articles L. 231-8, L. 231-9 et L. 231-13 sont applicables au contrat prévu au présent chapitre.
\n
" } }, "LEGIARTI000006824494": { "META": { "META_SPEC": { "META_ARTICLE": { "NUM": "L231-4", "ETAT": "VIGUEUR", "TYPE": "AUTONOME", "DATE_FIN": "2999-01-01", "DATE_DEBUT": "1991-12-01" } }, "META_COMMUN": { "ID": "LEGIARTI000006824494", "URL": "article/LEGI/ARTI/00/00/06/82/44/LEGIARTI000006824494.xml", "NATURE": "Article", "ORIGINE": "LEGI", "ANCIEN_ID": "UCAXXXXXXXX1X231L004XXAA" } }, "LIENS": { "LIEN": [ { "@id": "JORFTEXT000000516442", "#text": "Décret 78-621 1978-05-31 JORF 8 JUIN 1978", "@sens": "source", "@cidtexte": "JORFTEXT000000516442", "@numtexte": "78-621", "@typelien": "CODIFICATION", "@naturetexte": "DECRET", "@datesignatexte": "1978-05-31" }, { "@id": "JORFTEXT000000709335", "#text": "Loi 90-1129 1990-12-19 art. 8", "@sens": "source", "@cidtexte": "JORFTEXT000000709335", "@nortexte": "EQUX9000054L", "@numtexte": "90-1129", "@typelien": "SPEC_APPLI", "@naturetexte": "LOI", "@datesignatexte": "1990-12-19" }, { "@id": "LEGIARTI000006826206", "@num": "1", "#text": "Loi n°90-1129 du 19 décembre 1990 - art. 1 () JORF 22 décembre 1990 en vigueur le 1er décembre 1991", "@sens": "source", "@cidtexte": "JORFTEXT000000709335", "@nortexte": "EQUX9000054L", "@numtexte": "90-1129", "@typelien": "CREATION", "@naturetexte": "LOI", "@datesignatexte": "1990-12-19" }, { "@id": "LEGIARTI000047291666", "@num": "L511-7", "#text": "Code de la consommation - art. L511-7 (VD)", "@sens": "cible", "@cidtexte": "LEGITEXT000006069565", "@typelien": "CITATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000006824508", "@num": "L231-1", "#text": "Code de la construction et de l'habitation. - art. L231-1 (V)", "@sens": "source", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CITATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000006824507", "@num": "L232-2", "#text": "Code de la construction et de l'habitation. - art. L232-2 (V)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CITATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000006824517", "@num": "L241-1", "#text": "Code de la construction et de l'habitation. - art. L241-1 (V)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CITATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000006824636", "@num": "L271-1", "#text": "Code de la construction et de l'habitation. - art. L271-1 (V)", "@sens": "source", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CITATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000039041725", "@num": "R231-8", "#text": "Code de la construction et de l'habitation. - art. R231-8 (VD)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CITATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" } ] }, "CONTEXTE": { "TEXTE": { "TM": { "TM": { "TM": { "TM": { "TITRE_TM": [ { "@id": "LEGISCTA000006159020", "@fin": "2999-01-01", "#text": "Chapitre Ier : Contrat de construction d'une maison individuelle avec fourniture du plan.", "@debut": "1991-12-01" } ] }, "TITRE_TM": [ { "@id": "LEGISCTA000006143526", "@fin": "2999-01-01", "#text": "Titre III : Construction d'une maison individuelle.", "@debut": "1991-12-01" } ] }, "TITRE_TM": [ { "@id": "LEGISCTA000006128681", "@fin": "2999-01-01", "#text": "Livre II : Statut des constructeurs.", "@debut": "1978-06-08" } ] }, "TITRE_TM": [ { "@id": "LEGISCTA000006108136", "@fin": "2999-01-01", "#text": "Partie législative", "@debut": "1978-06-08" } ] }, "@cid": "LEGITEXT000006074096", "@nature": "CODE", "TITRE_TXT": [ { "@fin": "2999-01-01", "#text": "Code de la construction et de l'habitation", "@debut": "1977-03-10", "@id_txt": "LEGITEXT000006074096", "@c_titre_court": "Code de la construction et de l'habitation." } ], "@date_publi": "2999-01-01", "@date_signature": "2999-01-01" } }, "VERSIONS": { "VERSION": [ { "@etat": "VIGUEUR", "LIEN_ART": { "@id": "LEGIARTI000006824494", "@fin": "2999-01-01", "@num": "L231-4", "@etat": "VIGUEUR", "@debut": "1991-12-01", "@origine": "LEGI" } } ] }, "BLOC_TEXTUEL": { "CONTENU": "

I.-Le contrat défini à l'article L. 231-1 peut être conclu sous les conditions suspensives suivantes :

a) L'acquisition du terrain ou des droits réels permettant de construire si le maître de l'ouvrage bénéficie d'une promesse de vente ;

b) L'obtention du permis de construire et des autres autorisations administratives, le maître de l'ouvrage étant tenu de préciser la date limite de dépôt de la demande ;

c) L'obtention des prêts demandés pour le financement de la construction ;

d) L'obtention de l'assurance de dommages ;

e) L'obtention de la garantie de livraison.

Le délai maximum de réalisation des conditions suspensives ainsi que la date d'ouverture du chantier, déterminée à partir de ce délai, sont précisés par le contrat.

II.-Aucun versement, aucun dépôt, aucune souscription ou acceptation d'effets de commerce ne peuvent être exigés ou acceptés avant la signature du contrat défini à l'article L. 231-1 ni avant la date à laquelle la créance est exigible.

III.-Le contrat peut stipuler qu'un dépôt de garantie sera effectué à un compte spécial ouvert au nom du maître de l'ouvrage par un organisme habilité. Le montant de ce dépôt ne peut excéder 3 % du prix de la construction projetée tel qu'il est énoncé au contrat.

Les fonds ainsi déposés sont indisponibles, incessibles et insaisissables jusqu'à la réalisation de toutes les conditions ; dans ce cas, ces sommes viennent s'imputer sur les premiers paiements prévus par le contrat.

Les fonds déposés en garantie sont immédiatement restitués au maître de l'ouvrage, sans retenue ni pénalité, si toutes les conditions suspensives ne sont pas réalisées dans le délai prévu au contrat ou si le maître de l'ouvrage exerce la faculté de rétractation prévue à l'article L. 271-1.\n

Le contrat peut prévoir des paiements au constructeur avant la date d'ouverture du chantier, sous réserve que leur remboursement soit garanti par un établissement habilité à cet effet.

Un décret en Conseil d'Etat fixe la nature de la garantie et les conditions et limites dans lesquelles ces sommes sont versées.

" } }, "LEGIARTI000006824496": { "META": { "META_SPEC": { "META_ARTICLE": { "NUM": "L231-6", "ETAT": "MODIFIE", "TYPE": "AUTONOME", "DATE_FIN": "2006-01-01", "DATE_DEBUT": "1991-12-01" } }, "META_COMMUN": { "ID": "LEGIARTI000006824496", "URL": "article/LEGI/ARTI/00/00/06/82/44/LEGIARTI000006824496.xml", "NATURE": "Article", "ORIGINE": "LEGI", "ANCIEN_ID": "UCAXXXXXXXX1X231L006XXAA" } }, "LIENS": { "LIEN": [ { "@id": "JORFTEXT000000516442", "#text": "Décret 78-621 1978-05-31 JORF 8 JUIN 1978", "@sens": "source", "@cidtexte": "JORFTEXT000000516442", "@numtexte": "78-621", "@typelien": "CODIFICATION", "@naturetexte": "DECRET", "@datesignatexte": "1978-05-31" }, { "@id": "LEGIARTI000006400112", "@num": "37", "#text": "Loi n°85-98 du 25 janvier 1985 - art. 37 (M)", "@sens": "source", "@cidtexte": "JORFTEXT000000693911", "@numtexte": "85-98", "@typelien": "CITATION", "@naturetexte": "LOI", "@datesignatexte": "1985-01-25" }, { "@id": "JORFTEXT000000709335", "#text": "Loi 90-1129 1990-12-19 art. 8", "@sens": "source", "@cidtexte": "JORFTEXT000000709335", "@nortexte": "EQUX9000054L", "@numtexte": "90-1129", "@typelien": "SPEC_APPLI", "@naturetexte": "LOI", "@datesignatexte": "1990-12-19" }, { "@id": "LEGIARTI000006826206", "@num": "1", "#text": "Loi n°90-1129 du 19 décembre 1990 - art. 1 () JORF 22 décembre 1990 en vigueur le 1er décembre 1991", "@sens": "source", "@cidtexte": "JORFTEXT000000709335", "@nortexte": "EQUX9000054L", "@numtexte": "90-1129", "@typelien": "CREATION", "@naturetexte": "LOI", "@datesignatexte": "1990-12-19" }, { "@id": "LEGIARTI000006827088", "@num": "ANNEXE", "#text": "Décret n°91-1201 du 27 novembre 1991 - art. ANNEXE (V)", "@sens": "cible", "@cidtexte": "JORFTEXT000000344731", "@nortexte": "EQUC9101565D", "@numtexte": "91-1201", "@typelien": "CITATION", "@naturetexte": "DECRET", "@datesignatexte": "1991-11-27" }, { "@id": "LEGIARTI000041565897", "@num": "Annexe à l'article R231-13", "#text": "Code de la construction et de l'habitation. - art. Annexe à l'article R231-13 (VD)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CITATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000006824501", "@num": "L231-10", "#text": "Code de la construction et de l'habitation. - art. L231-10 (V)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CITATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000027645777", "@num": "L231-13", "#text": "Code de la construction et de l'habitation. - art. L231-13 (VD)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CITATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000006824657", "@num": "L231-2", "#text": "Code de la construction et de l'habitation. - art. L231-2 (M)", "@sens": "source", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CITATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000006824499", "@num": "L231-8", "#text": "Code de la construction et de l'habitation. - art. L231-8 (V)", "@sens": "source", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CITATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000006824507", "@num": "L232-2", "#text": "Code de la construction et de l'habitation. - art. L232-2 (V)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CITATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000032235569", "@num": "L241-8", "#text": "Code de la construction et de l'habitation. - art. L241-8 (VD)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CITATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000039041717", "@num": "R231-10", "#text": "Code de la construction et de l'habitation. - art. R231-10 (VD)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CITATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" } ] }, "CONTEXTE": { "TEXTE": { "TM": { "TM": { "TM": { "TM": { "TITRE_TM": [ { "@id": "LEGISCTA000006159020", "@fin": "2999-01-01", "#text": "Chapitre Ier : Contrat de construction d'une maison individuelle avec fourniture du plan.", "@debut": "1991-12-01" } ] }, "TITRE_TM": [ { "@id": "LEGISCTA000006143526", "@fin": "2999-01-01", "#text": "Titre III : Construction d'une maison individuelle.", "@debut": "1991-12-01" } ] }, "TITRE_TM": [ { "@id": "LEGISCTA000006128681", "@fin": "2999-01-01", "#text": "Livre II : Statut des constructeurs.", "@debut": "1978-06-08" } ] }, "TITRE_TM": [ { "@id": "LEGISCTA000006108136", "@fin": "2999-01-01", "#text": "Partie législative", "@debut": "1978-06-08" } ] }, "@cid": "LEGITEXT000006074096", "@nature": "CODE", "TITRE_TXT": [ { "@fin": "2999-01-01", "#text": "Code de la construction et de l'habitation", "@debut": "1977-03-10", "@id_txt": "LEGITEXT000006074096", "@c_titre_court": "Code de la construction et de l'habitation." } ], "@date_publi": "2999-01-01", "@date_signature": "2999-01-01" } }, "VERSIONS": { "VERSION": [ { "@etat": "MODIFIE", "LIEN_ART": { "@id": "LEGIARTI000006824496", "@fin": "2006-01-01", "@num": "L231-6", "@etat": "MODIFIE", "@debut": "1991-12-01", "@origine": "LEGI" } }, { "@etat": "MODIFIE", "LIEN_ART": { "@id": "LEGIARTI000006824497", "@fin": "2014-01-01", "@num": "L231-6", "@etat": "MODIFIE", "@debut": "2006-01-01", "@origine": "LEGI" } }, { "@etat": "MODIFIE", "LIEN_ART": { "@id": "LEGIARTI000027645773", "@fin": "2020-02-01", "@num": "L231-6", "@etat": "MODIFIE", "@debut": "2014-01-01", "@origine": "LEGI" } }, { "@etat": "VIGUEUR", "LIEN_ART": { "@id": "LEGIARTI000038433486", "@fin": "2999-01-01", "@num": "L231-6", "@etat": "VIGUEUR", "@debut": "2020-02-01", "@origine": "LEGI" } } ] }, "BLOC_TEXTUEL": { "CONTENU": "
I. - La garantie de livraison prévue au k de l'article L. 231-2 couvre le maître de l'ouvrage, à compter de la date d'ouverture du chantier, contre les risques d'inexécution ou de mauvaise exécution des travaux prévus au contrat, à prix et délais convenus.
\n
En cas de défaillance du constructeur, le garant prend à sa charge :
\n
a) Le coût des dépassements du prix convenu dès lors qu'ils sont nécessaires à l'achèvement de la construction, la garantie apportée à ce titre pouvant être assortie d'une franchise n'excédant pas 5 p. 100 du prix convenu ;
\n
b) Les conséquences du fait du constructeur ayant abouti à un paiement anticipé ou à un supplément de prix ;
\n
c) Les pénalités forfaitaires prévues au contrat en cas de retard de livraison excédant trente jours, le montant et le seuil minimum de ces pénalités étant fixés par décret.
\n
La garantie est constituée par une caution solidaire donnée par un établissement de crédit ou une entreprise d'assurance agréés à cet effet.
\n
II. - Dans le cas où le garant constate que le délai de livraison n'est pas respecté ou que les travaux nécessaires à la levée des réserves formulées à la réception ne sont pas réalisés, il met en demeure sans délai le constructeur soit de livrer l'immeuble, soit d'exécuter les travaux. Le garant est tenu à la même obligation lorsqu'il est informé par le maître de l'ouvrage des faits susindiqués.
\n
Quinze jours après une mise en demeure restée infructueuse, le garant procède à l'exécution de ses obligations dans les conditions prévues au paragraphe III du présent article.
\n
Au cas où, en cours d'exécution des travaux, le constructeur fait l'objet de la procédure de redressement judiciaire prévue par la loi n° 85-98 du 25 janvier 1985 relative au redressement et à la liquidation judiciaires des entreprises, le garant peut mettre en demeure l'administrateur de se prononcer sur l'exécution du contrat conformément à l'article 37 de ladite loi. A défaut de réponse dans le délai d'un mois et sans que ce délai puisse être prorogé pour quelque raison que ce soit, le garant procède à l'exécution de ses obligations. Il y procède également dans le cas où, malgré sa réponse positive, l'administrateur ne poursuit pas l'exécution du contrat dans les quinze jours qui suivent sa réponse.
\n
III. - Dans les cas prévus au paragraphe II ci-dessus et faute pour le constructeur ou l'administrateur de procéder à l'achèvement de la construction, le garant doit désigner sous sa responsabilité la personne qui terminera les travaux.
\n
Toutefois, et à condition que l'immeuble ait atteint le stade du hors d'eau, le garant peut proposer au maître de l'ouvrage de conclure lui-même des marchés de travaux avec des entreprises qui se chargeront de l'achèvement. Si le maître de l'ouvrage l'accepte, le garant verse directement aux entreprises les sommes dont il est redevable au titre du paragraphe I du présent article.
\n
En cas de défaillance du constructeur, le garant est en droit d'exiger de percevoir directement les sommes correspondant aux travaux qu'il effectue ou fait effectuer dans les conditions prévues au e de l'article L. 231-2.
\n
IV. - La garantie cesse lorsque la réception des travaux a été constatée par écrit et, le cas échéant, à l'expiration du délai de huit jours prévu à l'article L. 231-8 pour dénoncer les vices apparents ou, si des réserves ont été formulées, lorsque celles-ci ont été levées.
\n
" } }, "LEGIARTI000006824497": { "META": { "META_SPEC": { "META_ARTICLE": { "NUM": "L231-6", "ETAT": "MODIFIE", "TYPE": "AUTONOME", "DATE_FIN": "2014-01-01", "DATE_DEBUT": "2006-01-01" } }, "META_COMMUN": { "ID": "LEGIARTI000006824497", "URL": "article/LEGI/ARTI/00/00/06/82/44/LEGIARTI000006824497.xml", "NATURE": "Article", "ORIGINE": "LEGI", "ANCIEN_ID": "UCAXXXXXXXX1X231L006XXAB" } }, "LIENS": { "LIEN": [ { "@id": "JORFTEXT000000516442", "#text": "Décret 78-621 1978-05-31 JORF 8 JUIN 1978", "@sens": "source", "@cidtexte": "JORFTEXT000000516442", "@numtexte": "78-621", "@typelien": "CODIFICATION", "@naturetexte": "DECRET", "@datesignatexte": "1978-05-31" }, { "@id": "JORFTEXT000000709335", "#text": "Loi 90-1129 1990-12-19 art. 8", "@sens": "source", "@cidtexte": "JORFTEXT000000709335", "@nortexte": "EQUX9000054L", "@numtexte": "90-1129", "@typelien": "SPEC_APPLI", "@naturetexte": "LOI", "@datesignatexte": "1990-12-19" }, { "@id": "LEGIARTI000006827088", "@num": "ANNEXE", "#text": "Décret n°91-1201 du 27 novembre 1991 - art. ANNEXE (V)", "@sens": "cible", "@cidtexte": "JORFTEXT000000344731", "@nortexte": "EQUC9101565D", "@numtexte": "91-1201", "@typelien": "CITATION", "@naturetexte": "DECRET", "@datesignatexte": "1991-11-27" }, { "@id": "LEGIARTI000006521577", "@num": "165", "#text": "Loi n°2005-845 du 26 juillet 2005 - art. 165 (V) JORF 27 juillet 2005 en vigueur le 1er janvier 2006", "@sens": "source", "@cidtexte": "JORFTEXT000000632645", "@nortexte": "JUSX0400017L", "@numtexte": "2005-845", "@typelien": "MODIFICATION", "@naturetexte": "LOI", "@datesignatexte": "2005-07-26" }, { "@id": "LEGIARTI000041565897", "@num": "Annexe à l'article R231-13", "#text": "Code de la construction et de l'habitation. - art. Annexe à l'article R231-13 (VD)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CITATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000006824501", "@num": "L231-10", "#text": "Code de la construction et de l'habitation. - art. L231-10 (V)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CITATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000027645777", "@num": "L231-13", "#text": "Code de la construction et de l'habitation. - art. L231-13 (VD)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CITATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000006824657", "@num": "L231-2", "#text": "Code de la construction et de l'habitation. - art. L231-2 (V)", "@sens": "source", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CITATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000006824499", "@num": "L231-8", "#text": "Code de la construction et de l'habitation. - art. L231-8 (V)", "@sens": "source", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CITATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000006824507", "@num": "L232-2", "#text": "Code de la construction et de l'habitation. - art. L232-2 (V)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CITATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000032235569", "@num": "L241-8", "#text": "Code de la construction et de l'habitation. - art. L241-8 (VD)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CITATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000039041717", "@num": "R231-10", "#text": "Code de la construction et de l'habitation. - art. R231-10 (VD)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CITATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" } ] }, "CONTEXTE": { "TEXTE": { "TM": { "TM": { "TM": { "TM": { "TITRE_TM": [ { "@id": "LEGISCTA000006159020", "@fin": "2999-01-01", "#text": "Chapitre Ier : Contrat de construction d'une maison individuelle avec fourniture du plan.", "@debut": "1991-12-01" } ] }, "TITRE_TM": [ { "@id": "LEGISCTA000006143526", "@fin": "2999-01-01", "#text": "Titre III : Construction d'une maison individuelle.", "@debut": "1991-12-01" } ] }, "TITRE_TM": [ { "@id": "LEGISCTA000006128681", "@fin": "2999-01-01", "#text": "Livre II : Statut des constructeurs.", "@debut": "1978-06-08" } ] }, "TITRE_TM": [ { "@id": "LEGISCTA000006108136", "@fin": "2999-01-01", "#text": "Partie législative", "@debut": "1978-06-08" } ] }, "@cid": "LEGITEXT000006074096", "@nature": "CODE", "TITRE_TXT": [ { "@fin": "2999-01-01", "#text": "Code de la construction et de l'habitation", "@debut": "1977-03-10", "@id_txt": "LEGITEXT000006074096", "@c_titre_court": "Code de la construction et de l'habitation." } ], "@date_publi": "2999-01-01", "@date_signature": "2999-01-01" } }, "VERSIONS": { "VERSION": [ { "@etat": "MODIFIE", "LIEN_ART": { "@id": "LEGIARTI000006824496", "@fin": "2006-01-01", "@num": "L231-6", "@etat": "MODIFIE", "@debut": "1991-12-01", "@origine": "LEGI" } }, { "@etat": "MODIFIE", "LIEN_ART": { "@id": "LEGIARTI000006824497", "@fin": "2014-01-01", "@num": "L231-6", "@etat": "MODIFIE", "@debut": "2006-01-01", "@origine": "LEGI" } }, { "@etat": "MODIFIE", "LIEN_ART": { "@id": "LEGIARTI000027645773", "@fin": "2020-02-01", "@num": "L231-6", "@etat": "MODIFIE", "@debut": "2014-01-01", "@origine": "LEGI" } }, { "@etat": "VIGUEUR", "LIEN_ART": { "@id": "LEGIARTI000038433486", "@fin": "2999-01-01", "@num": "L231-6", "@etat": "VIGUEUR", "@debut": "2020-02-01", "@origine": "LEGI" } } ] }, "BLOC_TEXTUEL": { "CONTENU": "

En cas de défaillance du constructeur, le garant prend à sa charge :

a) Le coût des dépassements du prix convenu dès lors qu'ils sont nécessaires à l'achèvement de la construction, la garantie apportée à ce titre pouvant être assortie d'une franchise n'excédant pas 5 % du prix convenu ;

b) Les conséquences du fait du constructeur ayant abouti à un paiement anticipé ou à un supplément de prix ;

c) Les pénalités forfaitaires prévues au contrat en cas de retard de livraison excédant trente jours, le montant et le seuil minimum de ces pénalités étant fixés par décret.

La garantie est constituée par une caution solidaire donnée par un établissement de crédit ou une entreprise d'assurance agréés à cet effet.

II.-Dans le cas où le garant constate que le délai de livraison n'est pas respecté ou que les travaux nécessaires à la levée des réserves formulées à la réception ne sont pas réalisés, il met en demeure sans délai le constructeur soit de livrer l'immeuble, soit d'exécuter les travaux. Le garant est tenu à la même obligation lorsqu'il est informé par le maître de l'ouvrage des faits susindiqués.

Quinze jours après une mise en demeure restée infructueuse, le garant procède à l'exécution de ses obligations dans les conditions prévues au paragraphe III du présent article.

Au cas où, en cours d'exécution des travaux, le constructeur fait l'objet des procédures de sauvegarde et de redressement judiciaire prévues par le code de commerce, le garant peut mettre en demeure l'administrateur de se prononcer sur l'exécution du contrat conformément à l'article L. 621-28 dudit code. A défaut de réponse dans le délai d'un mois et sans que ce délai puisse être prorogé pour quelque raison que ce soit, le garant procède à l'exécution de ses obligations. Il y procède également dans le cas où, malgré sa réponse positive, l'administrateur ne poursuit pas l'exécution du contrat dans les quinze jours qui suivent sa réponse.

III.-Dans les cas prévus au paragraphe II ci-dessus et faute pour le constructeur ou l'administrateur de procéder à l'achèvement de la construction, le garant doit désigner sous sa responsabilité la personne qui terminera les travaux.

Toutefois, et à condition que l'immeuble ait atteint le stade du hors d'eau, le garant peut proposer au maître de l'ouvrage de conclure lui-même des marchés de travaux avec des entreprises qui se chargeront de l'achèvement. Si le maître de l'ouvrage l'accepte, le garant verse directement aux entreprises les sommes dont il est redevable au titre du paragraphe I du présent article.

En cas de défaillance du constructeur, le garant est en droit d'exiger de percevoir directement les sommes correspondant aux travaux qu'il effectue ou fait effectuer dans les conditions prévues au e de l'article L. 231-2.

IV.-La garantie cesse lorsque la réception des travaux a été constatée par écrit et, le cas échéant, à l'expiration du délai de huit jours prévu à l'article L. 231-8 pour dénoncer les vices apparents ou, si des réserves ont été formulées, lorsque celles-ci ont été levées.

" } }, "LEGIARTI000006824499": { "META": { "META_SPEC": { "META_ARTICLE": { "NUM": "L231-8", "ETAT": "MODIFIE", "TYPE": "AUTONOME", "DATE_FIN": "2021-07-01", "DATE_DEBUT": "1991-12-01" } }, "META_COMMUN": { "ID": "LEGIARTI000006824499", "URL": "article/LEGI/ARTI/00/00/06/82/44/LEGIARTI000006824499.xml", "NATURE": "Article", "ORIGINE": "LEGI", "ANCIEN_ID": "UCAXXXXXXXX1X231L008XXAA" } }, "LIENS": { "LIEN": [ { "@id": "JORFTEXT000000522423", "#text": "Loi n° 77-2 du 3 janvier 1977 (V)", "@sens": "source", "@cidtexte": "JORFTEXT000000522423", "@numtexte": "77-2", "@typelien": "CITATION", "@naturetexte": "LOI", "@datesignatexte": "1977-01-03" }, { "@id": "JORFTEXT000000516442", "#text": "Décret 78-621 1978-05-31 JORF 8 JUIN 1978", "@sens": "source", "@cidtexte": "JORFTEXT000000516442", "@numtexte": "78-621", "@typelien": "CODIFICATION", "@naturetexte": "DECRET", "@datesignatexte": "1978-05-31" }, { "@id": "JORFTEXT000000709335", "#text": "Loi 90-1129 1990-12-19 art. 8", "@sens": "source", "@cidtexte": "JORFTEXT000000709335", "@nortexte": "EQUX9000054L", "@numtexte": "90-1129", "@typelien": "SPEC_APPLI", "@naturetexte": "LOI", "@datesignatexte": "1990-12-19" }, { "@id": "LEGIARTI000006826206", "@num": "1", "#text": "Loi n°90-1129 du 19 décembre 1990 - art. 1 () JORF 22 décembre 1990 en vigueur le 1er décembre 1991", "@sens": "source", "@cidtexte": "JORFTEXT000000709335", "@nortexte": "EQUX9000054L", "@numtexte": "90-1129", "@typelien": "CREATION", "@naturetexte": "LOI", "@datesignatexte": "1990-12-19" }, { "@id": "LEGIARTI000006824172", "@num": "L111-23", "#text": "Code de la construction et de l'habitation. - art. L111-23 (V)", "@sens": "source", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CITATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000038433486", "@num": "L231-6", "#text": "Code de la construction et de l'habitation. - art. L231-6 (VD)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CITATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000006824507", "@num": "L232-2", "#text": "Code de la construction et de l'habitation. - art. L232-2 (V)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CITATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000039344324", "@num": "R231-7", "#text": "Code de la construction et de l'habitation. - art. R231-7 (VD)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CITATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" } ] }, "CONTEXTE": { "TEXTE": { "TM": { "TM": { "TM": { "TM": { "TITRE_TM": [ { "@id": "LEGISCTA000006159020", "@fin": "2999-01-01", "#text": "Chapitre Ier : Contrat de construction d'une maison individuelle avec fourniture du plan.", "@debut": "1991-12-01" } ] }, "TITRE_TM": [ { "@id": "LEGISCTA000006143526", "@fin": "2999-01-01", "#text": "Titre III : Construction d'une maison individuelle.", "@debut": "1991-12-01" } ] }, "TITRE_TM": [ { "@id": "LEGISCTA000006128681", "@fin": "2999-01-01", "#text": "Livre II : Statut des constructeurs.", "@debut": "1978-06-08" } ] }, "TITRE_TM": [ { "@id": "LEGISCTA000006108136", "@fin": "2999-01-01", "#text": "Partie législative", "@debut": "1978-06-08" } ] }, "@cid": "LEGITEXT000006074096", "@nature": "CODE", "TITRE_TXT": [ { "@fin": "2999-01-01", "#text": "Code de la construction et de l'habitation", "@debut": "1977-03-10", "@id_txt": "LEGITEXT000006074096", "@c_titre_court": "Code de la construction et de l'habitation." } ], "@date_publi": "2999-01-01", "@date_signature": "2999-01-01" } }, "VERSIONS": { "VERSION": [ { "@etat": "MODIFIE", "LIEN_ART": { "@id": "LEGIARTI000006824499", "@fin": "2021-07-01", "@num": "L231-8", "@etat": "MODIFIE", "@debut": "1991-12-01", "@origine": "LEGI" } }, { "@etat": "VIGUEUR", "LIEN_ART": { "@id": "LEGIARTI000041586850", "@fin": "2999-01-01", "@num": "L231-8", "@etat": "VIGUEUR", "@debut": "2021-07-01", "@origine": "LEGI" } } ] }, "BLOC_TEXTUEL": { "CONTENU": "
Le maître de l'ouvrage peut, par lettre recommandée avec accusé de réception dans les huit jours qui suivent la remise des clefs consécutive à la réception, dénoncer les vices apparents qu'il n'avait pas signalés lors de la réception afin qu'il y soit remédié dans le cadre de l'exécution du contrat.
\n
La disposition prévue à l'alinéa précédent ne s'applique pas quand le maître de l'ouvrage se fait assister, lors de la réception, par un professionnel habilité en application de la loi n° 77-2 du 3 janvier 1977 précitée ou des articles L. 111-23 et suivants ou par tout autre professionnel de la construction titulaire d'un contrat d'assurance couvrant les responsabilités pour ce type de mission.
" } }, "LEGIARTI000006824504": { "META": { "META_SPEC": { "META_ARTICLE": { "NUM": "L231-13", "ETAT": "MODIFIE", "TYPE": "AUTONOME", "DATE_FIN": "2004-12-10", "DATE_DEBUT": "1991-12-01" } }, "META_COMMUN": { "ID": "LEGIARTI000006824504", "URL": "article/LEGI/ARTI/00/00/06/82/45/LEGIARTI000006824504.xml", "NATURE": "Article", "ORIGINE": "LEGI", "ANCIEN_ID": "UCAXXXXXXXX1X231L013XXAA" } }, "LIENS": { "LIEN": [ { "@id": "LEGIARTI000006467156", "@num": "14", "#text": "Loi n°75-1334 du 31 décembre 1975 - art. 14 (V)", "@sens": "source", "@cidtexte": "JORFTEXT000000889241", "@numtexte": "75-1334", "@typelien": "CITATION", "@naturetexte": "LOI", "@datesignatexte": "1975-12-31" }, { "@id": "JORFTEXT000000516442", "#text": "Décret 78-621 1978-05-31 JORF 8 JUIN 1978", "@sens": "source", "@cidtexte": "JORFTEXT000000516442", "@numtexte": "78-621", "@typelien": "CODIFICATION", "@naturetexte": "DECRET", "@datesignatexte": "1978-05-31" }, { "@id": "JORFTEXT000000709335", "#text": "Loi 90-1129 1990-12-19 art. 8", "@sens": "source", "@cidtexte": "JORFTEXT000000709335", "@nortexte": "EQUX9000054L", "@numtexte": "90-1129", "@typelien": "SPEC_APPLI", "@naturetexte": "LOI", "@datesignatexte": "1990-12-19" }, { "@id": "LEGIARTI000006826206", "@num": "1", "#text": "Loi n°90-1129 du 19 décembre 1990 - art. 1 () JORF 22 décembre 1990 en vigueur le 1er décembre 1991", "@sens": "source", "@cidtexte": "JORFTEXT000000709335", "@nortexte": "EQUX9000054L", "@numtexte": "90-1129", "@typelien": "CREATION", "@naturetexte": "LOI", "@datesignatexte": "1990-12-19" }, { "@id": "LEGIARTI000023374155", "@num": "125", "#text": "LOI n°2008-1443\n du 30 décembre 2008 - art. 125 (V)", "@sens": "cible", "@cidtexte": "JORFTEXT000020014790", "@nortexte": "BCFX0826279L", "@numtexte": "2008-1443", "@typelien": "CITATION", "@naturetexte": "LOI", "@datesignatexte": "2008-12-30" }, { "@id": "LEGIARTI000020607705", "@num": "2", "#text": "Décret n°2009-246 du 3 mars 2009 - art. 2 (V)", "@sens": "cible", "@cidtexte": "JORFTEXT000020337446", "@nortexte": "ECET0829937D", "@numtexte": "2009-246", "@typelien": "CITATION", "@naturetexte": "DECRET", "@datesignatexte": "2009-03-03" }, { "@id": "LEGIARTI000020607714", "@num": "3", "#text": "Décret n°2009-246 du 3 mars 2009 - art. 3 (V)", "@sens": "cible", "@cidtexte": "JORFTEXT000020337446", "@nortexte": "ECET0829937D", "@numtexte": "2009-246", "@typelien": "CITATION", "@naturetexte": "DECRET", "@datesignatexte": "2009-03-03" }, { "@id": "LEGIARTI000020607712", "@num": "5", "#text": "Décret n°2009-246 du 3 mars 2009 - art. 5 (V)", "@sens": "cible", "@cidtexte": "JORFTEXT000020337446", "@nortexte": "ECET0829937D", "@numtexte": "2009-246", "@typelien": "CITATION", "@naturetexte": "DECRET", "@datesignatexte": "2009-03-03" }, { "@id": "LEGIARTI000020607710", "@num": "6", "#text": "Décret n°2009-246 du 3 mars 2009 - art. 6 (V)", "@sens": "cible", "@cidtexte": "JORFTEXT000020337446", "@nortexte": "ECET0829937D", "@numtexte": "2009-246", "@typelien": "CITATION", "@naturetexte": "DECRET", "@datesignatexte": "2009-03-03" }, { "@id": "LEGIARTI000041783207", "@num": "1", "#text": "Décret n°2020-397 du 4 avril 2020 - art. 1 (M)", "@sens": "cible", "@cidtexte": "JORFTEXT000041782333", "@nortexte": "ECOT2008817D", "@numtexte": "2020-397", "@typelien": "CITATION", "@naturetexte": "DECRET", "@datesignatexte": "2020-04-04" }, { "@id": "LEGIARTI000042084830", "@num": "2", "#text": "Décret n°2020-397 du 4 avril 2020 - art. 2 (V)", "@sens": "cible", "@cidtexte": "JORFTEXT000041782333", "@nortexte": "ECOT2008817D", "@numtexte": "2020-397", "@typelien": "CITATION", "@naturetexte": "DECRET", "@datesignatexte": "2020-04-04" }, { "@id": "LEGIARTI000042744442", "@num": "3", "#text": "Décret n°2020-397 du 4 avril 2020 - art. 3 (V)", "@sens": "cible", "@cidtexte": "JORFTEXT000041782333", "@nortexte": "ECOT2008817D", "@numtexte": "2020-397", "@typelien": "CITATION", "@naturetexte": "DECRET", "@datesignatexte": "2020-04-04" }, { "@id": "LEGIARTI000041783217", "@num": "6", "#text": "Décret n°2020-397 du 4 avril 2020 - art. 6 (V)", "@sens": "cible", "@cidtexte": "JORFTEXT000041782333", "@nortexte": "ECOT2008817D", "@numtexte": "2020-397", "@typelien": "CITATION", "@naturetexte": "DECRET", "@datesignatexte": "2020-04-04" }, { "@id": "LEGIARTI000041783219", "@num": "7", "#text": "Décret n°2020-397 du 4 avril 2020 - art. 7 (V)", "@sens": "cible", "@cidtexte": "JORFTEXT000041782333", "@nortexte": "ECOT2008817D", "@numtexte": "2020-397", "@typelien": "CITATION", "@naturetexte": "DECRET", "@datesignatexte": "2020-04-04" }, { "@id": "LEGIARTI000006824496", "@num": "L231-6", "#text": "Code de la construction et de l'habitation. - art. L231-6 (M)", "@sens": "source", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CITATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000006824507", "@num": "L232-2", "#text": "Code de la construction et de l'habitation. - art. L232-2 (V)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CITATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000006824535", "@num": "L241-9", "#text": "Code de la construction et de l'habitation. - art. L241-9 (V)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CITATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" } ] }, "CONTEXTE": { "TEXTE": { "TM": { "TM": { "TM": { "TM": { "TITRE_TM": [ { "@id": "LEGISCTA000006159020", "@fin": "2999-01-01", "#text": "Chapitre Ier : Contrat de construction d'une maison individuelle avec fourniture du plan.", "@debut": "1991-12-01" } ] }, "TITRE_TM": [ { "@id": "LEGISCTA000006143526", "@fin": "2999-01-01", "#text": "Titre III : Construction d'une maison individuelle.", "@debut": "1991-12-01" } ] }, "TITRE_TM": [ { "@id": "LEGISCTA000006128681", "@fin": "2999-01-01", "#text": "Livre II : Statut des constructeurs.", "@debut": "1978-06-08" } ] }, "TITRE_TM": [ { "@id": "LEGISCTA000006108136", "@fin": "2999-01-01", "#text": "Partie législative", "@debut": "1978-06-08" } ] }, "@cid": "LEGITEXT000006074096", "@nature": "CODE", "TITRE_TXT": [ { "@fin": "2999-01-01", "#text": "Code de la construction et de l'habitation", "@debut": "1977-03-10", "@id_txt": "LEGITEXT000006074096", "@c_titre_court": "Code de la construction et de l'habitation." } ], "@date_publi": "2999-01-01", "@date_signature": "2999-01-01" } }, "VERSIONS": { "VERSION": [ { "@etat": "MODIFIE", "LIEN_ART": { "@id": "LEGIARTI000006824504", "@fin": "2004-12-10", "@num": "L231-13", "@etat": "MODIFIE", "@debut": "1991-12-01", "@origine": "LEGI" } }, { "@etat": "MODIFIE", "LIEN_ART": { "@id": "LEGIARTI000006824505", "@fin": "2014-01-01", "@num": "L231-13", "@etat": "MODIFIE", "@debut": "2004-12-10", "@origine": "LEGI" } }, { "@etat": "VIGUEUR", "LIEN_ART": { "@id": "LEGIARTI000027645777", "@fin": "2999-01-01", "@num": "L231-13", "@etat": "VIGUEUR", "@debut": "2014-01-01", "@origine": "LEGI" } } ] }, "BLOC_TEXTUEL": { "CONTENU": "
Le constructeur est tenu de conclure par écrit les contrats de sous-traitance avant tout commencement d'exécution des travaux à la charge du sous-traitant. Ces contrats comportent les énonciations suivantes :
\n
a) La désignation de la construction ainsi que les nom et adresse du maître de l'ouvrage et de l'établissement qui apporte la garantie prévue à l'article L. 231-6 ;
\n
b) La description des travaux qui en font l'objet, conforme aux énonciations du contrat de construction ;
\n
c) Le prix convenu et, s'il y a lieu, les modalités de sa révision ;
\n
d) Le délai d'exécution des travaux et le montant des pénalités de retard ;
\n
e) Les modalités de règlement du prix, qui ne peut dépasser un délai de trente jours à compter de la date du versement effectué au constructeur par le maître de l'ouvrage ou le prêteur, en règlement de travaux comprenant ceux effectués par le sous-traitant et acceptés par le constructeur ;
\n
f) Le montant des pénalités dues par le constructeur en cas de retard de paiement ;
\n
g) La justification de l'une ou l'autre des garanties de paiement prévues à l'article 14 de la loi n° 75-1334 du 31 décembre 1975 relative à la sous-traitance.
\n
Copie des contrats de sous-traitance est adressée par le constructeur à l'établissement qui apporte la garantie prévue à l'article L. 231-6.
" } }, "LEGIARTI000006824505": { "META": { "META_SPEC": { "META_ARTICLE": { "NUM": "L231-13", "ETAT": "MODIFIE", "TYPE": "AUTONOME", "DATE_FIN": "2014-01-01", "DATE_DEBUT": "2004-12-10" } }, "META_COMMUN": { "ID": "LEGIARTI000006824505", "URL": "article/LEGI/ARTI/00/00/06/82/45/LEGIARTI000006824505.xml", "NATURE": "Article", "ORIGINE": "LEGI", "ANCIEN_ID": "UCAXXXXXXXX1X231L013XXAB" } }, "LIENS": { "LIEN": [ { "@id": "LEGIARTI000006467156", "@num": "14", "#text": "Loi n°75-1334 du 31 décembre 1975 - art. 14 (V)", "@sens": "source", "@cidtexte": "JORFTEXT000000889241", "@numtexte": "75-1334", "@typelien": "CITATION", "@naturetexte": "LOI", "@datesignatexte": "1975-12-31" }, { "@id": "JORFTEXT000000516442", "#text": "Décret 78-621 1978-05-31 JORF 8 JUIN 1978", "@sens": "source", "@cidtexte": "JORFTEXT000000516442", "@numtexte": "78-621", "@typelien": "CODIFICATION", "@naturetexte": "DECRET", "@datesignatexte": "1978-05-31" }, { "@id": "LEGIARTI000006529571", "@num": "39", "#text": "Loi n°2004-1343 du 9 décembre 2004 - art. 39 () JORF 10 décembre 2004", "@sens": "source", "@cidtexte": "JORFTEXT000000256180", "@nortexte": "FPPX0400010L", "@numtexte": "2004-1343", "@typelien": "MODIFICATION", "@naturetexte": "LOI", "@datesignatexte": "2004-12-09" }, { "@id": "LEGIARTI000023374155", "@num": "125", "#text": "LOI n°2008-1443\n du 30 décembre 2008 - art. 125 (V)", "@sens": "cible", "@cidtexte": "JORFTEXT000020014790", "@nortexte": "BCFX0826279L", "@numtexte": "2008-1443", "@typelien": "CITATION", "@naturetexte": "LOI", "@datesignatexte": "2008-12-30" }, { "@id": "LEGIARTI000020607705", "@num": "2", "#text": "Décret n°2009-246 du 3 mars 2009 - art. 2 (V)", "@sens": "cible", "@cidtexte": "JORFTEXT000020337446", "@nortexte": "ECET0829937D", "@numtexte": "2009-246", "@typelien": "CITATION", "@naturetexte": "DECRET", "@datesignatexte": "2009-03-03" }, { "@id": "LEGIARTI000020607714", "@num": "3", "#text": "Décret n°2009-246 du 3 mars 2009 - art. 3 (V)", "@sens": "cible", "@cidtexte": "JORFTEXT000020337446", "@nortexte": "ECET0829937D", "@numtexte": "2009-246", "@typelien": "CITATION", "@naturetexte": "DECRET", "@datesignatexte": "2009-03-03" }, { "@id": "LEGIARTI000020607712", "@num": "5", "#text": "Décret n°2009-246 du 3 mars 2009 - art. 5 (V)", "@sens": "cible", "@cidtexte": "JORFTEXT000020337446", "@nortexte": "ECET0829937D", "@numtexte": "2009-246", "@typelien": "CITATION", "@naturetexte": "DECRET", "@datesignatexte": "2009-03-03" }, { "@id": "LEGIARTI000020607710", "@num": "6", "#text": "Décret n°2009-246 du 3 mars 2009 - art. 6 (V)", "@sens": "cible", "@cidtexte": "JORFTEXT000020337446", "@nortexte": "ECET0829937D", "@numtexte": "2009-246", "@typelien": "CITATION", "@naturetexte": "DECRET", "@datesignatexte": "2009-03-03" }, { "@id": "LEGIARTI000041783207", "@num": "1", "#text": "Décret n°2020-397 du 4 avril 2020 - art. 1 (M)", "@sens": "cible", "@cidtexte": "JORFTEXT000041782333", "@nortexte": "ECOT2008817D", "@numtexte": "2020-397", "@typelien": "CITATION", "@naturetexte": "DECRET", "@datesignatexte": "2020-04-04" }, { "@id": "LEGIARTI000042084830", "@num": "2", "#text": "Décret n°2020-397 du 4 avril 2020 - art. 2 (V)", "@sens": "cible", "@cidtexte": "JORFTEXT000041782333", "@nortexte": "ECOT2008817D", "@numtexte": "2020-397", "@typelien": "CITATION", "@naturetexte": "DECRET", "@datesignatexte": "2020-04-04" }, { "@id": "LEGIARTI000042744442", "@num": "3", "#text": "Décret n°2020-397 du 4 avril 2020 - art. 3 (V)", "@sens": "cible", "@cidtexte": "JORFTEXT000041782333", "@nortexte": "ECOT2008817D", "@numtexte": "2020-397", "@typelien": "CITATION", "@naturetexte": "DECRET", "@datesignatexte": "2020-04-04" }, { "@id": "LEGIARTI000041783217", "@num": "6", "#text": "Décret n°2020-397 du 4 avril 2020 - art. 6 (V)", "@sens": "cible", "@cidtexte": "JORFTEXT000041782333", "@nortexte": "ECOT2008817D", "@numtexte": "2020-397", "@typelien": "CITATION", "@naturetexte": "DECRET", "@datesignatexte": "2020-04-04" }, { "@id": "LEGIARTI000041783219", "@num": "7", "#text": "Décret n°2020-397 du 4 avril 2020 - art. 7 (V)", "@sens": "cible", "@cidtexte": "JORFTEXT000041782333", "@nortexte": "ECOT2008817D", "@numtexte": "2020-397", "@typelien": "CITATION", "@naturetexte": "DECRET", "@datesignatexte": "2020-04-04" }, { "@id": "LEGIARTI000006824496", "@num": "L231-6", "#text": "Code de la construction et de l'habitation. - art. L231-6 (VT)", "@sens": "source", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CITATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000006824507", "@num": "L232-2", "#text": "Code de la construction et de l'habitation. - art. L232-2 (V)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CITATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000006824535", "@num": "L241-9", "#text": "Code de la construction et de l'habitation. - art. L241-9 (V)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CITATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" } ] }, "CONTEXTE": { "TEXTE": { "TM": { "TM": { "TM": { "TM": { "TITRE_TM": [ { "@id": "LEGISCTA000006159020", "@fin": "2999-01-01", "#text": "Chapitre Ier : Contrat de construction d'une maison individuelle avec fourniture du plan.", "@debut": "1991-12-01" } ] }, "TITRE_TM": [ { "@id": "LEGISCTA000006143526", "@fin": "2999-01-01", "#text": "Titre III : Construction d'une maison individuelle.", "@debut": "1991-12-01" } ] }, "TITRE_TM": [ { "@id": "LEGISCTA000006128681", "@fin": "2999-01-01", "#text": "Livre II : Statut des constructeurs.", "@debut": "1978-06-08" } ] }, "TITRE_TM": [ { "@id": "LEGISCTA000006108136", "@fin": "2999-01-01", "#text": "Partie législative", "@debut": "1978-06-08" } ] }, "@cid": "LEGITEXT000006074096", "@nature": "CODE", "TITRE_TXT": [ { "@fin": "2999-01-01", "#text": "Code de la construction et de l'habitation", "@debut": "1977-03-10", "@id_txt": "LEGITEXT000006074096", "@c_titre_court": "Code de la construction et de l'habitation." } ], "@date_publi": "2999-01-01", "@date_signature": "2999-01-01" } }, "VERSIONS": { "VERSION": [ { "@etat": "MODIFIE", "LIEN_ART": { "@id": "LEGIARTI000006824504", "@fin": "2004-12-10", "@num": "L231-13", "@etat": "MODIFIE", "@debut": "1991-12-01", "@origine": "LEGI" } }, { "@etat": "MODIFIE", "LIEN_ART": { "@id": "LEGIARTI000006824505", "@fin": "2014-01-01", "@num": "L231-13", "@etat": "MODIFIE", "@debut": "2004-12-10", "@origine": "LEGI" } }, { "@etat": "VIGUEUR", "LIEN_ART": { "@id": "LEGIARTI000027645777", "@fin": "2999-01-01", "@num": "L231-13", "@etat": "VIGUEUR", "@debut": "2014-01-01", "@origine": "LEGI" } } ] }, "BLOC_TEXTUEL": { "CONTENU": "
Le constructeur est tenu de conclure par écrit les contrats de sous-traitance avant tout commencement d'exécution des travaux à la charge du sous-traitant. Ces contrats comportent les énonciations suivantes :
\n
a) La désignation de la construction ainsi que les nom et adresse du maître de l'ouvrage et de l'établissement qui apporte la garantie prévue à l'article L. 231-6 ;
\n
b) La description des travaux qui en font l'objet, conforme aux énonciations du contrat de construction ;
\n
c) Le prix convenu et, s'il y a lieu, les modalités de sa révision ;
\n
d) Le délai d'exécution des travaux et le montant des pénalités de retard ;
\n
e) Les modalités de règlement du prix, qui ne peut dépasser un délai de trente jours à compter de la date du versement effectué au constructeur par le maître de l'ouvrage ou le prêteur, en règlement de travaux comprenant ceux effectués par le sous-traitant et acceptés par le constructeur ;
\n
f) Le montant des pénalités dues par le constructeur en cas de retard de paiement ;
\n
g) La justification de l'une ou l'autre des garanties de paiement prévues à l'article 14 de la loi n° 75-1334 du 31 décembre 1975 relative à la sous-traitance ou de toute autre garantie, délivrée par un établissement de crédit ou une entreprise d'assurance, de nature à garantir le paiement des sommes dues au titre du sous-traité.
\n
Copie des contrats de sous-traitance est adressée par le constructeur à l'établissement qui apporte la garantie prévue à l'article L. 231-6.
" } }, "LEGIARTI000006824657": { "META": { "META_SPEC": { "META_ARTICLE": { "NUM": "L231-2", "ETAT": "MODIFIE", "TYPE": "AUTONOME", "DATE_FIN": "1979-07-14", "DATE_DEBUT": "1978-06-08" } }, "META_COMMUN": { "ID": "LEGIARTI000006824657", "URL": "article/LEGI/ARTI/00/00/06/82/46/LEGIARTI000006824657.xml", "NATURE": "Article", "ORIGINE": "LEGI", "ANCIEN_ID": "UCAXXXXXXXX1X231L002XXAA" } }, "LIENS": { "LIEN": [ { "@id": "JORFTEXT000000687668", "#text": "Loi 71-579 1971-07-16 art. 45 al. 2 à 6", "@sens": "source", "@cidtexte": "JORFTEXT000000687668", "@numtexte": "71-579", "@typelien": "CONCORDANCE", "@naturetexte": "LOI", "@datesignatexte": "1971-07-16" }, { "@id": "LEGIARTI000006826382", "@num": "45", "#text": "Loi n°71-579 du 16 juillet 1971 - art. 45 (Ab)", "@sens": "cible", "@cidtexte": "JORFTEXT000000687668", "@numtexte": "71-579", "@typelien": "CONCORDE", "@naturetexte": "LOI", "@datesignatexte": "1971-07-16" }, { "@id": "JORFTEXT000000516442", "#text": "Décret 78-621 1978-05-31 JORF 8 juin 1978", "@sens": "source", "@cidtexte": "JORFTEXT000000516442", "@numtexte": "78-621", "@typelien": "CODIFICATION", "@naturetexte": "DECRET", "@datesignatexte": "1978-05-31" }, { "@id": "LEGIARTI000006829601", "@num": "9", "#text": "Arrêté du 30 décembre 1988 - art. 9 (V)", "@sens": "cible", "@cidtexte": "JORFTEXT000000873773", "@nortexte": "EQUC8800886A", "@typelien": "CITATION", "@naturetexte": "ARRETE", "@datesignatexte": "1988-12-30" }, { "@id": "LEGIARTI000006739977", "@num": "1", "#text": "Décret n°99-776 du 8 septembre 1999 - art. 1 (Ab)", "@sens": "cible", "@cidtexte": "JORFTEXT000000396628", "@nortexte": "ECOT9914031D", "@numtexte": "99-776", "@typelien": "CITATION", "@naturetexte": "DECRET", "@datesignatexte": "1999-09-08" }, { "@id": "LEGITEXT000050742475", "#text": "Arrêté du 3 décembre 2024 (V)", "@sens": "cible", "@cidtexte": "JORFTEXT000050731883", "@nortexte": "LRUL2422852A", "@typelien": "CITATION", "@naturetexte": "ARRETE", "@datesignatexte": "2024-12-03" }, { "@id": "LEGIARTI000006443512", "@num": "1792-1", "#text": "Code civil - art. 1792-1 (V)", "@sens": "source", "@cidtexte": "LEGITEXT000006070721", "@typelien": "CITATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000006824160", "@num": "L111-14", "#text": "Code de la construction et de l'habitation. - art. L111-14 (V)", "@sens": "source", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CITATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000041586868", "@num": "L231-1", "#text": "Code de la construction et de l'habitation. - art. L231-1 (VD)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CITATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000006824510", "@num": "L231-1-1", "#text": "Code de la construction et de l'habitation. - art. L231-1-1 (Ab)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CITATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000006824501", "@num": "L231-10", "#text": "Code de la construction et de l'habitation. - art. L231-10 (V)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CITATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000038433486", "@num": "L231-6", "#text": "Code de la construction et de l'habitation. - art. L231-6 (VD)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CITATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000006824498", "@num": "L231-7", "#text": "Code de la construction et de l'habitation. - art. L231-7 (V)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CITATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000006824507", "@num": "L232-2", "#text": "Code de la construction et de l'habitation. - art. L232-2 (V)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CITATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000006824514", "@num": "L241-1", "#text": "Code de la construction et de l'habitation. - art. L241-1 (M)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CITATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000006824660", "@num": "L241-3", "#text": "Code de la construction et de l'habitation. - art. L241-3 (M)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CITATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000006824538", "@num": "L242-2", "#text": "Code de la construction et de l'habitation. - art. L242-2 (V)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CITATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000006896534", "@num": "R*231-1", "#text": "Code de la construction et de l'habitation. - art. R*231-1 (M)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CITATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000006896543", "@num": "R*231-7", "#text": "Code de la construction et de l'habitation. - art. R*231-7 (M)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CITATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000039041705", "@num": "R231-13", "#text": "Code de la construction et de l'habitation. - art. R231-13 (VD)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CITATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000039041701", "@num": "R231-14", "#text": "Code de la construction et de l'habitation. - art. R231-14 (VD)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CITATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000039041754", "@num": "R231-2", "#text": "Code de la construction et de l'habitation. - art. R231-2 (VD)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CITATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000039041749", "@num": "R231-3", "#text": "Code de la construction et de l'habitation. - art. R231-3 (VD)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CITATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000039041744", "@num": "R231-4", "#text": "Code de la construction et de l'habitation. - art. R231-4 (VD)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CITATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000039041740", "@num": "R231-5", "#text": "Code de la construction et de l'habitation. - art. R231-5 (VD)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CITATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000006821757", "@num": "R421-24-3", "#text": "Code des assurances - art. R421-24-3 (Ab)", "@sens": "cible", "@cidtexte": "LEGITEXT000006073984", "@typelien": "CITATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000033655931", "@num": "D313-26", "#text": "Code monétaire et financier - art. D313-26 (VD)", "@sens": "cible", "@cidtexte": "LEGITEXT000006072026", "@typelien": "CITATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" } ] }, "CONTEXTE": { "TEXTE": { "TM": { "TM": { "TM": { "TM": { "TITRE_TM": [ { "@id": "LEGISCTA000006159020", "@fin": "2999-01-01", "#text": "Chapitre Ier : Contrat de construction d'une maison individuelle avec fourniture du plan.", "@debut": "1991-12-01" } ] }, "TITRE_TM": [ { "@id": "LEGISCTA000006143526", "@fin": "2999-01-01", "#text": "Titre III : Construction d'une maison individuelle.", "@debut": "1991-12-01" } ] }, "TITRE_TM": [ { "@id": "LEGISCTA000006128681", "@fin": "2999-01-01", "#text": "Livre II : Statut des constructeurs.", "@debut": "1978-06-08" } ] }, "TITRE_TM": [ { "@id": "LEGISCTA000006108136", "@fin": "2999-01-01", "#text": "Partie législative", "@debut": "1978-06-08" } ] }, "@cid": "LEGITEXT000006074096", "@nature": "CODE", "TITRE_TXT": [ { "@fin": "2999-01-01", "#text": "Code de la construction et de l'habitation", "@debut": "1977-03-10", "@id_txt": "LEGITEXT000006074096", "@c_titre_court": "Code de la construction et de l'habitation." } ], "@date_publi": "2999-01-01", "@date_signature": "2999-01-01" } }, "VERSIONS": { "VERSION": [ { "@etat": "MODIFIE", "LIEN_ART": { "@id": "LEGIARTI000006824657", "@fin": "1979-07-14", "@num": "L231-2", "@etat": "MODIFIE", "@debut": "1978-06-08", "@origine": "LEGI" } }, { "@etat": "MODIFIE", "LIEN_ART": { "@id": "LEGIARTI000006824658", "@fin": "1991-12-01", "@num": "L231-2", "@etat": "MODIFIE", "@debut": "1979-07-14", "@origine": "LEGI" } }, { "@etat": "MODIFIE", "LIEN_ART": { "@id": "LEGIARTI000006824659", "@fin": "2018-11-25", "@num": "L231-2", "@etat": "MODIFIE", "@debut": "1991-12-01", "@origine": "LEGI" } }, { "@etat": "MODIFIE", "LIEN_ART": { "@id": "LEGIARTI000037667723", "@fin": "2020-02-01", "@num": "L231-2", "@etat": "MODIFIE", "@debut": "2018-11-25", "@origine": "LEGI" } }, { "@etat": "MODIFIE", "LIEN_ART": { "@id": "LEGIARTI000038433496", "@fin": "2021-07-01", "@num": "L231-2", "@etat": "MODIFIE", "@debut": "2020-02-01", "@origine": "LEGI" } }, { "@etat": "VIGUEUR", "LIEN_ART": { "@id": "LEGIARTI000041586856", "@fin": "2999-01-01", "@num": "L231-2", "@etat": "VIGUEUR", "@debut": "2021-07-01", "@origine": "LEGI" } } ] }, "BLOC_TEXTUEL": { "CONTENU": "

La personne mentionnée au premier alinéa de l'article L. 231-1 est tenue d'exécuter les travaux décrits et estimés conformément au g dudit article aux prix et conditions mentionnés au contrat si le maître de l'ouvrage en fait la demande dans le délai de trois mois à partir de la signature du contrat.

\n
\n

Lorsque cette personne a fait état dans sa publicité ou dans le contrat de prêts destinés au financement de la construction, le contrat est, nonobstant toute stipulation contraire, réputé conclu sous la condition résolutoire du refus des prêts sauf si le maître de l'ouvrage a expressément indiqué qu'il renonçait à ces prêts.

\n
\n

Le contrat est également réputé conclu sous la condition suspensive qu'il soit satisfait à toutes les formalités réglementaires préalables à la construction.

\n
\n

La personne mentionnée au premier alinéa de l'article L. 231-1 ne peut exiger ou accepter du maître de l'ouvrage aucun versement, aucun dépôt, aucune souscription ou acceptation d'effet de commerce avant la signature du contrat. Les sommes qui peuvent être exigées à la signature du contrat sont restituées à l'acquéreur dans le cas où la condition suspensive prévue à l'alinéa précédent ne se réaliserait pas.

\n
\n

Aucun paiement ne peut non plus être exigé ni accepté avant la date à laquelle la créance est exigible.

\n
\n

La personne mentionnée à l'article L. 231-1, alinéa 1er, est réputée constructeur de l'ouvrage au sens de l'article 1792-1 du code civil reproduit à l'article L. 111-14 du présent code.

\n
" } }, "LEGIARTI000006824658": { "META": { "META_SPEC": { "META_ARTICLE": { "NUM": "L231-2", "ETAT": "MODIFIE", "TYPE": "AUTONOME", "DATE_FIN": "1991-12-01", "DATE_DEBUT": "1979-07-14" } }, "META_COMMUN": { "ID": "LEGIARTI000006824658", "URL": "article/LEGI/ARTI/00/00/06/82/46/LEGIARTI000006824658.xml", "NATURE": "Article", "ORIGINE": "LEGI", "ANCIEN_ID": "UCAXXXXXXXX1X231L002XXAB" } }, "LIENS": { "LIEN": [ { "@id": "JORFTEXT000000687668", "#text": "Loi 71-579 1971-07-16 art. 45 al. 2 à 6", "@sens": "source", "@cidtexte": "JORFTEXT000000687668", "@numtexte": "71-579", "@typelien": "CONCORDANCE", "@naturetexte": "LOI", "@datesignatexte": "1971-07-16" }, { "@id": "LEGIARTI000006826382", "@num": "45", "#text": "Loi n°71-579 du 16 juillet 1971 - art. 45 (Ab)", "@sens": "cible", "@cidtexte": "JORFTEXT000000687668", "@numtexte": "71-579", "@typelien": "CONCORDE", "@naturetexte": "LOI", "@datesignatexte": "1971-07-16" }, { "@id": "JORFTEXT000000516442", "#text": "Décret 78-621 1978-05-31 JORF 8 juin 1978", "@sens": "source", "@cidtexte": "JORFTEXT000000516442", "@numtexte": "78-621", "@typelien": "CODIFICATION", "@naturetexte": "DECRET", "@datesignatexte": "1978-05-31" }, { "@id": "LEGIARTI000006273347", "@num": "39", "#text": "Loi n°79-596 du 13 juillet 1979 - art. 39 () JORF 14 juillet 1979", "@sens": "source", "@cidtexte": "JORFTEXT000000886678", "@numtexte": "79-596", "@typelien": "MODIFICATION", "@naturetexte": "LOI", "@datesignatexte": "1979-07-13" }, { "@id": "LEGIARTI000006829601", "@num": "9", "#text": "Arrêté du 30 décembre 1988 - art. 9 (V)", "@sens": "cible", "@cidtexte": "JORFTEXT000000873773", "@nortexte": "EQUC8800886A", "@typelien": "CITATION", "@naturetexte": "ARRETE", "@datesignatexte": "1988-12-30" }, { "@id": "LEGIARTI000006739977", "@num": "1", "#text": "Décret n°99-776 du 8 septembre 1999 - art. 1 (Ab)", "@sens": "cible", "@cidtexte": "JORFTEXT000000396628", "@nortexte": "ECOT9914031D", "@numtexte": "99-776", "@typelien": "CITATION", "@naturetexte": "DECRET", "@datesignatexte": "1999-09-08" }, { "@id": "LEGITEXT000050742475", "#text": "Arrêté du 3 décembre 2024 (V)", "@sens": "cible", "@cidtexte": "JORFTEXT000050731883", "@nortexte": "LRUL2422852A", "@typelien": "CITATION", "@naturetexte": "ARRETE", "@datesignatexte": "2024-12-03" }, { "@id": "LEGIARTI000006443512", "@num": "1792-1", "#text": "Code civil - art. 1792-1 (V)", "@sens": "source", "@cidtexte": "LEGITEXT000006070721", "@typelien": "CITATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000006824160", "@num": "L111-14", "#text": "Code de la construction et de l'habitation. - art. L111-14 (V)", "@sens": "source", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CITATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000041586868", "@num": "L231-1", "#text": "Code de la construction et de l'habitation. - art. L231-1 (VD)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CITATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000006824510", "@num": "L231-1-1", "#text": "Code de la construction et de l'habitation. - art. L231-1-1 (Ab)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CITATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000006824501", "@num": "L231-10", "#text": "Code de la construction et de l'habitation. - art. L231-10 (V)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CITATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000038433486", "@num": "L231-6", "#text": "Code de la construction et de l'habitation. - art. L231-6 (VD)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CITATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000006824498", "@num": "L231-7", "#text": "Code de la construction et de l'habitation. - art. L231-7 (V)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CITATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000006824507", "@num": "L232-2", "#text": "Code de la construction et de l'habitation. - art. L232-2 (V)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CITATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000006824514", "@num": "L241-1", "#text": "Code de la construction et de l'habitation. - art. L241-1 (M)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CITATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000006824660", "@num": "L241-3", "#text": "Code de la construction et de l'habitation. - art. L241-3 (M)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CITATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000006824538", "@num": "L242-2", "#text": "Code de la construction et de l'habitation. - art. L242-2 (V)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CITATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000006896534", "@num": "R*231-1", "#text": "Code de la construction et de l'habitation. - art. R*231-1 (M)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CITATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000006896543", "@num": "R*231-7", "#text": "Code de la construction et de l'habitation. - art. R*231-7 (M)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CITATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000039041705", "@num": "R231-13", "#text": "Code de la construction et de l'habitation. - art. R231-13 (VD)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CITATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000039041701", "@num": "R231-14", "#text": "Code de la construction et de l'habitation. - art. R231-14 (VD)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CITATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000039041754", "@num": "R231-2", "#text": "Code de la construction et de l'habitation. - art. R231-2 (VD)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CITATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000039041749", "@num": "R231-3", "#text": "Code de la construction et de l'habitation. - art. R231-3 (VD)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CITATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000039041744", "@num": "R231-4", "#text": "Code de la construction et de l'habitation. - art. R231-4 (VD)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CITATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000039041740", "@num": "R231-5", "#text": "Code de la construction et de l'habitation. - art. R231-5 (VD)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CITATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000006821757", "@num": "R421-24-3", "#text": "Code des assurances - art. R421-24-3 (Ab)", "@sens": "cible", "@cidtexte": "LEGITEXT000006073984", "@typelien": "CITATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000033655931", "@num": "D313-26", "#text": "Code monétaire et financier - art. D313-26 (VD)", "@sens": "cible", "@cidtexte": "LEGITEXT000006072026", "@typelien": "CITATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" } ] }, "CONTEXTE": { "TEXTE": { "TM": { "TM": { "TM": { "TM": { "TITRE_TM": [ { "@id": "LEGISCTA000006159020", "@fin": "2999-01-01", "#text": "Chapitre Ier : Contrat de construction d'une maison individuelle avec fourniture du plan.", "@debut": "1991-12-01" } ] }, "TITRE_TM": [ { "@id": "LEGISCTA000006143526", "@fin": "2999-01-01", "#text": "Titre III : Construction d'une maison individuelle.", "@debut": "1991-12-01" } ] }, "TITRE_TM": [ { "@id": "LEGISCTA000006128681", "@fin": "2999-01-01", "#text": "Livre II : Statut des constructeurs.", "@debut": "1978-06-08" } ] }, "TITRE_TM": [ { "@id": "LEGISCTA000006108136", "@fin": "2999-01-01", "#text": "Partie législative", "@debut": "1978-06-08" } ] }, "@cid": "LEGITEXT000006074096", "@nature": "CODE", "TITRE_TXT": [ { "@fin": "2999-01-01", "#text": "Code de la construction et de l'habitation", "@debut": "1977-03-10", "@id_txt": "LEGITEXT000006074096", "@c_titre_court": "Code de la construction et de l'habitation." } ], "@date_publi": "2999-01-01", "@date_signature": "2999-01-01" } }, "VERSIONS": { "VERSION": [ { "@etat": "MODIFIE", "LIEN_ART": { "@id": "LEGIARTI000006824657", "@fin": "1979-07-14", "@num": "L231-2", "@etat": "MODIFIE", "@debut": "1978-06-08", "@origine": "LEGI" } }, { "@etat": "MODIFIE", "LIEN_ART": { "@id": "LEGIARTI000006824658", "@fin": "1991-12-01", "@num": "L231-2", "@etat": "MODIFIE", "@debut": "1979-07-14", "@origine": "LEGI" } }, { "@etat": "MODIFIE", "LIEN_ART": { "@id": "LEGIARTI000006824659", "@fin": "2018-11-25", "@num": "L231-2", "@etat": "MODIFIE", "@debut": "1991-12-01", "@origine": "LEGI" } }, { "@etat": "MODIFIE", "LIEN_ART": { "@id": "LEGIARTI000037667723", "@fin": "2020-02-01", "@num": "L231-2", "@etat": "MODIFIE", "@debut": "2018-11-25", "@origine": "LEGI" } }, { "@etat": "MODIFIE", "LIEN_ART": { "@id": "LEGIARTI000038433496", "@fin": "2021-07-01", "@num": "L231-2", "@etat": "MODIFIE", "@debut": "2020-02-01", "@origine": "LEGI" } }, { "@etat": "VIGUEUR", "LIEN_ART": { "@id": "LEGIARTI000041586856", "@fin": "2999-01-01", "@num": "L231-2", "@etat": "VIGUEUR", "@debut": "2021-07-01", "@origine": "LEGI" } } ] }, "BLOC_TEXTUEL": { "CONTENU": "

Le contrat est réputé conclu sous la condition suspensive qu'il soit satisfait à toutes les formalités réglementaires préalables à la construction.

Aucun paiement ne peut non plus être exigé ni accepté avant la date à laquelle la créance est exigible.

La personne mentionnée à l'article L. 231-1, alinéa 1er, est réputée constructeur de l'ouvrage au sens de l'article 1792-1 du Code civil reproduit à l'article L. 111-14 du présent code.

\n
" } }, "LEGIARTI000006824659": { "META": { "META_SPEC": { "META_ARTICLE": { "NUM": "L231-2", "ETAT": "MODIFIE", "TYPE": "AUTONOME", "DATE_FIN": "2018-11-25", "DATE_DEBUT": "1991-12-01" } }, "META_COMMUN": { "ID": "LEGIARTI000006824659", "URL": "article/LEGI/ARTI/00/00/06/82/46/LEGIARTI000006824659.xml", "NATURE": "Article", "ORIGINE": "LEGI", "ANCIEN_ID": "UCAXXXXXXXX1X231L002XXAC" } }, "LIENS": { "LIEN": [ { "@id": "JORFTEXT000000687668", "#text": "Loi 71-579 1971-07-16 art. 45 al. 2 à 6", "@sens": "source", "@cidtexte": "JORFTEXT000000687668", "@numtexte": "71-579", "@typelien": "CONCORDANCE", "@naturetexte": "LOI", "@datesignatexte": "1971-07-16" }, { "@id": "LEGIARTI000006826382", "@num": "45", "#text": "Loi n°71-579 du 16 juillet 1971 - art. 45 (Ab)", "@sens": "cible", "@cidtexte": "JORFTEXT000000687668", "@numtexte": "71-579", "@typelien": "CONCORDE", "@naturetexte": "LOI", "@datesignatexte": "1971-07-16" }, { "@id": "JORFTEXT000000522423", "#text": "Loi n° 77-2 du 3 janvier 1977 (V)", "@sens": "source", "@cidtexte": "JORFTEXT000000522423", "@numtexte": "77-2", "@typelien": "CITATION", "@naturetexte": "LOI", "@datesignatexte": "1977-01-03" }, { "@id": "JORFTEXT000000516442", "#text": "Décret 78-621 1978-05-31 JORF 8 JUIN 1978", "@sens": "source", "@cidtexte": "JORFTEXT000000516442", "@numtexte": "78-621", "@typelien": "CODIFICATION", "@naturetexte": "DECRET", "@datesignatexte": "1978-05-31" }, { "@id": "LEGIARTI000006829601", "@num": "9", "#text": "Arrêté du 30 décembre 1988 - art. 9 (V)", "@sens": "cible", "@cidtexte": "JORFTEXT000000873773", "@nortexte": "EQUC8800886A", "@typelien": "CITATION", "@naturetexte": "ARRETE", "@datesignatexte": "1988-12-30" }, { "@id": "JORFTEXT000000709335", "#text": "Loi 90-1129 1990-12-19 art. 8", "@sens": "source", "@cidtexte": "JORFTEXT000000709335", "@nortexte": "EQUX9000054L", "@numtexte": "90-1129", "@typelien": "SPEC_APPLI", "@naturetexte": "LOI", "@datesignatexte": "1990-12-19" }, { "@id": "LEGIARTI000006826206", "@num": "1", "#text": "Loi n°90-1129 du 19 décembre 1990 - art. 1 () JORF 22 décembre 1990 en vigueur le 1er décembre 1991", "@sens": "source", "@cidtexte": "JORFTEXT000000709335", "@nortexte": "EQUX9000054L", "@numtexte": "90-1129", "@typelien": "MODIFICATION", "@naturetexte": "LOI", "@datesignatexte": "1990-12-19" }, { "@id": "LEGIARTI000006739977", "@num": "1", "#text": "Décret n°99-776 du 8 septembre 1999 - art. 1 (Ab)", "@sens": "cible", "@cidtexte": "JORFTEXT000000396628", "@nortexte": "ECOT9914031D", "@numtexte": "99-776", "@typelien": "CITATION", "@naturetexte": "DECRET", "@datesignatexte": "1999-09-08" }, { "@id": "LEGITEXT000050742475", "#text": "Arrêté du 3 décembre 2024 (V)", "@sens": "cible", "@cidtexte": "JORFTEXT000050731883", "@nortexte": "LRUL2422852A", "@typelien": "CITATION", "@naturetexte": "ARRETE", "@datesignatexte": "2024-12-03" }, { "@id": "LEGIARTI000006795972", "@num": "L242-1", "#text": "Code des assurances - art. L242-1 (V)", "@sens": "source", "@cidtexte": "LEGITEXT000006073984", "@typelien": "CITATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000006824172", "@num": "L111-23", "#text": "Code de la construction et de l'habitation. - art. L111-23 (V)", "@sens": "source", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CITATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000041586868", "@num": "L231-1", "#text": "Code de la construction et de l'habitation. - art. L231-1 (VD)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CITATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000006824510", "@num": "L231-1-1", "#text": "Code de la construction et de l'habitation. - art. L231-1-1 (Ab)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CITATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000006824501", "@num": "L231-10", "#text": "Code de la construction et de l'habitation. - art. L231-10 (V)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CITATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000006824502", "@num": "L231-11", "#text": "Code de la construction et de l'habitation. - art. L231-11 (V)", "@sens": "source", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CITATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000038433486", "@num": "L231-6", "#text": "Code de la construction et de l'habitation. - art. L231-6 (VD)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CITATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000006824498", "@num": "L231-7", "#text": "Code de la construction et de l'habitation. - art. L231-7 (V)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CITATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000006824507", "@num": "L232-2", "#text": "Code de la construction et de l'habitation. - art. L232-2 (V)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CITATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000006824514", "@num": "L241-1", "#text": "Code de la construction et de l'habitation. - art. L241-1 (M)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CITATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000006824660", "@num": "L241-3", "#text": "Code de la construction et de l'habitation. - art. L241-3 (M)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CITATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000006824538", "@num": "L242-2", "#text": "Code de la construction et de l'habitation. - art. L242-2 (V)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CITATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000006896534", "@num": "R*231-1", "#text": "Code de la construction et de l'habitation. - art. R*231-1 (M)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CITATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000006896543", "@num": "R*231-7", "#text": "Code de la construction et de l'habitation. - art. R*231-7 (M)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CITATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000039041705", "@num": "R231-13", "#text": "Code de la construction et de l'habitation. - art. R231-13 (VD)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CITATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000039041701", "@num": "R231-14", "#text": "Code de la construction et de l'habitation. - art. R231-14 (VD)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CITATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000039041754", "@num": "R231-2", "#text": "Code de la construction et de l'habitation. - art. R231-2 (VD)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CITATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000039041749", "@num": "R231-3", "#text": "Code de la construction et de l'habitation. - art. R231-3 (VD)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CITATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000039041744", "@num": "R231-4", "#text": "Code de la construction et de l'habitation. - art. R231-4 (VD)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CITATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000039041740", "@num": "R231-5", "#text": "Code de la construction et de l'habitation. - art. R231-5 (VD)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CITATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000006821757", "@num": "R421-24-3", "#text": "Code des assurances - art. R421-24-3 (Ab)", "@sens": "cible", "@cidtexte": "LEGITEXT000006073984", "@typelien": "CITATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000033655931", "@num": "D313-26", "#text": "Code monétaire et financier - art. D313-26 (VD)", "@sens": "cible", "@cidtexte": "LEGITEXT000006072026", "@typelien": "CITATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" } ] }, "CONTEXTE": { "TEXTE": { "TM": { "TM": { "TM": { "TM": { "TITRE_TM": [ { "@id": "LEGISCTA000006159020", "@fin": "2999-01-01", "#text": "Chapitre Ier : Contrat de construction d'une maison individuelle avec fourniture du plan.", "@debut": "1991-12-01" } ] }, "TITRE_TM": [ { "@id": "LEGISCTA000006143526", "@fin": "2999-01-01", "#text": "Titre III : Construction d'une maison individuelle.", "@debut": "1991-12-01" } ] }, "TITRE_TM": [ { "@id": "LEGISCTA000006128681", "@fin": "2999-01-01", "#text": "Livre II : Statut des constructeurs.", "@debut": "1978-06-08" } ] }, "TITRE_TM": [ { "@id": "LEGISCTA000006108136", "@fin": "2999-01-01", "#text": "Partie législative", "@debut": "1978-06-08" } ] }, "@cid": "LEGITEXT000006074096", "@nature": "CODE", "TITRE_TXT": [ { "@fin": "2999-01-01", "#text": "Code de la construction et de l'habitation", "@debut": "1977-03-10", "@id_txt": "LEGITEXT000006074096", "@c_titre_court": "Code de la construction et de l'habitation." } ], "@date_publi": "2999-01-01", "@date_signature": "2999-01-01" } }, "VERSIONS": { "VERSION": [ { "@etat": "MODIFIE", "LIEN_ART": { "@id": "LEGIARTI000006824657", "@fin": "1979-07-14", "@num": "L231-2", "@etat": "MODIFIE", "@debut": "1978-06-08", "@origine": "LEGI" } }, { "@etat": "MODIFIE", "LIEN_ART": { "@id": "LEGIARTI000006824658", "@fin": "1991-12-01", "@num": "L231-2", "@etat": "MODIFIE", "@debut": "1979-07-14", "@origine": "LEGI" } }, { "@etat": "MODIFIE", "LIEN_ART": { "@id": "LEGIARTI000006824659", "@fin": "2018-11-25", "@num": "L231-2", "@etat": "MODIFIE", "@debut": "1991-12-01", "@origine": "LEGI" } }, { "@etat": "MODIFIE", "LIEN_ART": { "@id": "LEGIARTI000037667723", "@fin": "2020-02-01", "@num": "L231-2", "@etat": "MODIFIE", "@debut": "2018-11-25", "@origine": "LEGI" } }, { "@etat": "MODIFIE", "LIEN_ART": { "@id": "LEGIARTI000038433496", "@fin": "2021-07-01", "@num": "L231-2", "@etat": "MODIFIE", "@debut": "2020-02-01", "@origine": "LEGI" } }, { "@etat": "VIGUEUR", "LIEN_ART": { "@id": "LEGIARTI000041586856", "@fin": "2999-01-01", "@num": "L231-2", "@etat": "VIGUEUR", "@debut": "2021-07-01", "@origine": "LEGI" } } ] }, "BLOC_TEXTUEL": { "CONTENU": "
Le contrat visé à l'article L. 231-1 doit comporter les énonciations suivantes :
\n
a) La désignation du terrain destiné à l'implantation de la construction et la mention du titre de propriété du maître de l'ouvrage ou des droits réels lui permettant de construire ;
\n
b) L'affirmation de la conformité du projet aux règles de construction prescrites en application du présent code, notamment de son livre Ier, et du code de l'urbanisme ;
\n
c) La consistance et les caractéristiques techniques du bâtiment à construire comportant tous les travaux d'adaptation au sol, les raccordements aux réseaux divers et tous les travaux d'équipement intérieur ou extérieur indispensables à l'implantation et à l'utilisation de l'immeuble ;
\n
d) Le coût du bâtiment à construire, égal à la somme du prix convenu et, s'il y a lieu, du coût des travaux dont le maître de l'ouvrage se réserve l'exécution en précisant :
\n
-d'une part, le prix convenu qui est forfaitaire et définitif, sous réserve, s'il y a lieu, de sa révision dans les conditions et limites convenues conformément à l'article L. 231-11, et qui comporte la rémunération de tout ce qui est à la charge du constructeur, y compris le coût de la garantie de livraison ;
\n
-d'autre part, le coût des travaux dont le maître de l'ouvrage se réserve l'exécution, ceux-ci étant décrits et chiffrés par le constructeur et faisant l'objet, de la part du maître de l'ouvrage, d'une clause manuscrite spécifique et paraphée par laquelle il en accepte le coût et la charge ;
\n
e) Les modalités de règlement en fonction de l'état d'avancement des travaux ;
\n
f) L'indication que le maître de l'ouvrage pourra se faire assister par un professionnel habilité en application de la loi n° 77-2 du 3 janvier 1977 sur l'architecture ou des articles L. 111-23 et suivants lors de la réception ou par tout autre professionnel de la construction titulaire d'un contrat d'assurance couvrant les responsabilités pour ce type de mission ;
\n
g) L'indication de l'obtention du permis de construire et des autres autorisations administratives, dont une copie est annexée au contrat ;
\n
h) L'indication des modalités de financement, la nature et le montant des prêts obtenus et acceptés par le maître de l'ouvrage ;
\n
i) La date d'ouverture du chantier, le délai d'exécution des travaux et les pénalités prévues en cas de retard de livraison ;
\n
j) La référence de l'assurance de dommages souscrite par le maître de l'ouvrage, en application de l'article L. 242-1 du code des assurances ;
\n
k) Les justifications des garanties de remboursement et de livraison apportées par le constructeur, les attestations de ces garanties étant établies par le garant et annexées au contrat.
\n
Les stipulations du contrat, notamment celles relatives aux travaux à la charge du constructeur, au prix convenu, au délai d'exécution des travaux et aux pénalités applicables en cas de retard d'exécution peuvent se référer à des clauses types approuvées par décret en Conseil d'Etat.
" } }, "LEGIARTI000006826206": { "META": { "META_SPEC": { "META_ARTICLE": { "NUM": "1", "TYPE": "ENTIEREMENT_MODIF", "DATE_FIN": "2999-01-01", "DATE_DEBUT": "2999-01-01" } }, "META_COMMUN": { "ID": "LEGIARTI000006826206", "URL": "article/LEGI/ARTI/00/00/06/82/62/LEGIARTI000006826206.xml", "NATURE": "Article", "ORIGINE": "LEGI", "ANCIEN_ID": "UCEAJXXXXXX001AAXXXXXXAA" } }, "LIENS": { "LIEN": [ { "@id": "LEGIARTI000006824493", "@num": "L230-1", "#text": "Code de la construction et de l'habitation. - art. L230-1 (V)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CREATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000006824509", "@num": "L231-1", "#text": "Code de la construction et de l'habitation. - art. L231-1 (V)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "MODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000006824510", "@num": "L231-1-1", "#text": "Code de la construction et de l'habitation. - art. L231-1-1 (Ab)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "ABROGATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000006824511", "@num": "L231-1-2", "#text": "Code de la construction et de l'habitation. - art. L231-1-2 (Ab)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "ABROGATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000006824501", "@num": "L231-10", "#text": "Code de la construction et de l'habitation. - art. L231-10 (V)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CREATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000006824502", "@num": "L231-11", "#text": "Code de la construction et de l'habitation. - art. L231-11 (V)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CREATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000006824503", "@num": "L231-12", "#text": "Code de la construction et de l'habitation. - art. L231-12 (M)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CREATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000006824504", "@num": "L231-13", "#text": "Code de la construction et de l'habitation. - art. L231-13 (M)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CREATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000006824659", "@num": "L231-2", "#text": "Code de la construction et de l'habitation. - art. L231-2 (M)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "MODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000006824513", "@num": "L231-3", "#text": "Code de la construction et de l'habitation. - art. L231-3 (V)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "MODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000006824494", "@num": "L231-4", "#text": "Code de la construction et de l'habitation. - art. L231-4 (V)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CREATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000006824495", "@num": "L231-5", "#text": "Code de la construction et de l'habitation. - art. L231-5 (V)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CREATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000006824496", "@num": "L231-6", "#text": "Code de la construction et de l'habitation. - art. L231-6 (M)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CREATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000006824498", "@num": "L231-7", "#text": "Code de la construction et de l'habitation. - art. L231-7 (V)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CREATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000006824499", "@num": "L231-8", "#text": "Code de la construction et de l'habitation. - art. L231-8 (V)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CREATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000006824500", "@num": "L231-9", "#text": "Code de la construction et de l'habitation. - art. L231-9 (V)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CREATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000006824506", "@num": "L232-1", "#text": "Code de la construction et de l'habitation. - art. L232-1 (V)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CREATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000006824507", "@num": "L232-2", "#text": "Code de la construction et de l'habitation. - art. L232-2 (V)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CREATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" } ] }, "CONTEXTE": { "TEXTE": { "@cid": "JORFTEXT000000709335", "@nor": "EQUX9000054L", "@num": "90-1129", "@nature": "LOI", "TITRE_TXT": [ { "@fin": "2999-01-01", "#text": "LOI n° 90-1129 du 19 décembre 1990 relative au contrat de construction d'une maison individuelle (1)", "@debut": "2999-01-01", "@id_txt": "JORFTEXT000000709335", "@c_titre_court": "LOI n° 90-1129 du 19 décembre 1990" }, { "@fin": "2007-09-01", "#text": "Loi n°90-1129 du 19 décembre 1990 relative au contrat de construction d'une maison individuelle", "@debut": "1991-12-01", "@id_txt": "LEGITEXT000006076911", "@c_titre_court": "Loi n°90-1129 du 19 décembre 1990" } ], "@date_publi": "1990-12-22", "@date_signature": "1990-12-19", "@num_parution_jo": "0297" } }, "VERSIONS": { "VERSION": [ { "LIEN_ART": { "@id": "LEGIARTI000006826206", "@fin": "2999-01-01", "@num": "1", "@debut": "2999-01-01", "@origine": "LEGI" } } ] }, "BLOC_TEXTUEL": { "CONTENU": "a modifié les dispositions suivantes
\n
" } }, "LEGIARTI000027645773": { "META": { "META_SPEC": { "META_ARTICLE": { "NUM": "L231-6", "ETAT": "MODIFIE", "TYPE": "AUTONOME", "DATE_FIN": "2020-02-01", "DATE_DEBUT": "2014-01-01" } }, "META_COMMUN": { "ID": "LEGIARTI000027645773", "URL": "article/LEGI/ARTI/00/00/27/64/57/LEGIARTI000027645773.xml", "NATURE": "Article", "ORIGINE": "LEGI" } }, "LIENS": { "LIEN": [ { "@id": "JORFTEXT000000516442", "#text": "Décret n° 78-621 du 31 mai 1978", "@sens": "source", "@cidtexte": "JORFTEXT000000516442", "@numtexte": "78-621", "@typelien": "CODIFICATION", "@naturetexte": "DECRET", "@datesignatexte": "1978-05-31" }, { "@id": "LEGIARTI000006827088", "@num": "ANNEXE", "#text": "Décret n°91-1201 du 27 novembre 1991 - art. ANNEXE (V)", "@sens": "cible", "@cidtexte": "JORFTEXT000000344731", "@nortexte": "EQUC9101565D", "@numtexte": "91-1201", "@typelien": "CITATION", "@naturetexte": "DECRET", "@datesignatexte": "1991-11-27" }, { "@id": "LEGIARTI000027619883", "@num": "11", "#text": "Ordonnance n°2013-544\n du 27 juin 2013 - art. 11", "@sens": "cible", "@cidtexte": "JORFTEXT000027617519", "@nortexte": "EFIT1309910R", "@numtexte": "2013-544", "@typelien": "MODIFIE", "@naturetexte": "ORDONNANCE", "@datesignatexte": "2013-06-27" }, { "@id": "LEGIARTI000006235510", "@num": "L621-28", "#text": "Code de commerce - art. L621-28 (T)", "@sens": "source", "@cidtexte": "LEGITEXT000005634379", "@typelien": "CITATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000041565897", "@num": "Annexe à l'article R231-13", "#text": "Code de la construction et de l'habitation. - art. Annexe à l'article R231-13 (VD)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CITATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000006824501", "@num": "L231-10", "#text": "Code de la construction et de l'habitation. - art. L231-10 (V)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CITATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000027645777", "@num": "L231-13", "#text": "Code de la construction et de l'habitation. - art. L231-13 (VD)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CITATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000006824657", "@num": "L231-2", "#text": "Code de la construction et de l'habitation. - art. L231-2", "@sens": "source", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CITATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000006824499", "@num": "L231-8", "#text": "Code de la construction et de l'habitation. - art. L231-8 (V)", "@sens": "source", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CITATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000006824507", "@num": "L232-2", "#text": "Code de la construction et de l'habitation. - art. L232-2 (V)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CITATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000032235569", "@num": "L241-8", "#text": "Code de la construction et de l'habitation. - art. L241-8 (VD)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CITATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000039041717", "@num": "R231-10", "#text": "Code de la construction et de l'habitation. - art. R231-10 (VD)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CITATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" } ] }, "CONTEXTE": { "TEXTE": { "TM": { "TM": { "TM": { "TM": { "TITRE_TM": [ { "@id": "LEGISCTA000006159020", "@fin": "2999-01-01", "#text": "Chapitre Ier : Contrat de construction d'une maison individuelle avec fourniture du plan.", "@debut": "1991-12-01" } ] }, "TITRE_TM": [ { "@id": "LEGISCTA000006143526", "@fin": "2999-01-01", "#text": "Titre III : Construction d'une maison individuelle.", "@debut": "1991-12-01" } ] }, "TITRE_TM": [ { "@id": "LEGISCTA000006128681", "@fin": "2999-01-01", "#text": "Livre II : Statut des constructeurs.", "@debut": "1978-06-08" } ] }, "TITRE_TM": [ { "@id": "LEGISCTA000006108136", "@fin": "2999-01-01", "#text": "Partie législative", "@debut": "1978-06-08" } ] }, "@cid": "LEGITEXT000006074096", "@nature": "CODE", "TITRE_TXT": [ { "@fin": "2999-01-01", "#text": "Code de la construction et de l'habitation", "@debut": "1977-03-10", "@id_txt": "LEGITEXT000006074096", "@c_titre_court": "Code de la construction et de l'habitation." } ], "@date_publi": "2999-01-01", "@date_signature": "2999-01-01" } }, "VERSIONS": { "VERSION": [ { "@etat": "MODIFIE", "LIEN_ART": { "@id": "LEGIARTI000006824496", "@fin": "2006-01-01", "@num": "L231-6", "@etat": "MODIFIE", "@debut": "1991-12-01", "@origine": "LEGI" } }, { "@etat": "MODIFIE", "LIEN_ART": { "@id": "LEGIARTI000006824497", "@fin": "2014-01-01", "@num": "L231-6", "@etat": "MODIFIE", "@debut": "2006-01-01", "@origine": "LEGI" } }, { "@etat": "MODIFIE", "LIEN_ART": { "@id": "LEGIARTI000027645773", "@fin": "2020-02-01", "@num": "L231-6", "@etat": "MODIFIE", "@debut": "2014-01-01", "@origine": "LEGI" } }, { "@etat": "VIGUEUR", "LIEN_ART": { "@id": "LEGIARTI000038433486", "@fin": "2999-01-01", "@num": "L231-6", "@etat": "VIGUEUR", "@debut": "2020-02-01", "@origine": "LEGI" } } ] }, "BLOC_TEXTUEL": { "CONTENU": "

En cas de défaillance du constructeur, le garant prend à sa charge :

b) Les conséquences du fait du constructeur ayant abouti à un paiement anticipé ou à un supplément de prix ;

c) Les pénalités forfaitaires prévues au contrat en cas de retard de livraison excédant trente jours, le montant et le seuil minimum de ces pénalités étant fixés par décret.

La garantie est constituée par une caution solidaire donnée par un établissement de crédit, une société de financement ou une entreprise d'assurance agréés à cet effet.

Quinze jours après une mise en demeure restée infructueuse, le garant procède à l'exécution de ses obligations dans les conditions prévues au paragraphe III du présent article.

" } }, "LEGIARTI000027645777": { "META": { "META_SPEC": { "META_ARTICLE": { "NUM": "L231-13", "ETAT": "VIGUEUR", "TYPE": "AUTONOME", "DATE_FIN": "2999-01-01", "DATE_DEBUT": "2014-01-01" } }, "META_COMMUN": { "ID": "LEGIARTI000027645777", "URL": "article/LEGI/ARTI/00/00/27/64/57/LEGIARTI000027645777.xml", "NATURE": "Article", "ORIGINE": "LEGI" } }, "LIENS": { "LIEN": [ { "@id": "LEGIARTI000006467156", "@num": "14", "#text": "LOI n° 75-1334 du 31 décembre 1975 - art. 14", "@sens": "source", "@cidtexte": "JORFTEXT000000889241", "@numtexte": "75-1334", "@typelien": "CITATION", "@naturetexte": "LOI", "@datesignatexte": "1975-12-31" }, { "@id": "JORFTEXT000000516442", "#text": "Décret n° 78-621 du 31 mai 1978", "@sens": "source", "@cidtexte": "JORFTEXT000000516442", "@numtexte": "78-621", "@typelien": "CODIFICATION", "@naturetexte": "DECRET", "@datesignatexte": "1978-05-31" }, { "@id": "LEGIARTI000023374155", "@num": "125", "#text": "LOI n°2008-1443\n du 30 décembre 2008 - art. 125 (V)", "@sens": "cible", "@cidtexte": "JORFTEXT000020014790", "@nortexte": "BCFX0826279L", "@numtexte": "2008-1443", "@typelien": "CITATION", "@naturetexte": "LOI", "@datesignatexte": "2008-12-30" }, { "@id": "LEGIARTI000020607705", "@num": "2", "#text": "Décret n°2009-246 du 3 mars 2009 - art. 2 (V)", "@sens": "cible", "@cidtexte": "JORFTEXT000020337446", "@nortexte": "ECET0829937D", "@numtexte": "2009-246", "@typelien": "CITATION", "@naturetexte": "DECRET", "@datesignatexte": "2009-03-03" }, { "@id": "LEGIARTI000020607714", "@num": "3", "#text": "Décret n°2009-246 du 3 mars 2009 - art. 3 (V)", "@sens": "cible", "@cidtexte": "JORFTEXT000020337446", "@nortexte": "ECET0829937D", "@numtexte": "2009-246", "@typelien": "CITATION", "@naturetexte": "DECRET", "@datesignatexte": "2009-03-03" }, { "@id": "LEGIARTI000020607712", "@num": "5", "#text": "Décret n°2009-246 du 3 mars 2009 - art. 5 (V)", "@sens": "cible", "@cidtexte": "JORFTEXT000020337446", "@nortexte": "ECET0829937D", "@numtexte": "2009-246", "@typelien": "CITATION", "@naturetexte": "DECRET", "@datesignatexte": "2009-03-03" }, { "@id": "LEGIARTI000020607710", "@num": "6", "#text": "Décret n°2009-246 du 3 mars 2009 - art. 6 (V)", "@sens": "cible", "@cidtexte": "JORFTEXT000020337446", "@nortexte": "ECET0829937D", "@numtexte": "2009-246", "@typelien": "CITATION", "@naturetexte": "DECRET", "@datesignatexte": "2009-03-03" }, { "@id": "LEGIARTI000027619883", "@num": "11", "#text": "Ordonnance n°2013-544\n du 27 juin 2013 - art. 11", "@sens": "cible", "@cidtexte": "JORFTEXT000027617519", "@nortexte": "EFIT1309910R", "@numtexte": "2013-544", "@typelien": "MODIFIE", "@naturetexte": "ORDONNANCE", "@datesignatexte": "2013-06-27" }, { "@id": "LEGIARTI000041783207", "@num": "1", "#text": "Décret n°2020-397 du 4 avril 2020 - art. 1 (M)", "@sens": "cible", "@cidtexte": "JORFTEXT000041782333", "@nortexte": "ECOT2008817D", "@numtexte": "2020-397", "@typelien": "CITATION", "@naturetexte": "DECRET", "@datesignatexte": "2020-04-04" }, { "@id": "LEGIARTI000042084830", "@num": "2", "#text": "Décret n°2020-397 du 4 avril 2020 - art. 2 (V)", "@sens": "cible", "@cidtexte": "JORFTEXT000041782333", "@nortexte": "ECOT2008817D", "@numtexte": "2020-397", "@typelien": "CITATION", "@naturetexte": "DECRET", "@datesignatexte": "2020-04-04" }, { "@id": "LEGIARTI000042744442", "@num": "3", "#text": "Décret n°2020-397 du 4 avril 2020 - art. 3 (V)", "@sens": "cible", "@cidtexte": "JORFTEXT000041782333", "@nortexte": "ECOT2008817D", "@numtexte": "2020-397", "@typelien": "CITATION", "@naturetexte": "DECRET", "@datesignatexte": "2020-04-04" }, { "@id": "LEGIARTI000041783217", "@num": "6", "#text": "Décret n°2020-397 du 4 avril 2020 - art. 6 (V)", "@sens": "cible", "@cidtexte": "JORFTEXT000041782333", "@nortexte": "ECOT2008817D", "@numtexte": "2020-397", "@typelien": "CITATION", "@naturetexte": "DECRET", "@datesignatexte": "2020-04-04" }, { "@id": "LEGIARTI000041783219", "@num": "7", "#text": "Décret n°2020-397 du 4 avril 2020 - art. 7 (V)", "@sens": "cible", "@cidtexte": "JORFTEXT000041782333", "@nortexte": "ECOT2008817D", "@numtexte": "2020-397", "@typelien": "CITATION", "@naturetexte": "DECRET", "@datesignatexte": "2020-04-04" }, { "@id": "LEGIARTI000006824496", "@num": "L231-6", "#text": "Code de la construction et de l'habitation. - art. L231-6", "@sens": "source", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CITATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000006824507", "@num": "L232-2", "#text": "Code de la construction et de l'habitation. - art. L232-2 (V)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CITATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000006824535", "@num": "L241-9", "#text": "Code de la construction et de l'habitation. - art. L241-9 (V)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CITATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" } ] }, "CONTEXTE": { "TEXTE": { "TM": { "TM": { "TM": { "TM": { "TITRE_TM": [ { "@id": "LEGISCTA000006159020", "@fin": "2999-01-01", "#text": "Chapitre Ier : Contrat de construction d'une maison individuelle avec fourniture du plan.", "@debut": "1991-12-01" } ] }, "TITRE_TM": [ { "@id": "LEGISCTA000006143526", "@fin": "2999-01-01", "#text": "Titre III : Construction d'une maison individuelle.", "@debut": "1991-12-01" } ] }, "TITRE_TM": [ { "@id": "LEGISCTA000006128681", "@fin": "2999-01-01", "#text": "Livre II : Statut des constructeurs.", "@debut": "1978-06-08" } ] }, "TITRE_TM": [ { "@id": "LEGISCTA000006108136", "@fin": "2999-01-01", "#text": "Partie législative", "@debut": "1978-06-08" } ] }, "@cid": "LEGITEXT000006074096", "@nature": "CODE", "TITRE_TXT": [ { "@fin": "2999-01-01", "#text": "Code de la construction et de l'habitation", "@debut": "1977-03-10", "@id_txt": "LEGITEXT000006074096", "@c_titre_court": "Code de la construction et de l'habitation." } ], "@date_publi": "2999-01-01", "@date_signature": "2999-01-01" } }, "VERSIONS": { "VERSION": [ { "@etat": "MODIFIE", "LIEN_ART": { "@id": "LEGIARTI000006824504", "@fin": "2004-12-10", "@num": "L231-13", "@etat": "MODIFIE", "@debut": "1991-12-01", "@origine": "LEGI" } }, { "@etat": "MODIFIE", "LIEN_ART": { "@id": "LEGIARTI000006824505", "@fin": "2014-01-01", "@num": "L231-13", "@etat": "MODIFIE", "@debut": "2004-12-10", "@origine": "LEGI" } }, { "@etat": "VIGUEUR", "LIEN_ART": { "@id": "LEGIARTI000027645777", "@fin": "2999-01-01", "@num": "L231-13", "@etat": "VIGUEUR", "@debut": "2014-01-01", "@origine": "LEGI" } } ] }, "BLOC_TEXTUEL": { "CONTENU": "

Le constructeur est tenu de conclure par écrit les contrats de sous-traitance avant tout commencement d'exécution des travaux à la charge du sous-traitant. Ces contrats comportent les énonciations suivantes :

a) La désignation de la construction ainsi que les nom et adresse du maître de l'ouvrage et de l'établissement qui apporte la garantie prévue à l'article L. 231-6 ;

b) La description des travaux qui en font l'objet, conforme aux énonciations du contrat de construction ;

c) Le prix convenu et, s'il y a lieu, les modalités de sa révision ;

d) Le délai d'exécution des travaux et le montant des pénalités de retard ;

e) Les modalités de règlement du prix, qui ne peut dépasser un délai de trente jours à compter de la date du versement effectué au constructeur par le maître de l'ouvrage ou le prêteur, en règlement de travaux comprenant ceux effectués par le sous-traitant et acceptés par le constructeur ;

f) Le montant des pénalités dues par le constructeur en cas de retard de paiement ;

g) La justification de l'une ou l'autre des garanties de paiement prévues à l'article 14 de la loi n° 75-1334 du 31 décembre 1975 relative à la sous-traitance ou de toute autre garantie, délivrée par un établissement de crédit, une société de financement ou une entreprise d'assurance, de nature à garantir le paiement des sommes dues au titre du sous-traité.

Copie des contrats de sous-traitance est adressée par le constructeur à l'établissement qui apporte la garantie prévue à l'article L. 231-6.

" } }, "LEGIARTI000037667723": { "META": { "META_SPEC": { "META_ARTICLE": { "NUM": "L231-2", "ETAT": "MODIFIE", "TYPE": "AUTONOME", "DATE_FIN": "2020-02-01", "DATE_DEBUT": "2018-11-25" } }, "META_COMMUN": { "ID": "LEGIARTI000037667723", "URL": "article/LEGI/ARTI/00/00/37/66/77/LEGIARTI000037667723.xml", "NATURE": "Article", "ORIGINE": "LEGI" } }, "LIENS": { "LIEN": [ { "@id": "JORFTEXT000000687668", "#text": "Loi 71-579 1971-07-16 art. 45 al. 2 à 6", "@sens": "source", "@cidtexte": "JORFTEXT000000687668", "@numtexte": "71-579", "@typelien": "CONCORDANCE", "@naturetexte": "LOI", "@datesignatexte": "1971-07-16" }, { "@id": "LEGIARTI000006826382", "@num": "45", "#text": "Loi n°71-579 du 16 juillet 1971 - art. 45 (Ab)", "@sens": "cible", "@cidtexte": "JORFTEXT000000687668", "@numtexte": "71-579", "@typelien": "CONCORDE", "@naturetexte": "LOI", "@datesignatexte": "1971-07-16" }, { "@id": "JORFTEXT000000522423", "#text": "LOI n° 77-2 du 3 janvier 1977", "@sens": "source", "@cidtexte": "JORFTEXT000000522423", "@numtexte": "77-2", "@typelien": "CITATION", "@naturetexte": "LOI", "@datesignatexte": "1977-01-03" }, { "@id": "JORFTEXT000000516442", "#text": "Décret n° 78-621 du 31 mai 1978", "@sens": "source", "@cidtexte": "JORFTEXT000000516442", "@numtexte": "78-621", "@typelien": "CODIFICATION", "@naturetexte": "DECRET", "@datesignatexte": "1978-05-31" }, { "@id": "LEGIARTI000006829601", "@num": "9", "#text": "Arrêté du 30 décembre 1988 - art. 9 (V)", "@sens": "cible", "@cidtexte": "JORFTEXT000000873773", "@nortexte": "EQUC8800886A", "@typelien": "CITATION", "@naturetexte": "ARRETE", "@datesignatexte": "1988-12-30" }, { "@id": "LEGIARTI000006739977", "@num": "1", "#text": "Décret n°99-776 du 8 septembre 1999 - art. 1 (Ab)", "@sens": "cible", "@cidtexte": "JORFTEXT000000396628", "@nortexte": "ECOT9914031D", "@numtexte": "99-776", "@typelien": "CITATION", "@naturetexte": "DECRET", "@datesignatexte": "1999-09-08" }, { "@id": "LEGIARTI000037642281", "@num": "68", "#text": "LOI n°2018-1021 du 23 novembre 2018 - art. 68", "@sens": "cible", "@cidtexte": "JORFTEXT000037639478", "@nortexte": "TERL1805474L", "@numtexte": "2018-1021", "@typelien": "MODIFIE", "@naturetexte": "LOI", "@datesignatexte": "2018-11-23" }, { "@id": "LEGITEXT000050742475", "#text": "Arrêté du 3 décembre 2024 (V)", "@sens": "cible", "@cidtexte": "JORFTEXT000050731883", "@nortexte": "LRUL2422852A", "@typelien": "CITATION", "@naturetexte": "ARRETE", "@datesignatexte": "2024-12-03" }, { "@id": "LEGIARTI000006795972", "@num": "L242-1", "#text": "Code des assurances - art. L242-1", "@sens": "source", "@cidtexte": "LEGITEXT000006073984", "@typelien": "CITATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000006824172", "@num": "L111-23", "#text": "Code de la construction et de l'habitation. - art. L111-23", "@sens": "source", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CITATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000041586868", "@num": "L231-1", "#text": "Code de la construction et de l'habitation. - art. L231-1 (VD)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CITATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000006824510", "@num": "L231-1-1", "#text": "Code de la construction et de l'habitation. - art. L231-1-1 (Ab)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CITATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000006824501", "@num": "L231-10", "#text": "Code de la construction et de l'habitation. - art. L231-10 (V)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CITATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000006824502", "@num": "L231-11", "#text": "Code de la construction et de l'habitation. - art. L231-11", "@sens": "source", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CITATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000038433486", "@num": "L231-6", "#text": "Code de la construction et de l'habitation. - art. L231-6 (VD)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CITATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000006824498", "@num": "L231-7", "#text": "Code de la construction et de l'habitation. - art. L231-7 (V)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CITATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000006824507", "@num": "L232-2", "#text": "Code de la construction et de l'habitation. - art. L232-2 (V)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CITATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000006824514", "@num": "L241-1", "#text": "Code de la construction et de l'habitation. - art. L241-1 (M)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CITATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000006824660", "@num": "L241-3", "#text": "Code de la construction et de l'habitation. - art. L241-3 (M)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CITATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000006824538", "@num": "L242-2", "#text": "Code de la construction et de l'habitation. - art. L242-2 (V)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CITATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000006896534", "@num": "R*231-1", "#text": "Code de la construction et de l'habitation. - art. R*231-1 (M)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CITATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000006896543", "@num": "R*231-7", "#text": "Code de la construction et de l'habitation. - art. R*231-7 (M)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CITATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000039041705", "@num": "R231-13", "#text": "Code de la construction et de l'habitation. - art. R231-13 (VD)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CITATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000039041701", "@num": "R231-14", "#text": "Code de la construction et de l'habitation. - art. R231-14 (VD)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CITATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000039041754", "@num": "R231-2", "#text": "Code de la construction et de l'habitation. - art. R231-2 (VD)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CITATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000039041749", "@num": "R231-3", "#text": "Code de la construction et de l'habitation. - art. R231-3 (VD)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CITATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000039041744", "@num": "R231-4", "#text": "Code de la construction et de l'habitation. - art. R231-4 (VD)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CITATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000039041740", "@num": "R231-5", "#text": "Code de la construction et de l'habitation. - art. R231-5 (VD)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CITATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000006821757", "@num": "R421-24-3", "#text": "Code des assurances - art. R421-24-3 (Ab)", "@sens": "cible", "@cidtexte": "LEGITEXT000006073984", "@typelien": "CITATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000033655931", "@num": "D313-26", "#text": "Code monétaire et financier - art. D313-26 (VD)", "@sens": "cible", "@cidtexte": "LEGITEXT000006072026", "@typelien": "CITATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" } ] }, "CONTEXTE": { "TEXTE": { "TM": { "TM": { "TM": { "TM": { "TITRE_TM": [ { "@id": "LEGISCTA000006159020", "@fin": "2999-01-01", "#text": "Chapitre Ier : Contrat de construction d'une maison individuelle avec fourniture du plan.", "@debut": "1991-12-01" } ] }, "TITRE_TM": [ { "@id": "LEGISCTA000006143526", "@fin": "2999-01-01", "#text": "Titre III : Construction d'une maison individuelle.", "@debut": "1991-12-01" } ] }, "TITRE_TM": [ { "@id": "LEGISCTA000006128681", "@fin": "2999-01-01", "#text": "Livre II : Statut des constructeurs.", "@debut": "1978-06-08" } ] }, "TITRE_TM": [ { "@id": "LEGISCTA000006108136", "@fin": "2999-01-01", "#text": "Partie législative", "@debut": "1978-06-08" } ] }, "@cid": "LEGITEXT000006074096", "@nature": "CODE", "TITRE_TXT": [ { "@fin": "2999-01-01", "#text": "Code de la construction et de l'habitation", "@debut": "1977-03-10", "@id_txt": "LEGITEXT000006074096", "@c_titre_court": "Code de la construction et de l'habitation." } ], "@date_publi": "2999-01-01", "@date_signature": "2999-01-01" } }, "VERSIONS": { "VERSION": [ { "@etat": "MODIFIE", "LIEN_ART": { "@id": "LEGIARTI000006824657", "@fin": "1979-07-14", "@num": "L231-2", "@etat": "MODIFIE", "@debut": "1978-06-08", "@origine": "LEGI" } }, { "@etat": "MODIFIE", "LIEN_ART": { "@id": "LEGIARTI000006824658", "@fin": "1991-12-01", "@num": "L231-2", "@etat": "MODIFIE", "@debut": "1979-07-14", "@origine": "LEGI" } }, { "@etat": "MODIFIE", "LIEN_ART": { "@id": "LEGIARTI000006824659", "@fin": "2018-11-25", "@num": "L231-2", "@etat": "MODIFIE", "@debut": "1991-12-01", "@origine": "LEGI" } }, { "@etat": "MODIFIE", "LIEN_ART": { "@id": "LEGIARTI000037667723", "@fin": "2020-02-01", "@num": "L231-2", "@etat": "MODIFIE", "@debut": "2018-11-25", "@origine": "LEGI" } }, { "@etat": "MODIFIE", "LIEN_ART": { "@id": "LEGIARTI000038433496", "@fin": "2021-07-01", "@num": "L231-2", "@etat": "MODIFIE", "@debut": "2020-02-01", "@origine": "LEGI" } }, { "@etat": "VIGUEUR", "LIEN_ART": { "@id": "LEGIARTI000041586856", "@fin": "2999-01-01", "@num": "L231-2", "@etat": "VIGUEUR", "@debut": "2021-07-01", "@origine": "LEGI" } } ] }, "BLOC_TEXTUEL": { "CONTENU": "

Le contrat visé à l'article L. 231-1 doit comporter les énonciations suivantes :

a) La désignation du terrain destiné à l'implantation de la construction et la mention du titre de propriété du maître de l'ouvrage ou des droits réels lui permettant de construire ;

b) L'affirmation de la conformité du projet aux règles de construction prescrites en application du présent code, notamment de son livre Ier, et du code de l'urbanisme ;

c) La consistance et les caractéristiques techniques du bâtiment à construire comportant :

-tous les travaux d'adaptation au sol, notamment, le cas échéant, ceux rendus nécessaires par l'étude géotechnique mentionnée aux articles L. 112-22 et L. 112-23 du présent code, dont une copie est annexée au contrat ;
\n-les raccordements aux réseaux divers ;
\n-tous les travaux d'équipement intérieur ou extérieur indispensables à l'implantation et à l'utilisation de l'immeuble ;

d) Le coût du bâtiment à construire, égal à la somme du prix convenu et, s'il y a lieu, du coût des travaux dont le maître de l'ouvrage se réserve l'exécution en précisant :

-d'une part, le prix convenu qui est forfaitaire et définitif, sous réserve, s'il y a lieu, de sa révision dans les conditions et limites convenues conformément à l'article L. 231-11, et qui comporte la rémunération de tout ce qui est à la charge du constructeur, y compris le coût de la garantie de livraison ;

-d'autre part, le coût des travaux dont le maître de l'ouvrage se réserve l'exécution, ceux-ci étant décrits et chiffrés par le constructeur et faisant l'objet, de la part du maître de l'ouvrage, d'une clause manuscrite spécifique et paraphée par laquelle il en accepte le coût et la charge ;

e) Les modalités de règlement en fonction de l'état d'avancement des travaux ;

f) L'indication que le maître de l'ouvrage pourra se faire assister par un professionnel habilité en application de la loi n° 77-2 du 3 janvier 1977 sur l'architecture ou des articles L. 111-23 et suivants lors de la réception ou par tout autre professionnel de la construction titulaire d'un contrat d'assurance couvrant les responsabilités pour ce type de mission ;

g) L'indication de l'obtention du permis de construire et des autres autorisations administratives, dont une copie est annexée au contrat ;

h) L'indication des modalités de financement, la nature et le montant des prêts obtenus et acceptés par le maître de l'ouvrage ;

i) La date d'ouverture du chantier, le délai d'exécution des travaux et les pénalités prévues en cas de retard de livraison ;

j) La référence de l'assurance de dommages souscrite par le maître de l'ouvrage, en application de l'article L. 242-1 du code des assurances ;

k) Les justifications des garanties de remboursement et de livraison apportées par le constructeur, les attestations de ces garanties étant établies par le garant et annexées au contrat.

" } }, "LEGIARTI000038433486": { "META": { "META_SPEC": { "META_ARTICLE": { "NUM": "L231-6", "ETAT": "VIGUEUR", "TYPE": "AUTONOME", "DATE_FIN": "2999-01-01", "DATE_DEBUT": "2020-02-01" } }, "META_COMMUN": { "ID": "LEGIARTI000038433486", "URL": "article/LEGI/ARTI/00/00/38/43/34/LEGIARTI000038433486.xml", "NATURE": "Article", "ORIGINE": "LEGI" } }, "NOTA": { "CONTENU": "

Conformément à l'article 2 de l'ordonnance n° 2019-395 du 30 avril 2019, les présentes dispositions s'appliquent aux contrats conclus à compter du premier jour du troisième mois suivant la publication du décret prévu à l'article L. 242-2 du code de la construction et de l'habitation, dans sa rédaction issue du 4° de l'article 1er de la présente ordonnance et au plus tard à compter du premier jour du neuvième mois suivant celui de la publication de la présente ordonnance au Journal officiel de la République française.

" }, "LIENS": { "LIEN": [ { "@id": "JORFTEXT000000516442", "#text": "Décret n° 78-621 du 31 mai 1978", "@sens": "source", "@cidtexte": "JORFTEXT000000516442", "@numtexte": "78-621", "@typelien": "CODIFICATION", "@naturetexte": "DECRET", "@datesignatexte": "1978-05-31" }, { "@id": "LEGIARTI000006827088", "@num": "ANNEXE", "#text": "Décret n°91-1201 du 27 novembre 1991 - art. ANNEXE (V)", "@sens": "cible", "@cidtexte": "JORFTEXT000000344731", "@nortexte": "EQUC9101565D", "@numtexte": "91-1201", "@typelien": "CITATION", "@naturetexte": "DECRET", "@datesignatexte": "1991-11-27" }, { "@id": "LEGIARTI000038432548", "@num": "1", "#text": "Ordonnance n° 2019-395 du 30 avril 2019 - art. 1", "@sens": "cible", "@cidtexte": "JORFTEXT000038431584", "@nortexte": "TERL1908590R", "@numtexte": "2019-395", "@typelien": "MODIFIE", "@naturetexte": "ORDONNANCE", "@datesignatexte": "2019-04-30" }, { "@id": "LEGIARTI000006235510", "@num": "L621-28", "#text": "Code de commerce - art. L621-28", "@sens": "source", "@cidtexte": "LEGITEXT000005634379", "@typelien": "CITATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000041565897", "@num": "Annexe à l'article R231-13", "#text": "Code de la construction et de l'habitation. - art. Annexe à l'article R231-13 (VD)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CITATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000006824501", "@num": "L231-10", "#text": "Code de la construction et de l'habitation. - art. L231-10 (V)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CITATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000027645777", "@num": "L231-13", "#text": "Code de la construction et de l'habitation. - art. L231-13 (VD)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CITATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000006824657", "@num": "L231-2", "#text": "Code de la construction et de l'habitation. - art. L231-2", "@sens": "source", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CITATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000006824499", "@num": "L231-8", "#text": "Code de la construction et de l'habitation. - art. L231-8", "@sens": "source", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CITATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000006824507", "@num": "L232-2", "#text": "Code de la construction et de l'habitation. - art. L232-2 (V)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CITATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000032235569", "@num": "L241-8", "#text": "Code de la construction et de l'habitation. - art. L241-8 (VD)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CITATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000039041717", "@num": "R231-10", "#text": "Code de la construction et de l'habitation. - art. R231-10 (VD)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CITATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" } ] }, "CONTEXTE": { "TEXTE": { "TM": { "TM": { "TM": { "TM": { "TITRE_TM": [ { "@id": "LEGISCTA000006159020", "@fin": "2999-01-01", "#text": "Chapitre Ier : Contrat de construction d'une maison individuelle avec fourniture du plan.", "@debut": "1991-12-01" } ] }, "TITRE_TM": [ { "@id": "LEGISCTA000006143526", "@fin": "2999-01-01", "#text": "Titre III : Construction d'une maison individuelle.", "@debut": "1991-12-01" } ] }, "TITRE_TM": [ { "@id": "LEGISCTA000006128681", "@fin": "2999-01-01", "#text": "Livre II : Statut des constructeurs.", "@debut": "1978-06-08" } ] }, "TITRE_TM": [ { "@id": "LEGISCTA000006108136", "@fin": "2999-01-01", "#text": "Partie législative", "@debut": "1978-06-08" } ] }, "@cid": "LEGITEXT000006074096", "@nature": "CODE", "TITRE_TXT": [ { "@fin": "2999-01-01", "#text": "Code de la construction et de l'habitation", "@debut": "1977-03-10", "@id_txt": "LEGITEXT000006074096", "@c_titre_court": "Code de la construction et de l'habitation." } ], "@date_publi": "2999-01-01", "@date_signature": "2999-01-01" } }, "VERSIONS": { "VERSION": [ { "@etat": "MODIFIE", "LIEN_ART": { "@id": "LEGIARTI000006824496", "@fin": "2006-01-01", "@num": "L231-6", "@etat": "MODIFIE", "@debut": "1991-12-01", "@origine": "LEGI" } }, { "@etat": "MODIFIE", "LIEN_ART": { "@id": "LEGIARTI000006824497", "@fin": "2014-01-01", "@num": "L231-6", "@etat": "MODIFIE", "@debut": "2006-01-01", "@origine": "LEGI" } }, { "@etat": "MODIFIE", "LIEN_ART": { "@id": "LEGIARTI000027645773", "@fin": "2020-02-01", "@num": "L231-6", "@etat": "MODIFIE", "@debut": "2014-01-01", "@origine": "LEGI" } }, { "@etat": "VIGUEUR", "LIEN_ART": { "@id": "LEGIARTI000038433486", "@fin": "2999-01-01", "@num": "L231-6", "@etat": "VIGUEUR", "@debut": "2020-02-01", "@origine": "LEGI" } } ] }, "BLOC_TEXTUEL": { "CONTENU": "

I.-La garantie de livraison prévue au k de l'article L. 231-2 couvre le maître de l'ouvrage, à compter de la date d'ouverture du chantier, contre les risques d'inexécution ou de mauvaise exécution des travaux prévus au contrat, à prix et délais convenus. Dans le cas prévu à l'antépénultième alinéa de l'article L. 231-2, elle couvre également le maître de l'ouvrage, à compter de l'ouverture du chantier, contre les risques d'inexécution ou de mauvaise exécution de la fabrication, de la pose et de l'assemblage des éléments préfabriqués.

En cas de défaillance du constructeur, le garant prend à sa charge :

b) Les conséquences du fait du constructeur ayant abouti à un paiement anticipé ou à un supplément de prix ;

c) Les pénalités forfaitaires prévues au contrat en cas de retard de livraison excédant trente jours, le montant et le seuil minimum de ces pénalités étant fixés par décret.

La garantie est constituée par une caution solidaire donnée par un établissement de crédit, une société de financement ou une entreprise d'assurance agréés à cet effet.

Quinze jours après une mise en demeure restée infructueuse, le garant procède à l'exécution de ses obligations dans les conditions prévues au paragraphe III du présent article.

" } }, "LEGIARTI000038433496": { "META": { "META_SPEC": { "META_ARTICLE": { "NUM": "L231-2", "ETAT": "MODIFIE", "TYPE": "AUTONOME", "DATE_FIN": "2021-07-01", "DATE_DEBUT": "2020-02-01" } }, "META_COMMUN": { "ID": "LEGIARTI000038433496", "URL": "article/LEGI/ARTI/00/00/38/43/34/LEGIARTI000038433496.xml", "NATURE": "Article", "ORIGINE": "LEGI" } }, "NOTA": { "CONTENU": "

" }, "LIENS": { "LIEN": [ { "@id": "JORFTEXT000000687668", "#text": "Loi 71-579 1971-07-16 art. 45 al. 2 à 6", "@sens": "source", "@cidtexte": "JORFTEXT000000687668", "@numtexte": "71-579", "@typelien": "CONCORDANCE", "@naturetexte": "LOI", "@datesignatexte": "1971-07-16" }, { "@id": "LEGIARTI000006826382", "@num": "45", "#text": "Loi n°71-579 du 16 juillet 1971 - art. 45 (Ab)", "@sens": "cible", "@cidtexte": "JORFTEXT000000687668", "@numtexte": "71-579", "@typelien": "CONCORDE", "@naturetexte": "LOI", "@datesignatexte": "1971-07-16" }, { "@id": "JORFTEXT000000522423", "#text": "LOI n° 77-2 du 3 janvier 1977", "@sens": "source", "@cidtexte": "JORFTEXT000000522423", "@numtexte": "77-2", "@typelien": "CITATION", "@naturetexte": "LOI", "@datesignatexte": "1977-01-03" }, { "@id": "JORFTEXT000000516442", "#text": "Décret n° 78-621 du 31 mai 1978", "@sens": "source", "@cidtexte": "JORFTEXT000000516442", "@numtexte": "78-621", "@typelien": "CODIFICATION", "@naturetexte": "DECRET", "@datesignatexte": "1978-05-31" }, { "@id": "LEGIARTI000006829601", "@num": "9", "#text": "Arrêté du 30 décembre 1988 - art. 9 (V)", "@sens": "cible", "@cidtexte": "JORFTEXT000000873773", "@nortexte": "EQUC8800886A", "@typelien": "CITATION", "@naturetexte": "ARRETE", "@datesignatexte": "1988-12-30" }, { "@id": "LEGIARTI000006739977", "@num": "1", "#text": "Décret n°99-776 du 8 septembre 1999 - art. 1 (Ab)", "@sens": "cible", "@cidtexte": "JORFTEXT000000396628", "@nortexte": "ECOT9914031D", "@numtexte": "99-776", "@typelien": "CITATION", "@naturetexte": "DECRET", "@datesignatexte": "1999-09-08" }, { "@id": "LEGIARTI000038432548", "@num": "1", "#text": "Ordonnance n° 2019-395 du 30 avril 2019 - art. 1", "@sens": "cible", "@cidtexte": "JORFTEXT000038431584", "@nortexte": "TERL1908590R", "@numtexte": "2019-395", "@typelien": "MODIFIE", "@naturetexte": "ORDONNANCE", "@datesignatexte": "2019-04-30" }, { "@id": "LEGITEXT000050742475", "#text": "Arrêté du 3 décembre 2024 (V)", "@sens": "cible", "@cidtexte": "JORFTEXT000050731883", "@nortexte": "LRUL2422852A", "@typelien": "CITATION", "@naturetexte": "ARRETE", "@datesignatexte": "2024-12-03" }, { "@id": "LEGIARTI000006795972", "@num": "L242-1", "#text": "Code des assurances - art. L242-1", "@sens": "source", "@cidtexte": "LEGITEXT000006073984", "@typelien": "CITATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000037644962", "@num": "L111-1-1", "#text": "Code de la construction et de l'habitation. - art. L111-1-1", "@sens": "source", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CITATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000006824172", "@num": "L111-23", "#text": "Code de la construction et de l'habitation. - art. L111-23", "@sens": "source", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CITATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000037645136", "@num": "L112-22", "#text": "Code de la construction et de l'habitation. - art. L112-22", "@sens": "source", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CITATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000041586868", "@num": "L231-1", "#text": "Code de la construction et de l'habitation. - art. L231-1 (VD)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CITATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000006824510", "@num": "L231-1-1", "#text": "Code de la construction et de l'habitation. - art. L231-1-1 (Ab)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CITATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000006824501", "@num": "L231-10", "#text": "Code de la construction et de l'habitation. - art. L231-10 (V)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CITATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000006824502", "@num": "L231-11", "#text": "Code de la construction et de l'habitation. - art. L231-11", "@sens": "source", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CITATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000038433486", "@num": "L231-6", "#text": "Code de la construction et de l'habitation. - art. L231-6 (VD)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CITATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000006824498", "@num": "L231-7", "#text": "Code de la construction et de l'habitation. - art. L231-7 (V)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CITATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000006824507", "@num": "L232-2", "#text": "Code de la construction et de l'habitation. - art. L232-2 (V)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CITATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000006824514", "@num": "L241-1", "#text": "Code de la construction et de l'habitation. - art. L241-1 (M)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CITATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000006824660", "@num": "L241-3", "#text": "Code de la construction et de l'habitation. - art. L241-3 (M)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CITATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000038433476", "@num": "L242-2", "#text": "Code de la construction et de l'habitation. - art. L242-2 (VD)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CITATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000006896534", "@num": "R*231-1", "#text": "Code de la construction et de l'habitation. - art. R*231-1 (M)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CITATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000006896543", "@num": "R*231-7", "#text": "Code de la construction et de l'habitation. - art. R*231-7 (M)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CITATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000039041705", "@num": "R231-13", "#text": "Code de la construction et de l'habitation. - art. R231-13 (VD)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CITATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000039041701", "@num": "R231-14", "#text": "Code de la construction et de l'habitation. - art. R231-14 (VD)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CITATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000039041754", "@num": "R231-2", "#text": "Code de la construction et de l'habitation. - art. R231-2 (VD)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CITATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000039041749", "@num": "R231-3", "#text": "Code de la construction et de l'habitation. - art. R231-3 (VD)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CITATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000039041744", "@num": "R231-4", "#text": "Code de la construction et de l'habitation. - art. R231-4 (VD)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CITATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000039041740", "@num": "R231-5", "#text": "Code de la construction et de l'habitation. - art. R231-5 (VD)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CITATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000006821757", "@num": "R421-24-3", "#text": "Code des assurances - art. R421-24-3 (Ab)", "@sens": "cible", "@cidtexte": "LEGITEXT000006073984", "@typelien": "CITATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000033655931", "@num": "D313-26", "#text": "Code monétaire et financier - art. D313-26 (VD)", "@sens": "cible", "@cidtexte": "LEGITEXT000006072026", "@typelien": "CITATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" } ] }, "CONTEXTE": { "TEXTE": { "TM": { "TM": { "TM": { "TM": { "TITRE_TM": [ { "@id": "LEGISCTA000006159020", "@fin": "2999-01-01", "#text": "Chapitre Ier : Contrat de construction d'une maison individuelle avec fourniture du plan.", "@debut": "1991-12-01" } ] }, "TITRE_TM": [ { "@id": "LEGISCTA000006143526", "@fin": "2999-01-01", "#text": "Titre III : Construction d'une maison individuelle.", "@debut": "1991-12-01" } ] }, "TITRE_TM": [ { "@id": "LEGISCTA000006128681", "@fin": "2999-01-01", "#text": "Livre II : Statut des constructeurs.", "@debut": "1978-06-08" } ] }, "TITRE_TM": [ { "@id": "LEGISCTA000006108136", "@fin": "2999-01-01", "#text": "Partie législative", "@debut": "1978-06-08" } ] }, "@cid": "LEGITEXT000006074096", "@nature": "CODE", "TITRE_TXT": [ { "@fin": "2999-01-01", "#text": "Code de la construction et de l'habitation", "@debut": "1977-03-10", "@id_txt": "LEGITEXT000006074096", "@c_titre_court": "Code de la construction et de l'habitation." } ], "@date_publi": "2999-01-01", "@date_signature": "2999-01-01" } }, "VERSIONS": { "VERSION": [ { "@etat": "MODIFIE", "LIEN_ART": { "@id": "LEGIARTI000006824657", "@fin": "1979-07-14", "@num": "L231-2", "@etat": "MODIFIE", "@debut": "1978-06-08", "@origine": "LEGI" } }, { "@etat": "MODIFIE", "LIEN_ART": { "@id": "LEGIARTI000006824658", "@fin": "1991-12-01", "@num": "L231-2", "@etat": "MODIFIE", "@debut": "1979-07-14", "@origine": "LEGI" } }, { "@etat": "MODIFIE", "LIEN_ART": { "@id": "LEGIARTI000006824659", "@fin": "2018-11-25", "@num": "L231-2", "@etat": "MODIFIE", "@debut": "1991-12-01", "@origine": "LEGI" } }, { "@etat": "MODIFIE", "LIEN_ART": { "@id": "LEGIARTI000037667723", "@fin": "2020-02-01", "@num": "L231-2", "@etat": "MODIFIE", "@debut": "2018-11-25", "@origine": "LEGI" } }, { "@etat": "MODIFIE", "LIEN_ART": { "@id": "LEGIARTI000038433496", "@fin": "2021-07-01", "@num": "L231-2", "@etat": "MODIFIE", "@debut": "2020-02-01", "@origine": "LEGI" } }, { "@etat": "VIGUEUR", "LIEN_ART": { "@id": "LEGIARTI000041586856", "@fin": "2999-01-01", "@num": "L231-2", "@etat": "VIGUEUR", "@debut": "2021-07-01", "@origine": "LEGI" } } ] }, "BLOC_TEXTUEL": { "CONTENU": "

Le contrat visé à l'article L. 231-1 doit comporter les énonciations suivantes :

a) La désignation du terrain destiné à l'implantation de la construction et la mention du titre de propriété du maître de l'ouvrage ou des droits réels lui permettant de construire ;

b) L'affirmation de la conformité du projet aux règles de construction prescrites en application du présent code, notamment de son livre Ier, et du code de l'urbanisme ;

c) La consistance et les caractéristiques techniques du bâtiment à construire comportant :

-tous les travaux d'adaptation au sol, notamment, le cas échéant, ceux rendus nécessaires par l'étude géotechnique mentionnée aux articles L. 112-22 et L. 112-23 du présent code, dont une copie est annexée au contrat ;
-les raccordements aux réseaux divers ;
-tous les travaux d'équipement intérieur ou extérieur indispensables à l'implantation et à l'utilisation de l'immeuble ;

d) Le coût du bâtiment à construire, égal à la somme du prix convenu et, s'il y a lieu, du coût des travaux dont le maître de l'ouvrage se réserve l'exécution en précisant :

e) Les modalités de règlement en fonction de l'état d'avancement des travaux ;

g) L'indication de l'obtention du permis de construire et des autres autorisations administratives, dont une copie est annexée au contrat ;

h) L'indication des modalités de financement, la nature et le montant des prêts obtenus et acceptés par le maître de l'ouvrage ;

i) La date d'ouverture du chantier, le délai d'exécution des travaux et les pénalités prévues en cas de retard de livraison ;

j) La référence de l'assurance de dommages souscrite par le maître de l'ouvrage, en application de l'article L. 242-1 du code des assurances ;

k) Les justifications des garanties de remboursement et de livraison apportées par le constructeur, les attestations de ces garanties étant établies par le garant et annexées au contrat.

Lorsque le constructeur assure la fabrication, la pose et l'assemblage sur le chantier d'éléments préfabriqués dans les conditions définies à l'article L. 111-1-1, le contrat précise en outre la description et les caractéristiques des éléments préfabriqués, ainsi que les modalités selon lesquelles le maître de l'ouvrage est informé de l'achèvement et de la bonne exécution de la fabrication de ces éléments.

Dans le cas prévu au précédent alinéa, les modalités de règlement mentionnées au contrat, en vertu du e de l'article L. 231-2, tiennent compte de l'état d'avancement des travaux de construction et de l'achèvement de la fabrication des éléments préfabriqués.

Les stipulations du contrat, notamment celles relatives aux travaux à la charge du constructeur, au prix convenu, au délai d'exécution des travaux et aux pénalités applicables en cas de retard d'exécution, ainsi que celles relatives aux modalités selon lesquelles le maître de l'ouvrage est informé de l'achèvement et de la bonne exécution de la fabrication des éléments préfabriqués, peuvent se référer à des clauses types approuvées par décret en Conseil d'Etat.

" } }, "LEGIARTI000041586850": { "META": { "META_SPEC": { "META_ARTICLE": { "NUM": "L231-8", "ETAT": "VIGUEUR", "TYPE": "AUTONOME", "DATE_FIN": "2999-01-01", "DATE_DEBUT": "2021-07-01" } }, "META_COMMUN": { "ID": "LEGIARTI000041586850", "URL": "article/LEGI/ARTI/00/00/41/58/68/LEGIARTI000041586850.xml", "NATURE": "Article", "ORIGINE": "LEGI" } }, "NOTA": { "CONTENU": "

Conformément à l'article 8 de l'ordonnance 2020-71 du 29 janvier 2020, ces dispositions entrent en vigueur à une date fixée par décret en Conseil d'Etat, et au plus tard le 1er juillet 2021.

" }, "LIENS": { "LIEN": [ { "@id": "JORFTEXT000000522423", "#text": "LOI n° 77-2 du 3 janvier 1977", "@sens": "source", "@cidtexte": "JORFTEXT000000522423", "@numtexte": "77-2", "@typelien": "CITATION", "@naturetexte": "LOI", "@datesignatexte": "1977-01-03" }, { "@id": "JORFTEXT000000516442", "#text": "Décret n° 78-621 du 31 mai 1978", "@sens": "source", "@cidtexte": "JORFTEXT000000516442", "@numtexte": "78-621", "@typelien": "CODIFICATION", "@naturetexte": "DECRET", "@datesignatexte": "1978-05-31" }, { "@id": "LEGIARTI000041562499", "@num": "4", "#text": "Ordonnance n° 2020-71 du 29 janvier 2020 - art. 4", "@sens": "cible", "@cidtexte": "JORFTEXT000041506557", "@nortexte": "LOGL1933297R", "@numtexte": "2020-71", "@typelien": "MODIFIE", "@naturetexte": "ORDONNANCE", "@datesignatexte": "2020-01-29" }, { "@id": "LEGIARTI000006824172", "@num": "L111-23", "#text": "Code de la construction et de l'habitation. - art. L111-23", "@sens": "source", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CITATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000038433486", "@num": "L231-6", "#text": "Code de la construction et de l'habitation. - art. L231-6 (VD)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CITATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000006824507", "@num": "L232-2", "#text": "Code de la construction et de l'habitation. - art. L232-2 (V)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CITATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000039344324", "@num": "R231-7", "#text": "Code de la construction et de l'habitation. - art. R231-7 (VD)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CITATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" } ] }, "CONTEXTE": { "TEXTE": { "TM": { "TM": { "TM": { "TM": { "TITRE_TM": [ { "@id": "LEGISCTA000006159020", "@fin": "2999-01-01", "#text": "Chapitre Ier : Contrat de construction d'une maison individuelle avec fourniture du plan.", "@debut": "1991-12-01" } ] }, "TITRE_TM": [ { "@id": "LEGISCTA000006143526", "@fin": "2999-01-01", "#text": "Titre III : Construction d'une maison individuelle.", "@debut": "1991-12-01" } ] }, "TITRE_TM": [ { "@id": "LEGISCTA000006128681", "@fin": "2999-01-01", "#text": "Livre II : Statut des constructeurs.", "@debut": "1978-06-08" } ] }, "TITRE_TM": [ { "@id": "LEGISCTA000006108136", "@fin": "2999-01-01", "#text": "Partie législative", "@debut": "1978-06-08" } ] }, "@cid": "LEGITEXT000006074096", "@nature": "CODE", "TITRE_TXT": [ { "@fin": "2999-01-01", "#text": "Code de la construction et de l'habitation", "@debut": "1977-03-10", "@id_txt": "LEGITEXT000006074096", "@c_titre_court": "Code de la construction et de l'habitation." } ], "@date_publi": "2999-01-01", "@date_signature": "2999-01-01" } }, "VERSIONS": { "VERSION": [ { "@etat": "MODIFIE", "LIEN_ART": { "@id": "LEGIARTI000006824499", "@fin": "2021-07-01", "@num": "L231-8", "@etat": "MODIFIE", "@debut": "1991-12-01", "@origine": "LEGI" } }, { "@etat": "VIGUEUR", "LIEN_ART": { "@id": "LEGIARTI000041586850", "@fin": "2999-01-01", "@num": "L231-8", "@etat": "VIGUEUR", "@debut": "2021-07-01", "@origine": "LEGI" } } ] }, "BLOC_TEXTUEL": { "CONTENU": "

Le maître de l'ouvrage peut, par lettre recommandée avec accusé de réception dans les huit jours qui suivent la remise des clefs consécutive à la réception, dénoncer les vices apparents qu'il n'avait pas signalés lors de la réception afin qu'il y soit remédié dans le cadre de l'exécution du contrat.

La disposition prévue à l'alinéa précédent ne s'applique pas quand le maître de l'ouvrage se fait assister, lors de la réception, par un professionnel habilité en application de la loi n° 77-2 du 3 janvier 1977 précitée ou des articles L. 125-1 et suivants ou par tout autre professionnel de la construction titulaire d'un contrat d'assurance couvrant les responsabilités pour ce type de mission.

" } }, "LEGIARTI000041586856": { "META": { "META_SPEC": { "META_ARTICLE": { "NUM": "L231-2", "ETAT": "VIGUEUR", "TYPE": "AUTONOME", "DATE_FIN": "2999-01-01", "DATE_DEBUT": "2021-07-01" } }, "META_COMMUN": { "ID": "LEGIARTI000041586856", "URL": "article/LEGI/ARTI/00/00/41/58/68/LEGIARTI000041586856.xml", "NATURE": "Article", "ORIGINE": "LEGI" } }, "NOTA": { "CONTENU": "

Conformément à l'article 8 de l'ordonnance 2020-71 du 29 janvier 2020, ces dispositions entrent en vigueur à une date fixée par décret en Conseil d'Etat, et au plus tard le 1er juillet 2021.

" }, "LIENS": { "LIEN": [ { "@id": "JORFTEXT000000687668", "#text": "Loi 71-579 1971-07-16 art. 45 al. 2 à 6", "@sens": "source", "@cidtexte": "JORFTEXT000000687668", "@numtexte": "71-579", "@typelien": "CONCORDANCE", "@naturetexte": "LOI", "@datesignatexte": "1971-07-16" }, { "@id": "LEGIARTI000006826382", "@num": "45", "#text": "Loi n°71-579 du 16 juillet 1971 - art. 45 (Ab)", "@sens": "cible", "@cidtexte": "JORFTEXT000000687668", "@numtexte": "71-579", "@typelien": "CONCORDE", "@naturetexte": "LOI", "@datesignatexte": "1971-07-16" }, { "@id": "JORFTEXT000000522423", "#text": "LOI n° 77-2 du 3 janvier 1977", "@sens": "source", "@cidtexte": "JORFTEXT000000522423", "@numtexte": "77-2", "@typelien": "CITATION", "@naturetexte": "LOI", "@datesignatexte": "1977-01-03" }, { "@id": "JORFTEXT000000516442", "#text": "Décret n° 78-621 du 31 mai 1978", "@sens": "source", "@cidtexte": "JORFTEXT000000516442", "@numtexte": "78-621", "@typelien": "CODIFICATION", "@naturetexte": "DECRET", "@datesignatexte": "1978-05-31" }, { "@id": "LEGIARTI000006829601", "@num": "9", "#text": "Arrêté du 30 décembre 1988 - art. 9 (V)", "@sens": "cible", "@cidtexte": "JORFTEXT000000873773", "@nortexte": "EQUC8800886A", "@typelien": "CITATION", "@naturetexte": "ARRETE", "@datesignatexte": "1988-12-30" }, { "@id": "LEGIARTI000006739977", "@num": "1", "#text": "Décret n°99-776 du 8 septembre 1999 - art. 1 (Ab)", "@sens": "cible", "@cidtexte": "JORFTEXT000000396628", "@nortexte": "ECOT9914031D", "@numtexte": "99-776", "@typelien": "CITATION", "@naturetexte": "DECRET", "@datesignatexte": "1999-09-08" }, { "@id": "LEGIARTI000041562499", "@num": "4", "#text": "Ordonnance n° 2020-71 du 29 janvier 2020 - art. 4", "@sens": "cible", "@cidtexte": "JORFTEXT000041506557", "@nortexte": "LOGL1933297R", "@numtexte": "2020-71", "@typelien": "MODIFIE", "@naturetexte": "ORDONNANCE", "@datesignatexte": "2020-01-29" }, { "@id": "LEGITEXT000050742475", "#text": "Arrêté du 3 décembre 2024 (V)", "@sens": "cible", "@cidtexte": "JORFTEXT000050731883", "@nortexte": "LRUL2422852A", "@typelien": "CITATION", "@naturetexte": "ARRETE", "@datesignatexte": "2024-12-03" }, { "@id": "LEGIARTI000006795972", "@num": "L242-1", "#text": "Code des assurances - art. L242-1", "@sens": "source", "@cidtexte": "LEGITEXT000006073984", "@typelien": "CITATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000037644962", "@num": "L111-1-1", "#text": "Code de la construction et de l'habitation. - art. L111-1-1", "@sens": "source", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CITATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000006824172", "@num": "L111-23", "#text": "Code de la construction et de l'habitation. - art. L111-23", "@sens": "source", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CITATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000037645136", "@num": "L112-22", "#text": "Code de la construction et de l'habitation. - art. L112-22", "@sens": "source", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CITATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000041586868", "@num": "L231-1", "#text": "Code de la construction et de l'habitation. - art. L231-1 (VD)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CITATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000006824510", "@num": "L231-1-1", "#text": "Code de la construction et de l'habitation. - art. L231-1-1 (Ab)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CITATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000006824501", "@num": "L231-10", "#text": "Code de la construction et de l'habitation. - art. L231-10 (V)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CITATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000006824502", "@num": "L231-11", "#text": "Code de la construction et de l'habitation. - art. L231-11", "@sens": "source", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CITATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000038433486", "@num": "L231-6", "#text": "Code de la construction et de l'habitation. - art. L231-6 (VD)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CITATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000006824498", "@num": "L231-7", "#text": "Code de la construction et de l'habitation. - art. L231-7 (V)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CITATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000006824507", "@num": "L232-2", "#text": "Code de la construction et de l'habitation. - art. L232-2 (V)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CITATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000006824514", "@num": "L241-1", "#text": "Code de la construction et de l'habitation. - art. L241-1 (M)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CITATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000006824660", "@num": "L241-3", "#text": "Code de la construction et de l'habitation. - art. L241-3 (M)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CITATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000006824538", "@num": "L242-2", "#text": "Code de la construction et de l'habitation. - art. L242-2 (V)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CITATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000006896534", "@num": "R*231-1", "#text": "Code de la construction et de l'habitation. - art. R*231-1 (M)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CITATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000006896543", "@num": "R*231-7", "#text": "Code de la construction et de l'habitation. - art. R*231-7 (M)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CITATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000039041705", "@num": "R231-13", "#text": "Code de la construction et de l'habitation. - art. R231-13 (VD)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CITATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000039041701", "@num": "R231-14", "#text": "Code de la construction et de l'habitation. - art. R231-14 (VD)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CITATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000039041754", "@num": "R231-2", "#text": "Code de la construction et de l'habitation. - art. R231-2 (VD)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CITATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000039041749", "@num": "R231-3", "#text": "Code de la construction et de l'habitation. - art. R231-3 (VD)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CITATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000039041744", "@num": "R231-4", "#text": "Code de la construction et de l'habitation. - art. R231-4 (VD)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CITATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000039041740", "@num": "R231-5", "#text": "Code de la construction et de l'habitation. - art. R231-5 (VD)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CITATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000006821757", "@num": "R421-24-3", "#text": "Code des assurances - art. R421-24-3 (Ab)", "@sens": "cible", "@cidtexte": "LEGITEXT000006073984", "@typelien": "CITATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000033655931", "@num": "D313-26", "#text": "Code monétaire et financier - art. D313-26 (VD)", "@sens": "cible", "@cidtexte": "LEGITEXT000006072026", "@typelien": "CITATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" } ] }, "CONTEXTE": { "TEXTE": { "TM": { "TM": { "TM": { "TM": { "TITRE_TM": [ { "@id": "LEGISCTA000006159020", "@fin": "2999-01-01", "#text": "Chapitre Ier : Contrat de construction d'une maison individuelle avec fourniture du plan.", "@debut": "1991-12-01" } ] }, "TITRE_TM": [ { "@id": "LEGISCTA000006143526", "@fin": "2999-01-01", "#text": "Titre III : Construction d'une maison individuelle.", "@debut": "1991-12-01" } ] }, "TITRE_TM": [ { "@id": "LEGISCTA000006128681", "@fin": "2999-01-01", "#text": "Livre II : Statut des constructeurs.", "@debut": "1978-06-08" } ] }, "TITRE_TM": [ { "@id": "LEGISCTA000006108136", "@fin": "2999-01-01", "#text": "Partie législative", "@debut": "1978-06-08" } ] }, "@cid": "LEGITEXT000006074096", "@nature": "CODE", "TITRE_TXT": [ { "@fin": "2999-01-01", "#text": "Code de la construction et de l'habitation", "@debut": "1977-03-10", "@id_txt": "LEGITEXT000006074096", "@c_titre_court": "Code de la construction et de l'habitation." } ], "@date_publi": "2999-01-01", "@date_signature": "2999-01-01" } }, "VERSIONS": { "VERSION": [ { "@etat": "MODIFIE", "LIEN_ART": { "@id": "LEGIARTI000006824657", "@fin": "1979-07-14", "@num": "L231-2", "@etat": "MODIFIE", "@debut": "1978-06-08", "@origine": "LEGI" } }, { "@etat": "MODIFIE", "LIEN_ART": { "@id": "LEGIARTI000006824658", "@fin": "1991-12-01", "@num": "L231-2", "@etat": "MODIFIE", "@debut": "1979-07-14", "@origine": "LEGI" } }, { "@etat": "MODIFIE", "LIEN_ART": { "@id": "LEGIARTI000006824659", "@fin": "2018-11-25", "@num": "L231-2", "@etat": "MODIFIE", "@debut": "1991-12-01", "@origine": "LEGI" } }, { "@etat": "MODIFIE", "LIEN_ART": { "@id": "LEGIARTI000037667723", "@fin": "2020-02-01", "@num": "L231-2", "@etat": "MODIFIE", "@debut": "2018-11-25", "@origine": "LEGI" } }, { "@etat": "MODIFIE", "LIEN_ART": { "@id": "LEGIARTI000038433496", "@fin": "2021-07-01", "@num": "L231-2", "@etat": "MODIFIE", "@debut": "2020-02-01", "@origine": "LEGI" } }, { "@etat": "VIGUEUR", "LIEN_ART": { "@id": "LEGIARTI000041586856", "@fin": "2999-01-01", "@num": "L231-2", "@etat": "VIGUEUR", "@debut": "2021-07-01", "@origine": "LEGI" } } ] }, "BLOC_TEXTUEL": { "CONTENU": "

Le contrat visé à l'article L. 231-1 doit comporter les énonciations suivantes :

a) La désignation du terrain destiné à l'implantation de la construction et la mention du titre de propriété du maître de l'ouvrage ou des droits réels lui permettant de construire ;

b) L'affirmation de la conformité du projet aux règles de construction prescrites en application du présent code, notamment de son livre Ier, et du code de l'urbanisme ;

c) La consistance et les caractéristiques techniques du bâtiment à construire comportant :

-tous les travaux d'adaptation au sol, notamment, le cas échéant, ceux rendus nécessaires par l'étude géotechnique mentionnée aux articles L. 132-6 et L. 132-7 du présent code, dont une copie est annexée au contrat ;
\n-les raccordements aux réseaux divers ;
\n-tous les travaux d'équipement intérieur ou extérieur indispensables à l'implantation et à l'utilisation de l'immeuble ;

d) Le coût du bâtiment à construire, égal à la somme du prix convenu et, s'il y a lieu, du coût des travaux dont le maître de l'ouvrage se réserve l'exécution en précisant :

e) Les modalités de règlement en fonction de l'état d'avancement des travaux ;

f) L'indication que le maître de l'ouvrage pourra se faire assister par un professionnel habilité en application de la loi n° 77-2 du 3 janvier 1977 sur l'architecture ou des articles L. 125-1 et suivants lors de la réception ou par tout autre professionnel de la construction titulaire d'un contrat d'assurance couvrant les responsabilités pour ce type de mission ;

g) L'indication de l'obtention du permis de construire et des autres autorisations administratives, dont une copie est annexée au contrat ;

h) L'indication des modalités de financement, la nature et le montant des prêts obtenus et acceptés par le maître de l'ouvrage ;

i) La date d'ouverture du chantier, le délai d'exécution des travaux et les pénalités prévues en cas de retard de livraison ;

j) La référence de l'assurance de dommages souscrite par le maître de l'ouvrage, en application de l'article L. 242-1 du code des assurances ;

k) Les justifications des garanties de remboursement et de livraison apportées par le constructeur, les attestations de ces garanties étant établies par le garant et annexées au contrat.

" } }, "LEGIARTI000006824493": { "META": { "META_SPEC": { "META_ARTICLE": { "NUM": "L230-1", "ETAT": "VIGUEUR", "TYPE": "AUTONOME", "DATE_FIN": "2999-01-01", "DATE_DEBUT": "1991-12-01" } }, "META_COMMUN": { "ID": "LEGIARTI000006824493", "URL": "article/LEGI/ARTI/00/00/06/82/44/LEGIARTI000006824493.xml", "NATURE": "Article", "ORIGINE": "LEGI", "ANCIEN_ID": "UCAXXXXXXXX1X230L001XXAA" } }, "LIENS": { "LIEN": [ { "@id": "JORFTEXT000000516442", "#text": "Décret 78-621 1978-05-31 JORF 8 JUIN 1978", "@sens": "source", "@cidtexte": "JORFTEXT000000516442", "@numtexte": "78-621", "@typelien": "CODIFICATION", "@naturetexte": "DECRET", "@datesignatexte": "1978-05-31" }, { "@id": "JORFTEXT000000709335", "#text": "Loi 90-1129 1990-12-19 art. 8", "@sens": "source", "@cidtexte": "JORFTEXT000000709335", "@nortexte": "EQUX9000054L", "@numtexte": "90-1129", "@typelien": "SPEC_APPLI", "@naturetexte": "LOI", "@datesignatexte": "1990-12-19" }, { "@id": "LEGIARTI000006826206", "@num": "1", "#text": "Loi n°90-1129 du 19 décembre 1990 - art. 1 () JORF 22 décembre 1990 en vigueur le 1er décembre 1991", "@sens": "source", "@cidtexte": "JORFTEXT000000709335", "@nortexte": "EQUX9000054L", "@numtexte": "90-1129", "@typelien": "CREATION", "@naturetexte": "LOI", "@datesignatexte": "1990-12-19" } ] }, "CONTEXTE": { "TEXTE": { "TM": { "TM": { "TM": { "TITRE_TM": [ { "@id": "LEGISCTA000006143526", "@fin": "2999-01-01", "#text": "Titre III : Construction d'une maison individuelle.", "@debut": "1991-12-01" } ] }, "TITRE_TM": [ { "@id": "LEGISCTA000006128681", "@fin": "2999-01-01", "#text": "Livre II : Statut des constructeurs.", "@debut": "1978-06-08" } ] }, "TITRE_TM": [ { "@id": "LEGISCTA000006108136", "@fin": "2999-01-01", "#text": "Partie législative", "@debut": "1978-06-08" } ] }, "@cid": "LEGITEXT000006074096", "@nature": "CODE", "TITRE_TXT": [ { "@fin": "2999-01-01", "#text": "Code de la construction et de l'habitation", "@debut": "1977-03-10", "@id_txt": "LEGITEXT000006074096", "@c_titre_court": "Code de la construction et de l'habitation." } ], "@date_publi": "2999-01-01", "@date_signature": "2999-01-01" } }, "VERSIONS": { "VERSION": [ { "@etat": "VIGUEUR", "LIEN_ART": { "@id": "LEGIARTI000006824493", "@fin": "2999-01-01", "@num": "L230-1", "@etat": "VIGUEUR", "@debut": "1991-12-01", "@origine": "LEGI" } } ] }, "BLOC_TEXTUEL": { "CONTENU": "
Les règles prévues au présent titre sont d'ordre public.
\n
" } }, "LEGIARTI000006824495": { "META": { "META_SPEC": { "META_ARTICLE": { "NUM": "L231-5", "ETAT": "VIGUEUR", "TYPE": "AUTONOME", "DATE_FIN": "2999-01-01", "DATE_DEBUT": "1991-12-01" } }, "META_COMMUN": { "ID": "LEGIARTI000006824495", "URL": "article/LEGI/ARTI/00/00/06/82/44/LEGIARTI000006824495.xml", "NATURE": "Article", "ORIGINE": "LEGI", "ANCIEN_ID": "UCAXXXXXXXX1X231L005XXAA" } }, "LIENS": { "LIEN": [ { "@id": "JORFTEXT000000516442", "#text": "Décret 78-621 1978-05-31 JORF 8 JUIN 1978", "@sens": "source", "@cidtexte": "JORFTEXT000000516442", "@numtexte": "78-621", "@typelien": "CODIFICATION", "@naturetexte": "DECRET", "@datesignatexte": "1978-05-31" }, { "@id": "JORFTEXT000000709335", "#text": "Loi 90-1129 1990-12-19 art. 8", "@sens": "source", "@cidtexte": "JORFTEXT000000709335", "@nortexte": "EQUX9000054L", "@numtexte": "90-1129", "@typelien": "SPEC_APPLI", "@naturetexte": "LOI", "@datesignatexte": "1990-12-19" }, { "@id": "LEGIARTI000006826206", "@num": "1", "#text": "Loi n°90-1129 du 19 décembre 1990 - art. 1 () JORF 22 décembre 1990 en vigueur le 1er décembre 1991", "@sens": "source", "@cidtexte": "JORFTEXT000000709335", "@nortexte": "EQUX9000054L", "@numtexte": "90-1129", "@typelien": "CREATION", "@naturetexte": "LOI", "@datesignatexte": "1990-12-19" }, { "@id": "LEGIARTI000006824597", "@num": "L261-10", "#text": "Code de la construction et de l'habitation. - art. L261-10 (V)", "@sens": "source", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CITATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" } ] }, "CONTEXTE": { "TEXTE": { "TM": { "TM": { "TM": { "TM": { "TITRE_TM": [ { "@id": "LEGISCTA000006159020", "@fin": "2999-01-01", "#text": "Chapitre Ier : Contrat de construction d'une maison individuelle avec fourniture du plan.", "@debut": "1991-12-01" } ] }, "TITRE_TM": [ { "@id": "LEGISCTA000006143526", "@fin": "2999-01-01", "#text": "Titre III : Construction d'une maison individuelle.", "@debut": "1991-12-01" } ] }, "TITRE_TM": [ { "@id": "LEGISCTA000006128681", "@fin": "2999-01-01", "#text": "Livre II : Statut des constructeurs.", "@debut": "1978-06-08" } ] }, "TITRE_TM": [ { "@id": "LEGISCTA000006108136", "@fin": "2999-01-01", "#text": "Partie législative", "@debut": "1978-06-08" } ] }, "@cid": "LEGITEXT000006074096", "@nature": "CODE", "TITRE_TXT": [ { "@fin": "2999-01-01", "#text": "Code de la construction et de l'habitation", "@debut": "1977-03-10", "@id_txt": "LEGITEXT000006074096", "@c_titre_court": "Code de la construction et de l'habitation." } ], "@date_publi": "2999-01-01", "@date_signature": "2999-01-01" } }, "VERSIONS": { "VERSION": [ { "@etat": "VIGUEUR", "LIEN_ART": { "@id": "LEGIARTI000006824495", "@fin": "2999-01-01", "@num": "L231-5", "@etat": "VIGUEUR", "@debut": "1991-12-01", "@origine": "LEGI" } } ] }, "BLOC_TEXTUEL": { "CONTENU": "
L'obligation, instituée par le deuxième alinéa de l'article L. 261-10, de conclure un contrat conforme aux dispositions de l'alinéa premier de cet article ne s'applique pas lorsque celui qui procure indirectement le terrain est le constructeur.
\n
" } }, "LEGIARTI000006824498": { "META": { "META_SPEC": { "META_ARTICLE": { "NUM": "L231-7", "ETAT": "VIGUEUR", "TYPE": "AUTONOME", "DATE_FIN": "2999-01-01", "DATE_DEBUT": "1991-12-01" } }, "META_COMMUN": { "ID": "LEGIARTI000006824498", "URL": "article/LEGI/ARTI/00/00/06/82/44/LEGIARTI000006824498.xml", "NATURE": "Article", "ORIGINE": "LEGI", "ANCIEN_ID": "UCAXXXXXXXX1X231L007XXAA" } }, "LIENS": { "LIEN": [ { "@id": "JORFTEXT000000516442", "#text": "Décret 78-621 1978-05-31 JORF 8 JUIN 1978", "@sens": "source", "@cidtexte": "JORFTEXT000000516442", "@numtexte": "78-621", "@typelien": "CODIFICATION", "@naturetexte": "DECRET", "@datesignatexte": "1978-05-31" }, { "@id": "LEGIARTI000006826206", "@num": "1", "#text": "Loi n°90-1129 du 19 décembre 1990 - art. 1 () JORF 22 décembre 1990 en vigueur le 1er décembre 1991 rectificatif JORF 22 novembre 1991", "@sens": "source", "@cidtexte": "JORFTEXT000000709335", "@nortexte": "EQUX9000054L", "@numtexte": "90-1129", "@typelien": "CREATION", "@naturetexte": "LOI", "@datesignatexte": "1990-12-19" }, { "@id": "LEGIARTI000006824501", "@num": "L231-10", "#text": "Code de la construction et de l'habitation. - art. L231-10 (V)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CITATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000006824657", "@num": "L231-2", "#text": "Code de la construction et de l'habitation. - art. L231-2 (V)", "@sens": "source", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CITATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000039041713", "@num": "R231-11", "#text": "Code de la construction et de l'habitation. - art. R231-11 (VD)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CITATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" } ] }, "CONTEXTE": { "TEXTE": { "TM": { "TM": { "TM": { "TM": { "TITRE_TM": [ { "@id": "LEGISCTA000006159020", "@fin": "2999-01-01", "#text": "Chapitre Ier : Contrat de construction d'une maison individuelle avec fourniture du plan.", "@debut": "1991-12-01" } ] }, "TITRE_TM": [ { "@id": "LEGISCTA000006143526", "@fin": "2999-01-01", "#text": "Titre III : Construction d'une maison individuelle.", "@debut": "1991-12-01" } ] }, "TITRE_TM": [ { "@id": "LEGISCTA000006128681", "@fin": "2999-01-01", "#text": "Livre II : Statut des constructeurs.", "@debut": "1978-06-08" } ] }, "TITRE_TM": [ { "@id": "LEGISCTA000006108136", "@fin": "2999-01-01", "#text": "Partie législative", "@debut": "1978-06-08" } ] }, "@cid": "LEGITEXT000006074096", "@nature": "CODE", "TITRE_TXT": [ { "@fin": "2999-01-01", "#text": "Code de la construction et de l'habitation", "@debut": "1977-03-10", "@id_txt": "LEGITEXT000006074096", "@c_titre_court": "Code de la construction et de l'habitation." } ], "@date_publi": "2999-01-01", "@date_signature": "2999-01-01" } }, "VERSIONS": { "VERSION": [ { "@etat": "VIGUEUR", "LIEN_ART": { "@id": "LEGIARTI000006824498", "@fin": "2999-01-01", "@num": "L231-7", "@etat": "VIGUEUR", "@debut": "1991-12-01", "@origine": "LEGI" } } ] }, "BLOC_TEXTUEL": { "CONTENU": "
I.-Dans le cas prévu au d de l'article L. 231-2, le constructeur est tenu d'exécuter ou de faire exécuter les travaux dont le maître de l'ouvrage s'est réservé l'exécution aux prix et conditions mentionnés au contrat si le maître de l'ouvrage lui en fait la demande dans les quatre mois qui suivent la signature du contrat.
\n
II.-Est réputé non écrit tout mandat donné par le maître de l'ouvrage au constructeur ou à un de ses préposés aux fins de percevoir tout ou partie d'un prêt destiné au financement de la construction.
\n
III.-Les paiements intervenant aux différents stades de la construction peuvent être effectués directement par le prêteur, sous réserve de l'accord écrit du maître de l'ouvrage à chaque échéance et de l'information du garant.
\n
A défaut d'accord écrit du maître de l'ouvrage à chaque échéance, le prêteur est responsable des conséquences préjudiciables des paiements qu'il effectue aux différents stades de la construction.
" } }, "LEGIARTI000006824500": { "META": { "META_SPEC": { "META_ARTICLE": { "NUM": "L231-9", "ETAT": "VIGUEUR", "TYPE": "AUTONOME", "DATE_FIN": "2999-01-01", "DATE_DEBUT": "1991-12-01" } }, "META_COMMUN": { "ID": "LEGIARTI000006824500", "URL": "article/LEGI/ARTI/00/00/06/82/45/LEGIARTI000006824500.xml", "NATURE": "Article", "ORIGINE": "LEGI", "ANCIEN_ID": "UCAXXXXXXXX1X231L009XXAA" } }, "LIENS": { "LIEN": [ { "@id": "JORFTEXT000000516442", "#text": "Décret 78-621 1978-05-31 JORF 8 JUIN 1978", "@sens": "source", "@cidtexte": "JORFTEXT000000516442", "@numtexte": "78-621", "@typelien": "CODIFICATION", "@naturetexte": "DECRET", "@datesignatexte": "1978-05-31" }, { "@id": "JORFTEXT000000709335", "#text": "Loi 90-1129 1990-12-19 art. 8", "@sens": "source", "@cidtexte": "JORFTEXT000000709335", "@nortexte": "EQUX9000054L", "@numtexte": "90-1129", "@typelien": "SPEC_APPLI", "@naturetexte": "LOI", "@datesignatexte": "1990-12-19" }, { "@id": "LEGIARTI000006826206", "@num": "1", "#text": "Loi n°90-1129 du 19 décembre 1990 - art. 1 () JORF 22 décembre 1990 en vigueur le 1er décembre 1991", "@sens": "source", "@cidtexte": "JORFTEXT000000709335", "@nortexte": "EQUX9000054L", "@numtexte": "90-1129", "@typelien": "CREATION", "@naturetexte": "LOI", "@datesignatexte": "1990-12-19" }, { "@id": "LEGIARTI000006824507", "@num": "L232-2", "#text": "Code de la construction et de l'habitation. - art. L232-2 (V)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CITATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" } ] }, "CONTEXTE": { "TEXTE": { "TM": { "TM": { "TM": { "TM": { "TITRE_TM": [ { "@id": "LEGISCTA000006159020", "@fin": "2999-01-01", "#text": "Chapitre Ier : Contrat de construction d'une maison individuelle avec fourniture du plan.", "@debut": "1991-12-01" } ] }, "TITRE_TM": [ { "@id": "LEGISCTA000006143526", "@fin": "2999-01-01", "#text": "Titre III : Construction d'une maison individuelle.", "@debut": "1991-12-01" } ] }, "TITRE_TM": [ { "@id": "LEGISCTA000006128681", "@fin": "2999-01-01", "#text": "Livre II : Statut des constructeurs.", "@debut": "1978-06-08" } ] }, "TITRE_TM": [ { "@id": "LEGISCTA000006108136", "@fin": "2999-01-01", "#text": "Partie législative", "@debut": "1978-06-08" } ] }, "@cid": "LEGITEXT000006074096", "@nature": "CODE", "TITRE_TXT": [ { "@fin": "2999-01-01", "#text": "Code de la construction et de l'habitation", "@debut": "1977-03-10", "@id_txt": "LEGITEXT000006074096", "@c_titre_court": "Code de la construction et de l'habitation." } ], "@date_publi": "2999-01-01", "@date_signature": "2999-01-01" } }, "VERSIONS": { "VERSION": [ { "@etat": "VIGUEUR", "LIEN_ART": { "@id": "LEGIARTI000006824500", "@fin": "2999-01-01", "@num": "L231-9", "@etat": "VIGUEUR", "@debut": "1991-12-01", "@origine": "LEGI" } } ] }, "BLOC_TEXTUEL": { "CONTENU": "
Une notice d'information conforme à un modèle type agréé par arrêté conjoint des ministres chargés de la construction et de la consommation est jointe au contrat qui est adressé par le constructeur au maître de l'ouvrage par lettre recommandée avec avis de réception.
\n
" } }, "LEGIARTI000006824501": { "META": { "META_SPEC": { "META_ARTICLE": { "NUM": "L231-10", "ETAT": "VIGUEUR", "TYPE": "AUTONOME", "DATE_FIN": "2999-01-01", "DATE_DEBUT": "1991-12-01" } }, "META_COMMUN": { "ID": "LEGIARTI000006824501", "URL": "article/LEGI/ARTI/00/00/06/82/45/LEGIARTI000006824501.xml", "NATURE": "Article", "ORIGINE": "LEGI", "ANCIEN_ID": "UCAXXXXXXXX1X231L010XXAA" } }, "LIENS": { "LIEN": [ { "@id": "JORFTEXT000000516442", "#text": "Décret 78-621 1978-05-31 JORF 8 JUIN 1978", "@sens": "source", "@cidtexte": "JORFTEXT000000516442", "@numtexte": "78-621", "@typelien": "CODIFICATION", "@naturetexte": "DECRET", "@datesignatexte": "1978-05-31" }, { "@id": "JORFTEXT000000709335", "#text": "Loi 90-1129 1990-12-19 art. 8", "@sens": "source", "@cidtexte": "JORFTEXT000000709335", "@nortexte": "EQUX9000054L", "@numtexte": "90-1129", "@typelien": "SPEC_APPLI", "@naturetexte": "LOI", "@datesignatexte": "1990-12-19" }, { "@id": "LEGIARTI000006826206", "@num": "1", "#text": "Loi n°90-1129 du 19 décembre 1990 - art. 1 () JORF 22 décembre 1990 en vigueur le 1er décembre 1991", "@sens": "source", "@cidtexte": "JORFTEXT000000709335", "@nortexte": "EQUX9000054L", "@numtexte": "90-1129", "@typelien": "CREATION", "@naturetexte": "LOI", "@datesignatexte": "1990-12-19" }, { "@id": "LEGIARTI000006824657", "@num": "L231-2", "#text": "Code de la construction et de l'habitation. - art. L231-2 (V)", "@sens": "source", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CITATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000006824496", "@num": "L231-6", "#text": "Code de la construction et de l'habitation. - art. L231-6 (VT)", "@sens": "source", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CITATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000006824498", "@num": "L231-7", "#text": "Code de la construction et de l'habitation. - art. L231-7 (V)", "@sens": "source", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CITATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" } ] }, "CONTEXTE": { "TEXTE": { "TM": { "TM": { "TM": { "TM": { "TITRE_TM": [ { "@id": "LEGISCTA000006159020", "@fin": "2999-01-01", "#text": "Chapitre Ier : Contrat de construction d'une maison individuelle avec fourniture du plan.", "@debut": "1991-12-01" } ] }, "TITRE_TM": [ { "@id": "LEGISCTA000006143526", "@fin": "2999-01-01", "#text": "Titre III : Construction d'une maison individuelle.", "@debut": "1991-12-01" } ] }, "TITRE_TM": [ { "@id": "LEGISCTA000006128681", "@fin": "2999-01-01", "#text": "Livre II : Statut des constructeurs.", "@debut": "1978-06-08" } ] }, "TITRE_TM": [ { "@id": "LEGISCTA000006108136", "@fin": "2999-01-01", "#text": "Partie législative", "@debut": "1978-06-08" } ] }, "@cid": "LEGITEXT000006074096", "@nature": "CODE", "TITRE_TXT": [ { "@fin": "2999-01-01", "#text": "Code de la construction et de l'habitation", "@debut": "1977-03-10", "@id_txt": "LEGITEXT000006074096", "@c_titre_court": "Code de la construction et de l'habitation." } ], "@date_publi": "2999-01-01", "@date_signature": "2999-01-01" } }, "VERSIONS": { "VERSION": [ { "@etat": "VIGUEUR", "LIEN_ART": { "@id": "LEGIARTI000006824501", "@fin": "2999-01-01", "@num": "L231-10", "@etat": "VIGUEUR", "@debut": "1991-12-01", "@origine": "LEGI" } } ] }, "BLOC_TEXTUEL": { "CONTENU": "
Aucun prêteur ne peut émettre une offre de prêt sans avoir vérifié que le contrat comporte celles des énonciations mentionnées à l'article L. 231-2 qui doivent y figurer au moment où l'acte lui est transmis et ne peut débloquer les fonds s'il n'a pas communication de l'attestation de garantie de livraison.
\n
Dans les cas de défaillance du constructeur visés au paragraphe II de l'article L. 231-6 et nonobstant l'accord du maître de l'ouvrage prévu au premier alinéa du paragraphe III de l'article L. 231-7, le prêteur est responsable des conséquences préjudiciables d'un versement excédant le pourcentage maximum du prix total exigible aux différents stades de la construction d'après l'état d'avancement des travaux dès lors que ce versement résulte de l'exécution d'une clause irrégulière du contrat.
" } }, "LEGIARTI000006824502": { "META": { "META_SPEC": { "META_ARTICLE": { "NUM": "L231-11", "ETAT": "MODIFIE", "TYPE": "AUTONOME", "DATE_FIN": "2014-02-10", "DATE_DEBUT": "1991-12-01" } }, "META_COMMUN": { "ID": "LEGIARTI000006824502", "URL": "article/LEGI/ARTI/00/00/06/82/45/LEGIARTI000006824502.xml", "NATURE": "Article", "ORIGINE": "LEGI", "ANCIEN_ID": "UCAXXXXXXXX1X231L011XXAA" } }, "LIENS": { "LIEN": [ { "@id": "JORFTEXT000000516442", "#text": "Décret 78-621 1978-05-31 JORF 8 JUIN 1978", "@sens": "source", "@cidtexte": "JORFTEXT000000516442", "@numtexte": "78-621", "@typelien": "CODIFICATION", "@naturetexte": "DECRET", "@datesignatexte": "1978-05-31" }, { "@id": "JORFTEXT000000709335", "#text": "Loi 90-1129 1990-12-19 art. 8", "@sens": "source", "@cidtexte": "JORFTEXT000000709335", "@nortexte": "EQUX9000054L", "@numtexte": "90-1129", "@typelien": "SPEC_APPLI", "@naturetexte": "LOI", "@datesignatexte": "1990-12-19" }, { "@id": "LEGIARTI000006826206", "@num": "1", "#text": "Loi n°90-1129 du 19 décembre 1990 - art. 1 () JORF 22 décembre 1990 en vigueur le 1er décembre 1991", "@sens": "source", "@cidtexte": "JORFTEXT000000709335", "@nortexte": "EQUX9000054L", "@numtexte": "90-1129", "@typelien": "CREATION", "@naturetexte": "LOI", "@datesignatexte": "1990-12-19" }, { "@id": "LEGITEXT000028573818", "#text": "Décret n°2014-114 du 7 février 2014 (V)", "@sens": "cible", "@cidtexte": "JORFTEXT000028572356", "@nortexte": "DEVX1331261D", "@numtexte": "2014-114", "@typelien": "CITATION", "@naturetexte": "DECRET", "@datesignatexte": "2014-02-07" }, { "@id": "LEGIARTI000006824508", "@num": "L231-1", "#text": "Code de la construction et de l'habitation. - art. L231-1 (V)", "@sens": "source", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CITATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000036568688", "@num": "L231-12", "#text": "Code de la construction et de l'habitation. - art. L231-12 (V)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CITATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000041586856", "@num": "L231-2", "#text": "Code de la construction et de l'habitation. - art. L231-2 (VD)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CITATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000039041736", "@num": "R231-6", "#text": "Code de la construction et de l'habitation. - art. R231-6 (VD)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CITATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" } ] }, "CONTEXTE": { "TEXTE": { "TM": { "TM": { "TM": { "TM": { "TITRE_TM": [ { "@id": "LEGISCTA000006159020", "@fin": "2999-01-01", "#text": "Chapitre Ier : Contrat de construction d'une maison individuelle avec fourniture du plan.", "@debut": "1991-12-01" } ] }, "TITRE_TM": [ { "@id": "LEGISCTA000006143526", "@fin": "2999-01-01", "#text": "Titre III : Construction d'une maison individuelle.", "@debut": "1991-12-01" } ] }, "TITRE_TM": [ { "@id": "LEGISCTA000006128681", "@fin": "2999-01-01", "#text": "Livre II : Statut des constructeurs.", "@debut": "1978-06-08" } ] }, "TITRE_TM": [ { "@id": "LEGISCTA000006108136", "@fin": "2999-01-01", "#text": "Partie législative", "@debut": "1978-06-08" } ] }, "@cid": "LEGITEXT000006074096", "@nature": "CODE", "TITRE_TXT": [ { "@fin": "2999-01-01", "#text": "Code de la construction et de l'habitation", "@debut": "1977-03-10", "@id_txt": "LEGITEXT000006074096", "@c_titre_court": "Code de la construction et de l'habitation." } ], "@date_publi": "2999-01-01", "@date_signature": "2999-01-01" } }, "VERSIONS": { "VERSION": [ { "@etat": "MODIFIE", "LIEN_ART": { "@id": "LEGIARTI000006824502", "@fin": "2014-02-10", "@num": "L231-11", "@etat": "MODIFIE", "@debut": "1991-12-01", "@origine": "LEGI" } }, { "@etat": "VIGUEUR", "LIEN_ART": { "@id": "LEGIARTI000028574448", "@fin": "2999-01-01", "@num": "L231-11", "@etat": "VIGUEUR", "@debut": "2014-02-10", "@origine": "LEGI" } } ] }, "BLOC_TEXTUEL": { "CONTENU": "

Au cas où le contrat défini à l'article L. 231-1 prévoit la révision du prix, celle-ci ne peut être calculée qu'en fonction de la variation d'un indice national du bâtiment tous corps d'état mesurant l'évolution du coût des facteurs de production dans le bâtiment, publié par le ministre chargé de la construction et de l'habitation, et, au choix des parties, selon l'une des deux modalités ci-après :

a) Révision du prix d'après la variation de l'indice entre la date de la signature du contrat et la date fixée à l'article L. 231-12, le prix ainsi révisé ne pouvant subir aucune variation après cette date ;

b) Révision sur chaque paiement dans une limite exprimée en pourcentage de la variation de l'indice défini ci-dessus entre la date de signature du contrat et la date de livraison prévue au contrat, aucune révision ne pouvant être effectuée au-delà d'une période de neuf mois suivant la date définie à l'article L. 231-12 lorsque la livraison prévue doit avoir lieu postérieurement à l'expiration de cette période.

Ces modalités doivent être portées, préalablement à la signature du contrat, à la connaissance du maître de l'ouvrage par la personne qui se charge de la construction. Elles doivent être reproduites dans le contrat, cet acte devant en outre porter, paraphée par le maître de l'ouvrage, une clause par laquelle celui-ci reconnaît en avoir été informé dans les conditions prévues ci-dessus.

La modalité choisie d'un commun accord par les parties doit figurer dans le contrat.

A défaut des mentions prévues aux deux alinéas précédents, le prix figurant au contrat n'est pas révisable.

L'indice et la limite prévus ci-dessus sont définis par décret en Conseil d'Etat. Cette limite, destinée à tenir compte des frais fixes, des approvisionnements constitués et des améliorations de productivité, doit être comprise entre 60% et 80% de la variation de l'indice.

L'indice servant de base pour le calcul de la révision est le dernier indice publié au jour de la signature du contrat. La variation prise en compte résulte de la comparaison de cet indice avec le dernier indice publié avant la date de chaque paiement ou avant celle prévue à l'article L. 231-12 selon le choix exprimé par les parties.

" } }, "LEGIARTI000006824503": { "META": { "META_SPEC": { "META_ARTICLE": { "NUM": "L231-12", "ETAT": "MODIFIE", "TYPE": "AUTONOME", "DATE_FIN": "2016-07-01", "DATE_DEBUT": "1991-12-01" } }, "META_COMMUN": { "ID": "LEGIARTI000006824503", "URL": "article/LEGI/ARTI/00/00/06/82/45/LEGIARTI000006824503.xml", "NATURE": "Article", "ORIGINE": "LEGI", "ANCIEN_ID": "UCAXXXXXXXX1X231L012XXAA" } }, "LIENS": { "LIEN": [ { "@id": "JORFTEXT000000516442", "#text": "Décret 78-621 1978-05-31 JORF 8 JUIN 1978", "@sens": "source", "@cidtexte": "JORFTEXT000000516442", "@numtexte": "78-621", "@typelien": "CODIFICATION", "@naturetexte": "DECRET", "@datesignatexte": "1978-05-31" }, { "@id": "LEGIARTI000006508635", "@num": "17", "#text": "Loi n°79-596 du 13 juillet 1979 - art. 17 (Ab)", "@sens": "source", "@cidtexte": "JORFTEXT000000886678", "@numtexte": "79-596", "@typelien": "CITATION", "@naturetexte": "LOI", "@datesignatexte": "1979-07-13" }, { "@id": "JORFTEXT000000709335", "#text": "Loi 90-1129 1990-12-19 art. 8", "@sens": "source", "@cidtexte": "JORFTEXT000000709335", "@nortexte": "EQUX9000054L", "@numtexte": "90-1129", "@typelien": "SPEC_APPLI", "@naturetexte": "LOI", "@datesignatexte": "1990-12-19" }, { "@id": "LEGIARTI000006826206", "@num": "1", "#text": "Loi n°90-1129 du 19 décembre 1990 - art. 1 () JORF 22 décembre 1990 en vigueur le 1er décembre 1991", "@sens": "source", "@cidtexte": "JORFTEXT000000709335", "@nortexte": "EQUX9000054L", "@numtexte": "90-1129", "@typelien": "CREATION", "@naturetexte": "LOI", "@datesignatexte": "1990-12-19" }, { "@id": "LEGIARTI000028574448", "@num": "L231-11", "#text": "Code de la construction et de l'habitation. - art. L231-11 (V)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CITATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" } ] }, "CONTEXTE": { "TEXTE": { "TM": { "TM": { "TM": { "TM": { "TITRE_TM": [ { "@id": "LEGISCTA000006159020", "@fin": "2999-01-01", "#text": "Chapitre Ier : Contrat de construction d'une maison individuelle avec fourniture du plan.", "@debut": "1991-12-01" } ] }, "TITRE_TM": [ { "@id": "LEGISCTA000006143526", "@fin": "2999-01-01", "#text": "Titre III : Construction d'une maison individuelle.", "@debut": "1991-12-01" } ] }, "TITRE_TM": [ { "@id": "LEGISCTA000006128681", "@fin": "2999-01-01", "#text": "Livre II : Statut des constructeurs.", "@debut": "1978-06-08" } ] }, "TITRE_TM": [ { "@id": "LEGISCTA000006108136", "@fin": "2999-01-01", "#text": "Partie législative", "@debut": "1978-06-08" } ] }, "@cid": "LEGITEXT000006074096", "@nature": "CODE", "TITRE_TXT": [ { "@fin": "2999-01-01", "#text": "Code de la construction et de l'habitation", "@debut": "1977-03-10", "@id_txt": "LEGITEXT000006074096", "@c_titre_court": "Code de la construction et de l'habitation." } ], "@date_publi": "2999-01-01", "@date_signature": "2999-01-01" } }, "VERSIONS": { "VERSION": [ { "@etat": "MODIFIE", "LIEN_ART": { "@id": "LEGIARTI000006824503", "@fin": "2016-07-01", "@num": "L231-12", "@etat": "MODIFIE", "@debut": "1991-12-01", "@origine": "LEGI" } }, { "@etat": "VIGUEUR", "LIEN_ART": { "@id": "LEGIARTI000036568688", "@fin": "2999-01-01", "@num": "L231-12", "@etat": "VIGUEUR", "@debut": "2016-07-01", "@origine": "LEGI" } } ] }, "BLOC_TEXTUEL": { "CONTENU": "
La date prévue pour l'application des deuxième (a) et troisième (b) alinéas de l'article L. 231-11 est celle de l'expiration d'un délai d'un mois qui suit la plus tardive des deux dates suivantes :
\n
a) La date de l'obtention, tacite ou expresse, des autorisations administratives nécessaires pour entreprendre la construction ;
\n
b) La date de la réalisation de la condition suspensive sous laquelle le contrat a été conclu ou est considéré comme conclu en application des articles 17 et 18 de la loi n° 79-596 du 13 juillet 1979 relative à l'information et à la protection des emprunteurs dans le domaine immobilier.
" } }, "LEGIARTI000006824506": { "META": { "META_SPEC": { "META_ARTICLE": { "NUM": "L232-1", "ETAT": "MODIFIE", "TYPE": "AUTONOME", "DATE_FIN": "2021-07-01", "DATE_DEBUT": "1991-12-01" } }, "META_COMMUN": { "ID": "LEGIARTI000006824506", "URL": "article/LEGI/ARTI/00/00/06/82/45/LEGIARTI000006824506.xml", "NATURE": "Article", "ORIGINE": "LEGI", "ANCIEN_ID": "UCAXXXXXXXX1X232L001XXAA" } }, "LIENS": { "LIEN": [ { "@id": "JORFTEXT000000522423", "#text": "Loi n° 77-2 du 3 janvier 1977 (V)", "@sens": "source", "@cidtexte": "JORFTEXT000000522423", "@numtexte": "77-2", "@typelien": "CITATION", "@naturetexte": "LOI", "@datesignatexte": "1977-01-03" }, { "@id": "JORFTEXT000000516442", "#text": "Décret 78-621 1978-05-31 JORF 8 JUIN 1978", "@sens": "source", "@cidtexte": "JORFTEXT000000516442", "@numtexte": "78-621", "@typelien": "CODIFICATION", "@naturetexte": "DECRET", "@datesignatexte": "1978-05-31" }, { "@id": "JORFTEXT000000709335", "#text": "Loi 90-1129 1990-12-19 art. 8", "@sens": "source", "@cidtexte": "JORFTEXT000000709335", "@nortexte": "EQUX9000054L", "@numtexte": "90-1129", "@typelien": "SPEC_APPLI", "@naturetexte": "LOI", "@datesignatexte": "1990-12-19" }, { "@id": "LEGIARTI000006826206", "@num": "1", "#text": "Loi n°90-1129 du 19 décembre 1990 - art. 1 () JORF 22 décembre 1990 en vigueur le 1er décembre 1991", "@sens": "source", "@cidtexte": "JORFTEXT000000709335", "@nortexte": "EQUX9000054L", "@numtexte": "90-1129", "@typelien": "CREATION", "@naturetexte": "LOI", "@datesignatexte": "1990-12-19" }, { "@id": "LEGIARTI000006830648", "@num": "3", "#text": "Arrêté du 27 novembre 1991 - art. 3 (V)", "@sens": "cible", "@cidtexte": "JORFTEXT000000526871", "@nortexte": "EQUC9101692A", "@typelien": "CITATION", "@naturetexte": "ARRETE", "@datesignatexte": "1991-11-27" }, { "@id": "LEGIARTI000021355420", "@num": "1", "#text": "Arrêté du 19 novembre 2009 - art. 1 (V)", "@sens": "cible", "@cidtexte": "JORFTEXT000021344622", "@nortexte": "DEVU0926808A", "@typelien": "CITATION", "@naturetexte": "ARRETE", "@datesignatexte": "2009-11-19" }, { "@id": "LEGIARTI000027550543", "@num": "7", "#text": "Arrêté du 30 décembre 2010 - art. 7 (Ab)", "@sens": "cible", "@cidtexte": "JORFTEXT000023332971", "@nortexte": "DEVL1026553A", "@typelien": "CITATION", "@naturetexte": "ARRETE", "@datesignatexte": "2010-12-30" }, { "@id": "LEGIARTI000045581767", "@num": "4-1", "#text": "Arrêté du 11 octobre 2011 - art. 4-1 (V)", "@sens": "cible", "@cidtexte": "JORFTEXT000024695233", "@nortexte": "DEVL1126896A", "@typelien": "CITATION", "@naturetexte": "ARRETE", "@datesignatexte": "2011-10-11" }, { "@id": "LEGIARTI000050745443", "@num": "1", "#text": "Arrêté du 29 juin 2020 - art. 1 (V)", "@sens": "cible", "@cidtexte": "JORFTEXT000042106692", "@nortexte": "ECOT2013713A", "@typelien": "CITATION", "@naturetexte": "ARRETE", "@datesignatexte": "2020-06-29" }, { "@id": "LEGIARTI000044503425", "@num": "10", "#text": "Arrêté du 9 décembre 2021 - art. 10", "@sens": "cible", "@cidtexte": "JORFTEXT000044501420", "@nortexte": "LOGL2114162A", "@typelien": "CITATION", "@naturetexte": "ARRETE", "@datesignatexte": "2021-12-09" }, { "@id": "LEGITEXT000050742475", "#text": "Arrêté du 3 décembre 2024 (V)", "@sens": "cible", "@cidtexte": "JORFTEXT000050731883", "@nortexte": "LRUL2422852A", "@typelien": "CITATION", "@naturetexte": "ARRETE", "@datesignatexte": "2024-12-03" }, { "@id": "LEGITEXT000050742642", "#text": "Arrêté du 3 décembre 2024 (V)", "@sens": "cible", "@cidtexte": "JORFTEXT000050731018", "@nortexte": "ECOT2430597A", "@typelien": "CITATION", "@naturetexte": "ARRETE", "@datesignatexte": "2024-12-03" }, { "@id": "LEGIARTI000050742674", "@num": "1", "#text": "Arrêté du 3 décembre 2024 - art. 1", "@sens": "cible", "@cidtexte": "JORFTEXT000050731018", "@nortexte": "ECOT2430597A", "@typelien": "CITATION", "@naturetexte": "ARRETE", "@datesignatexte": "2024-12-03" }, { "@id": "LEGIARTI000006795972", "@num": "L242-1", "#text": "Code des assurances - art. L242-1 (V)", "@sens": "source", "@cidtexte": "LEGITEXT000006073984", "@typelien": "CITATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000006824172", "@num": "L111-23", "#text": "Code de la construction et de l'habitation. - art. L111-23 (V)", "@sens": "source", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CITATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000006824508", "@num": "L231-1", "#text": "Code de la construction et de l'habitation. - art. L231-1 (V)", "@sens": "source", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CITATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000028806974", "@num": "L241-3", "#text": "Code de la construction et de l'habitation. - art. L241-3 (V)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CITATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000032235569", "@num": "L241-8", "#text": "Code de la construction et de l'habitation. - art. L241-8 (VD)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CITATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000038433476", "@num": "L242-2", "#text": "Code de la construction et de l'habitation. - art. L242-2 (VD)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CITATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000046680556", "@num": "R172-1", "#text": "Code de la construction et de l'habitation. - art. R172-1 (V)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CITATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000039041691", "@num": "R232-3", "#text": "Code de la construction et de l'habitation. - art. R232-3 (VD)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CITATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000039041682", "@num": "R232-5", "#text": "Code de la construction et de l'habitation. - art. R232-5 (VD)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CITATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000039041673", "@num": "R232-7", "#text": "Code de la construction et de l'habitation. - art. R232-7 (VD)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CITATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000033655931", "@num": "D313-26", "#text": "Code monétaire et financier - art. D313-26 (VD)", "@sens": "cible", "@cidtexte": "LEGITEXT000006072026", "@typelien": "CITATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" } ] }, "CONTEXTE": { "TEXTE": { "TM": { "TM": { "TM": { "TM": { "TITRE_TM": [ { "@id": "LEGISCTA000006159021", "@fin": "2999-01-01", "#text": "Chapitre II : Contrat de construction d'une maison individuelle sans fourniture du plan.", "@debut": "1991-12-01" } ] }, "TITRE_TM": [ { "@id": "LEGISCTA000006143526", "@fin": "2999-01-01", "#text": "Titre III : Construction d'une maison individuelle.", "@debut": "1991-12-01" } ] }, "TITRE_TM": [ { "@id": "LEGISCTA000006128681", "@fin": "2999-01-01", "#text": "Livre II : Statut des constructeurs.", "@debut": "1978-06-08" } ] }, "TITRE_TM": [ { "@id": "LEGISCTA000006108136", "@fin": "2999-01-01", "#text": "Partie législative", "@debut": "1978-06-08" } ] }, "@cid": "LEGITEXT000006074096", "@nature": "CODE", "TITRE_TXT": [ { "@fin": "2999-01-01", "#text": "Code de la construction et de l'habitation", "@debut": "1977-03-10", "@id_txt": "LEGITEXT000006074096", "@c_titre_court": "Code de la construction et de l'habitation." } ], "@date_publi": "2999-01-01", "@date_signature": "2999-01-01" } }, "VERSIONS": { "VERSION": [ { "@etat": "MODIFIE", "LIEN_ART": { "@id": "LEGIARTI000006824506", "@fin": "2021-07-01", "@num": "L232-1", "@etat": "MODIFIE", "@debut": "1991-12-01", "@origine": "LEGI" } }, { "@etat": "VIGUEUR", "LIEN_ART": { "@id": "LEGIARTI000041586842", "@fin": "2999-01-01", "@num": "L232-1", "@etat": "VIGUEUR", "@debut": "2021-07-01", "@origine": "LEGI" } } ] }, "BLOC_TEXTUEL": { "CONTENU": "
Le contrat de louage d'ouvrage n'entrant pas dans le champ d'application de l'article L. 231-1 et ayant au moins pour objet l'exécution des travaux de gros oeuvre, de mise hors d'eau et hors d'air d'un immeuble à usage d'habitation ou d'un immeuble à usage professionnel et d'habitation, ne comportant pas plus de deux logements destinés au même maître de l'ouvrage, doit être rédigé par écrit et préciser :
\n
a) La désignation du terrain ;
\n
b) La consistance et les caractéristiques techniques de l'ouvrage à réaliser ;
\n
c) Le prix convenu forfaitaire et définitif, sous réserve, s'il y a lieu, de sa révision dans les conditions et limites convenues, ainsi que les modalités de son règlement au fur et à mesure de l'exécution des travaux ;
\n
d) Le délai d'exécution des travaux et les pénalités applicables en cas de retard de livraison ;
\n
e) La référence de l'assurance de dommages souscrite par le maître de l'ouvrage en application de l'article L. 242-1 du code des assurances ;
\n
f) L'indication que le maître de l'ouvrage pourra se faire assister par un professionnel habilité en application de la loi n° 77-2 du 3 janvier 1977 précitée ou des articles L. 111-23 et suivants lors de la réception ou par tout autre professionnel de la construction titulaire d'un contrat d'assurance couvrant les responsabilités pour ce type de mission ;
\n
g) L'engagement de l'entrepreneur de fournir, au plus tard à la date d'ouverture du chantier, la justification de la garantie de livraison qu'il apporte au maître de l'ouvrage, l'attestation de cette garantie étant établie par le garant et annexée au contrat.
" } } }, "article_lien": [ { "article_id": "LEGIARTI000027645773", "cible": true, "cidtexte": "LEGITEXT000006074096", "id": "LEGIARTI000006824507", "typelien": "CITATION" }, { "article_id": "LEGIARTI000027645777", "cible": true, "cidtexte": "LEGITEXT000006074096", "id": "LEGIARTI000006824507", "typelien": "CITATION" }, { "article_id": "LEGIARTI000006824494", "cible": true, "cidtexte": "LEGITEXT000006074096", "id": "LEGIARTI000006824507", "typelien": "CITATION" }, { "article_id": "LEGIARTI000006824497", "cible": true, "cidtexte": "LEGITEXT000006074096", "id": "LEGIARTI000006824507", "typelien": "CITATION" }, { "article_id": "LEGIARTI000006824499", "cible": true, "cidtexte": "LEGITEXT000006074096", "id": "LEGIARTI000006824507", "typelien": "CITATION" }, { "article_id": "LEGIARTI000006824504", "cible": true, "cidtexte": "LEGITEXT000006074096", "id": "LEGIARTI000006824507", "typelien": "CITATION" }, { "article_id": "LEGIARTI000006824505", "cible": true, "cidtexte": "LEGITEXT000006074096", "id": "LEGIARTI000006824507", "typelien": "CITATION" }, { "article_id": "LEGIARTI000006824659", "cible": true, "cidtexte": "LEGITEXT000006074096", "id": "LEGIARTI000006824507", "typelien": "CITATION" }, { "article_id": "LEGIARTI000006824657", "cible": true, "cidtexte": "LEGITEXT000006074096", "id": "LEGIARTI000006824507", "typelien": "CITATION" }, { "article_id": "LEGIARTI000006824658", "cible": true, "cidtexte": "LEGITEXT000006074096", "id": "LEGIARTI000006824507", "typelien": "CITATION" }, { "article_id": "LEGIARTI000037667723", "cible": true, "cidtexte": "LEGITEXT000006074096", "id": "LEGIARTI000006824507", "typelien": "CITATION" }, { "article_id": "LEGIARTI000038433486", "cible": true, "cidtexte": "LEGITEXT000006074096", "id": "LEGIARTI000006824507", "typelien": "CITATION" }, { "article_id": "LEGIARTI000038433496", "cible": true, "cidtexte": "LEGITEXT000006074096", "id": "LEGIARTI000006824507", "typelien": "CITATION" }, { "article_id": "LEGIARTI000006824496", "cible": true, "cidtexte": "LEGITEXT000006074096", "id": "LEGIARTI000006824507", "typelien": "CITATION" }, { "article_id": "LEGIARTI000041586850", "cible": true, "cidtexte": "LEGITEXT000006074096", "id": "LEGIARTI000006824507", "typelien": "CITATION" }, { "article_id": "LEGIARTI000041586856", "cible": true, "cidtexte": "LEGITEXT000006074096", "id": "LEGIARTI000006824507", "typelien": "CITATION" }, { "article_id": "LEGIARTI000006826206", "cible": true, "cidtexte": "LEGITEXT000006074096", "id": "LEGIARTI000006824507", "typelien": "CREATION" } ], "texte_version": { "JORFTEXT000000516442": { "SM": { "CONTENU": "Application de l'article 2 de la loi n° 72-535 du 30 juin 1972.‎\nAux termes de l’article 1er de la loi n° 83-440 du 2 juin 1983, « La partie législative du code de la ‎construction et de l'habitation a force de loi ». ‎" }, "META": { "META_SPEC": { "META_TEXTE_VERSION": { "LIENS": { "LIEN": [ { "@id": "JORFTEXT000000873125", "#text": "Décret n° 48-290 du 16 février 1948", "@sens": "source", "@cidtexte": "JORFTEXT000000873125", "@numtexte": "48-290", "@typelien": "MODIFIE", "@naturetexte": "DECRET", "@datesignatexte": "1948-02-16" }, { "@id": "JORFTEXT000000850930", "#text": "Décret n°50-834 du 11 juillet 1950", "@sens": "source", "@cidtexte": "JORFTEXT000000850930", "@numtexte": "50-834", "@typelien": "MODIFIE", "@naturetexte": "DECRET", "@datesignatexte": "1950-07-11" }, { "@id": "JORFTEXT000000886659", "#text": "Loi n°51-1372 du 1 décembre 1951", "@sens": "source", "@cidtexte": "JORFTEXT000000886659", "@numtexte": "51-1372", "@typelien": "MODIFIE", "@naturetexte": "LOI", "@datesignatexte": "1951-12-01" }, { "@id": "JORFTEXT000000313744", "#text": "Loi n° 53-46 du 3 février 1953", "@sens": "source", "@cidtexte": "JORFTEXT000000313744", "@numtexte": "53-46", "@typelien": "MODIFIE", "@naturetexte": "LOI", "@datesignatexte": "1953-02-03" }, { "@id": "JORFTEXT000000874918", "#text": "Loi n°53-75 du 6 février 1953", "@sens": "source", "@cidtexte": "JORFTEXT000000874918", "@numtexte": "53-75", "@typelien": "MODIFIE", "@naturetexte": "LOI", "@datesignatexte": "1953-02-06" }, { "@id": "JORFTEXT000000874906", "#text": "Loi n°53-592 du 27 juin 1953", "@sens": "source", "@cidtexte": "JORFTEXT000000874906", "@numtexte": "53-592", "@typelien": "MODIFIE", "@naturetexte": "LOI", "@datesignatexte": "1953-06-27" }, { "@id": "JORFTEXT000000847752", "#text": "Décret n°53-849 du 18 septembre 1953", "@sens": "source", "@cidtexte": "JORFTEXT000000847752", "@numtexte": "53-849", "@typelien": "MODIFIE", "@naturetexte": "DECRET", "@datesignatexte": "1953-09-18" }, { "@id": "JORFTEXT000000299486", "#text": "Décret n°53-958 du 30 septembre 1953", "@sens": "source", "@cidtexte": "JORFTEXT000000299486", "@numtexte": "53-958", "@typelien": "MODIFIE", "@naturetexte": "DECRET", "@datesignatexte": "1953-09-30" }, { "@id": "JORFTEXT000000847998", "#text": "Décret n°53-982 du 30 septembre 1953", "@sens": "source", "@cidtexte": "JORFTEXT000000847998", "@numtexte": "53-982", "@typelien": "MODIFIE", "@naturetexte": "DECRET", "@datesignatexte": "1953-09-30" }, { "@id": "JORFTEXT000000314405", "#text": "Loi n°54-364 du 2 avril 1954", "@sens": "source", "@cidtexte": "JORFTEXT000000314405", "@numtexte": "54-364", "@typelien": "MODIFIE", "@naturetexte": "LOI", "@datesignatexte": "1954-04-02" }, { "@id": "JORFTEXT000000312511", "#text": "Loi n°54-726 du 15 juillet 1954", "@sens": "source", "@cidtexte": "JORFTEXT000000312511", "@numtexte": "54-726", "@typelien": "MODIFIE", "@naturetexte": "LOI", "@datesignatexte": "1954-07-15" }, { "@id": "JORFTEXT000000503700", "#text": "Loi n° 55-1044 du 6 août 1955", "@sens": "source", "@cidtexte": "JORFTEXT000000503700", "@numtexte": "55-1044", "@typelien": "MODIFIE", "@naturetexte": "LOI", "@datesignatexte": "1955-08-06" }, { "@id": "JORFTEXT000000880566", "#text": "Loi n°56-588 du 18 juin 1956", "@sens": "source", "@cidtexte": "JORFTEXT000000880566", "@numtexte": "56-588", "@typelien": "ABROGE", "@naturetexte": "LOI", "@datesignatexte": "1956-06-18" }, { "@id": "JORFTEXT000000504678", "#text": "Loi n° 56-765 du 3 août 1956", "@sens": "source", "@cidtexte": "JORFTEXT000000504678", "@numtexte": "56-765", "@typelien": "MODIFIE", "@naturetexte": "LOI", "@datesignatexte": "1956-08-03" }, { "@id": "JORFTEXT000000691962", "#text": "Loi n°56-1223 du 3 décembre 1956", "@sens": "source", "@cidtexte": "JORFTEXT000000691962", "@numtexte": "56-1223", "@typelien": "MODIFIE", "@naturetexte": "LOI", "@datesignatexte": "1956-12-03" }, { "@id": "JORFTEXT000000869701", "#text": "Décret n°57-757 du 5 juillet 1957", "@sens": "source", "@cidtexte": "JORFTEXT000000869701", "@numtexte": "57-757", "@typelien": "MODIFIE", "@naturetexte": "DECRET", "@datesignatexte": "1957-07-05" }, { "@id": "JORFTEXT000000315837", "#text": "LOI n° 57-908 du 7 août 1957", "@sens": "source", "@cidtexte": "JORFTEXT000000315837", "@numtexte": "57-908", "@typelien": "MODIFIE", "@naturetexte": "LOI", "@datesignatexte": "1957-08-07" }, { "@id": "JORFTEXT000000501612", "#text": "Loi n°58-336 du 29 mars 1958", "@sens": "source", "@cidtexte": "JORFTEXT000000501612", "@numtexte": "58-336", "@typelien": "MODIFIE", "@naturetexte": "LOI", "@datesignatexte": "1958-03-29" }, { "@id": "JORFTEXT000000314224", "#text": "Décret n°58-713 du 9 août 1958", "@sens": "source", "@cidtexte": "JORFTEXT000000314224", "@numtexte": "58-713", "@typelien": "MODIFIE", "@naturetexte": "DECRET", "@datesignatexte": "1958-08-09" }, { "@id": "JORFTEXT000000339372", "#text": "Ordonnance n°58-886 du 25 septembre 1958", "@sens": "source", "@cidtexte": "JORFTEXT000000339372", "@numtexte": "58-886", "@typelien": "MODIFIE", "@naturetexte": "ORDONNANCE", "@datesignatexte": "1958-09-25" }, { "@id": "JORFTEXT000000339269", "#text": "Ordonnance n°58-1341 du 27 décembre 1958", "@sens": "source", "@cidtexte": "JORFTEXT000000339269", "@numtexte": "58-1341", "@typelien": "MODIFIE", "@naturetexte": "ORDONNANCE", "@datesignatexte": "1958-12-27" }, { "@id": "JORFTEXT000000516477", "#text": "Ordonnance n° 58-1440 du 31 décembre 1958", "@sens": "source", "@cidtexte": "JORFTEXT000000516477", "@numtexte": "58-1440", "@typelien": "MODIFIE", "@naturetexte": "ORDONNANCE", "@datesignatexte": "1958-12-31" }, { "@id": "JORFTEXT000000517180", "#text": "Ordonnance n°58-1442 du 31 décembre 1958", "@sens": "source", "@cidtexte": "JORFTEXT000000517180", "@numtexte": "58-1442", "@typelien": "MODIFIE", "@naturetexte": "ORDONNANCE", "@datesignatexte": "1958-12-31" }, { "@id": "JORFTEXT000000886690", "#text": "Ordonnance n°58-1441 du 31 décembre 1958", "@sens": "source", "@cidtexte": "JORFTEXT000000886690", "@numtexte": "58-1441", "@typelien": "MODIFIE", "@naturetexte": "ORDONNANCE", "@datesignatexte": "1958-12-31" }, { "@id": "JORFTEXT000000886692", "#text": "Ordonnance n°58-1451 du 31 décembre 1958", "@sens": "source", "@cidtexte": "JORFTEXT000000886692", "@numtexte": "58-1451", "@typelien": "MODIFIE", "@naturetexte": "ORDONNANCE", "@datesignatexte": "1958-12-31" }, { "@id": "JORFTEXT000000693941", "#text": "Ordonnance n°59-235 du 4 février 1959", "@sens": "source", "@cidtexte": "JORFTEXT000000693941", "@numtexte": "59-235", "@typelien": "MODIFIE", "@naturetexte": "ORDONNANCE", "@datesignatexte": "1959-02-04" }, { "@id": "JORFTEXT000000874213", "#text": "Loi n° 59-1454 du 26 décembre 1959", "@sens": "source", "@cidtexte": "JORFTEXT000000874213", "@numtexte": "59-1454", "@typelien": "MODIFIE", "@naturetexte": "LOI", "@datesignatexte": "1959-12-26" }, { "@id": "JORFTEXT000000313955", "#text": "Loi n°60-731 du 28 juillet 1960", "@sens": "source", "@cidtexte": "JORFTEXT000000313955", "@numtexte": "60-731", "@typelien": "MODIFIE", "@naturetexte": "LOI", "@datesignatexte": "1960-07-28" }, { "@id": "JORFTEXT000000314675", "#text": "Loi n°60-1369 du 21 décembre 1960", "@sens": "source", "@cidtexte": "JORFTEXT000000314675", "@numtexte": "60-1369", "@typelien": "MODIFIE", "@naturetexte": "LOI", "@datesignatexte": "1960-12-21" }, { "@id": "JORFTEXT000000313949", "#text": "Loi n°60-1384 du 23 décembre 1960", "@sens": "source", "@cidtexte": "JORFTEXT000000313949", "@numtexte": "60-1384", "@typelien": "MODIFIE", "@naturetexte": "LOI", "@datesignatexte": "1960-12-23" }, { "@id": "JORFTEXT000000313964", "#text": "Loi n°62-790 du 13 juillet 1962", "@sens": "source", "@cidtexte": "JORFTEXT000000313964", "@numtexte": "62-790", "@typelien": "MODIFIE", "@naturetexte": "LOI", "@datesignatexte": "1962-07-13" }, { "@id": "JORFTEXT000000684498", "#text": "Loi n°62-902 du 4 août 1962", "@sens": "source", "@cidtexte": "JORFTEXT000000684498", "@numtexte": "62-902", "@typelien": "MODIFIE", "@naturetexte": "LOI", "@datesignatexte": "1962-08-04" }, { "@id": "JORFTEXT000000865043", "#text": "Loi n°63-613 du 28 juin 1963", "@sens": "source", "@cidtexte": "JORFTEXT000000865043", "@numtexte": "63-613", "@typelien": "MODIFIE", "@naturetexte": "LOI", "@datesignatexte": "1963-06-28" }, { "@id": "JORFTEXT000000691709", "#text": "Loi n°64-688 du 8 juillet 1964", "@sens": "source", "@cidtexte": "JORFTEXT000000691709", "@numtexte": "64-688", "@typelien": "MODIFIE", "@naturetexte": "LOI", "@datesignatexte": "1964-07-08" }, { "@id": "JORFTEXT000000509982", "#text": "Loi n°64-1247 du 16 décembre 1964", "@sens": "source", "@cidtexte": "JORFTEXT000000509982", "@numtexte": "64-1247", "@typelien": "MODIFIE", "@naturetexte": "LOI", "@datesignatexte": "1964-12-16" }, { "@id": "JORFTEXT000000684760", "#text": "Loi n° 64-1278 du 23 décembre 1964", "@sens": "source", "@cidtexte": "JORFTEXT000000684760", "@numtexte": "64-1278", "@typelien": "MODIFIE", "@naturetexte": "LOI", "@datesignatexte": "1964-12-23" }, { "@id": "JORFTEXT000000320406", "#text": "Loi n°65-554 du 10 juillet 1965", "@sens": "source", "@cidtexte": "JORFTEXT000000320406", "@numtexte": "65-554", "@typelien": "MODIFIE", "@naturetexte": "LOI", "@datesignatexte": "1965-07-10" }, { "@id": "JORFTEXT000000320408", "#text": "Loi n° 65-556 du 10 juillet 1965", "@sens": "source", "@cidtexte": "JORFTEXT000000320408", "@numtexte": "65-556", "@typelien": "MODIFIE", "@naturetexte": "LOI", "@datesignatexte": "1965-07-10" }, { "@id": "JORFTEXT000000320413", "#text": "Loi n°66-10 du 6 janvier 1966", "@sens": "source", "@cidtexte": "JORFTEXT000000320413", "@numtexte": "66-10", "@typelien": "MODIFIE", "@naturetexte": "LOI", "@datesignatexte": "1966-01-06" }, { "@id": "JORFTEXT000000337941", "#text": "Décret n°66-406 du 15 juin 1966", "@sens": "source", "@cidtexte": "JORFTEXT000000337941", "@numtexte": "66-406", "@typelien": "MODIFIE", "@naturetexte": "DECRET", "@datesignatexte": "1966-06-15" }, { "@id": "JORFTEXT000000504213", "#text": "Loi n°66-473 du 5 juillet 1966", "@sens": "source", "@cidtexte": "JORFTEXT000000504213", "@numtexte": "66-473", "@typelien": "MODIFIE", "@naturetexte": "LOI", "@datesignatexte": "1966-07-05" }, { "@id": "JORFTEXT000000880760", "#text": "Loi n°67-3 du 3 janvier 1967", "@sens": "source", "@cidtexte": "JORFTEXT000000880760", "@numtexte": "67-3", "@typelien": "MODIFIE", "@naturetexte": "LOI", "@datesignatexte": "1967-01-03" }, { "@id": "JORFTEXT000000692714", "#text": "Loi n°67-547 du 7 juillet 1967", "@sens": "source", "@cidtexte": "JORFTEXT000000692714", "@numtexte": "67-547", "@typelien": "MODIFIE", "@naturetexte": "LOI", "@datesignatexte": "1967-07-07" }, { "@id": "JORFTEXT000000878012", "#text": "Loi n°67-1172 du 22 décembre 1967", "@sens": "source", "@cidtexte": "JORFTEXT000000878012", "@numtexte": "67-1172", "@typelien": "MODIFIE", "@naturetexte": "LOI", "@datesignatexte": "1967-12-22" }, { "@id": "JORFTEXT000000501076", "#text": "LOI n° 67-1253 du 30 décembre 1967", "@sens": "source", "@cidtexte": "JORFTEXT000000501076", "@numtexte": "67-1253", "@typelien": "MODIFIE", "@naturetexte": "LOI", "@datesignatexte": "1967-12-30" }, { "@id": "JORFTEXT000000317516", "#text": "Loi n°68-696 du 31 juillet 1968", "@sens": "source", "@cidtexte": "JORFTEXT000000317516", "@numtexte": "68-696", "@typelien": "MODIFIE", "@naturetexte": "LOI", "@datesignatexte": "1968-07-31" }, { "@id": "JORFTEXT000000511690", "#text": "Loi n°69-2 du 3 janvier 1969", "@sens": "source", "@cidtexte": "JORFTEXT000000511690", "@numtexte": "69-2", "@typelien": "MODIFIE", "@naturetexte": "LOI", "@datesignatexte": "1969-01-03" }, { "@id": "JORFTEXT000000693422", "#text": "Loi n°69-9 du 3 janvier 1969", "@sens": "source", "@cidtexte": "JORFTEXT000000693422", "@numtexte": "69-9", "@typelien": "MODIFIE", "@naturetexte": "LOI", "@datesignatexte": "1969-01-03" }, { "@id": "JORFTEXT000000521285", "#text": "Loi n°69-1161 du 24 décembre 1969", "@sens": "source", "@cidtexte": "JORFTEXT000000521285", "@numtexte": "69-1161", "@typelien": "MODIFIE", "@naturetexte": "LOI", "@datesignatexte": "1969-12-24" }, { "@id": "JORFTEXT000000512440", "#text": "Loi n°70-576 du 3 juillet 1970", "@sens": "source", "@cidtexte": "JORFTEXT000000512440", "@numtexte": "70-576", "@typelien": "MODIFIE", "@naturetexte": "LOI", "@datesignatexte": "1970-07-03" }, { "@id": "JORFTEXT000000321623", "#text": "Loi n°70-599 du 9 juillet 1970", "@sens": "source", "@cidtexte": "JORFTEXT000000321623", "@numtexte": "70-599", "@typelien": "MODIFIE", "@naturetexte": "LOI", "@datesignatexte": "1970-07-09" }, { "@id": "JORFTEXT000000693669", "#text": "Loi n° 70-612 du 10 juillet 1970", "@sens": "source", "@cidtexte": "JORFTEXT000000693669", "@numtexte": "70-612", "@typelien": "MODIFIE", "@naturetexte": "LOI", "@datesignatexte": "1970-07-10" }, { "@id": "JORFTEXT000000874226", "#text": "LOI n° 70-1283 du 31 décembre 1970", "@sens": "source", "@cidtexte": "JORFTEXT000000874226", "@numtexte": "70-1283", "@typelien": "MODIFIE", "@naturetexte": "LOI", "@datesignatexte": "1970-12-31" }, { "@id": "JORFTEXT000000322079", "#text": "Loi n°71-580 du 16 juillet 1971", "@sens": "source", "@cidtexte": "JORFTEXT000000322079", "@numtexte": "71-580", "@typelien": "MODIFIE", "@naturetexte": "LOI", "@datesignatexte": "1971-07-16" }, { "@id": "JORFTEXT000000687668", "#text": "Loi n°71-579 du 16 juillet 1971", "@sens": "source", "@cidtexte": "JORFTEXT000000687668", "@numtexte": "71-579", "@typelien": "MODIFIE", "@naturetexte": "LOI", "@datesignatexte": "1971-07-16" }, { "@id": "JORFTEXT000000875174", "#text": "Loi n° 71-582 du 16 juillet 1971", "@sens": "source", "@cidtexte": "JORFTEXT000000875174", "@numtexte": "71-582", "@typelien": "MODIFIE", "@naturetexte": "LOI", "@datesignatexte": "1971-07-16" }, { "@id": "JORFTEXT000000864826", "#text": "LOI n° 72-535 du 30 juin 1972", "@sens": "source", "@cidtexte": "JORFTEXT000000864826", "@numtexte": "72-535", "@typelien": "APPLICATION", "@naturetexte": "LOI", "@datesignatexte": "1972-06-30" }, { "@id": "JORFTEXT000000864837", "#text": "Loi n°72-649 du 11 juillet 1972", "@sens": "source", "@cidtexte": "JORFTEXT000000864837", "@numtexte": "72-649", "@typelien": "MODIFIE", "@naturetexte": "LOI", "@datesignatexte": "1972-07-11" }, { "@id": "JORFTEXT000000322512", "#text": "Loi n°73-627 du 10 juillet 1973", "@sens": "source", "@cidtexte": "JORFTEXT000000322512", "@numtexte": "73-627", "@typelien": "MODIFIE", "@naturetexte": "LOI", "@datesignatexte": "1973-07-10" }, { "@id": "JORFTEXT000000888776", "#text": "LOI n° 74-908 du 29 octobre 1974", "@sens": "source", "@cidtexte": "JORFTEXT000000888776", "@numtexte": "74-908", "@typelien": "MODIFIE", "@naturetexte": "LOI", "@datesignatexte": "1974-10-29" }, { "@id": "LEGIARTI000006272936", "@num": "60", "#text": "Loi n°74-1129 du 30 décembre 1974 - art. 60 (V)", "@sens": "cible", "@cidtexte": "JORFTEXT000000889172", "@numtexte": "74-1129", "@typelien": "MODIFICATION", "@naturetexte": "LOI", "@datesignatexte": "1974-12-30" }, { "@id": "JORFTEXT000000889172", "#text": "Loi n°74-1129 du 30 décembre 1974", "@sens": "source", "@cidtexte": "JORFTEXT000000889172", "@numtexte": "74-1129", "@typelien": "MODIFIE", "@naturetexte": "LOI", "@datesignatexte": "1974-12-30" }, { "@id": "JORFTEXT000000333976", "#text": "Loi n°75-534 du 30 juin 1975", "@sens": "source", "@cidtexte": "JORFTEXT000000333976", "@numtexte": "75-534", "@typelien": "MODIFIE", "@naturetexte": "LOI", "@datesignatexte": "1975-06-30" }, { "@id": "JORFTEXT000000333764", "#text": "Loi n°75-1255 du 27 décembre 1975", "@sens": "source", "@cidtexte": "JORFTEXT000000333764", "@numtexte": "75-1255", "@typelien": "MODIFIE", "@naturetexte": "LOI", "@datesignatexte": "1975-12-27" }, { "@id": "JORFTEXT000000699207", "#text": "Loi n°75-1328 du 31 décembre 1975", "@sens": "source", "@cidtexte": "JORFTEXT000000699207", "@numtexte": "75-1328", "@typelien": "MODIFIE", "@naturetexte": "LOI", "@datesignatexte": "1975-12-31" }, { "@id": "JORFTEXT000000889243", "#text": "Loi n°75-1351 du 31 décembre 1975", "@sens": "source", "@cidtexte": "JORFTEXT000000889243", "@numtexte": "75-1351", "@typelien": "MODIFIE", "@naturetexte": "LOI", "@datesignatexte": "1975-12-31" }, { "@id": "JORFTEXT000000522254", "#text": "Loi n°76-1232 du 29 décembre 1976", "@sens": "source", "@cidtexte": "JORFTEXT000000522254", "@numtexte": "76-1232", "@typelien": "MODIFIE", "@naturetexte": "LOI", "@datesignatexte": "1976-12-29" }, { "@id": "JORFTEXT000000699570", "#text": "Loi n°76-1285 du 31 décembre 1976", "@sens": "source", "@cidtexte": "JORFTEXT000000699570", "@numtexte": "76-1285", "@typelien": "MODIFIE", "@naturetexte": "LOI", "@datesignatexte": "1976-12-31" }, { "@id": "JORFTEXT000000888376", "#text": "Loi n°77-1 du 3 janvier 1977", "@sens": "source", "@cidtexte": "JORFTEXT000000888376", "@numtexte": "77-1", "@typelien": "MODIFIE", "@naturetexte": "LOI", "@datesignatexte": "1977-01-03" }, { "@id": "JORFTEXT000000704793", "#text": "Loi n°77-804 du 19 juillet 1977", "@sens": "source", "@cidtexte": "JORFTEXT000000704793", "@numtexte": "77-804", "@typelien": "MODIFIE", "@naturetexte": "LOI", "@datesignatexte": "1977-07-19" }, { "@id": "JORFTEXT000000333071", "#text": "Loi n°77-1457 du 29 décembre 1977", "@sens": "source", "@cidtexte": "JORFTEXT000000333071", "@numtexte": "77-1457", "@typelien": "MODIFIE", "@naturetexte": "LOI", "@datesignatexte": "1977-12-29" }, { "@id": "JORFTEXT000000704549", "#text": "LOI n° 77-1467 du 30 décembre 1977", "@sens": "source", "@cidtexte": "JORFTEXT000000704549", "@numtexte": "77-1467", "@typelien": "MODIFIE", "@naturetexte": "LOI", "@datesignatexte": "1977-12-30" }, { "@id": "JORFTEXT000000887507", "#text": "Loi n°77-1466 du 30 décembre 1977", "@sens": "source", "@cidtexte": "JORFTEXT000000887507", "@numtexte": "77-1466", "@typelien": "MODIFIE", "@naturetexte": "LOI", "@datesignatexte": "1977-12-30" }, { "@id": "JORFTEXT000000522720", "#text": "Loi n°78-12 du 4 janvier 1978", "@sens": "source", "@cidtexte": "JORFTEXT000000522720", "@numtexte": "78-12", "@typelien": "MODIFIE", "@naturetexte": "LOI", "@datesignatexte": "1978-01-04" }, { "@id": "JORFTEXT000000885342", "#text": "Décret n°84-593 du 9 juillet 1984", "@sens": "cible", "@cidtexte": "JORFTEXT000000885342", "@numtexte": "84-593", "@typelien": "MODIFIE", "@naturetexte": "DECRET", "@datesignatexte": "1984-07-09" }, { "@id": "JORFARTI000038342231", "@num": "2", "#text": "Décision n°2019-772 QPC du 5 avril 2019 - art. 2, v. init.", "@sens": "cible", "@cidtexte": "JORFTEXT000038342206", "@nortexte": "CSCX1910185S", "@numtexte": "2019-772 QPC", "@typelien": "CITATION", "@naturetexte": "DECISION", "@datesignatexte": "2019-04-05" }, { "@id": "JORFARTI000038342207", "#text": "Décision n°2019-772 QPC du 5 avril 2019 - art., v. init.", "@sens": "cible", "@cidtexte": "JORFTEXT000038342206", "@nortexte": "CSCX1910185S", "@numtexte": "2019-772 QPC", "@typelien": "CITATION", "@naturetexte": "DECISION", "@datesignatexte": "2019-04-05" }, { "@id": "LEGIARTI000006312839", "@num": "1723 decies", "#text": "CODE GENERAL DES IMPOTS, CGI. - art. 1723 decies (M)", "@sens": "cible", "@cidtexte": "LEGITEXT000006069577", "@typelien": "MODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000006824100", "@num": "L111-1", "#text": "Code de la construction et de l'habitation. - art. L111-1 (M)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000006824101", "@num": "L111-1", "#text": "Code de la construction et de l'habitation. - art. L111-1 (M)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000041587679", "@num": "L111-1", "#text": "Code de la construction et de l'habitation. - art. L111-1 (M)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000043976954", "@num": "L111-1", "#text": "Code de la construction et de l'habitation. - art. L111-1 (V)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000006824102", "@num": "L111-1", "#text": "Code de la construction et de l'habitation. - art. L111-1 (VT)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000006824151", "@num": "L111-10", "#text": "Code de la construction et de l'habitation. - art. L111-10 (M)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000006824152", "@num": "L111-10", "#text": "Code de la construction et de l'habitation. - art. L111-10 (V)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000006824153", "@num": "L111-10-1", "#text": "Code de la construction et de l'habitation. - art. L111-10-1 (V)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000006824154", "@num": "L111-11", "#text": "Code de la construction et de l'habitation. - art. L111-11 (M)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000006824155", "@num": "L111-11", "#text": "Code de la construction et de l'habitation. - art. L111-11 (V)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000006824156", "@num": "L111-11-1", "#text": "Code de la construction et de l'habitation. - art. L111-11-1 (V)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000006824157", "@num": "L111-11-2", "#text": "Code de la construction et de l'habitation. - art. L111-11-2 (V)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000006824158", "@num": "L111-12", "#text": "Code de la construction et de l'habitation. - art. L111-12 (V)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000006824159", "@num": "L111-13", "#text": "Code de la construction et de l'habitation. - art. L111-13 (V)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000006824160", "@num": "L111-14", "#text": "Code de la construction et de l'habitation. - art. L111-14 (V)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000006824161", "@num": "L111-15", "#text": "Code de la construction et de l'habitation. - art. L111-15 (M)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000006824162", "@num": "L111-15", "#text": "Code de la construction et de l'habitation. - art. L111-15 (V)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000006824163", "@num": "L111-16", "#text": "Code de la construction et de l'habitation. - art. L111-16 (M)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000006824164", "@num": "L111-16", "#text": "Code de la construction et de l'habitation. - art. L111-16 (V)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000006824165", "@num": "L111-17", "#text": "Code de la construction et de l'habitation. - art. L111-17 (V)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000039382301", "@num": "L111-17", "#text": "Code de la construction et de l'habitation. - art. L111-17 (VD)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000006824166", "@num": "L111-18", "#text": "Code de la construction et de l'habitation. - art. L111-18 (V)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CREATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000006824166", "@num": "L111-18", "#text": "Code de la construction et de l'habitation. - art. L111-18 (V)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000006824167", "@num": "L111-19", "#text": "Code de la construction et de l'habitation. - art. L111-19 (V)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000006824168", "@num": "L111-19-1", "#text": "Code de la construction et de l'habitation. - art. L111-19-1 (V)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000006824103", "@num": "L111-2", "#text": "Code de la construction et de l'habitation. - art. L111-2 (V)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000006824169", "@num": "L111-20", "#text": "Code de la construction et de l'habitation. - art. L111-20 (V)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000006824170", "@num": "L111-21", "#text": "Code de la construction et de l'habitation. - art. L111-21 (V)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000006824171", "@num": "L111-22", "#text": "Code de la construction et de l'habitation. - art. L111-22 (V)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000006824172", "@num": "L111-23", "#text": "Code de la construction et de l'habitation. - art. L111-23 (M)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000006824173", "@num": "L111-23", "#text": "Code de la construction et de l'habitation. - art. L111-23 (V)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000006824174", "@num": "L111-24", "#text": "Code de la construction et de l'habitation. - art. L111-24 (M)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000006824175", "@num": "L111-24", "#text": "Code de la construction et de l'habitation. - art. L111-24 (V)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000006824176", "@num": "L111-25", "#text": "Code de la construction et de l'habitation. - art. L111-25 (V)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000006824178", "@num": "L111-26", "#text": "Code de la construction et de l'habitation. - art. L111-26 (M)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000006824177", "@num": "L111-26", "#text": "Code de la construction et de l'habitation. - art. L111-26 (M)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000006824179", "@num": "L111-26", "#text": "Code de la construction et de l'habitation. - art. L111-26 (M)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000006824180", "@num": "L111-26", "#text": "Code de la construction et de l'habitation. - art. L111-26 (V)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000006824181", "@num": "L111-27", "#text": "Code de la construction et de l'habitation. - art. L111-27 (M)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000006824182", "@num": "L111-27", "#text": "Code de la construction et de l'habitation. - art. L111-27 (V)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000006824183", "@num": "L111-28", "#text": "Code de la construction et de l'habitation. - art. L111-28 (M)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000006824184", "@num": "L111-28", "#text": "Code de la construction et de l'habitation. - art. L111-28 (V)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000006824185", "@num": "L111-29", "#text": "Code de la construction et de l'habitation. - art. L111-29 (M)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000006824186", "@num": "L111-29", "#text": "Code de la construction et de l'habitation. - art. L111-29 (V)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000006824104", "@num": "L111-3", "#text": "Code de la construction et de l'habitation. - art. L111-3 (M)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000006824105", "@num": "L111-3", "#text": "Code de la construction et de l'habitation. - art. L111-3 (V)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000031219899", "@num": "L111-3", "#text": "Code de la construction et de l'habitation. - art. L111-3 (VD)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000006824188", "@num": "L111-30", "#text": "Code de la construction et de l'habitation. - art. L111-30 (M)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000006824189", "@num": "L111-30", "#text": "Code de la construction et de l'habitation. - art. L111-30 (V)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000006824190", "@num": "L111-31", "#text": "Code de la construction et de l'habitation. - art. L111-31 (M)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000006824191", "@num": "L111-31", "#text": "Code de la construction et de l'habitation. - art. L111-31 (V)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000006824192", "@num": "L111-32", "#text": "Code de la construction et de l'habitation. - art. L111-32 (M)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000006824193", "@num": "L111-32", "#text": "Code de la construction et de l'habitation. - art. L111-32 (V)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000006824207", "@num": "L111-32-1", "#text": "Code de la construction et de l'habitation. - art. L111-32-1 (V)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000006824194", "@num": "L111-33", "#text": "Code de la construction et de l'habitation. - art. L111-33 (M)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000006824195", "@num": "L111-33", "#text": "Code de la construction et de l'habitation. - art. L111-33 (V)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000006824209", "@num": "L111-34", "#text": "Code de la construction et de l'habitation. - art. L111-34 (M)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000006824210", "@num": "L111-34", "#text": "Code de la construction et de l'habitation. - art. L111-34 (M)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000006824208", "@num": "L111-34", "#text": "Code de la construction et de l'habitation. - art. L111-34 (M)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000006824211", "@num": "L111-34", "#text": "Code de la construction et de l'habitation. - art. L111-34 (V)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000006824196", "@num": "L111-35", "#text": "Code de la construction et de l'habitation. - art. L111-35 (M)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000006824197", "@num": "L111-35", "#text": "Code de la construction et de l'habitation. - art. L111-35 (V)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000006824198", "@num": "L111-36", "#text": "Code de la construction et de l'habitation. - art. L111-36 (M)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000006824199", "@num": "L111-36", "#text": "Code de la construction et de l'habitation. - art. L111-36 (V)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000006824200", "@num": "L111-37", "#text": "Code de la construction et de l'habitation. - art. L111-37 (M)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000006824201", "@num": "L111-37", "#text": "Code de la construction et de l'habitation. - art. L111-37 (V)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000006824202", "@num": "L111-38", "#text": "Code de la construction et de l'habitation. - art. L111-38 (M)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CREATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000006824202", "@num": "L111-38", "#text": "Code de la construction et de l'habitation. - art. L111-38 (M)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000006824203", "@num": "L111-38", "#text": "Code de la construction et de l'habitation. - art. L111-38 (V)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000006824205", "@num": "L111-39", "#text": "Code de la construction et de l'habitation. - art. L111-39 (M)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000006824206", "@num": "L111-39", "#text": "Code de la construction et de l'habitation. - art. L111-39 (V)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000006824106", "@num": "L111-4", "#text": "Code de la construction et de l'habitation. - art. L111-4 (M)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000006824107", "@num": "L111-4", "#text": "Code de la construction et de l'habitation. - art. L111-4 (M)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000037671221", "@num": "L111-4", "#text": "Code de la construction et de l'habitation. - art. L111-4 (V)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000006824212", "@num": "L111-40", "#text": "Code de la construction et de l'habitation. - art. L111-40 (V)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000006824213", "@num": "L111-41", "#text": "Code de la construction et de l'habitation. - art. L111-41 (V)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000006824108", "@num": "L111-5", "#text": "Code de la construction et de l'habitation. - art. L111-5 (M)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000006824109", "@num": "L111-5", "#text": "Code de la construction et de l'habitation. - art. L111-5 (V)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000006824117", "@num": "L111-5-1", "#text": "Code de la construction et de l'habitation. - art. L111-5-1 (V)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000006824110", "@num": "L111-6", "#text": "Code de la construction et de l'habitation. - art. L111-6 (M)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000006824111", "@num": "L111-6", "#text": "Code de la construction et de l'habitation. - art. L111-6 (V)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000006824115", "@num": "L111-6-1", "#text": "Code de la construction et de l'habitation. - art. L111-6-1 (M)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000006824113", "@num": "L111-6-1", "#text": "Code de la construction et de l'habitation. - art. L111-6-1 (M)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000006824114", "@num": "L111-6-1", "#text": "Code de la construction et de l'habitation. - art. L111-6-1 (M)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000006824116", "@num": "L111-6-1", "#text": "Code de la construction et de l'habitation. - art. L111-6-1 (V)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000006824118", "@num": "L111-6-2", "#text": "Code de la construction et de l'habitation. - art. L111-6-2 (Ab)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000006824119", "@num": "L111-6-2-1", "#text": "Code de la construction et de l'habitation. - art. L111-6-2-1 (V)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000006824120", "@num": "L111-6-2-2", "#text": "Code de la construction et de l'habitation. - art. L111-6-2-2 (V)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000006824121", "@num": "L111-6-2-3", "#text": "Code de la construction et de l'habitation. - art. L111-6-2-3 (V)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000006824122", "@num": "L111-6-3", "#text": "Code de la construction et de l'habitation. - art. L111-6-3 (V)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000006824124", "@num": "L111-7", "#text": "Code de la construction et de l'habitation. - art. L111-7 (M)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000006824125", "@num": "L111-7", "#text": "Code de la construction et de l'habitation. - art. L111-7 (M)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000006824126", "@num": "L111-7", "#text": "Code de la construction et de l'habitation. - art. L111-7 (M)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000006824123", "@num": "L111-7", "#text": "Code de la construction et de l'habitation. - art. L111-7 (MMN)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000029522088", "@num": "L111-7", "#text": "Code de la construction et de l'habitation. - art. L111-7 (V)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000006824131", "@num": "L111-7-1", "#text": "Code de la construction et de l'habitation. - art. L111-7-1 (M)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000033974444", "@num": "L111-7-1", "#text": "Code de la construction et de l'habitation. - art. L111-7-1 (M)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000006824132", "@num": "L111-7-1", "#text": "Code de la construction et de l'habitation. - art. L111-7-1 (V)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000024423355", "@num": "L111-7-1", "#text": "Code de la construction et de l'habitation. - art. L111-7-1 (V)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000037667688", "@num": "L111-7-1", "#text": "Code de la construction et de l'habitation. - art. L111-7-1 (V)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000029522068", "@num": "L111-7-1", "#text": "Code de la construction et de l'habitation. - art. L111-7-1 (VD)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000006824133", "@num": "L111-7-2", "#text": "Code de la construction et de l'habitation. - art. L111-7-2 (M)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000006824134", "@num": "L111-7-2", "#text": "Code de la construction et de l'habitation. - art. L111-7-2 (V)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000006824135", "@num": "L111-7-3", "#text": "Code de la construction et de l'habitation. - art. L111-7-3 (M)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000006824136", "@num": "L111-7-3", "#text": "Code de la construction et de l'habitation. - art. L111-7-3 (M)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000029522076", "@num": "L111-7-3", "#text": "Code de la construction et de l'habitation. - art. L111-7-3 (M)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000030978438", "@num": "L111-7-3", "#text": "Code de la construction et de l'habitation. - art. L111-7-3 (V)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000006824137", "@num": "L111-7-4", "#text": "Code de la construction et de l'habitation. - art. L111-7-4 (M)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000006824138", "@num": "L111-7-4", "#text": "Code de la construction et de l'habitation. - art. L111-7-4 (V)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000006824128", "@num": "L111-8", "#text": "Code de la construction et de l'habitation. - art. L111-8 (M)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000006824129", "@num": "L111-8", "#text": "Code de la construction et de l'habitation. - art. L111-8 (M)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000025019451", "@num": "L111-8", "#text": "Code de la construction et de l'habitation. - art. L111-8 (M)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000006824127", "@num": "L111-8", "#text": "Code de la construction et de l'habitation. - art. L111-8 (MMN)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000006824130", "@num": "L111-8", "#text": "Code de la construction et de l'habitation. - art. L111-8 (V)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000037670462", "@num": "L111-8", "#text": "Code de la construction et de l'habitation. - art. L111-8 (V)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000006824140", "@num": "L111-8-1", "#text": "Code de la construction et de l'habitation. - art. L111-8-1 (Ab)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000006824139", "@num": "L111-8-1", "#text": "Code de la construction et de l'habitation. - art. L111-8-1 (M)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000006824142", "@num": "L111-8-2", "#text": "Code de la construction et de l'habitation. - art. L111-8-2 (Ab)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000006824141", "@num": "L111-8-2", "#text": "Code de la construction et de l'habitation. - art. L111-8-2 (M)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000006824143", "@num": "L111-8-3", "#text": "Code de la construction et de l'habitation. - art. L111-8-3 (M)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000006824144", "@num": "L111-8-3", "#text": "Code de la construction et de l'habitation. - art. L111-8-3 (V)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000006824145", "@num": "L111-8-3-1", "#text": "Code de la construction et de l'habitation. - art. L111-8-3-1 (M)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000006824146", "@num": "L111-8-3-1", "#text": "Code de la construction et de l'habitation. - art. L111-8-3-1 (V)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000006824147", "@num": "L111-8-4", "#text": "Code de la construction et de l'habitation. - art. L111-8-4 (M)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000006824148", "@num": "L111-8-4", "#text": "Code de la construction et de l'habitation. - art. L111-8-4 (V)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000025760483", "@num": "L111-8-4", "#text": "Code de la construction et de l'habitation. - art. L111-8-4 (V)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000006824149", "@num": "L111-9", "#text": "Code de la construction et de l'habitation. - art. L111-9 (M)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000006824149", "@num": "L111-9", "#text": "Code de la construction et de l'habitation. - art. L111-9 (M)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CONCORDANCE", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000006824150", "@num": "L111-9", "#text": "Code de la construction et de l'habitation. - art. L111-9 (V)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000006824150", "@num": "L111-9", "#text": "Code de la construction et de l'habitation. - art. L111-9 (V)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CONCORDANCE", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000006824215", "@num": "L112-1", "#text": "Code de la construction et de l'habitation. - art. L112-1 (M)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000041587664", "@num": "L112-1", "#text": "Code de la construction et de l'habitation. - art. L112-1 (V)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000006824216", "@num": "L112-1", "#text": "Code de la construction et de l'habitation. - art. L112-1 (VT)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000041587589", "@num": "L112-10", "#text": "Code de la construction et de l'habitation. - art. L112-10 (V)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000006824228", "@num": "L112-10", "#text": "Code de la construction et de l'habitation. - art. L112-10 (VT)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000041587576", "@num": "L112-11", "#text": "Code de la construction et de l'habitation. - art. L112-11 (M)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000046123657", "@num": "L112-11", "#text": "Code de la construction et de l'habitation. - art. L112-11 (V)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000006824229", "@num": "L112-11", "#text": "Code de la construction et de l'habitation. - art. L112-11 (VT)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000006824231", "@num": "L112-12", "#text": "Code de la construction et de l'habitation. - art. L112-12 (M)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000006824230", "@num": "L112-12", "#text": "Code de la construction et de l'habitation. - art. L112-12 (M)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000006824232", "@num": "L112-12", "#text": "Code de la construction et de l'habitation. - art. L112-12 (V)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000041587568", "@num": "L112-12", "#text": "Code de la construction et de l'habitation. - art. L112-12 (V)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000032042837", "@num": "L112-12", "#text": "Code de la construction et de l'habitation. - art. L112-12 (VD)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000033933397", "@num": "L112-12", "#text": "Code de la construction et de l'habitation. - art. L112-12 (VD)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000041587555", "@num": "L112-13", "#text": "Code de la construction et de l'habitation. - art. L112-13 (V)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000006824233", "@num": "L112-13", "#text": "Code de la construction et de l'habitation. - art. L112-13 (VT)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000006824234", "@num": "L112-14", "#text": "Code de la construction et de l'habitation. - art. L112-14 (V)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000006824235", "@num": "L112-15", "#text": "Code de la construction et de l'habitation. - art. L112-15 (V)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000006824236", "@num": "L112-16", "#text": "Code de la construction et de l'habitation. - art. L112-16 (M)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000006824237", "@num": "L112-16", "#text": "Code de la construction et de l'habitation. - art. L112-16 (M)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000041411136", "@num": "L112-16", "#text": "Code de la construction et de l'habitation. - art. L112-16 (V)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000006824238", "@num": "L112-17", "#text": "Code de la construction et de l'habitation. - art. L112-17 (V)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000025760480", "@num": "L112-17", "#text": "Code de la construction et de l'habitation. - art. L112-17 (V)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000006824240", "@num": "L112-18", "#text": "Code de la construction et de l'habitation. - art. L112-18 (M)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000037667712", "@num": "L112-18", "#text": "Code de la construction et de l'habitation. - art. L112-18 (V)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000006824241", "@num": "L112-19", "#text": "Code de la construction et de l'habitation. - art. L112-19 (M)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000037667704", "@num": "L112-19", "#text": "Code de la construction et de l'habitation. - art. L112-19 (V)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000041587657", "@num": "L112-2", "#text": "Code de la construction et de l'habitation. - art. L112-2 (V)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000006824220", "@num": "L112-2", "#text": "Code de la construction et de l'habitation. - art. L112-2 (VT)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000006824217", "@num": "L112-3", "#text": "Code de la construction et de l'habitation. - art. L112-3 (Ab)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000006824217", "@num": "L112-3", "#text": "Code de la construction et de l'habitation. - art. L112-3 (Ab)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CREATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000041587652", "@num": "L112-3", "#text": "Code de la construction et de l'habitation. - art. L112-3 (V)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000006824218", "@num": "L112-4", "#text": "Code de la construction et de l'habitation. - art. L112-4 (M)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000041587642", "@num": "L112-4", "#text": "Code de la construction et de l'habitation. - art. L112-4 (V)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000006824219", "@num": "L112-4", "#text": "Code de la construction et de l'habitation. - art. L112-4 (VT)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000006824221", "@num": "L112-5", "#text": "Code de la construction et de l'habitation. - art. L112-5 (V)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000041587635", "@num": "L112-5", "#text": "Code de la construction et de l'habitation. - art. L112-5 (V)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000023490989", "@num": "L112-5", "#text": "Code de la construction et de l'habitation. - art. L112-5 (VD)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000006824222", "@num": "L112-6", "#text": "Code de la construction et de l'habitation. - art. L112-6 (V)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000006824224", "@num": "L112-7", "#text": "Code de la construction et de l'habitation. - art. L112-7 (M)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000041587619", "@num": "L112-7", "#text": "Code de la construction et de l'habitation. - art. L112-7 (V)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000006824225", "@num": "L112-7", "#text": "Code de la construction et de l'habitation. - art. L112-7 (VT)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000041587611", "@num": "L112-8", "#text": "Code de la construction et de l'habitation. - art. L112-8 (V)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000006824226", "@num": "L112-8", "#text": "Code de la construction et de l'habitation. - art. L112-8 (VT)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000041587597", "@num": "L112-9", "#text": "Code de la construction et de l'habitation. - art. L112-9 (V)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000006824227", "@num": "L112-9", "#text": "Code de la construction et de l'habitation. - art. L112-9 (VT)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000006824243", "@num": "L122-1", "#text": "Code de la construction et de l'habitation. - art. L122-1 (M)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000006824242", "@num": "L122-1", "#text": "Code de la construction et de l'habitation. - art. L122-1 (M)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000006824244", "@num": "L122-1", "#text": "Code de la construction et de l'habitation. - art. L122-1 (M)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000041587895", "@num": "L122-1", "#text": "Code de la construction et de l'habitation. - art. L122-1 (M)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000047303728", "@num": "L122-1", "#text": "Code de la construction et de l'habitation. - art. L122-1 (V)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000037667174", "@num": "L122-1", "#text": "Code de la construction et de l'habitation. - art. L122-1 (VT)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000006824246", "@num": "L122-2", "#text": "Code de la construction et de l'habitation. - art. L122-2 (Ab)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000006824245", "@num": "L122-2", "#text": "Code de la construction et de l'habitation. - art. L122-2 (M)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000041587892", "@num": "L122-2", "#text": "Code de la construction et de l'habitation. - art. L122-2 (V)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000006824247", "@num": "L123-1", "#text": "Code de la construction et de l'habitation. - art. L123-1 (M)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000041587884", "@num": "L123-1", "#text": "Code de la construction et de l'habitation. - art. L123-1 (V)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000006824248", "@num": "L123-1", "#text": "Code de la construction et de l'habitation. - art. L123-1 (VT)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000006824249", "@num": "L123-2", "#text": "Code de la construction et de l'habitation. - art. L123-2 (M)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000041587876", "@num": "L123-2", "#text": "Code de la construction et de l'habitation. - art. L123-2 (V)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000006824250", "@num": "L123-2", "#text": "Code de la construction et de l'habitation. - art. L123-2 (VT)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000006824251", "@num": "L123-3", "#text": "Code de la construction et de l'habitation. - art. L123-3 (M)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000006824252", "@num": "L123-3", "#text": "Code de la construction et de l'habitation. - art. L123-3 (V)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000006824253", "@num": "L123-4", "#text": "Code de la construction et de l'habitation. - art. L123-4 (M)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000041587852", "@num": "L123-4", "#text": "Code de la construction et de l'habitation. - art. L123-4 (V)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000041411102", "@num": "L123-4", "#text": "Code de la construction et de l'habitation. - art. L123-4 (VT)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000041587830", "@num": "L124-1", "#text": "Code de la construction et de l'habitation. - art. L124-1 (V)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000006824254", "@num": "L124-1", "#text": "Code de la construction et de l'habitation. - art. L124-1 (VT)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000006824255", "@num": "L125-1", "#text": "Code de la construction et de l'habitation. - art. L125-1 (M)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000006824256", "@num": "L125-1", "#text": "Code de la construction et de l'habitation. - art. L125-1 (M)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000041587822", "@num": "L125-1", "#text": "Code de la construction et de l'habitation. - art. L125-1 (V)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000033973894", "@num": "L125-1", "#text": "Code de la construction et de l'habitation. - art. L125-1 (VT)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000006824257", "@num": "L125-2", "#text": "Code de la construction et de l'habitation. - art. L125-2 (M)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000041587814", "@num": "L125-2", "#text": "Code de la construction et de l'habitation. - art. L125-2 (V)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000006824258", "@num": "L125-2", "#text": "Code de la construction et de l'habitation. - art. L125-2 (VT)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000006824259", "@num": "L125-2-1", "#text": "Code de la construction et de l'habitation. - art. L125-2-1 (V)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000006824261", "@num": "L125-2-2", "#text": "Code de la construction et de l'habitation. - art. L125-2-2 (V)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000006824262", "@num": "L125-2-3", "#text": "Code de la construction et de l'habitation. - art. L125-2-3 (M)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000006824263", "@num": "L125-2-3", "#text": "Code de la construction et de l'habitation. - art. L125-2-3 (V)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000006824264", "@num": "L125-2-4", "#text": "Code de la construction et de l'habitation. - art. L125-2-4 (V)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000041587806", "@num": "L125-3", "#text": "Code de la construction et de l'habitation. - art. L125-3 (V)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000006824265", "@num": "L125-3", "#text": "Code de la construction et de l'habitation. - art. L125-3 (VT)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000041587801", "@num": "L125-4", "#text": "Code de la construction et de l'habitation. - art. L125-4 (V)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000006824266", "@num": "L125-4", "#text": "Code de la construction et de l'habitation. - art. L125-4 (VT)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000041587796", "@num": "L125-5", "#text": "Code de la construction et de l'habitation. - art. L125-5 (V)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000006824267", "@num": "L125-5", "#text": "Code de la construction et de l'habitation. - art. L125-5 (VT)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000006824268", "@num": "L126-1", "#text": "Code de la construction et de l'habitation. - art. L126-1 (M)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000006824269", "@num": "L126-1", "#text": "Code de la construction et de l'habitation. - art. L126-1 (V)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000041587468", "@num": "L126-1", "#text": "Code de la construction et de l'habitation. - art. L126-1 (V)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000006824270", "@num": "L126-2", "#text": "Code de la construction et de l'habitation. - art. L126-2 (M)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000006824271", "@num": "L126-2", "#text": "Code de la construction et de l'habitation. - art. L126-2 (V)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000041587479", "@num": "L126-2", "#text": "Code de la construction et de l'habitation. - art. L126-2 (V)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000006824273", "@num": "L126-3", "#text": "Code de la construction et de l'habitation. - art. L126-3 (M)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000006824274", "@num": "L126-3", "#text": "Code de la construction et de l'habitation. - art. L126-3 (V)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000006824276", "@num": "L127-1", "#text": "Code de la construction et de l'habitation. - art. L127-1 (M)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000006824275", "@num": "L127-1", "#text": "Code de la construction et de l'habitation. - art. L127-1 (M)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000006824277", "@num": "L127-1", "#text": "Code de la construction et de l'habitation. - art. L127-1 (VT)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000006824278", "@num": "L128-1", "#text": "Code de la construction et de l'habitation. - art. L128-1 (V)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000006824279", "@num": "L128-2", "#text": "Code de la construction et de l'habitation. - art. L128-2 (M)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000006824280", "@num": "L128-2", "#text": "Code de la construction et de l'habitation. - art. L128-2 (V)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000006824281", "@num": "L128-3", "#text": "Code de la construction et de l'habitation. - art. L128-3 (V)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000006824282", "@num": "L129-1", "#text": "Code de la construction et de l'habitation. - art. L129-1 (M)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000006824283", "@num": "L129-1", "#text": "Code de la construction et de l'habitation. - art. L129-1 (VT)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000006824284", "@num": "L129-2", "#text": "Code de la construction et de l'habitation. - art. L129-2 (M)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000006824285", "@num": "L129-2", "#text": "Code de la construction et de l'habitation. - art. L129-2 (V)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000006824287", "@num": "L129-3", "#text": "Code de la construction et de l'habitation. - art. L129-3 (M)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000006824288", "@num": "L129-3", "#text": "Code de la construction et de l'habitation. - art. L129-3 (V)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000006824291", "@num": "L129-4", "#text": "Code de la construction et de l'habitation. - art. L129-4 (M)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000006824290", "@num": "L129-4", "#text": "Code de la construction et de l'habitation. - art. L129-4 (M)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000006824289", "@num": "L129-4", "#text": "Code de la construction et de l'habitation. - art. L129-4 (M)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000006824292", "@num": "L129-4", "#text": "Code de la construction et de l'habitation. - art. L129-4 (V)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000006824293", "@num": "L129-4-1", "#text": "Code de la construction et de l'habitation. - art. L129-4-1 (V)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000006824294", "@num": "L129-5", "#text": "Code de la construction et de l'habitation. - art. L129-5 (M)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000006824295", "@num": "L129-5", "#text": "Code de la construction et de l'habitation. - art. L129-5 (V)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000006824296", "@num": "L129-6", "#text": "Code de la construction et de l'habitation. - art. L129-6 (V)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000006824297", "@num": "L129-7", "#text": "Code de la construction et de l'habitation. - art. L129-7 (V)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000006824298", "@num": "L131-1", "#text": "Code de la construction et de l'habitation. - art. L131-1 (M)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000006824299", "@num": "L131-1", "#text": "Code de la construction et de l'habitation. - art. L131-1 (V)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000041588086", "@num": "L131-1", "#text": "Code de la construction et de l'habitation. - art. L131-1 (V)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000023981222", "@num": "L131-1", "#text": "Code de la construction et de l'habitation. - art. L131-1 (VD)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000006824300", "@num": "L131-2", "#text": "Code de la construction et de l'habitation. - art. L131-2 (M)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000006824301", "@num": "L131-2", "#text": "Code de la construction et de l'habitation. - art. L131-2 (V)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000041588080", "@num": "L131-2", "#text": "Code de la construction et de l'habitation. - art. L131-2 (V)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000023981216", "@num": "L131-2", "#text": "Code de la construction et de l'habitation. - art. L131-2 (VD)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000006824302", "@num": "L131-3", "#text": "Code de la construction et de l'habitation. - art. L131-3 (M)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000006824303", "@num": "L131-3", "#text": "Code de la construction et de l'habitation. - art. L131-3 (V)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000041588074", "@num": "L131-3", "#text": "Code de la construction et de l'habitation. - art. L131-3 (V)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000023981212", "@num": "L131-3", "#text": "Code de la construction et de l'habitation. - art. L131-3 (VD)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000006824304", "@num": "L131-4", "#text": "Code de la construction et de l'habitation. - art. L131-4 (M)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000006824305", "@num": "L131-4", "#text": "Code de la construction et de l'habitation. - art. L131-4 (VT)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000006824306", "@num": "L131-5", "#text": "Code de la construction et de l'habitation. - art. L131-5 (M)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000006824307", "@num": "L131-5", "#text": "Code de la construction et de l'habitation. - art. L131-5 (VT)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000006824308", "@num": "L131-6", "#text": "Code de la construction et de l'habitation. - art. L131-6 (M)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000006824309", "@num": "L131-6", "#text": "Code de la construction et de l'habitation. - art. L131-6 (VT)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000006824310", "@num": "L131-7", "#text": "Code de la construction et de l'habitation. - art. L131-7 (M)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000006824311", "@num": "L131-7", "#text": "Code de la construction et de l'habitation. - art. L131-7 (VT)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000006824312", "@num": "L132-1", "#text": "Code de la construction et de l'habitation. - art. L132-1 (M)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000041588064", "@num": "L132-1", "#text": "Code de la construction et de l'habitation. - art. L132-1 (V)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000006824313", "@num": "L132-1", "#text": "Code de la construction et de l'habitation. - art. L132-1 (VT)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000006824314", "@num": "L132-2", "#text": "Code de la construction et de l'habitation. - art. L132-2 (M)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000041588055", "@num": "L132-2", "#text": "Code de la construction et de l'habitation. - art. L132-2 (V)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000006824315", "@num": "L132-2", "#text": "Code de la construction et de l'habitation. - art. L132-2 (VT)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000006824316", "@num": "L132-3", "#text": "Code de la construction et de l'habitation. - art. L132-3 (M)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000006824317", "@num": "L132-3", "#text": "Code de la construction et de l'habitation. - art. L132-3 (V)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000006824318", "@num": "L132-4", "#text": "Code de la construction et de l'habitation. - art. L132-4 (M)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000041588036", "@num": "L132-4", "#text": "Code de la construction et de l'habitation. - art. L132-4 (V)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000006824319", "@num": "L132-4", "#text": "Code de la construction et de l'habitation. - art. L132-4 (VT)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000006824320", "@num": "L132-5", "#text": "Code de la construction et de l'habitation. - art. L132-5 (M)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000006824321", "@num": "L132-5", "#text": "Code de la construction et de l'habitation. - art. L132-5 (V)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000041588033", "@num": "L132-5", "#text": "Code de la construction et de l'habitation. - art. L132-5 (V)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000038791051", "@num": "L132-5", "#text": "Code de la construction et de l'habitation. - art. L132-5 (VD)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000006824322", "@num": "L133-1", "#text": "Code de la construction et de l'habitation. - art. L133-1 (M)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000006824323", "@num": "L133-1", "#text": "Code de la construction et de l'habitation. - art. L133-1 (V)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000024040925", "@num": "L133-1", "#text": "Code de la construction et de l'habitation. - art. L133-1 (V)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000041588020", "@num": "L133-1", "#text": "Code de la construction et de l'habitation. - art. L133-1 (V)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000028808016", "@num": "L133-1", "#text": "Code de la construction et de l'habitation. - art. L133-1 (VT)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000006824324", "@num": "L133-2", "#text": "Code de la construction et de l'habitation. - art. L133-2 (M)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000006824325", "@num": "L133-2", "#text": "Code de la construction et de l'habitation. - art. L133-2 (V)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000024040921", "@num": "L133-2", "#text": "Code de la construction et de l'habitation. - art. L133-2 (V)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000028808012", "@num": "L133-2", "#text": "Code de la construction et de l'habitation. - art. L133-2 (V)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000041588013", "@num": "L133-2", "#text": "Code de la construction et de l'habitation. - art. L133-2 (V)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000038791047", "@num": "L133-2", "#text": "Code de la construction et de l'habitation. - art. L133-2 (VD)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000006824326", "@num": "L133-3", "#text": "Code de la construction et de l'habitation. - art. L133-3 (M)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000006824327", "@num": "L133-3", "#text": "Code de la construction et de l'habitation. - art. L133-3 (V)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000028808009", "@num": "L133-3", "#text": "Code de la construction et de l'habitation. - art. L133-3 (VT)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000006824328", "@num": "L133-4", "#text": "Code de la construction et de l'habitation. - art. L133-4 (M)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000006824329", "@num": "L133-4", "#text": "Code de la construction et de l'habitation. - art. L133-4 (V)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000028808005", "@num": "L133-4", "#text": "Code de la construction et de l'habitation. - art. L133-4 (VT)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000006824330", "@num": "L133-5", "#text": "Code de la construction et de l'habitation. - art. L133-5 (M)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000006824331", "@num": "L133-5", "#text": "Code de la construction et de l'habitation. - art. L133-5 (M)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000006824332", "@num": "L133-5", "#text": "Code de la construction et de l'habitation. - art. L133-5 (V)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000028808002", "@num": "L133-5", "#text": "Code de la construction et de l'habitation. - art. L133-5 (VT)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000006824333", "@num": "L133-6", "#text": "Code de la construction et de l'habitation. - art. L133-6 (M)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000006824334", "@num": "L133-6", "#text": "Code de la construction et de l'habitation. - art. L133-6 (V)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000028807997", "@num": "L133-6", "#text": "Code de la construction et de l'habitation. - art. L133-6 (VT)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000006824336", "@num": "L134-1", "#text": "Code de la construction et de l'habitation. - art. L134-1 (M)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000006824337", "@num": "L134-1", "#text": "Code de la construction et de l'habitation. - art. L134-1 (M)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000006824338", "@num": "L134-1", "#text": "Code de la construction et de l'habitation. - art. L134-1 (V)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000006824339", "@num": "L134-2", "#text": "Code de la construction et de l'habitation. - art. L134-2 (M)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000006824340", "@num": "L134-2", "#text": "Code de la construction et de l'habitation. - art. L134-2 (M)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000006824341", "@num": "L134-2", "#text": "Code de la construction et de l'habitation. - art. L134-2 (V)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000006824343", "@num": "L134-3", "#text": "Code de la construction et de l'habitation. - art. L134-3 (M)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000006824342", "@num": "L134-3", "#text": "Code de la construction et de l'habitation. - art. L134-3 (M)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000006824344", "@num": "L134-3", "#text": "Code de la construction et de l'habitation. - art. L134-3 (V)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000006824346", "@num": "L134-4", "#text": "Code de la construction et de l'habitation. - art. L134-4 (M)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000006824345", "@num": "L134-4", "#text": "Code de la construction et de l'habitation. - art. L134-4 (M)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000006824347", "@num": "L134-4", "#text": "Code de la construction et de l'habitation. - art. L134-4 (V)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000006824349", "@num": "L134-5", "#text": "Code de la construction et de l'habitation. - art. L134-5 (M)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000006824348", "@num": "L134-5", "#text": "Code de la construction et de l'habitation. - art. L134-5 (M)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000006824350", "@num": "L134-5", "#text": "Code de la construction et de l'habitation. - art. L134-5 (V)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000006824352", "@num": "L134-6", "#text": "Code de la construction et de l'habitation. - art. L134-6 (M)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000006824351", "@num": "L134-6", "#text": "Code de la construction et de l'habitation. - art. L134-6 (M)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000041588161", "@num": "L134-6", "#text": "Code de la construction et de l'habitation. - art. L134-6 (V)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000006824353", "@num": "L134-6", "#text": "Code de la construction et de l'habitation. - art. L134-6 (VT)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000006824354", "@num": "L134-7", "#text": "Code de la construction et de l'habitation. - art. L134-7 (M)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000041588152", "@num": "L134-7", "#text": "Code de la construction et de l'habitation. - art. L134-7 (V)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000006824355", "@num": "L134-7", "#text": "Code de la construction et de l'habitation. - art. L134-7 (VT)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000006824357", "@num": "L135-1", "#text": "Code de la construction et de l'habitation. - art. L135-1 (V)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000006824358", "@num": "L142-1", "#text": "Code de la construction et de l'habitation. - art. L142-1 (V)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000006824359", "@num": "L142-2", "#text": "Code de la construction et de l'habitation. - art. L142-2 (M)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000041588229", "@num": "L142-2", "#text": "Code de la construction et de l'habitation. - art. L142-2 (V)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000031063662", "@num": "L142-2", "#text": "Code de la construction et de l'habitation. - art. L142-2 (VT)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000006824360", "@num": "L151-1", "#text": "Code de la construction et de l'habitation. - art. L151-1 (M)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000006824361", "@num": "L151-1", "#text": "Code de la construction et de l'habitation. - art. L151-1 (M)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000006824362", "@num": "L151-1", "#text": "Code de la construction et de l'habitation. - art. L151-1 (M)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000037201456", "@num": "L151-1", "#text": "Code de la construction et de l'habitation. - art. L151-1 (M)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000041588294", "@num": "L151-1", "#text": "Code de la construction et de l'habitation. - art. L151-1 (V)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000037667865", "@num": "L151-1", "#text": "Code de la construction et de l'habitation. - art. L151-1 (VT)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000006824392", "@num": "L152-1", "#text": "Code de la construction et de l'habitation. - art. L152-1 (M)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000006824389", "@num": "L152-1", "#text": "Code de la construction et de l'habitation. - art. L152-1 (M)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000006824395", "@num": "L152-1", "#text": "Code de la construction et de l'habitation. - art. L152-1 (M)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000006824390", "@num": "L152-1", "#text": "Code de la construction et de l'habitation. - art. L152-1 (M)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000006824393", "@num": "L152-1", "#text": "Code de la construction et de l'habitation. - art. L152-1 (M)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000006824388", "@num": "L152-1", "#text": "Code de la construction et de l'habitation. - art. L152-1 (M)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000006824394", "@num": "L152-1", "#text": "Code de la construction et de l'habitation. - art. L152-1 (M)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000006824391", "@num": "L152-1", "#text": "Code de la construction et de l'habitation. - art. L152-1 (M)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000006824396", "@num": "L152-1", "#text": "Code de la construction et de l'habitation. - art. L152-1 (V)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000006824375", "@num": "L152-10", "#text": "Code de la construction et de l'habitation. - art. L152-10 (M)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000006824376", "@num": "L152-10", "#text": "Code de la construction et de l'habitation. - art. L152-10 (M)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000006824377", "@num": "L152-10", "#text": "Code de la construction et de l'habitation. - art. L152-10 (M)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000037667810", "@num": "L152-10", "#text": "Code de la construction et de l'habitation. - art. L152-10 (VT)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000006824379", "@num": "L152-11", "#text": "Code de la construction et de l'habitation. - art. L152-11 (M)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000006824378", "@num": "L152-11", "#text": "Code de la construction et de l'habitation. - art. L152-11 (M)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000006824380", "@num": "L152-11", "#text": "Code de la construction et de l'habitation. - art. L152-11 (V)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000006824381", "@num": "L152-12", "#text": "Code de la construction et de l'habitation. - art. L152-12 (V)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000041588274", "@num": "L152-2", "#text": "Code de la construction et de l'habitation. - art. L152-2 (V)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000006824364", "@num": "L152-2", "#text": "Code de la construction et de l'habitation. - art. L152-2 (VT)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000006824366", "@num": "L152-3", "#text": "Code de la construction et de l'habitation. - art. L152-3 (M)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000006824367", "@num": "L152-3", "#text": "Code de la construction et de l'habitation. - art. L152-3 (M)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000006824365", "@num": "L152-3", "#text": "Code de la construction et de l'habitation. - art. L152-3 (M)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000006824368", "@num": "L152-3", "#text": "Code de la construction et de l'habitation. - art. L152-3 (V)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000041588266", "@num": "L152-3", "#text": "Code de la construction et de l'habitation. - art. L152-3 (V)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000024041603", "@num": "L152-3", "#text": "Code de la construction et de l'habitation. - art. L152-3 (VT)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000006824409", "@num": "L152-4", "#text": "Code de la construction et de l'habitation. - art. L152-4 (M)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000006824403", "@num": "L152-4", "#text": "Code de la construction et de l'habitation. - art. L152-4 (M)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000006824397", "@num": "L152-4", "#text": "Code de la construction et de l'habitation. - art. L152-4 (M)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000006824402", "@num": "L152-4", "#text": "Code de la construction et de l'habitation. - art. L152-4 (M)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000006824408", "@num": "L152-4", "#text": "Code de la construction et de l'habitation. - art. L152-4 (M)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000006824400", "@num": "L152-4", "#text": "Code de la construction et de l'habitation. - art. L152-4 (M)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000006824401", "@num": "L152-4", "#text": "Code de la construction et de l'habitation. - art. L152-4 (M)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000006824398", "@num": "L152-4", "#text": "Code de la construction et de l'habitation. - art. L152-4 (M)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000006824406", "@num": "L152-4", "#text": "Code de la construction et de l'habitation. - art. L152-4 (M)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000006824405", "@num": "L152-4", "#text": "Code de la construction et de l'habitation. - art. L152-4 (M)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000006824404", "@num": "L152-4", "#text": "Code de la construction et de l'habitation. - art. L152-4 (M)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000006824407", "@num": "L152-4", "#text": "Code de la construction et de l'habitation. - art. L152-4 (MMN)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000006824399", "@num": "L152-4", "#text": "Code de la construction et de l'habitation. - art. L152-4 (MMN)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000006824369", "@num": "L152-5", "#text": "Code de la construction et de l'habitation. - art. L152-5 (VT)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000006824370", "@num": "L152-6", "#text": "Code de la construction et de l'habitation. - art. L152-6 (V)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000039279946", "@num": "L152-6", "#text": "Code de la construction et de l'habitation. - art. L152-6 (VD)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000006824371", "@num": "L152-7", "#text": "Code de la construction et de l'habitation. - art. L152-7 (M)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000006824372", "@num": "L152-7", "#text": "Code de la construction et de l'habitation. - art. L152-7 (VT)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000006824373", "@num": "L152-8", "#text": "Code de la construction et de l'habitation. - art. L152-8 (VT)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000006824374", "@num": "L152-9", "#text": "Code de la construction et de l'habitation. - art. L152-9 (V)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000039279943", "@num": "L152-9", "#text": "Code de la construction et de l'habitation. - art. L152-9 (VD)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000006824382", "@num": "L161-1", "#text": "Code de la construction et de l'habitation. - art. L161-1 (M)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000006824383", "@num": "L161-1", "#text": "Code de la construction et de l'habitation. - art. L161-1 (V)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000041588425", "@num": "L161-1", "#text": "Code de la construction et de l'habitation. - art. L161-1 (V)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000025760475", "@num": "L161-1", "#text": "Code de la construction et de l'habitation. - art. L161-1 (VT)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000006824385", "@num": "L161-2", "#text": "Code de la construction et de l'habitation. - art. L161-2 (M)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000006824384", "@num": "L161-2", "#text": "Code de la construction et de l'habitation. - art. L161-2 (M)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000006824386", "@num": "L161-2", "#text": "Code de la construction et de l'habitation. - art. L161-2 (M)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000006824387", "@num": "L161-2", "#text": "Code de la construction et de l'habitation. - art. L161-2 (M)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000041588408", "@num": "L161-2", "#text": "Code de la construction et de l'habitation. - art. L161-2 (V)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000037201686", "@num": "L161-2", "#text": "Code de la construction et de l'habitation. - art. L161-2 (VT)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000006824410", "@num": "L210-1", "#text": "Code de la construction et de l'habitation. - art. L210-1 (V)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000006824411", "@num": "L211-1", "#text": "Code de la construction et de l'habitation. - art. L211-1 (V)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000006824412", "@num": "L211-2", "#text": "Code de la construction et de l'habitation. - art. L211-2 (V)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000006824413", "@num": "L211-3", "#text": "Code de la construction et de l'habitation. - art. L211-3 (V)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000006824414", "@num": "L211-4", "#text": "Code de la construction et de l'habitation. - art. L211-4 (V)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000006824415", "@num": "L212-1", "#text": "Code de la construction et de l'habitation. - art. L212-1 (V)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000006824424", "@num": "L212-10", "#text": "Code de la construction et de l'habitation. - art. L212-10 (V)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000006824425", "@num": "L212-11", "#text": "Code de la construction et de l'habitation. - art. L212-11 (V)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000006824426", "@num": "L212-12", "#text": "Code de la construction et de l'habitation. - art. L212-12 (V)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000006824427", "@num": "L212-13", "#text": "Code de la construction et de l'habitation. - art. L212-13 (V)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000006824428", "@num": "L212-14", "#text": "Code de la construction et de l'habitation. - art. L212-14 (V)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000039279933", "@num": "L212-14", "#text": "Code de la construction et de l'habitation. - art. L212-14 (VD)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000006824429", "@num": "L212-15", "#text": "Code de la construction et de l'habitation. - art. L212-15 (M)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000038584327", "@num": "L212-15", "#text": "Code de la construction et de l'habitation. - art. L212-15 (V)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000039279928", "@num": "L212-15", "#text": "Code de la construction et de l'habitation. - art. L212-15 (VD)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000006824430", "@num": "L212-16", "#text": "Code de la construction et de l'habitation. - art. L212-16 (V)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000006824431", "@num": "L212-17", "#text": "Code de la construction et de l'habitation. - art. L212-17 (V)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000006824416", "@num": "L212-2", "#text": "Code de la construction et de l'habitation. - art. L212-2 (V)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000006824417", "@num": "L212-3", "#text": "Code de la construction et de l'habitation. - art. L212-3 (V)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000006824418", "@num": "L212-4", "#text": "Code de la construction et de l'habitation. - art. L212-4 (M)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CREATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000006824418", "@num": "L212-4", "#text": "Code de la construction et de l'habitation. - art. L212-4 (M)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000038584335", "@num": "L212-4", "#text": "Code de la construction et de l'habitation. - art. L212-4 (V)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000006824419", "@num": "L212-5", "#text": "Code de la construction et de l'habitation. - art. L212-5 (V)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000006824420", "@num": "L212-6", "#text": "Code de la construction et de l'habitation. - art. L212-6 (V)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000039279937", "@num": "L212-6", "#text": "Code de la construction et de l'habitation. - art. L212-6 (VD)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000006824421", "@num": "L212-7", "#text": "Code de la construction et de l'habitation. - art. L212-7 (V)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000006824422", "@num": "L212-8", "#text": "Code de la construction et de l'habitation. - art. L212-8 (V)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000006824423", "@num": "L212-9", "#text": "Code de la construction et de l'habitation. - art. L212-9 (V)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000038791043", "@num": "L212-9", "#text": "Code de la construction et de l'habitation. - art. L212-9 (VD)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000006824432", "@num": "L213-1", "#text": "Code de la construction et de l'habitation. - art. L213-1 (M)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000006824441", "@num": "L213-10", "#text": "Code de la construction et de l'habitation. - art. L213-10 (V)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000006824442", "@num": "L213-11", "#text": "Code de la construction et de l'habitation. - art. L213-11 (V)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000039279923", "@num": "L213-11", "#text": "Code de la construction et de l'habitation. - art. L213-11 (VD)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000006824443", "@num": "L213-12", "#text": "Code de la construction et de l'habitation. - art. L213-12 (V)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000039279919", "@num": "L213-12", "#text": "Code de la construction et de l'habitation. - art. L213-12 (VD)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000006824444", "@num": "L213-13", "#text": "Code de la construction et de l'habitation. - art. L213-13 (V)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000006824445", "@num": "L213-14", "#text": "Code de la construction et de l'habitation. - art. L213-14 (V)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000006824446", "@num": "L213-15", "#text": "Code de la construction et de l'habitation. - art. L213-15 (V)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000006824433", "@num": "L213-2", "#text": "Code de la construction et de l'habitation. - art. L213-2 (V)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000006824434", "@num": "L213-3", "#text": "Code de la construction et de l'habitation. - art. L213-3 (V)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000006824435", "@num": "L213-4", "#text": "Code de la construction et de l'habitation. - art. L213-4 (V)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000006824436", "@num": "L213-5", "#text": "Code de la construction et de l'habitation. - art. L213-5 (V)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000006824437", "@num": "L213-6", "#text": "Code de la construction et de l'habitation. - art. L213-6 (V)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000006824438", "@num": "L213-7", "#text": "Code de la construction et de l'habitation. - art. L213-7 (V)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000006824439", "@num": "L213-8", "#text": "Code de la construction et de l'habitation. - art. L213-8 (V)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000006824440", "@num": "L213-9", "#text": "Code de la construction et de l'habitation. - art. L213-9 (V)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000006824447", "@num": "L214-1", "#text": "Code de la construction et de l'habitation. - art. L214-1 (V)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000006824448", "@num": "L214-2", "#text": "Code de la construction et de l'habitation. - art. L214-2 (V)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000006824449", "@num": "L214-3", "#text": "Code de la construction et de l'habitation. - art. L214-3 (V)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000006824450", "@num": "L214-4", "#text": "Code de la construction et de l'habitation. - art. L214-4 (V)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000006824451", "@num": "L214-5", "#text": "Code de la construction et de l'habitation. - art. L214-5 (M)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000006824452", "@num": "L214-5", "#text": "Code de la construction et de l'habitation. - art. L214-5 (V)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000006824453", "@num": "L214-6", "#text": "Code de la construction et de l'habitation. - art. L214-6 (V)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000006824454", "@num": "L214-7", "#text": "Code de la construction et de l'habitation. - art. L214-7 (V)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000006824455", "@num": "L214-8", "#text": "Code de la construction et de l'habitation. - art. L214-8 (V)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000006824456", "@num": "L214-9", "#text": "Code de la construction et de l'habitation. - art. L214-9 (V)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000006824457", "@num": "L215-1", "#text": "Code de la construction et de l'habitation. - art. L215-1 (M)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000006824458", "@num": "L215-1", "#text": "Code de la construction et de l'habitation. - art. L215-1 (M)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000037668897", "@num": "L215-1", "#text": "Code de la construction et de l'habitation. - art. L215-1 (V)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000006824459", "@num": "L215-1-1", "#text": "Code de la construction et de l'habitation. - art. L215-1-1 (V)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000006824460", "@num": "L215-1-2", "#text": "Code de la construction et de l'habitation. - art. L215-1-2 (V)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000006824475", "@num": "L215-10", "#text": "Code de la construction et de l'habitation. - art. L215-10 (M)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000006824476", "@num": "L215-10", "#text": "Code de la construction et de l'habitation. - art. L215-10 (VT)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000006824461", "@num": "L215-2", "#text": "Code de la construction et de l'habitation. - art. L215-2 (V)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000006824462", "@num": "L215-3", "#text": "Code de la construction et de l'habitation. - art. L215-3 (M)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000006824463", "@num": "L215-3", "#text": "Code de la construction et de l'habitation. - art. L215-3 (V)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000006824464", "@num": "L215-4", "#text": "Code de la construction et de l'habitation. - art. L215-4 (M)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000006824465", "@num": "L215-4", "#text": "Code de la construction et de l'habitation. - art. L215-4 (M)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000037668909", "@num": "L215-4", "#text": "Code de la construction et de l'habitation. - art. L215-4 (V)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000006824466", "@num": "L215-5", "#text": "Code de la construction et de l'habitation. - art. L215-5 (M)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000006824467", "@num": "L215-5", "#text": "Code de la construction et de l'habitation. - art. L215-5 (V)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000006824468", "@num": "L215-6", "#text": "Code de la construction et de l'habitation. - art. L215-6 (V)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000006824469", "@num": "L215-7", "#text": "Code de la construction et de l'habitation. - art. L215-7 (M)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000006824470", "@num": "L215-7", "#text": "Code de la construction et de l'habitation. - art. L215-7 (M)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000037668915", "@num": "L215-7", "#text": "Code de la construction et de l'habitation. - art. L215-7 (V)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000006824471", "@num": "L215-8", "#text": "Code de la construction et de l'habitation. - art. L215-8 (M)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000006824472", "@num": "L215-8", "#text": "Code de la construction et de l'habitation. - art. L215-8 (V)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000006824473", "@num": "L215-9", "#text": "Code de la construction et de l'habitation. - art. L215-9 (M)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000006824474", "@num": "L215-9", "#text": "Code de la construction et de l'habitation. - art. L215-9 (V)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000006824477", "@num": "L221-1", "#text": "Code de la construction et de l'habitation. - art. L221-1 (V)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000006824478", "@num": "L221-2", "#text": "Code de la construction et de l'habitation. - art. L221-2 (V)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000006824479", "@num": "L221-3", "#text": "Code de la construction et de l'habitation. - art. L221-3 (V)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000006824480", "@num": "L221-4", "#text": "Code de la construction et de l'habitation. - art. L221-4 (V)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000006824481", "@num": "L221-5", "#text": "Code de la construction et de l'habitation. - art. L221-5 (V)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000006824482", "@num": "L221-6", "#text": "Code de la construction et de l'habitation. - art. L221-6 (V)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000006824483", "@num": "L222-1", "#text": "Code de la construction et de l'habitation. - art. L222-1 (V)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000006824484", "@num": "L222-2", "#text": "Code de la construction et de l'habitation. - art. L222-2 (M)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000006824485", "@num": "L222-2", "#text": "Code de la construction et de l'habitation. - art. L222-2 (V)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000006824486", "@num": "L222-3", "#text": "Code de la construction et de l'habitation. - art. L222-3 (V)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000006824487", "@num": "L222-4", "#text": "Code de la construction et de l'habitation. - art. L222-4 (M)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000006824488", "@num": "L222-4", "#text": "Code de la construction et de l'habitation. - art. L222-4 (V)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000032042882", "@num": "L222-4", "#text": "Code de la construction et de l'habitation. - art. L222-4 (VD)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000006824489", "@num": "L222-5", "#text": "Code de la construction et de l'habitation. - art. L222-5 (V)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000006824490", "@num": "L222-6", "#text": "Code de la construction et de l'habitation. - art. L222-6 (M)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000006824491", "@num": "L222-6", "#text": "Code de la construction et de l'habitation. - art. L222-6 (V)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000006824492", "@num": "L222-7", "#text": "Code de la construction et de l'habitation. - art. L222-7 (V)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000006824493", "@num": "L230-1", "#text": "Code de la construction et de l'habitation. - art. L230-1 (V)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000006824508", "@num": "L231-1", "#text": "Code de la construction et de l'habitation. - art. L231-1 (M)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000006824509", "@num": "L231-1", "#text": "Code de la construction et de l'habitation. - art. L231-1 (V)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000041586868", "@num": "L231-1", "#text": "Code de la construction et de l'habitation. - art. L231-1 (VD)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000006824510", "@num": "L231-1-1", "#text": "Code de la construction et de l'habitation. - art. L231-1-1 (Ab)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000006824511", "@num": "L231-1-2", "#text": "Code de la construction et de l'habitation. - art. L231-1-2 (Ab)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000006824501", "@num": "L231-10", "#text": "Code de la construction et de l'habitation. - art. L231-10 (V)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000006824502", "@num": "L231-11", "#text": "Code de la construction et de l'habitation. - art. L231-11 (V)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000028574448", "@num": "L231-11", "#text": "Code de la construction et de l'habitation. - art. L231-11 (V)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000006824503", "@num": "L231-12", "#text": "Code de la construction et de l'habitation. - art. L231-12 (M)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000006824504", "@num": "L231-13", "#text": "Code de la construction et de l'habitation. - art. L231-13 (M)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000006824505", "@num": "L231-13", "#text": "Code de la construction et de l'habitation. - art. L231-13 (V)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000027645777", "@num": "L231-13", "#text": "Code de la construction et de l'habitation. - art. L231-13 (VD)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000006824657", "@num": "L231-2", "#text": "Code de la construction et de l'habitation. - art. L231-2 (M)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000006824658", "@num": "L231-2", "#text": "Code de la construction et de l'habitation. - art. L231-2 (M)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000006824659", "@num": "L231-2", "#text": "Code de la construction et de l'habitation. - art. L231-2 (M)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000037667723", "@num": "L231-2", "#text": "Code de la construction et de l'habitation. - art. L231-2 (V)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000038433496", "@num": "L231-2", "#text": "Code de la construction et de l'habitation. - art. L231-2 (VD)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000041586856", "@num": "L231-2", "#text": "Code de la construction et de l'habitation. - art. L231-2 (VD)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000006824512", "@num": "L231-3", "#text": "Code de la construction et de l'habitation. - art. L231-3 (M)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000006824513", "@num": "L231-3", "#text": "Code de la construction et de l'habitation. - art. L231-3 (V)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000038433492", "@num": "L231-3", "#text": "Code de la construction et de l'habitation. - art. L231-3 (VD)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000006824494", "@num": "L231-4", "#text": "Code de la construction et de l'habitation. - art. L231-4 (V)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000006824495", "@num": "L231-5", "#text": "Code de la construction et de l'habitation. - art. L231-5 (V)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000006824496", "@num": "L231-6", "#text": "Code de la construction et de l'habitation. - art. L231-6 (M)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000006824497", "@num": "L231-6", "#text": "Code de la construction et de l'habitation. - art. L231-6 (V)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000027645773", "@num": "L231-6", "#text": "Code de la construction et de l'habitation. - art. L231-6 (VD)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000038433486", "@num": "L231-6", "#text": "Code de la construction et de l'habitation. - art. L231-6 (VD)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000006824498", "@num": "L231-7", "#text": "Code de la construction et de l'habitation. - art. L231-7 (V)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000006824499", "@num": "L231-8", "#text": "Code de la construction et de l'habitation. - art. L231-8 (V)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000041586850", "@num": "L231-8", "#text": "Code de la construction et de l'habitation. - art. L231-8 (VD)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000006824500", "@num": "L231-9", "#text": "Code de la construction et de l'habitation. - art. L231-9 (V)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000006824506", "@num": "L232-1", "#text": "Code de la construction et de l'habitation. - art. L232-1 (V)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000041586842", "@num": "L232-1", "#text": "Code de la construction et de l'habitation. - art. L232-1 (VD)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000006824507", "@num": "L232-2", "#text": "Code de la construction et de l'habitation. - art. L232-2 (V)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000006824515", "@num": "L241-1", "#text": "Code de la construction et de l'habitation. - art. L241-1 (M)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000006824516", "@num": "L241-1", "#text": "Code de la construction et de l'habitation. - art. L241-1 (M)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000006824514", "@num": "L241-1", "#text": "Code de la construction et de l'habitation. - art. L241-1 (M)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000006824517", "@num": "L241-1", "#text": "Code de la construction et de l'habitation. - art. L241-1 (V)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000006824518", "@num": "L241-2", "#text": "Code de la construction et de l'habitation. - art. L241-2 (M)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000006824519", "@num": "L241-2", "#text": "Code de la construction et de l'habitation. - art. L241-2 (V)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000006824662", "@num": "L241-3", "#text": "Code de la construction et de l'habitation. - art. L241-3 (M)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000006824661", "@num": "L241-3", "#text": "Code de la construction et de l'habitation. - art. L241-3 (M)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000006824660", "@num": "L241-3", "#text": "Code de la construction et de l'habitation. - art. L241-3 (M)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CREATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000006824660", "@num": "L241-3", "#text": "Code de la construction et de l'habitation. - art. L241-3 (M)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000006824663", "@num": "L241-3", "#text": "Code de la construction et de l'habitation. - art. L241-3 (V)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000028806974", "@num": "L241-3", "#text": "Code de la construction et de l'habitation. - art. L241-3 (V)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000006824520", "@num": "L241-4", "#text": "Code de la construction et de l'habitation. - art. L241-4 (V)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000006824522", "@num": "L241-5", "#text": "Code de la construction et de l'habitation. - art. L241-5 (M)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000006824521", "@num": "L241-5", "#text": "Code de la construction et de l'habitation. - art. L241-5 (M)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000006824523", "@num": "L241-5", "#text": "Code de la construction et de l'habitation. - art. L241-5 (V)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000006824525", "@num": "L241-6", "#text": "Code de la construction et de l'habitation. - art. L241-6 (M)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000006824524", "@num": "L241-6", "#text": "Code de la construction et de l'habitation. - art. L241-6 (M)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000006824526", "@num": "L241-6", "#text": "Code de la construction et de l'habitation. - art. L241-6 (V)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000006824527", "@num": "L241-7", "#text": "Code de la construction et de l'habitation. - art. L241-7 (M)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000006824528", "@num": "L241-7", "#text": "Code de la construction et de l'habitation. - art. L241-7 (V)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000006824529", "@num": "L241-8", "#text": "Code de la construction et de l'habitation. - art. L241-8 (M)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000006824530", "@num": "L241-8", "#text": "Code de la construction et de l'habitation. - art. L241-8 (M)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000006824531", "@num": "L241-8", "#text": "Code de la construction et de l'habitation. - art. L241-8 (V)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000024042460", "@num": "L241-8", "#text": "Code de la construction et de l'habitation. - art. L241-8 (V)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000037667923", "@num": "L241-8", "#text": "Code de la construction et de l'habitation. - art. L241-8 (V)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000032235569", "@num": "L241-8", "#text": "Code de la construction et de l'habitation. - art. L241-8 (VD)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000006824533", "@num": "L241-9", "#text": "Code de la construction et de l'habitation. - art. L241-9 (M)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000006824534", "@num": "L241-9", "#text": "Code de la construction et de l'habitation. - art. L241-9 (M)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000006824532", "@num": "L241-9", "#text": "Code de la construction et de l'habitation. - art. L241-9 (M)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000006824535", "@num": "L241-9", "#text": "Code de la construction et de l'habitation. - art. L241-9 (V)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000006824536", "@num": "L242-1", "#text": "Code de la construction et de l'habitation. - art. L242-1 (V)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000006824537", "@num": "L242-2", "#text": "Code de la construction et de l'habitation. - art. L242-2 (M)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000006824538", "@num": "L242-2", "#text": "Code de la construction et de l'habitation. - art. L242-2 (V)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000038433476", "@num": "L242-2", "#text": "Code de la construction et de l'habitation. - art. L242-2 (VD)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000006824655", "@num": "L242-3", "#text": "Code de la construction et de l'habitation. - art. L242-3 (M)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000006824656", "@num": "L242-3", "#text": "Code de la construction et de l'habitation. - art. L242-3 (V)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000006824539", "@num": "L242-4", "#text": "Code de la construction et de l'habitation. - art. L242-4 (V)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000006824540", "@num": "L251-1", "#text": "Code de la construction et de l'habitation. - art. L251-1 (M)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000006824541", "@num": "L251-1", "#text": "Code de la construction et de l'habitation. - art. L251-1 (M)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000006824542", "@num": "L251-1", "#text": "Code de la construction et de l'habitation. - art. L251-1 (V)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000006824543", "@num": "L251-2", "#text": "Code de la construction et de l'habitation. - art. L251-2 (M)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000006824544", "@num": "L251-2", "#text": "Code de la construction et de l'habitation. - art. L251-2 (M)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000006824545", "@num": "L251-2", "#text": "Code de la construction et de l'habitation. - art. L251-2 (V)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000006824546", "@num": "L251-3", "#text": "Code de la construction et de l'habitation. - art. L251-3 (M)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000006824547", "@num": "L251-3", "#text": "Code de la construction et de l'habitation. - art. L251-3 (M)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000006824548", "@num": "L251-3", "#text": "Code de la construction et de l'habitation. - art. L251-3 (V)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000006824550", "@num": "L251-4", "#text": "Code de la construction et de l'habitation. - art. L251-4 (M)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000006824549", "@num": "L251-4", "#text": "Code de la construction et de l'habitation. - art. L251-4 (M)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000006824551", "@num": "L251-4", "#text": "Code de la construction et de l'habitation. - art. L251-4 (V)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000006824665", "@num": "L251-5", "#text": "Code de la construction et de l'habitation. - art. L251-5 (M)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000006824666", "@num": "L251-5", "#text": "Code de la construction et de l'habitation. - art. L251-5 (M)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000006824664", "@num": "L251-5", "#text": "Code de la construction et de l'habitation. - art. L251-5 (M)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000006824667", "@num": "L251-5", "#text": "Code de la construction et de l'habitation. - art. L251-5 (V)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000039279916", "@num": "L251-5", "#text": "Code de la construction et de l'habitation. - art. L251-5 (VD)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000006824554", "@num": "L251-6", "#text": "Code de la construction et de l'habitation. - art. L251-6 (M)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000006824552", "@num": "L251-6", "#text": "Code de la construction et de l'habitation. - art. L251-6 (M)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000006824553", "@num": "L251-6", "#text": "Code de la construction et de l'habitation. - art. L251-6 (M)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000006824555", "@num": "L251-6", "#text": "Code de la construction et de l'habitation. - art. L251-6 (V)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000028808870", "@num": "L251-6", "#text": "Code de la construction et de l'habitation. - art. L251-6 (V)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000006824556", "@num": "L251-7", "#text": "Code de la construction et de l'habitation. - art. L251-7 (M)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000006824557", "@num": "L251-7", "#text": "Code de la construction et de l'habitation. - art. L251-7 (M)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000006824558", "@num": "L251-7", "#text": "Code de la construction et de l'habitation. - art. L251-7 (V)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000006824559", "@num": "L251-8", "#text": "Code de la construction et de l'habitation. - art. L251-8 (M)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000006824560", "@num": "L251-8", "#text": "Code de la construction et de l'habitation. - art. L251-8 (M)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000006824561", "@num": "L251-8", "#text": "Code de la construction et de l'habitation. - art. L251-8 (V)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000006824670", "@num": "L251-9", "#text": "Code de la construction et de l'habitation. - art. L251-9 (M)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000006824668", "@num": "L251-9", "#text": "Code de la construction et de l'habitation. - art. L251-9 (M)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000006824669", "@num": "L251-9", "#text": "Code de la construction et de l'habitation. - art. L251-9 (M)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000006824671", "@num": "L251-9", "#text": "Code de la construction et de l'habitation. - art. L251-9 (V)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000006824562", "@num": "L252-1", "#text": "Code de la construction et de l'habitation. - art. L252-1 (M)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000006824563", "@num": "L252-1", "#text": "Code de la construction et de l'habitation. - art. L252-1 (V)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000006824564", "@num": "L252-2", "#text": "Code de la construction et de l'habitation. - art. L252-2 (M)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000006824565", "@num": "L252-2", "#text": "Code de la construction et de l'habitation. - art. L252-2 (V)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000006824566", "@num": "L252-3", "#text": "Code de la construction et de l'habitation. - art. L252-3 (M)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000006824567", "@num": "L252-3", "#text": "Code de la construction et de l'habitation. - art. L252-3 (V)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000028807807", "@num": "L252-3", "#text": "Code de la construction et de l'habitation. - art. L252-3 (V)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000038834032", "@num": "L252-3", "#text": "Code de la construction et de l'habitation. - art. L252-3 (VD)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000006824568", "@num": "L252-4", "#text": "Code de la construction et de l'habitation. - art. L252-4 (M)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000006824569", "@num": "L252-4", "#text": "Code de la construction et de l'habitation. - art. L252-4 (V)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000028807804", "@num": "L252-4", "#text": "Code de la construction et de l'habitation. - art. L252-4 (V)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000006824570", "@num": "L253-1", "#text": "Code de la construction et de l'habitation. - art. L253-1 (V)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000006824571", "@num": "L253-2", "#text": "Code de la construction et de l'habitation. - art. L253-2 (V)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000028807822", "@num": "L253-2", "#text": "Code de la construction et de l'habitation. - art. L253-2 (V)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000038834025", "@num": "L253-2", "#text": "Code de la construction et de l'habitation. - art. L253-2 (VD)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000006824572", "@num": "L253-3", "#text": "Code de la construction et de l'habitation. - art. L253-3 (V)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000006824573", "@num": "L253-4", "#text": "Code de la construction et de l'habitation. - art. L253-4 (V)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000006824574", "@num": "L253-5", "#text": "Code de la construction et de l'habitation. - art. L253-5 (V)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000028807829", "@num": "L253-5", "#text": "Code de la construction et de l'habitation. - art. L253-5 (V)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000006824575", "@num": "L253-6", "#text": "Code de la construction et de l'habitation. - art. L253-6 (V)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000006824576", "@num": "L253-7", "#text": "Code de la construction et de l'habitation. - art. L253-7 (V)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000006824577", "@num": "L253-8", "#text": "Code de la construction et de l'habitation. - art. L253-8 (M)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000037670834", "@num": "L253-8", "#text": "Code de la construction et de l'habitation. - art. L253-8 (V)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000006824578", "@num": "L261-1", "#text": "Code de la construction et de l'habitation. - art. L261-1 (M)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000006824579", "@num": "L261-1", "#text": "Code de la construction et de l'habitation. - art. L261-1 (V)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000006824597", "@num": "L261-10", "#text": "Code de la construction et de l'habitation. - art. L261-10 (M)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000006824598", "@num": "L261-10", "#text": "Code de la construction et de l'habitation. - art. L261-10 (M)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000006824599", "@num": "L261-10", "#text": "Code de la construction et de l'habitation. - art. L261-10 (V)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000006824672", "@num": "L261-11", "#text": "Code de la construction et de l'habitation. - art. L261-11 (M)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000006824673", "@num": "L261-11", "#text": "Code de la construction et de l'habitation. - art. L261-11 (M)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000006824674", "@num": "L261-11", "#text": "Code de la construction et de l'habitation. - art. L261-11 (M)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000006824675", "@num": "L261-11", "#text": "Code de la construction et de l'habitation. - art. L261-11 (V)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000024025873", "@num": "L261-11", "#text": "Code de la construction et de l'habitation. - art. L261-11 (V)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000037667798", "@num": "L261-11", "#text": "Code de la construction et de l'habitation. - art. L261-11 (V)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000028028659", "@num": "L261-11", "#text": "Code de la construction et de l'habitation. - art. L261-11 (VD)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000006824600", "@num": "L261-11-1", "#text": "Code de la construction et de l'habitation. - art. L261-11-1 (M)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000006824601", "@num": "L261-11-1", "#text": "Code de la construction et de l'habitation. - art. L261-11-1 (V)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000028574443", "@num": "L261-11-1", "#text": "Code de la construction et de l'habitation. - art. L261-11-1 (V)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000006824602", "@num": "L261-12", "#text": "Code de la construction et de l'habitation. - art. L261-12 (M)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000006824603", "@num": "L261-12", "#text": "Code de la construction et de l'habitation. - art. L261-12 (V)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000006824605", "@num": "L261-13", "#text": "Code de la construction et de l'habitation. - art. L261-13 (M)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000006824604", "@num": "L261-13", "#text": "Code de la construction et de l'habitation. - art. L261-13 (M)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000006824606", "@num": "L261-13", "#text": "Code de la construction et de l'habitation. - art. L261-13 (V)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000032042863", "@num": "L261-13", "#text": "Code de la construction et de l'habitation. - art. L261-13 (VD)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000006824607", "@num": "L261-14", "#text": "Code de la construction et de l'habitation. - art. L261-14 (M)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000006824608", "@num": "L261-14", "#text": "Code de la construction et de l'habitation. - art. L261-14 (V)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000006824677", "@num": "L261-15", "#text": "Code de la construction et de l'habitation. - art. L261-15 (M)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000006824678", "@num": "L261-15", "#text": "Code de la construction et de l'habitation. - art. L261-15 (M)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000006824676", "@num": "L261-15", "#text": "Code de la construction et de l'habitation. - art. L261-15 (M)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000006824679", "@num": "L261-15", "#text": "Code de la construction et de l'habitation. - art. L261-15 (M)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000006824609", "@num": "L261-16", "#text": "Code de la construction et de l'habitation. - art. L261-16 (M)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000006824610", "@num": "L261-16", "#text": "Code de la construction et de l'habitation. - art. L261-16 (V)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000006824613", "@num": "L261-17", "#text": "Code de la construction et de l'habitation. - art. L261-17 (Ab)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000006824612", "@num": "L261-17", "#text": "Code de la construction et de l'habitation. - art. L261-17 (M)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000006824611", "@num": "L261-17", "#text": "Code de la construction et de l'habitation. - art. L261-17 (M)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000006824615", "@num": "L261-18", "#text": "Code de la construction et de l'habitation. - art. L261-18 (Ab)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000006824614", "@num": "L261-18", "#text": "Code de la construction et de l'habitation. - art. L261-18 (M)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000006824616", "@num": "L261-19", "#text": "Code de la construction et de l'habitation. - art. L261-19 (Ab)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000006824580", "@num": "L261-2", "#text": "Code de la construction et de l'habitation. - art. L261-2 (M)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000006824581", "@num": "L261-2", "#text": "Code de la construction et de l'habitation. - art. L261-2 (V)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000006824617", "@num": "L261-20", "#text": "Code de la construction et de l'habitation. - art. L261-20 (Ab)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000006824619", "@num": "L261-21", "#text": "Code de la construction et de l'habitation. - art. L261-21 (Ab)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000006824618", "@num": "L261-21", "#text": "Code de la construction et de l'habitation. - art. L261-21 (M)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000006824620", "@num": "L261-22", "#text": "Code de la construction et de l'habitation. - art. L261-22 (M)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000006824621", "@num": "L261-22", "#text": "Code de la construction et de l'habitation. - art. L261-22 (V)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000006824582", "@num": "L261-3", "#text": "Code de la construction et de l'habitation. - art. L261-3 (M)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000006824583", "@num": "L261-3", "#text": "Code de la construction et de l'habitation. - art. L261-3 (V)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000006824584", "@num": "L261-4", "#text": "Code de la construction et de l'habitation. - art. L261-4 (M)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000006824585", "@num": "L261-4", "#text": "Code de la construction et de l'habitation. - art. L261-4 (V)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000006824586", "@num": "L261-5", "#text": "Code de la construction et de l'habitation. - art. L261-5 (M)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000006824587", "@num": "L261-5", "#text": "Code de la construction et de l'habitation. - art. L261-5 (M)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000006824588", "@num": "L261-6", "#text": "Code de la construction et de l'habitation. - art. L261-6 (M)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000006824589", "@num": "L261-6", "#text": "Code de la construction et de l'habitation. - art. L261-6 (V)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000006824590", "@num": "L261-7", "#text": "Code de la construction et de l'habitation. - art. L261-7 (M)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000006824591", "@num": "L261-7", "#text": "Code de la construction et de l'habitation. - art. L261-7 (M)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000006824593", "@num": "L261-8", "#text": "Code de la construction et de l'habitation. - art. L261-8 (M)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000006824592", "@num": "L261-8", "#text": "Code de la construction et de l'habitation. - art. L261-8 (M)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000006824594", "@num": "L261-8", "#text": "Code de la construction et de l'habitation. - art. L261-8 (V)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000006824595", "@num": "L261-9", "#text": "Code de la construction et de l'habitation. - art. L261-9 (M)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000006824596", "@num": "L261-9", "#text": "Code de la construction et de l'habitation. - art. L261-9 (V)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000006824622", "@num": "L262-1", "#text": "Code de la construction et de l'habitation. - art. L262-1 (V)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000006824631", "@num": "L262-10", "#text": "Code de la construction et de l'habitation. - art. L262-10 (V)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000006824632", "@num": "L262-11", "#text": "Code de la construction et de l'habitation. - art. L262-11 (V)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000006824623", "@num": "L262-2", "#text": "Code de la construction et de l'habitation. - art. L262-2 (V)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000041586824", "@num": "L262-2", "#text": "Code de la construction et de l'habitation. - art. L262-2 (VD)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000006824624", "@num": "L262-3", "#text": "Code de la construction et de l'habitation. - art. L262-3 (V)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000006824625", "@num": "L262-4", "#text": "Code de la construction et de l'habitation. - art. L262-4 (V)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000041586816", "@num": "L262-4", "#text": "Code de la construction et de l'habitation. - art. L262-4 (VD)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000006824626", "@num": "L262-5", "#text": "Code de la construction et de l'habitation. - art. L262-5 (V)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000028574438", "@num": "L262-5", "#text": "Code de la construction et de l'habitation. - art. L262-5 (V)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000006824627", "@num": "L262-6", "#text": "Code de la construction et de l'habitation. - art. L262-6 (V)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000006824628", "@num": "L262-7", "#text": "Code de la construction et de l'habitation. - art. L262-7 (V)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000037667787", "@num": "L262-7", "#text": "Code de la construction et de l'habitation. - art. L262-7 (V)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000027645782", "@num": "L262-7", "#text": "Code de la construction et de l'habitation. - art. L262-7 (VD)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000006824629", "@num": "L262-8", "#text": "Code de la construction et de l'habitation. - art. L262-8 (V)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000006824630", "@num": "L262-9", "#text": "Code de la construction et de l'habitation. - art. L262-9 (V)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000006824633", "@num": "L263-1", "#text": "Code de la construction et de l'habitation. - art. L263-1 (V)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000006824634", "@num": "L263-2", "#text": "Code de la construction et de l'habitation. - art. L263-2 (V)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000006824635", "@num": "L263-3", "#text": "Code de la construction et de l'habitation. - art. L263-3 (V)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000006824637", "@num": "L271-1", "#text": "Code de la construction et de l'habitation. - art. L271-1 (M)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000006824638", "@num": "L271-1", "#text": "Code de la construction et de l'habitation. - art. L271-1 (M)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000006824639", "@num": "L271-1", "#text": "Code de la construction et de l'habitation. - art. L271-1 (M)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000031012919", "@num": "L271-1", "#text": "Code de la construction et de l'habitation. - art. L271-1 (M)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000006824636", "@num": "L271-1", "#text": "Code de la construction et de l'habitation. - art. L271-1 (T)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000037667917", "@num": "L271-1", "#text": "Code de la construction et de l'habitation. - art. L271-1 (V)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000006824641", "@num": "L271-2", "#text": "Code de la construction et de l'habitation. - art. L271-2 (M)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000006824640", "@num": "L271-2", "#text": "Code de la construction et de l'habitation. - art. L271-2 (M)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000006824642", "@num": "L271-2", "#text": "Code de la construction et de l'habitation. - art. L271-2 (M)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000031012910", "@num": "L271-2", "#text": "Code de la construction et de l'habitation. - art. L271-2 (V)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000006824643", "@num": "L271-3", "#text": "Code de la construction et de l'habitation. - art. L271-3 (M)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000006824644", "@num": "L271-3", "#text": "Code de la construction et de l'habitation. - art. L271-3 (V)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000006824645", "@num": "L271-4", "#text": "Code de la construction et de l'habitation. - art. L271-4 (M)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000006824646", "@num": "L271-4", "#text": "Code de la construction et de l'habitation. - art. L271-4 (M)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000006824647", "@num": "L271-4", "#text": "Code de la construction et de l'habitation. - art. L271-4 (V)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000006824648", "@num": "L271-5", "#text": "Code de la construction et de l'habitation. - art. L271-5 (M)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000006824649", "@num": "L271-5", "#text": "Code de la construction et de l'habitation. - art. L271-5 (M)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000006824650", "@num": "L271-5", "#text": "Code de la construction et de l'habitation. - art. L271-5 (V)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000043978261", "@num": "L271-5", "#text": "Code de la construction et de l'habitation. - art. L271-5 (VD)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000006824651", "@num": "L271-6", "#text": "Code de la construction et de l'habitation. - art. L271-6 (M)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000006824652", "@num": "L271-6", "#text": "Code de la construction et de l'habitation. - art. L271-6 (V)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000006824653", "@num": "L281-1", "#text": "Code de la construction et de l'habitation. - art. L281-1 (MMN)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000006824654", "@num": "L281-1", "#text": "Code de la construction et de l'habitation. - art. L281-1 (V)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000025760489", "@num": "L281-1", "#text": "Code de la construction et de l'habitation. - art. L281-1 (V)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000006824680", "@num": "L300-1", "#text": "Code de la construction et de l'habitation. - art. L300-1 (V)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000006824681", "@num": "L301-1", "#text": "Code de la construction et de l'habitation. - art. L301-1 (M)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000006824682", "@num": "L301-1", "#text": "Code de la construction et de l'habitation. - art. L301-1 (M)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000006824683", "@num": "L301-1", "#text": "Code de la construction et de l'habitation. - art. L301-1 (M)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000006824684", "@num": "L301-1", "#text": "Code de la construction et de l'habitation. - art. L301-1 (M)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000037667771", "@num": "L301-1", "#text": "Code de la construction et de l'habitation. - art. L301-1 (V)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000006824733", "@num": "L301-2", "#text": "Code de la construction et de l'habitation. - art. L301-2 (M)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000006824734", "@num": "L301-2", "#text": "Code de la construction et de l'habitation. - art. L301-2 (M)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000006824735", "@num": "L301-2", "#text": "Code de la construction et de l'habitation. - art. L301-2 (V)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000028808838", "@num": "L301-2", "#text": "Code de la construction et de l'habitation. - art. L301-2 (V)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000006824766", "@num": "L302-1", "#text": "Code de la construction et de l'habitation. - art. L302-1 (M)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000006824764", "@num": "L302-1", "#text": "Code de la construction et de l'habitation. - art. L302-1 (M)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000006824767", "@num": "L302-1", "#text": "Code de la construction et de l'habitation. - art. L302-1 (M)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000006824765", "@num": "L302-1", "#text": "Code de la construction et de l'habitation. - art. L302-1 (M)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000006824768", "@num": "L302-1", "#text": "Code de la construction et de l'habitation. - art. L302-1 (M)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000006824763", "@num": "L302-1", "#text": "Code de la construction et de l'habitation. - art. L302-1 (M)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000006824769", "@num": "L302-1", "#text": "Code de la construction et de l'habitation. - art. L302-1 (M)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000006824770", "@num": "L302-1", "#text": "Code de la construction et de l'habitation. - art. L302-1 (V)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000006824788", "@num": "L302-10", "#text": "Code de la construction et de l'habitation. - art. L302-10 (Ab)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000006824789", "@num": "L302-10", "#text": "Code de la construction et de l'habitation. - art. L302-10 (M)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000006824790", "@num": "L302-10", "#text": "Code de la construction et de l'habitation. - art. L302-10 (M)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000049392211", "@num": "L302-10", "#text": "Code de la construction et de l'habitation. - art. L302-10 (V)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000006824793", "@num": "L302-11", "#text": "Code de la construction et de l'habitation. - art. L302-11 (M)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000006824794", "@num": "L302-11", "#text": "Code de la construction et de l'habitation. - art. L302-11 (V)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000006824795", "@num": "L302-12", "#text": "Code de la construction et de l'habitation. - art. L302-12 (M)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000006824796", "@num": "L302-12", "#text": "Code de la construction et de l'habitation. - art. L302-12 (V)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000027573599", "@num": "L302-12", "#text": "Code de la construction et de l'habitation. - art. L302-12 (VD)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000033463255", "@num": "L302-12", "#text": "Code de la construction et de l'habitation. - art. L302-12 (VD)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000028807158", "@num": "L302-12", "#text": "Code de la construction et de l'habitation. - art. L302-12 (VT)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000006824685", "@num": "L302-2", "#text": "Code de la construction et de l'habitation. - art. L302-2 (M)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000006824686", "@num": "L302-2", "#text": "Code de la construction et de l'habitation. - art. L302-2 (M)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000006824687", "@num": "L302-2", "#text": "Code de la construction et de l'habitation. - art. L302-2 (M)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000006824688", "@num": "L302-2", "#text": "Code de la construction et de l'habitation. - art. L302-2 (M)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000006824689", "@num": "L302-2", "#text": "Code de la construction et de l'habitation. - art. L302-2 (V)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000006824774", "@num": "L302-3", "#text": "Code de la construction et de l'habitation. - art. L302-3 (M)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000006824773", "@num": "L302-3", "#text": "Code de la construction et de l'habitation. - art. L302-3 (M)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000006824775", "@num": "L302-3", "#text": "Code de la construction et de l'habitation. - art. L302-3 (V)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000006824690", "@num": "L302-4", "#text": "Code de la construction et de l'habitation. - art. L302-4 (M)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000006824692", "@num": "L302-4", "#text": "Code de la construction et de l'habitation. - art. L302-4 (M)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000006824694", "@num": "L302-4", "#text": "Code de la construction et de l'habitation. - art. L302-4 (M)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000006824691", "@num": "L302-4", "#text": "Code de la construction et de l'habitation. - art. L302-4 (M)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000006824693", "@num": "L302-4", "#text": "Code de la construction et de l'habitation. - art. L302-4 (M)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000006824695", "@num": "L302-4", "#text": "Code de la construction et de l'habitation. - art. L302-4 (V)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000006824772", "@num": "L302-4-1", "#text": "Code de la construction et de l'habitation. - art. L302-4-1 (Ab)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000006824771", "@num": "L302-4-1", "#text": "Code de la construction et de l'habitation. - art. L302-4-1 (M)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000006824699", "@num": "L302-5", "#text": "Code de la construction et de l'habitation. - art. L302-5 (M)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000006824697", "@num": "L302-5", "#text": "Code de la construction et de l'habitation. - art. L302-5 (M)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000006824704", "@num": "L302-5", "#text": "Code de la construction et de l'habitation. - art. L302-5 (M)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000006824701", "@num": "L302-5", "#text": "Code de la construction et de l'habitation. - art. L302-5 (M)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000006824702", "@num": "L302-5", "#text": "Code de la construction et de l'habitation. - art. L302-5 (M)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000006824700", "@num": "L302-5", "#text": "Code de la construction et de l'habitation. - art. L302-5 (M)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000006824703", "@num": "L302-5", "#text": "Code de la construction et de l'habitation. - art. L302-5 (M)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000006824696", "@num": "L302-5", "#text": "Code de la construction et de l'habitation. - art. L302-5 (M)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000006824698", "@num": "L302-5", "#text": "Code de la construction et de l'habitation. - art. L302-5 (M)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000033972991", "@num": "L302-5", "#text": "Code de la construction et de l'habitation. - art. L302-5 (M)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000030957872", "@num": "L302-5", "#text": "Code de la construction et de l'habitation. - art. L302-5 (MMN)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000006824705", "@num": "L302-5", "#text": "Code de la construction et de l'habitation. - art. L302-5 (V)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000023259643", "@num": "L302-5", "#text": "Code de la construction et de l'habitation. - art. L302-5 (V)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000026968785", "@num": "L302-5", "#text": "Code de la construction et de l'habitation. - art. L302-5 (V)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000037670560", "@num": "L302-5", "#text": "Code de la construction et de l'habitation. - art. L302-5 (V)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000038833969", "@num": "L302-5", "#text": "Code de la construction et de l'habitation. - art. L302-5 (VD)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000031019858", "@num": "L302-5", "#text": "Code de la construction et de l'habitation. - art. L302-5 (VT)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000038891453", "@num": "L302-5", "#text": "Code de la construction et de l'habitation. - art. L302-5 (VT)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000045211110", "@num": "L302-5", "#text": "Code de la construction et de l'habitation. - art. L302-5 (VT)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000006824709", "@num": "L302-5-1", "#text": "Code de la construction et de l'habitation. - art. L302-5-1 (Ab)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000006824708", "@num": "L302-5-1", "#text": "Code de la construction et de l'habitation. - art. L302-5-1 (Ab)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000006824706", "@num": "L302-5-1", "#text": "Code de la construction et de l'habitation. - art. L302-5-1 (M)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000006824707", "@num": "L302-5-1", "#text": "Code de la construction et de l'habitation. - art. L302-5-1 (M)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000006824713", "@num": "L302-6", "#text": "Code de la construction et de l'habitation. - art. L302-6 (M)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000006824716", "@num": "L302-6", "#text": "Code de la construction et de l'habitation. - art. L302-6 (M)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000006824714", "@num": "L302-6", "#text": "Code de la construction et de l'habitation. - art. L302-6 (M)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000006824711", "@num": "L302-6", "#text": "Code de la construction et de l'habitation. - art. L302-6 (M)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000006824710", "@num": "L302-6", "#text": "Code de la construction et de l'habitation. - art. L302-6 (M)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000006824712", "@num": "L302-6", "#text": "Code de la construction et de l'habitation. - art. L302-6 (M)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000006824715", "@num": "L302-6", "#text": "Code de la construction et de l'habitation. - art. L302-6 (M)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000026968805", "@num": "L302-6", "#text": "Code de la construction et de l'habitation. - art. L302-6 (M)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000033972983", "@num": "L302-6", "#text": "Code de la construction et de l'habitation. - art. L302-6 (M)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000006824717", "@num": "L302-6", "#text": "Code de la construction et de l'habitation. - art. L302-6 (V)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000037670601", "@num": "L302-6", "#text": "Code de la construction et de l'habitation. - art. L302-6 (V)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000006824722", "@num": "L302-7", "#text": "Code de la construction et de l'habitation. - art. L302-7 (M)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000006824721", "@num": "L302-7", "#text": "Code de la construction et de l'habitation. - art. L302-7 (M)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000006824718", "@num": "L302-7", "#text": "Code de la construction et de l'habitation. - art. L302-7 (M)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000006824723", "@num": "L302-7", "#text": "Code de la construction et de l'habitation. - art. L302-7 (M)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000006824719", "@num": "L302-7", "#text": "Code de la construction et de l'habitation. - art. L302-7 (M)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000006824720", "@num": "L302-7", "#text": "Code de la construction et de l'habitation. - art. L302-7 (M)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000006824724", "@num": "L302-7", "#text": "Code de la construction et de l'habitation. - art. L302-7 (V)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000006824728", "@num": "L302-8", "#text": "Code de la construction et de l'habitation. - art. L302-8 (M)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000006824730", "@num": "L302-8", "#text": "Code de la construction et de l'habitation. - art. L302-8 (M)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000006824731", "@num": "L302-8", "#text": "Code de la construction et de l'habitation. - art. L302-8 (M)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000006824727", "@num": "L302-8", "#text": "Code de la construction et de l'habitation. - art. L302-8 (M)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000006824729", "@num": "L302-8", "#text": "Code de la construction et de l'habitation. - art. L302-8 (M)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000006824725", "@num": "L302-8", "#text": "Code de la construction et de l'habitation. - art. L302-8 (M)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000006824726", "@num": "L302-8", "#text": "Code de la construction et de l'habitation. - art. L302-8 (M)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000028809066", "@num": "L302-8", "#text": "Code de la construction et de l'habitation. - art. L302-8 (M)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000033972966", "@num": "L302-8", "#text": "Code de la construction et de l'habitation. - art. L302-8 (M)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000037670621", "@num": "L302-8", "#text": "Code de la construction et de l'habitation. - art. L302-8 (M)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000006824732", "@num": "L302-8", "#text": "Code de la construction et de l'habitation. - art. L302-8 (V)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000023259627", "@num": "L302-8", "#text": "Code de la construction et de l'habitation. - art. L302-8 (V)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000026968822", "@num": "L302-8", "#text": "Code de la construction et de l'habitation. - art. L302-8 (V)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000045211201", "@num": "L302-8", "#text": "Code de la construction et de l'habitation. - art. L302-8 (V)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000006824778", "@num": "L302-9", "#text": "Code de la construction et de l'habitation. - art. L302-9 (M)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000006824779", "@num": "L302-9", "#text": "Code de la construction et de l'habitation. - art. L302-9 (M)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000006824776", "@num": "L302-9", "#text": "Code de la construction et de l'habitation. - art. L302-9 (M)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000006824777", "@num": "L302-9", "#text": "Code de la construction et de l'habitation. - art. L302-9 (M)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000006824780", "@num": "L302-9", "#text": "Code de la construction et de l'habitation. - art. L302-9 (V)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000028807170", "@num": "L302-9", "#text": "Code de la construction et de l'habitation. - art. L302-9 (V)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000006824783", "@num": "L302-9-1", "#text": "Code de la construction et de l'habitation. - art. L302-9-1 (M)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000006824781", "@num": "L302-9-1", "#text": "Code de la construction et de l'habitation. - art. L302-9-1 (M)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000006824782", "@num": "L302-9-1", "#text": "Code de la construction et de l'habitation. - art. L302-9-1 (M)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000033973187", "@num": "L302-9-1", "#text": "Code de la construction et de l'habitation. - art. L302-9-1 (M)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000006824784", "@num": "L302-9-1", "#text": "Code de la construction et de l'habitation. - art. L302-9-1 (V)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000026968829", "@num": "L302-9-1", "#text": "Code de la construction et de l'habitation. - art. L302-9-1 (V)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000028634242", "@num": "L302-9-1", "#text": "Code de la construction et de l'habitation. - art. L302-9-1 (V)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000028807161", "@num": "L302-9-1", "#text": "Code de la construction et de l'habitation. - art. L302-9-1 (V)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000045211229", "@num": "L302-9-1", "#text": "Code de la construction et de l'habitation. - art. L302-9-1 (V)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000031782465", "@num": "L302-9-1", "#text": "Code de la construction et de l'habitation. - art. L302-9-1 (VD)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000006824791", "@num": "L302-9-1-1", "#text": "Code de la construction et de l'habitation. - art. L302-9-1-1 (M)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000006824792", "@num": "L302-9-1-1", "#text": "Code de la construction et de l'habitation. - art. L302-9-1-1 (V)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000006824785", "@num": "L302-9-2", "#text": "Code de la construction et de l'habitation. - art. L302-9-2 (M)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000006824786", "@num": "L302-9-2", "#text": "Code de la construction et de l'habitation. - art. L302-9-2 (M)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000006824787", "@num": "L302-9-2", "#text": "Code de la construction et de l'habitation. - art. L302-9-2 (V)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000025760512", "@num": "L302-9-2", "#text": "Code de la construction et de l'habitation. - art. L302-9-2 (V)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000006824799", "@num": "L303-1", "#text": "Code de la construction et de l'habitation. - art. L303-1 (M)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000006824797", "@num": "L303-1", "#text": "Code de la construction et de l'habitation. - art. L303-1 (M)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000006824800", "@num": "L303-1", "#text": "Code de la construction et de l'habitation. - art. L303-1 (M)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000006824798", "@num": "L303-1", "#text": "Code de la construction et de l'habitation. - art. L303-1 (M)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000006824801", "@num": "L303-1", "#text": "Code de la construction et de l'habitation. - art. L303-1 (V)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000033974796", "@num": "L303-1", "#text": "Code de la construction et de l'habitation. - art. L303-1 (V)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000029945370", "@num": "L303-1", "#text": "Code de la construction et de l'habitation. - art. L303-1 (VD)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000006824802", "@num": "L311-1", "#text": "Code de la construction et de l'habitation. - art. L311-1 (V)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000006824816", "@num": "L311-10", "#text": "Code de la construction et de l'habitation. - art. L311-10 (V)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000006824817", "@num": "L311-11", "#text": "Code de la construction et de l'habitation. - art. L311-11 (V)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CREATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000006824817", "@num": "L311-11", "#text": "Code de la construction et de l'habitation. - art. L311-11 (V)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000006824818", "@num": "L311-12", "#text": "Code de la construction et de l'habitation. - art. L311-12 (V)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000006824819", "@num": "L311-13", "#text": "Code de la construction et de l'habitation. - art. L311-13 (M)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000006824820", "@num": "L311-13", "#text": "Code de la construction et de l'habitation. - art. L311-13 (M)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000006824821", "@num": "L311-13", "#text": "Code de la construction et de l'habitation. - art. L311-13 (V)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000006824822", "@num": "L311-14", "#text": "Code de la construction et de l'habitation. - art. L311-14 (Ab)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000006824803", "@num": "L311-2", "#text": "Code de la construction et de l'habitation. - art. L311-2 (V)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000006824806", "@num": "L311-3", "#text": "Code de la construction et de l'habitation. - art. L311-3 (M)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000006824807", "@num": "L311-3", "#text": "Code de la construction et de l'habitation. - art. L311-3 (M)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000006824808", "@num": "L311-3", "#text": "Code de la construction et de l'habitation. - art. L311-3 (V)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000006824804", "@num": "L311-4", "#text": "Code de la construction et de l'habitation. - art. L311-4 (V)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000006824810", "@num": "L311-5", "#text": "Code de la construction et de l'habitation. - art. L311-5 (M)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000006824809", "@num": "L311-5", "#text": "Code de la construction et de l'habitation. - art. L311-5 (M)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000006824811", "@num": "L311-5", "#text": "Code de la construction et de l'habitation. - art. L311-5 (V)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000006824812", "@num": "L311-6", "#text": "Code de la construction et de l'habitation. - art. L311-6 (M)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000006824813", "@num": "L311-6", "#text": "Code de la construction et de l'habitation. - art. L311-6 (V)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000006824805", "@num": "L311-7", "#text": "Code de la construction et de l'habitation. - art. L311-7 (V)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000006824814", "@num": "L311-8", "#text": "Code de la construction et de l'habitation. - art. L311-8 (V)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000006824815", "@num": "L311-9", "#text": "Code de la construction et de l'habitation. - art. L311-9 (Ab)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000006825053", "@num": "L312-1", "#text": "Code de la construction et de l'habitation. - art. L312-1 (M)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000006825052", "@num": "L312-1", "#text": "Code de la construction et de l'habitation. - art. L312-1 (M)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000006825055", "@num": "L312-1", "#text": "Code de la construction et de l'habitation. - art. L312-1 (M)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000006825051", "@num": "L312-1", "#text": "Code de la construction et de l'habitation. - art. L312-1 (M)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000006825054", "@num": "L312-1", "#text": "Code de la construction et de l'habitation. - art. L312-1 (M)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000006825056", "@num": "L312-1", "#text": "Code de la construction et de l'habitation. - art. L312-1 (V)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000041471383", "@num": "L312-1", "#text": "Code de la construction et de l'habitation. - art. L312-1 (V)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000027645785", "@num": "L312-1", "#text": "Code de la construction et de l'habitation. - art. L312-1 (VD)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000006825060", "@num": "L312-2", "#text": "Code de la construction et de l'habitation. - art. L312-2 (AbD)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000006825059", "@num": "L312-2", "#text": "Code de la construction et de l'habitation. - art. L312-2 (M)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000006825058", "@num": "L312-2", "#text": "Code de la construction et de l'habitation. - art. L312-2 (M)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000006825057", "@num": "L312-2", "#text": "Code de la construction et de l'habitation. - art. L312-2 (M)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000006825061", "@num": "L312-2", "#text": "Code de la construction et de l'habitation. - art. L312-2 (VD)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000006824823", "@num": "L312-2-1", "#text": "Code de la construction et de l'habitation. - art. L312-2-1 (M)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000006824824", "@num": "L312-2-1", "#text": "Code de la construction et de l'habitation. - art. L312-2-1 (V)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000006825063", "@num": "L312-3", "#text": "Code de la construction et de l'habitation. - art. L312-3 (M)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000006825062", "@num": "L312-3", "#text": "Code de la construction et de l'habitation. - art. L312-3 (M)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000006825064", "@num": "L312-3", "#text": "Code de la construction et de l'habitation. - art. L312-3 (V)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000038833965", "@num": "L312-3", "#text": "Code de la construction et de l'habitation. - art. L312-3 (VD)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000006824825", "@num": "L312-4", "#text": "Code de la construction et de l'habitation. - art. L312-4 (M)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000006824826", "@num": "L312-4", "#text": "Code de la construction et de l'habitation. - art. L312-4 (V)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000027573595", "@num": "L312-4", "#text": "Code de la construction et de l'habitation. - art. L312-4 (VD)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000006825065", "@num": "L312-5", "#text": "Code de la construction et de l'habitation. - art. L312-5 (M)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000006825066", "@num": "L312-5", "#text": "Code de la construction et de l'habitation. - art. L312-5 (M)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000006825067", "@num": "L312-5", "#text": "Code de la construction et de l'habitation. - art. L312-5 (V)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000006825068", "@num": "L312-6", "#text": "Code de la construction et de l'habitation. - art. L312-6 (M)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000006825069", "@num": "L312-6", "#text": "Code de la construction et de l'habitation. - art. L312-6 (M)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000006825070", "@num": "L312-6", "#text": "Code de la construction et de l'habitation. - art. L312-6 (V)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000006825146", "@num": "L313-1", "#text": "Code de la construction et de l'habitation. - art. L313-1 (An)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000006825133", "@num": "L313-1", "#text": "Code de la construction et de l'habitation. - art. L313-1 (M)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000006825134", "@num": "L313-1", "#text": "Code de la construction et de l'habitation. - art. L313-1 (M)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000006825141", "@num": "L313-1", "#text": "Code de la construction et de l'habitation. - art. L313-1 (M)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000006825132", "@num": "L313-1", "#text": "Code de la construction et de l'habitation. - art. L313-1 (M)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000006825142", "@num": "L313-1", "#text": "Code de la construction et de l'habitation. - art. L313-1 (M)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000006825145", "@num": "L313-1", "#text": "Code de la construction et de l'habitation. - art. L313-1 (M)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000006825138", "@num": "L313-1", "#text": "Code de la construction et de l'habitation. - art. L313-1 (M)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000006825135", "@num": "L313-1", "#text": "Code de la construction et de l'habitation. - art. L313-1 (M)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000006825140", "@num": "L313-1", "#text": "Code de la construction et de l'habitation. - art. L313-1 (M)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000006825136", "@num": "L313-1", "#text": "Code de la construction et de l'habitation. - art. L313-1 (M)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000006825137", "@num": "L313-1", "#text": "Code de la construction et de l'habitation. - art. L313-1 (M)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000006825143", "@num": "L313-1", "#text": "Code de la construction et de l'habitation. - art. L313-1 (M)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000006825144", "@num": "L313-1", "#text": "Code de la construction et de l'habitation. - art. L313-1 (M)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000006825139", "@num": "L313-1", "#text": "Code de la construction et de l'habitation. - art. L313-1 (M)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000006825147", "@num": "L313-1", "#text": "Code de la construction et de l'habitation. - art. L313-1 (V)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000006824832", "@num": "L313-1-1", "#text": "Code de la construction et de l'habitation. - art. L313-1-1 (T)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000006824833", "@num": "L313-1-2", "#text": "Code de la construction et de l'habitation. - art. L313-1-2 (T)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000006824834", "@num": "L313-1-3", "#text": "Code de la construction et de l'habitation. - art. L313-1-3 (T)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000006824860", "@num": "L313-10", "#text": "Code de la construction et de l'habitation. - art. L313-10 (M)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000006824859", "@num": "L313-10", "#text": "Code de la construction et de l'habitation. - art. L313-10 (M)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000006824861", "@num": "L313-10", "#text": "Code de la construction et de l'habitation. - art. L313-10 (V)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000006824862", "@num": "L313-11", "#text": "Code de la construction et de l'habitation. - art. L313-11 (M)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000006824863", "@num": "L313-11", "#text": "Code de la construction et de l'habitation. - art. L313-11 (M)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000006824864", "@num": "L313-11", "#text": "Code de la construction et de l'habitation. - art. L313-11 (V)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000006824866", "@num": "L313-12", "#text": "Code de la construction et de l'habitation. - art. L313-12 (M)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000006824865", "@num": "L313-12", "#text": "Code de la construction et de l'habitation. - art. L313-12 (M)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000006824867", "@num": "L313-12", "#text": "Code de la construction et de l'habitation. - art. L313-12 (V)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000006824870", "@num": "L313-13", "#text": "Code de la construction et de l'habitation. - art. L313-13 (M)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000006824868", "@num": "L313-13", "#text": "Code de la construction et de l'habitation. - art. L313-13 (M)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000006824869", "@num": "L313-13", "#text": "Code de la construction et de l'habitation. - art. L313-13 (M)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000006824871", "@num": "L313-13", "#text": "Code de la construction et de l'habitation. - art. L313-13 (V)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000006824872", "@num": "L313-14", "#text": "Code de la construction et de l'habitation. - art. L313-14 (M)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000006824873", "@num": "L313-14", "#text": "Code de la construction et de l'habitation. - art. L313-14 (M)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000006824874", "@num": "L313-14", "#text": "Code de la construction et de l'habitation. - art. L313-14 (V)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000006824875", "@num": "L313-15", "#text": "Code de la construction et de l'habitation. - art. L313-15 (M)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000006824876", "@num": "L313-15", "#text": "Code de la construction et de l'habitation. - art. L313-15 (M)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000006824877", "@num": "L313-15", "#text": "Code de la construction et de l'habitation. - art. L313-15 (V)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000006824878", "@num": "L313-16", "#text": "Code de la construction et de l'habitation. - art. L313-16 (M)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000006824880", "@num": "L313-16", "#text": "Code de la construction et de l'habitation. - art. L313-16 (M)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000006824879", "@num": "L313-16", "#text": "Code de la construction et de l'habitation. - art. L313-16 (T)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000006824881", "@num": "L313-16", "#text": "Code de la construction et de l'habitation. - art. L313-16 (V)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000006824882", "@num": "L313-16-1", "#text": "Code de la construction et de l'habitation. - art. L313-16-1 (T)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000006824883", "@num": "L313-16-1", "#text": "Code de la construction et de l'habitation. - art. L313-16-1 (V)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000006824886", "@num": "L313-16-2", "#text": "Code de la construction et de l'habitation. - art. L313-16-2 (V)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000006824887", "@num": "L313-16-3", "#text": "Code de la construction et de l'habitation. - art. L313-16-3 (V)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000006824888", "@num": "L313-16-4", "#text": "Code de la construction et de l'habitation. - art. L313-16-4 (V)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000006824884", "@num": "L313-17", "#text": "Code de la construction et de l'habitation. - art. L313-17 (M)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000006824885", "@num": "L313-17", "#text": "Code de la construction et de l'habitation. - art. L313-17 (V)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000028809142", "@num": "L313-18", "#text": "Code de la construction et de l'habitation. - art. L313-18 (M)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000006824889", "@num": "L313-18", "#text": "Code de la construction et de l'habitation. - art. L313-18 (V)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000033282527", "@num": "L313-18", "#text": "Code de la construction et de l'habitation. - art. L313-18 (V)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000006824898", "@num": "L313-19", "#text": "Code de la construction et de l'habitation. - art. L313-19 (M)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000006824900", "@num": "L313-19", "#text": "Code de la construction et de l'habitation. - art. L313-19 (M)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000006824899", "@num": "L313-19", "#text": "Code de la construction et de l'habitation. - art. L313-19 (M)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000006824896", "@num": "L313-19", "#text": "Code de la construction et de l'habitation. - art. L313-19 (M)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000006824897", "@num": "L313-19", "#text": "Code de la construction et de l'habitation. - art. L313-19 (M)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000006824901", "@num": "L313-19", "#text": "Code de la construction et de l'habitation. - art. L313-19 (V)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000006824835", "@num": "L313-2", "#text": "Code de la construction et de l'habitation. - art. L313-2 (T)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000006824903", "@num": "L313-20", "#text": "Code de la construction et de l'habitation. - art. L313-20 (M)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000006824902", "@num": "L313-20", "#text": "Code de la construction et de l'habitation. - art. L313-20 (M)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000006824904", "@num": "L313-20", "#text": "Code de la construction et de l'habitation. - art. L313-20 (V)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000006824890", "@num": "L313-21", "#text": "Code de la construction et de l'habitation. - art. L313-21 (V)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000006824891", "@num": "L313-22", "#text": "Code de la construction et de l'habitation. - art. L313-22 (V)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000006824892", "@num": "L313-23", "#text": "Code de la construction et de l'habitation. - art. L313-23 (V)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000006824893", "@num": "L313-24", "#text": "Code de la construction et de l'habitation. - art. L313-24 (Ab)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000006824894", "@num": "L313-25", "#text": "Code de la construction et de l'habitation. - art. L313-25 (M)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000006824895", "@num": "L313-25", "#text": "Code de la construction et de l'habitation. - art. L313-25 (V)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000006824905", "@num": "L313-26", "#text": "Code de la construction et de l'habitation. - art. L313-26 (M)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000037670796", "@num": "L313-26", "#text": "Code de la construction et de l'habitation. - art. L313-26 (V)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000006824906", "@num": "L313-26-1", "#text": "Code de la construction et de l'habitation. - art. L313-26-1 (V)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000006824907", "@num": "L313-27", "#text": "Code de la construction et de l'habitation. - art. L313-27 (V)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000033282746", "@num": "L313-27", "#text": "Code de la construction et de l'habitation. - art. L313-27 (V)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000028808537", "@num": "L313-27", "#text": "Code de la construction et de l'habitation. - art. L313-27 (VD)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000028809109", "@num": "L313-28", "#text": "Code de la construction et de l'habitation. - art. L313-28 (Ab)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000006824908", "@num": "L313-28", "#text": "Code de la construction et de l'habitation. - art. L313-28 (V)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000006824909", "@num": "L313-29", "#text": "Code de la construction et de l'habitation. - art. L313-29 (M)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000028809098", "@num": "L313-29", "#text": "Code de la construction et de l'habitation. - art. L313-29 (M)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000006824910", "@num": "L313-29", "#text": "Code de la construction et de l'habitation. - art. L313-29 (V)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000033282734", "@num": "L313-29", "#text": "Code de la construction et de l'habitation. - art. L313-29 (V)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000006824836", "@num": "L313-3", "#text": "Code de la construction et de l'habitation. - art. L313-3 (M)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000006824837", "@num": "L313-3", "#text": "Code de la construction et de l'habitation. - art. L313-3 (T)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000006824915", "@num": "L313-30", "#text": "Code de la construction et de l'habitation. - art. L313-30 (M)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000006824916", "@num": "L313-30", "#text": "Code de la construction et de l'habitation. - art. L313-30 (V)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000024041588", "@num": "L313-30", "#text": "Code de la construction et de l'habitation. - art. L313-30 (V)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000006824911", "@num": "L313-31", "#text": "Code de la construction et de l'habitation. - art. L313-31 (M)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000006824912", "@num": "L313-31", "#text": "Code de la construction et de l'habitation. - art. L313-31 (V)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000006824917", "@num": "L313-32", "#text": "Code de la construction et de l'habitation. - art. L313-32 (M)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000006824918", "@num": "L313-32", "#text": "Code de la construction et de l'habitation. - art. L313-32 (M)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000033282720", "@num": "L313-32", "#text": "Code de la construction et de l'habitation. - art. L313-32 (V)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000006824913", "@num": "L313-32-1", "#text": "Code de la construction et de l'habitation. - art. L313-32-1 (V)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000006824914", "@num": "L313-33", "#text": "Code de la construction et de l'habitation. - art. L313-33 (V)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000006824838", "@num": "L313-4", "#text": "Code de la construction et de l'habitation. - art. L313-4 (M)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000006824839", "@num": "L313-4", "#text": "Code de la construction et de l'habitation. - art. L313-4 (M)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000006824840", "@num": "L313-4", "#text": "Code de la construction et de l'habitation. - art. L313-4 (M)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000006824841", "@num": "L313-4", "#text": "Code de la construction et de l'habitation. - art. L313-4 (V)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000028670832", "@num": "L313-4", "#text": "Code de la construction et de l'habitation. - art. L313-4 (VD)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000037387268", "@num": "L313-4", "#text": "Code de la construction et de l'habitation. - art. L313-4 (VD)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000006824842", "@num": "L313-5", "#text": "Code de la construction et de l'habitation. - art. L313-5 (M)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000006824843", "@num": "L313-5", "#text": "Code de la construction et de l'habitation. - art. L313-5 (M)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000006824844", "@num": "L313-5", "#text": "Code de la construction et de l'habitation. - art. L313-5 (V)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000006824845", "@num": "L313-6", "#text": "Code de la construction et de l'habitation. - art. L313-6 (M)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000006824846", "@num": "L313-6", "#text": "Code de la construction et de l'habitation. - art. L313-6 (V)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000006824848", "@num": "L313-7", "#text": "Code de la construction et de l'habitation. - art. L313-7 (M)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000006824847", "@num": "L313-7", "#text": "Code de la construction et de l'habitation. - art. L313-7 (M)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000006824849", "@num": "L313-7", "#text": "Code de la construction et de l'habitation. - art. L313-7 (M)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000006824850", "@num": "L313-7", "#text": "Code de la construction et de l'habitation. - art. L313-7 (M)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000006824851", "@num": "L313-7", "#text": "Code de la construction et de l'habitation. - art. L313-7 (V)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000006824852", "@num": "L313-7-1", "#text": "Code de la construction et de l'habitation. - art. L313-7-1 (T)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000006824853", "@num": "L313-8", "#text": "Code de la construction et de l'habitation. - art. L313-8 (M)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000006824854", "@num": "L313-8", "#text": "Code de la construction et de l'habitation. - art. L313-8 (V)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000006824857", "@num": "L313-9", "#text": "Code de la construction et de l'habitation. - art. L313-9 (M)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000006824856", "@num": "L313-9", "#text": "Code de la construction et de l'habitation. - art. L313-9 (M)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000006824855", "@num": "L313-9", "#text": "Code de la construction et de l'habitation. - art. L313-9 (M)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000006824858", "@num": "L313-9", "#text": "Code de la construction et de l'habitation. - art. L313-9 (V)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000006825072", "@num": "L315-1", "#text": "Code de la construction et de l'habitation. - art. L315-1 (M)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000006825073", "@num": "L315-1", "#text": "Code de la construction et de l'habitation. - art. L315-1 (M)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000006825071", "@num": "L315-1", "#text": "Code de la construction et de l'habitation. - art. L315-1 (M)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000006825074", "@num": "L315-1", "#text": "Code de la construction et de l'habitation. - art. L315-1 (V)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000023372155", "@num": "L315-1", "#text": "Code de la construction et de l'habitation. - art. L315-1 (VD)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000006825094", "@num": "L315-10", "#text": "Code de la construction et de l'habitation. - art. L315-10 (Ab)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000006825095", "@num": "L315-11", "#text": "Code de la construction et de l'habitation. - art. L315-11 (Ab)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000006825096", "@num": "L315-12", "#text": "Code de la construction et de l'habitation. - art. L315-12 (Ab)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000006825097", "@num": "L315-13", "#text": "Code de la construction et de l'habitation. - art. L315-13 (Ab)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000006825098", "@num": "L315-14", "#text": "Code de la construction et de l'habitation. - art. L315-14 (Ab)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000006825099", "@num": "L315-15", "#text": "Code de la construction et de l'habitation. - art. L315-15 (Ab)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000006825100", "@num": "L315-16", "#text": "Code de la construction et de l'habitation. - art. L315-16 (Ab)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000006825101", "@num": "L315-17", "#text": "Code de la construction et de l'habitation. - art. L315-17 (Ab)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000006825102", "@num": "L315-18", "#text": "Code de la construction et de l'habitation. - art. L315-18 (Ab)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000006825104", "@num": "L315-19", "#text": "Code de la construction et de l'habitation. - art. L315-19 (Ab)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000006825103", "@num": "L315-19", "#text": "Code de la construction et de l'habitation. - art. L315-19 (M)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000006825078", "@num": "L315-2", "#text": "Code de la construction et de l'habitation. - art. L315-2 (M)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000006825077", "@num": "L315-2", "#text": "Code de la construction et de l'habitation. - art. L315-2 (M)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000006825076", "@num": "L315-2", "#text": "Code de la construction et de l'habitation. - art. L315-2 (M)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000006825075", "@num": "L315-2", "#text": "Code de la construction et de l'habitation. - art. L315-2 (M)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000006825079", "@num": "L315-2", "#text": "Code de la construction et de l'habitation. - art. L315-2 (V)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000023372161", "@num": "L315-2", "#text": "Code de la construction et de l'habitation. - art. L315-2 (V)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000006825106", "@num": "L315-20", "#text": "Code de la construction et de l'habitation. - art. L315-20 (Ab)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000006825105", "@num": "L315-20", "#text": "Code de la construction et de l'habitation. - art. L315-20 (M)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000006825108", "@num": "L315-21", "#text": "Code de la construction et de l'habitation. - art. L315-21 (Ab)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000006825107", "@num": "L315-21", "#text": "Code de la construction et de l'habitation. - art. L315-21 (M)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000006825110", "@num": "L315-22", "#text": "Code de la construction et de l'habitation. - art. L315-22 (Ab)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000006825109", "@num": "L315-22", "#text": "Code de la construction et de l'habitation. - art. L315-22 (M)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000006825112", "@num": "L315-23", "#text": "Code de la construction et de l'habitation. - art. L315-23 (Ab)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000006825111", "@num": "L315-23", "#text": "Code de la construction et de l'habitation. - art. L315-23 (M)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000006825114", "@num": "L315-24", "#text": "Code de la construction et de l'habitation. - art. L315-24 (Ab)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000006825113", "@num": "L315-24", "#text": "Code de la construction et de l'habitation. - art. L315-24 (M)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000006825116", "@num": "L315-25", "#text": "Code de la construction et de l'habitation. - art. L315-25 (Ab)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000006825115", "@num": "L315-25", "#text": "Code de la construction et de l'habitation. - art. L315-25 (M)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000006825118", "@num": "L315-26", "#text": "Code de la construction et de l'habitation. - art. L315-26 (Ab)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000006825117", "@num": "L315-26", "#text": "Code de la construction et de l'habitation. - art. L315-26 (M)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000006825120", "@num": "L315-27", "#text": "Code de la construction et de l'habitation. - art. L315-27 (Ab)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000006825119", "@num": "L315-27", "#text": "Code de la construction et de l'habitation. - art. L315-27 (M)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000006825123", "@num": "L315-28", "#text": "Code de la construction et de l'habitation. - art. L315-28 (Ab)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000006825121", "@num": "L315-28", "#text": "Code de la construction et de l'habitation. - art. L315-28 (M)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000006825122", "@num": "L315-28", "#text": "Code de la construction et de l'habitation. - art. L315-28 (V)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000006825125", "@num": "L315-29", "#text": "Code de la construction et de l'habitation. - art. L315-29 (Ab)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000006825124", "@num": "L315-29", "#text": "Code de la construction et de l'habitation. - art. L315-29 (M)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000006825081", "@num": "L315-3", "#text": "Code de la construction et de l'habitation. - art. L315-3 (M)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000006825080", "@num": "L315-3", "#text": "Code de la construction et de l'habitation. - art. L315-3 (M)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000006825082", "@num": "L315-3", "#text": "Code de la construction et de l'habitation. - art. L315-3 (V)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000006825127", "@num": "L315-30", "#text": "Code de la construction et de l'habitation. - art. L315-30 (Ab)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000006825126", "@num": "L315-30", "#text": "Code de la construction et de l'habitation. - art. L315-30 (M)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000006825129", "@num": "L315-31", "#text": "Code de la construction et de l'habitation. - art. L315-31 (Ab)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000006825128", "@num": "L315-31", "#text": "Code de la construction et de l'habitation. - art. L315-31 (M)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000006825131", "@num": "L315-32", "#text": "Code de la construction et de l'habitation. - art. L315-32 (Ab)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000006825130", "@num": "L315-32", "#text": "Code de la construction et de l'habitation. - art. L315-32 (M)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000006825083", "@num": "L315-4", "#text": "Code de la construction et de l'habitation. - art. L315-4 (M)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000023372158", "@num": "L315-4", "#text": "Code de la construction et de l'habitation. - art. L315-4 (M)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000006825085", "@num": "L315-4", "#text": "Code de la construction et de l'habitation. - art. L315-4 (V)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000036427279", "@num": "L315-4", "#text": "Code de la construction et de l'habitation. - art. L315-4 (V)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000006825087", "@num": "L315-5", "#text": "Code de la construction et de l'habitation. - art. L315-5 (M)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000006825086", "@num": "L315-5", "#text": "Code de la construction et de l'habitation. - art. L315-5 (M)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000006825088", "@num": "L315-5", "#text": "Code de la construction et de l'habitation. - art. L315-5 (V)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000006825089", "@num": "L315-6", "#text": "Code de la construction et de l'habitation. - art. L315-6 (M)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000006825090", "@num": "L315-6", "#text": "Code de la construction et de l'habitation. - art. L315-6 (V)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000006825091", "@num": "L315-7", "#text": "Code de la construction et de l'habitation. - art. L315-7 (Ab)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000006825092", "@num": "L315-8", "#text": "Code de la construction et de l'habitation. - art. L315-8 (Ab)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000006825093", "@num": "L315-9", "#text": "Code de la construction et de l'habitation. - art. L315-9 (Ab)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000006824919", "@num": "L316-1", "#text": "Code de la construction et de l'habitation. - art. L316-1 (V)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000006824920", "@num": "L316-2", "#text": "Code de la construction et de l'habitation. - art. L316-2 (V)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000028419291", "@num": "L316-3", "#text": "Code de la construction et de l'habitation. - art. L316-3 (M)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000006824921", "@num": "L316-3", "#text": "Code de la construction et de l'habitation. - art. L316-3 (V)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000031096894", "@num": "L316-3", "#text": "Code de la construction et de l'habitation. - art. L316-3 (V)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000027645789", "@num": "L316-3", "#text": "Code de la construction et de l'habitation. - art. L316-3 (VD)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000006824922", "@num": "L316-4", "#text": "Code de la construction et de l'habitation. - art. L316-4 (V)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000028419287", "@num": "L316-4", "#text": "Code de la construction et de l'habitation. - art. L316-4 (V)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000006824927", "@num": "L321-1", "#text": "Code de la construction et de l'habitation. - art. L321-1 (M)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000006824926", "@num": "L321-1", "#text": "Code de la construction et de l'habitation. - art. L321-1 (M)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000006824924", "@num": "L321-1", "#text": "Code de la construction et de l'habitation. - art. L321-1 (M)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000006824923", "@num": "L321-1", "#text": "Code de la construction et de l'habitation. - art. L321-1 (M)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000006824925", "@num": "L321-1", "#text": "Code de la construction et de l'habitation. - art. L321-1 (M)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000006824928", "@num": "L321-1", "#text": "Code de la construction et de l'habitation. - art. L321-1 (V)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000006824936", "@num": "L321-1-1", "#text": "Code de la construction et de l'habitation. - art. L321-1-1 (M)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000006824935", "@num": "L321-1-1", "#text": "Code de la construction et de l'habitation. - art. L321-1-1 (M)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000006824934", "@num": "L321-1-1", "#text": "Code de la construction et de l'habitation. - art. L321-1-1 (M)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000006824937", "@num": "L321-1-1", "#text": "Code de la construction et de l'habitation. - art. L321-1-1 (V)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000027573587", "@num": "L321-1-1", "#text": "Code de la construction et de l'habitation. - art. L321-1-1 (VD)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000028809054", "@num": "L321-1-1", "#text": "Code de la construction et de l'habitation. - art. L321-1-1 (VT)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000006824948", "@num": "L321-10", "#text": "Code de la construction et de l'habitation. - art. L321-10 (Ab)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000006824949", "@num": "L321-10", "#text": "Code de la construction et de l'habitation. - art. L321-10 (V)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000006824950", "@num": "L321-11", "#text": "Code de la construction et de l'habitation. - art. L321-11 (M)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000006824951", "@num": "L321-11", "#text": "Code de la construction et de l'habitation. - art. L321-11 (V)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000006824952", "@num": "L321-12", "#text": "Code de la construction et de l'habitation. - art. L321-12 (M)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000006824953", "@num": "L321-12", "#text": "Code de la construction et de l'habitation. - art. L321-12 (V)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000006824932", "@num": "L321-2", "#text": "Code de la construction et de l'habitation. - art. L321-2 (M)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000006824930", "@num": "L321-2", "#text": "Code de la construction et de l'habitation. - art. L321-2 (M)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000006824929", "@num": "L321-2", "#text": "Code de la construction et de l'habitation. - art. L321-2 (M)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000006824931", "@num": "L321-2", "#text": "Code de la construction et de l'habitation. - art. L321-2 (M)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000006824933", "@num": "L321-2", "#text": "Code de la construction et de l'habitation. - art. L321-2 (V)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000006825148", "@num": "L321-3", "#text": "Code de la construction et de l'habitation. - art. L321-3 (Ab)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000006825149", "@num": "L321-3", "#text": "Code de la construction et de l'habitation. - art. L321-3 (M)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000006825150", "@num": "L321-3", "#text": "Code de la construction et de l'habitation. - art. L321-3 (V)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000006825151", "@num": "L321-4", "#text": "Code de la construction et de l'habitation. - art. L321-4 (Ab)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000006825152", "@num": "L321-4", "#text": "Code de la construction et de l'habitation. - art. L321-4 (M)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000006825153", "@num": "L321-4", "#text": "Code de la construction et de l'habitation. - art. L321-4 (V)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000006824938", "@num": "L321-5", "#text": "Code de la construction et de l'habitation. - art. L321-5 (M)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000006824939", "@num": "L321-5", "#text": "Code de la construction et de l'habitation. - art. L321-5 (V)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000006824940", "@num": "L321-6", "#text": "Code de la construction et de l'habitation. - art. L321-6 (M)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000006824941", "@num": "L321-6", "#text": "Code de la construction et de l'habitation. - art. L321-6 (V)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000006824942", "@num": "L321-7", "#text": "Code de la construction et de l'habitation. - art. L321-7 (M)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000006824943", "@num": "L321-7", "#text": "Code de la construction et de l'habitation. - art. L321-7 (V)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000006824944", "@num": "L321-8", "#text": "Code de la construction et de l'habitation. - art. L321-8 (M)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000006824945", "@num": "L321-8", "#text": "Code de la construction et de l'habitation. - art. L321-8 (V)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000038833957", "@num": "L321-8", "#text": "Code de la construction et de l'habitation. - art. L321-8 (VD)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000006824946", "@num": "L321-9", "#text": "Code de la construction et de l'habitation. - art. L321-9 (M)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000006824947", "@num": "L321-9", "#text": "Code de la construction et de l'habitation. - art. L321-9 (V)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000024040929", "@num": "L321-9", "#text": "Code de la construction et de l'habitation. - art. L321-9 (V)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000006824954", "@num": "L322-1", "#text": "Code de la construction et de l'habitation. - art. L322-1 (Ab)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000006824955", "@num": "L322-2", "#text": "Code de la construction et de l'habitation. - art. L322-2 (Ab)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000006824957", "@num": "L322-3", "#text": "Code de la construction et de l'habitation. - art. L322-3 (Ab)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000006824956", "@num": "L322-3", "#text": "Code de la construction et de l'habitation. - art. L322-3 (M)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000006824958", "@num": "L324-1", "#text": "Code de la construction et de l'habitation. - art. L324-1 (V)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000006824959", "@num": "L341-1", "#text": "Code de la construction et de l'habitation. - art. L341-1 (V)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000006824960", "@num": "L351-1", "#text": "Code de la construction et de l'habitation. - art. L351-1 (VT)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000006824979", "@num": "L351-10", "#text": "Code de la construction et de l'habitation. - art. L351-10 (M)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000006824980", "@num": "L351-10", "#text": "Code de la construction et de l'habitation. - art. L351-10 (V)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000006824981", "@num": "L351-11", "#text": "Code de la construction et de l'habitation. - art. L351-11 (M)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000006824982", "@num": "L351-11", "#text": "Code de la construction et de l'habitation. - art. L351-11 (V)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000006824983", "@num": "L351-12", "#text": "Code de la construction et de l'habitation. - art. L351-12 (V)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000006824986", "@num": "L351-13", "#text": "Code de la construction et de l'habitation. - art. L351-13 (M)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000006824985", "@num": "L351-13", "#text": "Code de la construction et de l'habitation. - art. L351-13 (M)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000006824984", "@num": "L351-13", "#text": "Code de la construction et de l'habitation. - art. L351-13 (M)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000006824987", "@num": "L351-13", "#text": "Code de la construction et de l'habitation. - art. L351-13 (V)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000006824988", "@num": "L351-14", "#text": "Code de la construction et de l'habitation. - art. L351-14 (M)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000006824989", "@num": "L351-14", "#text": "Code de la construction et de l'habitation. - art. L351-14 (V)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000028807041", "@num": "L351-14", "#text": "Code de la construction et de l'habitation. - art. L351-14 (VT)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000006824990", "@num": "L351-15", "#text": "Code de la construction et de l'habitation. - art. L351-15 (M)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000037670049", "@num": "L351-15", "#text": "Code de la construction et de l'habitation. - art. L351-15 (VT)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000006825159", "@num": "L351-2", "#text": "Code de la construction et de l'habitation. - art. L351-2 (M)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000006825158", "@num": "L351-2", "#text": "Code de la construction et de l'habitation. - art. L351-2 (M)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000006825156", "@num": "L351-2", "#text": "Code de la construction et de l'habitation. - art. L351-2 (M)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000006825154", "@num": "L351-2", "#text": "Code de la construction et de l'habitation. - art. L351-2 (M)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000006825157", "@num": "L351-2", "#text": "Code de la construction et de l'habitation. - art. L351-2 (M)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000006825160", "@num": "L351-2", "#text": "Code de la construction et de l'habitation. - art. L351-2 (M)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000006825155", "@num": "L351-2", "#text": "Code de la construction et de l'habitation. - art. L351-2 (M)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000006825161", "@num": "L351-2", "#text": "Code de la construction et de l'habitation. - art. L351-2 (M)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000030024129", "@num": "L351-2", "#text": "Code de la construction et de l'habitation. - art. L351-2 (M)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000031782454", "@num": "L351-2", "#text": "Code de la construction et de l'habitation. - art. L351-2 (M)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000036432665", "@num": "L351-2", "#text": "Code de la construction et de l'habitation. - art. L351-2 (VT)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000006824961", "@num": "L351-2-1", "#text": "Code de la construction et de l'habitation. - art. L351-2-1 (M)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000006824962", "@num": "L351-2-1", "#text": "Code de la construction et de l'habitation. - art. L351-2-1 (V)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000006824963", "@num": "L351-2-2", "#text": "Code de la construction et de l'habitation. - art. L351-2-2 (VT)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000006825164", "@num": "L351-3", "#text": "Code de la construction et de l'habitation. - art. L351-3 (M)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000006825162", "@num": "L351-3", "#text": "Code de la construction et de l'habitation. - art. L351-3 (M)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000006825167", "@num": "L351-3", "#text": "Code de la construction et de l'habitation. - art. L351-3 (M)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000006825163", "@num": "L351-3", "#text": "Code de la construction et de l'habitation. - art. L351-3 (M)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000006825165", "@num": "L351-3", "#text": "Code de la construction et de l'habitation. - art. L351-3 (M)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000006825166", "@num": "L351-3", "#text": "Code de la construction et de l'habitation. - art. L351-3 (M)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000006825168", "@num": "L351-3", "#text": "Code de la construction et de l'habitation. - art. L351-3 (V)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000006824965", "@num": "L351-3-1", "#text": "Code de la construction et de l'habitation. - art. L351-3-1 (M)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000006824964", "@num": "L351-3-1", "#text": "Code de la construction et de l'habitation. - art. L351-3-1 (M)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000023271162", "@num": "L351-3-1", "#text": "Code de la construction et de l'habitation. - art. L351-3-1 (M)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000006824966", "@num": "L351-3-1", "#text": "Code de la construction et de l'habitation. - art. L351-3-1 (V)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000032400522", "@num": "L351-3-1", "#text": "Code de la construction et de l'habitation. - art. L351-3-1 (VT)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000006824967", "@num": "L351-4", "#text": "Code de la construction et de l'habitation. - art. L351-4 (VT)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000006824968", "@num": "L351-5", "#text": "Code de la construction et de l'habitation. - art. L351-5 (VT)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000006824969", "@num": "L351-6", "#text": "Code de la construction et de l'habitation. - art. L351-6 (M)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000006824970", "@num": "L351-6", "#text": "Code de la construction et de l'habitation. - art. L351-6 (M)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000006824971", "@num": "L351-6", "#text": "Code de la construction et de l'habitation. - art. L351-6 (M)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000031780996", "@num": "L351-6", "#text": "Code de la construction et de l'habitation. - art. L351-6 (VT)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000006824972", "@num": "L351-7", "#text": "Code de la construction et de l'habitation. - art. L351-7 (M)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000006824973", "@num": "L351-7", "#text": "Code de la construction et de l'habitation. - art. L351-7 (M)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000026798219", "@num": "L351-7", "#text": "Code de la construction et de l'habitation. - art. L351-7 (M)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000030023172", "@num": "L351-7", "#text": "Code de la construction et de l'habitation. - art. L351-7 (M)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000031782338", "@num": "L351-7", "#text": "Code de la construction et de l'habitation. - art. L351-7 (M)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000006824974", "@num": "L351-7", "#text": "Code de la construction et de l'habitation. - art. L351-7 (V)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000033811765", "@num": "L351-7", "#text": "Code de la construction et de l'habitation. - art. L351-7 (VT)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000006824975", "@num": "L351-8", "#text": "Code de la construction et de l'habitation. - art. L351-8 (M)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000006824976", "@num": "L351-8", "#text": "Code de la construction et de l'habitation. - art. L351-8 (M)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000031780985", "@num": "L351-8", "#text": "Code de la construction et de l'habitation. - art. L351-8 (M)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000033974234", "@num": "L351-8", "#text": "Code de la construction et de l'habitation. - art. L351-8 (VT)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000006824977", "@num": "L351-9", "#text": "Code de la construction et de l'habitation. - art. L351-9 (M)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000006824978", "@num": "L351-9", "#text": "Code de la construction et de l'habitation. - art. L351-9 (VT)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000006824991", "@num": "L352-1", "#text": "Code de la construction et de l'habitation. - art. L352-1 (V)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000006824992", "@num": "L353-1", "#text": "Code de la construction et de l'habitation. - art. L353-1 (V)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000038833853", "@num": "L353-1", "#text": "Code de la construction et de l'habitation. - art. L353-1 (VD)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000006825007", "@num": "L353-10", "#text": "Code de la construction et de l'habitation. - art. L353-10 (M)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000006825008", "@num": "L353-10", "#text": "Code de la construction et de l'habitation. - art. L353-10 (M)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000006825009", "@num": "L353-10", "#text": "Code de la construction et de l'habitation. - art. L353-10 (V)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000006825002", "@num": "L353-11", "#text": "Code de la construction et de l'habitation. - art. L353-11 (V)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000028808531", "@num": "L353-11", "#text": "Code de la construction et de l'habitation. - art. L353-11 (VD)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000038833846", "@num": "L353-11", "#text": "Code de la construction et de l'habitation. - art. L353-11 (VD)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000006825003", "@num": "L353-12", "#text": "Code de la construction et de l'habitation. - art. L353-12 (V)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000006825004", "@num": "L353-13", "#text": "Code de la construction et de l'habitation. - art. L353-13 (V)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000006825010", "@num": "L353-14", "#text": "Code de la construction et de l'habitation. - art. L353-14 (M)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000006825011", "@num": "L353-14", "#text": "Code de la construction et de l'habitation. - art. L353-14 (V)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000006825174", "@num": "L353-15", "#text": "Code de la construction et de l'habitation. - art. L353-15 (M)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000006825172", "@num": "L353-15", "#text": "Code de la construction et de l'habitation. - art. L353-15 (M)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000006825175", "@num": "L353-15", "#text": "Code de la construction et de l'habitation. - art. L353-15 (M)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000006825169", "@num": "L353-15", "#text": "Code de la construction et de l'habitation. - art. L353-15 (M)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000006825173", "@num": "L353-15", "#text": "Code de la construction et de l'habitation. - art. L353-15 (M)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000006825171", "@num": "L353-15", "#text": "Code de la construction et de l'habitation. - art. L353-15 (M)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000006825170", "@num": "L353-15", "#text": "Code de la construction et de l'habitation. - art. L353-15 (M)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000006825176", "@num": "L353-15", "#text": "Code de la construction et de l'habitation. - art. L353-15 (V)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000006825014", "@num": "L353-15-1", "#text": "Code de la construction et de l'habitation. - art. L353-15-1 (Ab)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000006825012", "@num": "L353-15-1", "#text": "Code de la construction et de l'habitation. - art. L353-15-1 (M)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000006825013", "@num": "L353-15-1", "#text": "Code de la construction et de l'habitation. - art. L353-15-1 (M)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000028807084", "@num": "L353-15-2", "#text": "Code de la construction et de l'habitation. - art. L353-15-2 (M)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000006825015", "@num": "L353-15-2", "#text": "Code de la construction et de l'habitation. - art. L353-15-2 (V)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000006824993", "@num": "L353-2", "#text": "Code de la construction et de l'habitation. - art. L353-2 (M)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000006824994", "@num": "L353-2", "#text": "Code de la construction et de l'habitation. - art. L353-2 (V)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000038833921", "@num": "L353-2", "#text": "Code de la construction et de l'habitation. - art. L353-2 (VD)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000006824995", "@num": "L353-3", "#text": "Code de la construction et de l'habitation. - art. L353-3 (V)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000006824996", "@num": "L353-4", "#text": "Code de la construction et de l'habitation. - art. L353-4 (V)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000038833912", "@num": "L353-4", "#text": "Code de la construction et de l'habitation. - art. L353-4 (VD)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000006824997", "@num": "L353-5", "#text": "Code de la construction et de l'habitation. - art. L353-5 (V)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000038833908", "@num": "L353-5", "#text": "Code de la construction et de l'habitation. - art. L353-5 (VD)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000006824998", "@num": "L353-6", "#text": "Code de la construction et de l'habitation. - art. L353-6 (V)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000038833916", "@num": "L353-6", "#text": "Code de la construction et de l'habitation. - art. L353-6 (VD)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000006825005", "@num": "L353-7", "#text": "Code de la construction et de l'habitation. - art. L353-7 (M)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000006825006", "@num": "L353-7", "#text": "Code de la construction et de l'habitation. - art. L353-7 (M)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000037668703", "@num": "L353-7", "#text": "Code de la construction et de l'habitation. - art. L353-7 (V)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000006824999", "@num": "L353-8", "#text": "Code de la construction et de l'habitation. - art. L353-8 (V)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CREATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000006824999", "@num": "L353-8", "#text": "Code de la construction et de l'habitation. - art. L353-8 (V)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000006825000", "@num": "L353-9", "#text": "Code de la construction et de l'habitation. - art. L353-9 (V)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000006825001", "@num": "L353-9-1", "#text": "Code de la construction et de l'habitation. - art. L353-9-1 (V)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000038833903", "@num": "L353-9-1", "#text": "Code de la construction et de l'habitation. - art. L353-9-1 (VD)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000006825032", "@num": "L361-1", "#text": "Code de la construction et de l'habitation. - art. L361-1 (Ab)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000006825031", "@num": "L361-1", "#text": "Code de la construction et de l'habitation. - art. L361-1 (M)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000037289883", "@num": "L361-1", "#text": "Code de la construction et de l'habitation. - art. L361-1 (V)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000006825034", "@num": "L362-1", "#text": "Code de la construction et de l'habitation. - art. L362-1 (Ab)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000006825033", "@num": "L362-1", "#text": "Code de la construction et de l'habitation. - art. L362-1 (M)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000006825036", "@num": "L362-2", "#text": "Code de la construction et de l'habitation. - art. L362-2 (Ab)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000006825035", "@num": "L362-2", "#text": "Code de la construction et de l'habitation. - art. L362-2 (M)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000006825038", "@num": "L363-1", "#text": "Code de la construction et de l'habitation. - art. L363-1 (Ab)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000006825037", "@num": "L363-1", "#text": "Code de la construction et de l'habitation. - art. L363-1 (M)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000006825046", "@num": "L371-1", "#text": "Code de la construction et de l'habitation. - art. L371-1 (M)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000006825047", "@num": "L371-1", "#text": "Code de la construction et de l'habitation. - art. L371-1 (V)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000025760504", "@num": "L371-1", "#text": "Code de la construction et de l'habitation. - art. L371-1 (V)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000006825048", "@num": "L371-2", "#text": "Code de la construction et de l'habitation. - art. L371-2 (M)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000006825049", "@num": "L371-2", "#text": "Code de la construction et de l'habitation. - art. L371-2 (V)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000025760500", "@num": "L371-2", "#text": "Code de la construction et de l'habitation. - art. L371-2 (V)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000038833828", "@num": "L371-2", "#text": "Code de la construction et de l'habitation. - art. L371-2 (VD)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000006825178", "@num": "L371-3", "#text": "Code de la construction et de l'habitation. - art. L371-3 (M)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000006825177", "@num": "L371-3", "#text": "Code de la construction et de l'habitation. - art. L371-3 (M)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000006825179", "@num": "L371-3", "#text": "Code de la construction et de l'habitation. - art. L371-3 (V)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000006825050", "@num": "L371-4", "#text": "Code de la construction et de l'habitation. - art. L371-4 (V)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000025760495", "@num": "L371-4", "#text": "Code de la construction et de l'habitation. - art. L371-4 (V)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000026660083", "@num": "L371-4", "#text": "Code de la construction et de l'habitation. - art. L371-4 (V)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000036431613", "@num": "L371-4", "#text": "Code de la construction et de l'habitation. - art. L371-4 (V)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000035902995", "@num": "L371-4", "#text": "Code de la construction et de l'habitation. - art. L371-4 (VD)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000006825180", "@num": "L411", "#text": "Code de la construction et de l'habitation. - art. L411 (V)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000006825576", "@num": "L411-1", "#text": "Code de la construction et de l'habitation. - art. L411-1 (M)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000006825577", "@num": "L411-1", "#text": "Code de la construction et de l'habitation. - art. L411-1 (M)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000006825578", "@num": "L411-1", "#text": "Code de la construction et de l'habitation. - art. L411-1 (M)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000006825579", "@num": "L411-1", "#text": "Code de la construction et de l'habitation. - art. L411-1 (M)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000039784767", "@num": "L411-1", "#text": "Code de la construction et de l'habitation. - art. L411-1 (V)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000006825184", "@num": "L411-2", "#text": "Code de la construction et de l'habitation. - art. L411-2 (M)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000006825183", "@num": "L411-2", "#text": "Code de la construction et de l'habitation. - art. L411-2 (M)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000006825181", "@num": "L411-2", "#text": "Code de la construction et de l'habitation. - art. L411-2 (M)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000006825186", "@num": "L411-2", "#text": "Code de la construction et de l'habitation. - art. L411-2 (M)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000006825188", "@num": "L411-2", "#text": "Code de la construction et de l'habitation. - art. L411-2 (M)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000006825182", "@num": "L411-2", "#text": "Code de la construction et de l'habitation. - art. L411-2 (M)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000006825187", "@num": "L411-2", "#text": "Code de la construction et de l'habitation. - art. L411-2 (M)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000006825185", "@num": "L411-2", "#text": "Code de la construction et de l'habitation. - art. L411-2 (M)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000006825189", "@num": "L411-2", "#text": "Code de la construction et de l'habitation. - art. L411-2 (V)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000006825190", "@num": "L411-2", "#text": "Code de la construction et de l'habitation. - art. L411-2 (VD)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000006825191", "@num": "L411-3", "#text": "Code de la construction et de l'habitation. - art. L411-3 (M)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000006825192", "@num": "L411-3", "#text": "Code de la construction et de l'habitation. - art. L411-3 (M)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000006825193", "@num": "L411-3", "#text": "Code de la construction et de l'habitation. - art. L411-3 (M)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000028807072", "@num": "L411-3", "#text": "Code de la construction et de l'habitation. - art. L411-3 (M)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000033974662", "@num": "L411-3", "#text": "Code de la construction et de l'habitation. - art. L411-3 (M)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000037668965", "@num": "L411-3", "#text": "Code de la construction et de l'habitation. - art. L411-3 (M)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000006825194", "@num": "L411-3", "#text": "Code de la construction et de l'habitation. - art. L411-3 (V)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000025577145", "@num": "L411-3", "#text": "Code de la construction et de l'habitation. - art. L411-3 (V)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000045211496", "@num": "L411-3", "#text": "Code de la construction et de l'habitation. - art. L411-3 (V)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000006825196", "@num": "L411-4", "#text": "Code de la construction et de l'habitation. - art. L411-4 (M)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000006825195", "@num": "L411-4", "#text": "Code de la construction et de l'habitation. - art. L411-4 (M)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000028807064", "@num": "L411-4", "#text": "Code de la construction et de l'habitation. - art. L411-4 (M)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000006825197", "@num": "L411-4", "#text": "Code de la construction et de l'habitation. - art. L411-4 (V)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000025577136", "@num": "L411-4", "#text": "Code de la construction et de l'habitation. - art. L411-4 (V)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000037668951", "@num": "L411-4", "#text": "Code de la construction et de l'habitation. - art. L411-4 (V)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000038834247", "@num": "L411-4", "#text": "Code de la construction et de l'habitation. - art. L411-4 (VD)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000028806735", "@num": "L411-5", "#text": "Code de la construction et de l'habitation. - art. L411-5 (M)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000006825198", "@num": "L411-5", "#text": "Code de la construction et de l'habitation. - art. L411-5 (V)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000033972951", "@num": "L411-5", "#text": "Code de la construction et de l'habitation. - art. L411-5 (V)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000038834239", "@num": "L411-5", "#text": "Code de la construction et de l'habitation. - art. L411-5 (VD)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000006825199", "@num": "L411-5-1", "#text": "Code de la construction et de l'habitation. - art. L411-5-1 (V)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000045211308", "@num": "L411-5-1", "#text": "Code de la construction et de l'habitation. - art. L411-5-1 (V)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000038834233", "@num": "L411-5-1", "#text": "Code de la construction et de l'habitation. - art. L411-5-1 (VD)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000006825200", "@num": "L411-6", "#text": "Code de la construction et de l'habitation. - art. L411-6 (V)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000038834229", "@num": "L411-6", "#text": "Code de la construction et de l'habitation. - art. L411-6 (VD)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000006825201", "@num": "L411-7", "#text": "Code de la construction et de l'habitation. - art. L411-7 (V)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000006825202", "@num": "L411-8", "#text": "Code de la construction et de l'habitation. - art. L411-8 (V)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000028808988", "@num": "L411-8", "#text": "Code de la construction et de l'habitation. - art. L411-8 (V)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000006825583", "@num": "L421-1", "#text": "Code de la construction et de l'habitation. - art. L421-1 (M)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000006825585", "@num": "L421-1", "#text": "Code de la construction et de l'habitation. - art. L421-1 (M)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000006825584", "@num": "L421-1", "#text": "Code de la construction et de l'habitation. - art. L421-1 (M)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000006825581", "@num": "L421-1", "#text": "Code de la construction et de l'habitation. - art. L421-1 (M)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000006825589", "@num": "L421-1", "#text": "Code de la construction et de l'habitation. - art. L421-1 (M)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000006825588", "@num": "L421-1", "#text": "Code de la construction et de l'habitation. - art. L421-1 (M)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000006825587", "@num": "L421-1", "#text": "Code de la construction et de l'habitation. - art. L421-1 (M)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000006825580", "@num": "L421-1", "#text": "Code de la construction et de l'habitation. - art. L421-1 (M)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000006825582", "@num": "L421-1", "#text": "Code de la construction et de l'habitation. - art. L421-1 (M)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000006825586", "@num": "L421-1", "#text": "Code de la construction et de l'habitation. - art. L421-1 (M)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000006825590", "@num": "L421-1", "#text": "Code de la construction et de l'habitation. - art. L421-1 (V)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000006825203", "@num": "L421-1-1", "#text": "Code de la construction et de l'habitation. - art. L421-1-1 (Ab)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000006825204", "@num": "L421-1-2", "#text": "Code de la construction et de l'habitation. - art. L421-1-2 (Ab)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000006825218", "@num": "L421-10", "#text": "Code de la construction et de l'habitation. - art. L421-10 (M)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000006825219", "@num": "L421-10", "#text": "Code de la construction et de l'habitation. - art. L421-10 (M)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000006825220", "@num": "L421-10", "#text": "Code de la construction et de l'habitation. - art. L421-10 (M)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000037668545", "@num": "L421-10", "#text": "Code de la construction et de l'habitation. - art. L421-10 (V)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000006825221", "@num": "L421-11", "#text": "Code de la construction et de l'habitation. - art. L421-11 (M)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000006825222", "@num": "L421-11", "#text": "Code de la construction et de l'habitation. - art. L421-11 (M)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000033974619", "@num": "L421-11", "#text": "Code de la construction et de l'habitation. - art. L421-11 (V)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000006825223", "@num": "L421-12", "#text": "Code de la construction et de l'habitation. - art. L421-12 (M)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000006825224", "@num": "L421-12", "#text": "Code de la construction et de l'habitation. - art. L421-12 (M)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000006825225", "@num": "L421-12", "#text": "Code de la construction et de l'habitation. - art. L421-12 (V)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000006825226", "@num": "L421-13", "#text": "Code de la construction et de l'habitation. - art. L421-13 (M)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000006825227", "@num": "L421-13", "#text": "Code de la construction et de l'habitation. - art. L421-13 (V)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000028808890", "@num": "L421-13", "#text": "Code de la construction et de l'habitation. - art. L421-13 (V)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000006825228", "@num": "L421-14", "#text": "Code de la construction et de l'habitation. - art. L421-14 (VT)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000006825229", "@num": "L421-15", "#text": "Code de la construction et de l'habitation. - art. L421-15 (V)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000006825230", "@num": "L421-16", "#text": "Code de la construction et de l'habitation. - art. L421-16 (V)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000028534539", "@num": "L421-16", "#text": "Code de la construction et de l'habitation. - art. L421-16 (V)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000006825231", "@num": "L421-17", "#text": "Code de la construction et de l'habitation. - art. L421-17 (V)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000037668522", "@num": "L421-17", "#text": "Code de la construction et de l'habitation. - art. L421-17 (VD)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000027794830", "@num": "L421-18", "#text": "Code de la construction et de l'habitation. - art. L421-18 (M)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000006825232", "@num": "L421-18", "#text": "Code de la construction et de l'habitation. - art. L421-18 (V)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000037668180", "@num": "L421-18", "#text": "Code de la construction et de l'habitation. - art. L421-18 (V)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000006825233", "@num": "L421-19", "#text": "Code de la construction et de l'habitation. - art. L421-19 (VT)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000006825208", "@num": "L421-2", "#text": "Code de la construction et de l'habitation. - art. L421-2 (M)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000006825209", "@num": "L421-2", "#text": "Code de la construction et de l'habitation. - art. L421-2 (M)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000006825210", "@num": "L421-2", "#text": "Code de la construction et de l'habitation. - art. L421-2 (V)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000006825234", "@num": "L421-20", "#text": "Code de la construction et de l'habitation. - art. L421-20 (V)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000028808799", "@num": "L421-20", "#text": "Code de la construction et de l'habitation. - art. L421-20 (VT)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000006825235", "@num": "L421-21", "#text": "Code de la construction et de l'habitation. - art. L421-21 (V)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000037668494", "@num": "L421-21", "#text": "Code de la construction et de l'habitation. - art. L421-21 (VD)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000006825236", "@num": "L421-22", "#text": "Code de la construction et de l'habitation. - art. L421-22 (V)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000028808795", "@num": "L421-22", "#text": "Code de la construction et de l'habitation. - art. L421-22 (V)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000037668489", "@num": "L421-22", "#text": "Code de la construction et de l'habitation. - art. L421-22 (VD)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000006825237", "@num": "L421-23", "#text": "Code de la construction et de l'habitation. - art. L421-23 (M)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000032443224", "@num": "L421-23", "#text": "Code de la construction et de l'habitation. - art. L421-23 (V)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000006825238", "@num": "L421-24", "#text": "Code de la construction et de l'habitation. - art. L421-24 (V)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000006825206", "@num": "L421-3", "#text": "Code de la construction et de l'habitation. - art. L421-3 (M)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000006825205", "@num": "L421-3", "#text": "Code de la construction et de l'habitation. - art. L421-3 (M)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000006825207", "@num": "L421-3", "#text": "Code de la construction et de l'habitation. - art. L421-3 (V)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000006825592", "@num": "L421-4", "#text": "Code de la construction et de l'habitation. - art. L421-4 (M)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000006825591", "@num": "L421-4", "#text": "Code de la construction et de l'habitation. - art. L421-4 (M)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000006825593", "@num": "L421-4", "#text": "Code de la construction et de l'habitation. - art. L421-4 (M)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000006825594", "@num": "L421-4", "#text": "Code de la construction et de l'habitation. - art. L421-4 (V)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000006825211", "@num": "L421-5", "#text": "Code de la construction et de l'habitation. - art. L421-5 (M)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000006825212", "@num": "L421-5", "#text": "Code de la construction et de l'habitation. - art. L421-5 (V)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000006825596", "@num": "L421-6", "#text": "Code de la construction et de l'habitation. - art. L421-6 (M)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000006825595", "@num": "L421-6", "#text": "Code de la construction et de l'habitation. - art. L421-6 (M)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000028808878", "@num": "L421-6", "#text": "Code de la construction et de l'habitation. - art. L421-6 (M)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000006825597", "@num": "L421-6", "#text": "Code de la construction et de l'habitation. - art. L421-6 (V)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000031106396", "@num": "L421-6", "#text": "Code de la construction et de l'habitation. - art. L421-6 (V)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000033463273", "@num": "L421-6", "#text": "Code de la construction et de l'habitation. - art. L421-6 (VD)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000033973601", "@num": "L421-6", "#text": "Code de la construction et de l'habitation. - art. L421-6 (VT)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000037668560", "@num": "L421-6", "#text": "Code de la construction et de l'habitation. - art. L421-6 (VT)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000006825598", "@num": "L421-7", "#text": "Code de la construction et de l'habitation. - art. L421-7 (Ab)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000006825599", "@num": "L421-7", "#text": "Code de la construction et de l'habitation. - art. L421-7 (V)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000006825213", "@num": "L421-8", "#text": "Code de la construction et de l'habitation. - art. L421-8 (M)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000006825214", "@num": "L421-8", "#text": "Code de la construction et de l'habitation. - art. L421-8 (M)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000006825215", "@num": "L421-8", "#text": "Code de la construction et de l'habitation. - art. L421-8 (M)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000006825216", "@num": "L421-9", "#text": "Code de la construction et de l'habitation. - art. L421-9 (M)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000006825217", "@num": "L421-9", "#text": "Code de la construction et de l'habitation. - art. L421-9 (M)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000033972883", "@num": "L421-9", "#text": "Code de la construction et de l'habitation. - art. L421-9 (M)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000037668160", "@num": "L421-9", "#text": "Code de la construction et de l'habitation. - art. L421-9 (V)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000006825243", "@num": "L422-1", "#text": "Code de la construction et de l'habitation. - art. L422-1 (V)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000006825279", "@num": "L422-10", "#text": "Code de la construction et de l'habitation. - art. L422-10 (AbD)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000006825280", "@num": "L422-10", "#text": "Code de la construction et de l'habitation. - art. L422-10 (VD)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000028808519", "@num": "L422-10", "#text": "Code de la construction et de l'habitation. - art. L422-10 (VD)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000006825275", "@num": "L422-11", "#text": "Code de la construction et de l'habitation. - art. L422-11 (AbD)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000006825274", "@num": "L422-11", "#text": "Code de la construction et de l'habitation. - art. L422-11 (M)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000028808832", "@num": "L422-11", "#text": "Code de la construction et de l'habitation. - art. L422-11 (V)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000006825276", "@num": "L422-11", "#text": "Code de la construction et de l'habitation. - art. L422-11 (VD)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000006825281", "@num": "L422-12", "#text": "Code de la construction et de l'habitation. - art. L422-12 (M)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000006825282", "@num": "L422-12", "#text": "Code de la construction et de l'habitation. - art. L422-12 (M)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000006825283", "@num": "L422-12", "#text": "Code de la construction et de l'habitation. - art. L422-12 (V)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000029320852", "@num": "L422-12", "#text": "Code de la construction et de l'habitation. - art. L422-12 (V)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000006825284", "@num": "L422-13", "#text": "Code de la construction et de l'habitation. - art. L422-13 (M)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000006825285", "@num": "L422-13", "#text": "Code de la construction et de l'habitation. - art. L422-13 (V)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000024040966", "@num": "L422-13", "#text": "Code de la construction et de l'habitation. - art. L422-13 (V)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000006825632", "@num": "L422-14", "#text": "Code de la construction et de l'habitation. - art. L422-14 (M)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000006825633", "@num": "L422-14", "#text": "Code de la construction et de l'habitation. - art. L422-14 (M)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000006825634", "@num": "L422-14", "#text": "Code de la construction et de l'habitation. - art. L422-14 (M)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000006825635", "@num": "L422-14", "#text": "Code de la construction et de l'habitation. - art. L422-14 (M)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000006825636", "@num": "L422-14", "#text": "Code de la construction et de l'habitation. - art. L422-14 (V)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000006825637", "@num": "L422-15", "#text": "Code de la construction et de l'habitation. - art. L422-15 (M)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000006825638", "@num": "L422-15", "#text": "Code de la construction et de l'habitation. - art. L422-15 (M)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000006825639", "@num": "L422-15", "#text": "Code de la construction et de l'habitation. - art. L422-15 (V)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000006825286", "@num": "L422-16", "#text": "Code de la construction et de l'habitation. - art. L422-16 (V)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000006825287", "@num": "L422-17", "#text": "Code de la construction et de l'habitation. - art. L422-17 (V)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000006825288", "@num": "L422-18", "#text": "Code de la construction et de l'habitation. - art. L422-18 (V)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000006825289", "@num": "L422-19", "#text": "Code de la construction et de l'habitation. - art. L422-19 (V)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000006825289", "@num": "L422-19", "#text": "Code de la construction et de l'habitation. - art. L422-19 (V)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CREATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000006825610", "@num": "L422-2", "#text": "Code de la construction et de l'habitation. - art. L422-2 (M)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000006825602", "@num": "L422-2", "#text": "Code de la construction et de l'habitation. - art. L422-2 (M)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000006825608", "@num": "L422-2", "#text": "Code de la construction et de l'habitation. - art. L422-2 (M)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000006825603", "@num": "L422-2", "#text": "Code de la construction et de l'habitation. - art. L422-2 (M)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000006825604", "@num": "L422-2", "#text": "Code de la construction et de l'habitation. - art. L422-2 (M)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000006825605", "@num": "L422-2", "#text": "Code de la construction et de l'habitation. - art. L422-2 (M)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000006825606", "@num": "L422-2", "#text": "Code de la construction et de l'habitation. - art. L422-2 (M)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000006825600", "@num": "L422-2", "#text": "Code de la construction et de l'habitation. - art. L422-2 (M)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000006825607", "@num": "L422-2", "#text": "Code de la construction et de l'habitation. - art. L422-2 (M)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000006825601", "@num": "L422-2", "#text": "Code de la construction et de l'habitation. - art. L422-2 (M)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000006825609", "@num": "L422-2", "#text": "Code de la construction et de l'habitation. - art. L422-2 (M)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000006825611", "@num": "L422-2", "#text": "Code de la construction et de l'habitation. - art. L422-2 (V)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000006825239", "@num": "L422-2-1", "#text": "Code de la construction et de l'habitation. - art. L422-2-1 (M)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000006825241", "@num": "L422-2-1", "#text": "Code de la construction et de l'habitation. - art. L422-2-1 (M)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000006825240", "@num": "L422-2-1", "#text": "Code de la construction et de l'habitation. - art. L422-2-1 (M)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000032042894", "@num": "L422-2-1", "#text": "Code de la construction et de l'habitation. - art. L422-2-1 (M)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000006825242", "@num": "L422-2-1", "#text": "Code de la construction et de l'habitation. - art. L422-2-1 (V)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000023259619", "@num": "L422-2-1", "#text": "Code de la construction et de l'habitation. - art. L422-2-1 (V)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000027794822", "@num": "L422-2-1", "#text": "Code de la construction et de l'habitation. - art. L422-2-1 (V)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000028809759", "@num": "L422-2-1", "#text": "Code de la construction et de l'habitation. - art. L422-2-1 (V)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000033972874", "@num": "L422-2-1", "#text": "Code de la construction et de l'habitation. - art. L422-2-1 (V)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000031105906", "@num": "L422-2-1", "#text": "Code de la construction et de l'habitation. - art. L422-2-1 (VD)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000033282941", "@num": "L422-2-1", "#text": "Code de la construction et de l'habitation. - art. L422-2-1 (VT)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000006825612", "@num": "L422-3", "#text": "Code de la construction et de l'habitation. - art. L422-3 (M)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000006825620", "@num": "L422-3", "#text": "Code de la construction et de l'habitation. - art. L422-3 (M)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000006825616", "@num": "L422-3", "#text": "Code de la construction et de l'habitation. - art. L422-3 (M)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000006825617", "@num": "L422-3", "#text": "Code de la construction et de l'habitation. - art. L422-3 (M)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000006825615", "@num": "L422-3", "#text": "Code de la construction et de l'habitation. - art. L422-3 (M)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000006825613", "@num": "L422-3", "#text": "Code de la construction et de l'habitation. - art. L422-3 (M)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000006825618", "@num": "L422-3", "#text": "Code de la construction et de l'habitation. - art. L422-3 (M)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000006825614", "@num": "L422-3", "#text": "Code de la construction et de l'habitation. - art. L422-3 (M)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000006825621", "@num": "L422-3", "#text": "Code de la construction et de l'habitation. - art. L422-3 (M)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000006825619", "@num": "L422-3", "#text": "Code de la construction et de l'habitation. - art. L422-3 (M)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000006825622", "@num": "L422-3", "#text": "Code de la construction et de l'habitation. - art. L422-3 (V)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000006825244", "@num": "L422-3-1", "#text": "Code de la construction et de l'habitation. - art. L422-3-1 (Ab)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000006825245", "@num": "L422-3-1", "#text": "Code de la construction et de l'habitation. - art. L422-3-1 (M)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000006825246", "@num": "L422-3-1", "#text": "Code de la construction et de l'habitation. - art. L422-3-1 (V)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000006825249", "@num": "L422-3-2", "#text": "Code de la construction et de l'habitation. - art. L422-3-2 (Ab)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000006825248", "@num": "L422-3-2", "#text": "Code de la construction et de l'habitation. - art. L422-3-2 (M)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000006825247", "@num": "L422-3-2", "#text": "Code de la construction et de l'habitation. - art. L422-3-2 (M)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000029321434", "@num": "L422-3-2", "#text": "Code de la construction et de l'habitation. - art. L422-3-2 (M)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000006825250", "@num": "L422-3-2", "#text": "Code de la construction et de l'habitation. - art. L422-3-2 (V)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000037668923", "@num": "L422-3-2", "#text": "Code de la construction et de l'habitation. - art. L422-3-2 (V)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000041715834", "@num": "L422-3-2", "#text": "Code de la construction et de l'habitation. - art. L422-3-2 (VD)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000006825627", "@num": "L422-4", "#text": "Code de la construction et de l'habitation. - art. L422-4 (AbD)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000006825626", "@num": "L422-4", "#text": "Code de la construction et de l'habitation. - art. L422-4 (M)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000006825625", "@num": "L422-4", "#text": "Code de la construction et de l'habitation. - art. L422-4 (M)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000006825623", "@num": "L422-4", "#text": "Code de la construction et de l'habitation. - art. L422-4 (M)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000006825624", "@num": "L422-4", "#text": "Code de la construction et de l'habitation. - art. L422-4 (M)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000037668941", "@num": "L422-4", "#text": "Code de la construction et de l'habitation. - art. L422-4 (V)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000006825253", "@num": "L422-4-1", "#text": "Code de la construction et de l'habitation. - art. L422-4-1 (AbD)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000006825251", "@num": "L422-4-1", "#text": "Code de la construction et de l'habitation. - art. L422-4-1 (M)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000006825252", "@num": "L422-4-1", "#text": "Code de la construction et de l'habitation. - art. L422-4-1 (M)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000006825255", "@num": "L422-4-2", "#text": "Code de la construction et de l'habitation. - art. L422-4-2 (AbD)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000006825254", "@num": "L422-4-2", "#text": "Code de la construction et de l'habitation. - art. L422-4-2 (M)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000006825256", "@num": "L422-4-3", "#text": "Code de la construction et de l'habitation. - art. L422-4-3 (AbD)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000006825630", "@num": "L422-5", "#text": "Code de la construction et de l'habitation. - art. L422-5 (AbD)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000006825628", "@num": "L422-5", "#text": "Code de la construction et de l'habitation. - art. L422-5 (M)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000006825629", "@num": "L422-5", "#text": "Code de la construction et de l'habitation. - art. L422-5 (M)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000006825631", "@num": "L422-5", "#text": "Code de la construction et de l'habitation. - art. L422-5 (VD)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000006825258", "@num": "L422-5-1", "#text": "Code de la construction et de l'habitation. - art. L422-5-1 (AbD)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000006825257", "@num": "L422-5-1", "#text": "Code de la construction et de l'habitation. - art. L422-5-1 (M)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000006825259", "@num": "L422-5-1", "#text": "Code de la construction et de l'habitation. - art. L422-5-1 (VD)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000006825261", "@num": "L422-6", "#text": "Code de la construction et de l'habitation. - art. L422-6 (AbD)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000006825260", "@num": "L422-6", "#text": "Code de la construction et de l'habitation. - art. L422-6 (M)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000006825262", "@num": "L422-6", "#text": "Code de la construction et de l'habitation. - art. L422-6 (VD)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000006825265", "@num": "L422-7", "#text": "Code de la construction et de l'habitation. - art. L422-7 (AbD)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000006825264", "@num": "L422-7", "#text": "Code de la construction et de l'habitation. - art. L422-7 (M)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000006825263", "@num": "L422-7", "#text": "Code de la construction et de l'habitation. - art. L422-7 (M)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000006825266", "@num": "L422-7", "#text": "Code de la construction et de l'habitation. - art. L422-7 (VD)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000006825270", "@num": "L422-8", "#text": "Code de la construction et de l'habitation. - art. L422-8 (AbD)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000006825268", "@num": "L422-8", "#text": "Code de la construction et de l'habitation. - art. L422-8 (M)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000006825267", "@num": "L422-8", "#text": "Code de la construction et de l'habitation. - art. L422-8 (M)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000006825269", "@num": "L422-8", "#text": "Code de la construction et de l'habitation. - art. L422-8 (M)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000006825271", "@num": "L422-8", "#text": "Code de la construction et de l'habitation. - art. L422-8 (VD)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000028808528", "@num": "L422-8", "#text": "Code de la construction et de l'habitation. - art. L422-8 (VD)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000006825277", "@num": "L422-8-1", "#text": "Code de la construction et de l'habitation. - art. L422-8-1 (AbD)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000006825278", "@num": "L422-8-1", "#text": "Code de la construction et de l'habitation. - art. L422-8-1 (VD)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000028808525", "@num": "L422-8-1", "#text": "Code de la construction et de l'habitation. - art. L422-8-1 (VD)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000006825272", "@num": "L422-9", "#text": "Code de la construction et de l'habitation. - art. L422-9 (AbD)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000006825273", "@num": "L422-9", "#text": "Code de la construction et de l'habitation. - art. L422-9 (VD)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000028808522", "@num": "L422-9", "#text": "Code de la construction et de l'habitation. - art. L422-9 (VD)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000006825291", "@num": "L423-1", "#text": "Code de la construction et de l'habitation. - art. L423-1 (M)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000006825292", "@num": "L423-1", "#text": "Code de la construction et de l'habitation. - art. L423-1 (M)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000037668148", "@num": "L423-1", "#text": "Code de la construction et de l'habitation. - art. L423-1 (V)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000006825290", "@num": "L423-1 A", "#text": "Code de la construction et de l'habitation. - art. L423-1 A (Ab)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000006825293", "@num": "L423-1-1", "#text": "Code de la construction et de l'habitation. - art. L423-1-1 (Ab)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000006825294", "@num": "L423-1-1", "#text": "Code de la construction et de l'habitation. - art. L423-1-1 (M)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000006825295", "@num": "L423-1-1", "#text": "Code de la construction et de l'habitation. - art. L423-1-1 (V)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000006825296", "@num": "L423-1-2", "#text": "Code de la construction et de l'habitation. - art. L423-1-2 (Ab)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000006825297", "@num": "L423-1-2", "#text": "Code de la construction et de l'habitation. - art. L423-1-2 (M)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000031145692", "@num": "L423-1-2", "#text": "Code de la construction et de l'habitation. - art. L423-1-2 (M)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000037668094", "@num": "L423-1-2", "#text": "Code de la construction et de l'habitation. - art. L423-1-2 (V)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000006825298", "@num": "L423-1-3", "#text": "Code de la construction et de l'habitation. - art. L423-1-3 (Ab)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000006825299", "@num": "L423-1-3", "#text": "Code de la construction et de l'habitation. - art. L423-1-3 (M)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000006825300", "@num": "L423-1-3", "#text": "Code de la construction et de l'habitation. - art. L423-1-3 (M)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000037668071", "@num": "L423-1-3", "#text": "Code de la construction et de l'habitation. - art. L423-1-3 (V)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000006825301", "@num": "L423-1-4", "#text": "Code de la construction et de l'habitation. - art. L423-1-4 (Ab)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000006825318", "@num": "L423-10", "#text": "Code de la construction et de l'habitation. - art. L423-10 (M)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000006825319", "@num": "L423-10", "#text": "Code de la construction et de l'habitation. - art. L423-10 (M)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000006825317", "@num": "L423-10", "#text": "Code de la construction et de l'habitation. - art. L423-10 (M)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000006825320", "@num": "L423-10", "#text": "Code de la construction et de l'habitation. - art. L423-10 (V)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000006825321", "@num": "L423-11", "#text": "Code de la construction et de l'habitation. - art. L423-11 (M)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000006825322", "@num": "L423-11", "#text": "Code de la construction et de l'habitation. - art. L423-11 (M)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000006825323", "@num": "L423-11", "#text": "Code de la construction et de l'habitation. - art. L423-11 (M)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000006825324", "@num": "L423-11", "#text": "Code de la construction et de l'habitation. - art. L423-11 (V)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000006825325", "@num": "L423-11-1", "#text": "Code de la construction et de l'habitation. - art. L423-11-1 (V)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000006825326", "@num": "L423-11-2", "#text": "Code de la construction et de l'habitation. - art. L423-11-2 (V)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000006825327", "@num": "L423-11-3", "#text": "Code de la construction et de l'habitation. - art. L423-11-3 (V)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000006825328", "@num": "L423-12", "#text": "Code de la construction et de l'habitation. - art. L423-12 (V)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000028808516", "@num": "L423-12", "#text": "Code de la construction et de l'habitation. - art. L423-12 (VD)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000006825329", "@num": "L423-13", "#text": "Code de la construction et de l'habitation. - art. L423-13 (V)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000028808326", "@num": "L423-13", "#text": "Code de la construction et de l'habitation. - art. L423-13 (V)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000006825302", "@num": "L423-2", "#text": "Code de la construction et de l'habitation. - art. L423-2 (V)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000037668119", "@num": "L423-2", "#text": "Code de la construction et de l'habitation. - art. L423-2 (VD)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000006825303", "@num": "L423-3", "#text": "Code de la construction et de l'habitation. - art. L423-3 (AbD)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000028808983", "@num": "L423-3", "#text": "Code de la construction et de l'habitation. - art. L423-3 (V)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000006825304", "@num": "L423-3", "#text": "Code de la construction et de l'habitation. - art. L423-3 (VD)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000006825305", "@num": "L423-4", "#text": "Code de la construction et de l'habitation. - art. L423-4 (Ab)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000006825306", "@num": "L423-4", "#text": "Code de la construction et de l'habitation. - art. L423-4 (AbD)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000028808826", "@num": "L423-4", "#text": "Code de la construction et de l'habitation. - art. L423-4 (V)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000006825307", "@num": "L423-4", "#text": "Code de la construction et de l'habitation. - art. L423-4 (VD)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000006825308", "@num": "L423-5", "#text": "Code de la construction et de l'habitation. - art. L423-5 (Ab)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000006825309", "@num": "L423-5", "#text": "Code de la construction et de l'habitation. - art. L423-5 (V)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000028808819", "@num": "L423-5", "#text": "Code de la construction et de l'habitation. - art. L423-5 (V)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000039652825", "@num": "L423-5", "#text": "Code de la construction et de l'habitation. - art. L423-5 (VD)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000006825310", "@num": "L423-6", "#text": "Code de la construction et de l'habitation. - art. L423-6 (Ab)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000024040952", "@num": "L423-6", "#text": "Code de la construction et de l'habitation. - art. L423-6 (M)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000033282931", "@num": "L423-6", "#text": "Code de la construction et de l'habitation. - art. L423-6 (V)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000006825311", "@num": "L423-7", "#text": "Code de la construction et de l'habitation. - art. L423-7 (Ab)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000006825312", "@num": "L423-8", "#text": "Code de la construction et de l'habitation. - art. L423-8 (Ab)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000006825315", "@num": "L423-9", "#text": "Code de la construction et de l'habitation. - art. L423-9 (AbD)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000006825314", "@num": "L423-9", "#text": "Code de la construction et de l'habitation. - art. L423-9 (M)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000006825313", "@num": "L423-9", "#text": "Code de la construction et de l'habitation. - art. L423-9 (M)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000006825316", "@num": "L423-9", "#text": "Code de la construction et de l'habitation. - art. L423-9 (VD)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000006825330", "@num": "L424-1", "#text": "Code de la construction et de l'habitation. - art. L424-1 (V)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000006825331", "@num": "L424-2", "#text": "Code de la construction et de l'habitation. - art. L424-2 (M)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000037668339", "@num": "L424-2", "#text": "Code de la construction et de l'habitation. - art. L424-2 (V)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000006825640", "@num": "L431-1", "#text": "Code de la construction et de l'habitation. - art. L431-1 (M)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000006825642", "@num": "L431-1", "#text": "Code de la construction et de l'habitation. - art. L431-1 (M)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000006825641", "@num": "L431-1", "#text": "Code de la construction et de l'habitation. - art. L431-1 (M)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000006825643", "@num": "L431-1", "#text": "Code de la construction et de l'habitation. - art. L431-1 (V)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000038834168", "@num": "L431-1", "#text": "Code de la construction et de l'habitation. - art. L431-1 (VD)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000006825332", "@num": "L431-2", "#text": "Code de la construction et de l'habitation. - art. L431-2 (V)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000006825645", "@num": "L431-3", "#text": "Code de la construction et de l'habitation. - art. L431-3 (M)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000006825644", "@num": "L431-3", "#text": "Code de la construction et de l'habitation. - art. L431-3 (M)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000006825646", "@num": "L431-3", "#text": "Code de la construction et de l'habitation. - art. L431-3 (V)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000006825648", "@num": "L431-4", "#text": "Code de la construction et de l'habitation. - art. L431-4 (M)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000006825647", "@num": "L431-4", "#text": "Code de la construction et de l'habitation. - art. L431-4 (M)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000006825649", "@num": "L431-4", "#text": "Code de la construction et de l'habitation. - art. L431-4 (V)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000006825650", "@num": "L431-5", "#text": "Code de la construction et de l'habitation. - art. L431-5 (M)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000006825651", "@num": "L431-5", "#text": "Code de la construction et de l'habitation. - art. L431-5 (V)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000006825652", "@num": "L431-6", "#text": "Code de la construction et de l'habitation. - art. L431-6 (Ab)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000006825652", "@num": "L431-6", "#text": "Code de la construction et de l'habitation. - art. L431-6 (Ab)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CREATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000006825653", "@num": "L432-1", "#text": "Code de la construction et de l'habitation. - art. L432-1 (M)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000006825654", "@num": "L432-1", "#text": "Code de la construction et de l'habitation. - art. L432-1 (V)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000006825334", "@num": "L432-2", "#text": "Code de la construction et de l'habitation. - art. L432-2 (M)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000006825333", "@num": "L432-2", "#text": "Code de la construction et de l'habitation. - art. L432-2 (M)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CREATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000006825333", "@num": "L432-2", "#text": "Code de la construction et de l'habitation. - art. L432-2 (M)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000006825335", "@num": "L432-2", "#text": "Code de la construction et de l'habitation. - art. L432-2 (V)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000006825336", "@num": "L432-3", "#text": "Code de la construction et de l'habitation. - art. L432-3 (V)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000006825337", "@num": "L432-4", "#text": "Code de la construction et de l'habitation. - art. L432-4 (V)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000006825655", "@num": "L432-5", "#text": "Code de la construction et de l'habitation. - art. L432-5 (Ab)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000006825656", "@num": "L432-6", "#text": "Code de la construction et de l'habitation. - art. L432-6 (M)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000006825657", "@num": "L432-6", "#text": "Code de la construction et de l'habitation. - art. L432-6 (V)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000028808508", "@num": "L432-6", "#text": "Code de la construction et de l'habitation. - art. L432-6 (VD)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000038834164", "@num": "L432-6", "#text": "Code de la construction et de l'habitation. - art. L432-6 (VD)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000006825338", "@num": "L433-1", "#text": "Code de la construction et de l'habitation. - art. L433-1 (M)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000006825339", "@num": "L433-1", "#text": "Code de la construction et de l'habitation. - art. L433-1 (M)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000037667739", "@num": "L433-1", "#text": "Code de la construction et de l'habitation. - art. L433-1 (V)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000037739039", "@num": "L433-1", "#text": "Code de la construction et de l'habitation. - art. L433-1 (VD)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000006825340", "@num": "L441", "#text": "Code de la construction et de l'habitation. - art. L441 (M)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000006825341", "@num": "L441", "#text": "Code de la construction et de l'habitation. - art. L441 (M)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000033971964", "@num": "L441", "#text": "Code de la construction et de l'habitation. - art. L441 (M)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000037667676", "@num": "L441", "#text": "Code de la construction et de l'habitation. - art. L441 (V)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000006825396", "@num": "L441-1", "#text": "Code de la construction et de l'habitation. - art. L441-1 (M)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000006825389", "@num": "L441-1", "#text": "Code de la construction et de l'habitation. - art. L441-1 (M)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000006825391", "@num": "L441-1", "#text": "Code de la construction et de l'habitation. - art. L441-1 (M)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000006825388", "@num": "L441-1", "#text": "Code de la construction et de l'habitation. - art. L441-1 (M)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000006825392", "@num": "L441-1", "#text": "Code de la construction et de l'habitation. - art. L441-1 (M)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000006825395", "@num": "L441-1", "#text": "Code de la construction et de l'habitation. - art. L441-1 (M)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000006825393", "@num": "L441-1", "#text": "Code de la construction et de l'habitation. - art. L441-1 (M)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000006825394", "@num": "L441-1", "#text": "Code de la construction et de l'habitation. - art. L441-1 (M)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000006825390", "@num": "L441-1", "#text": "Code de la construction et de l'habitation. - art. L441-1 (M)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000006825397", "@num": "L441-1", "#text": "Code de la construction et de l'habitation. - art. L441-1 (V)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000006825401", "@num": "L441-1-1", "#text": "Code de la construction et de l'habitation. - art. L441-1-1 (M)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000006825399", "@num": "L441-1-1", "#text": "Code de la construction et de l'habitation. - art. L441-1-1 (M)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000006825398", "@num": "L441-1-1", "#text": "Code de la construction et de l'habitation. - art. L441-1-1 (M)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000006825400", "@num": "L441-1-1", "#text": "Code de la construction et de l'habitation. - art. L441-1-1 (M)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000006825402", "@num": "L441-1-1", "#text": "Code de la construction et de l'habitation. - art. L441-1-1 (V)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000006825405", "@num": "L441-1-2", "#text": "Code de la construction et de l'habitation. - art. L441-1-2 (M)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000006825404", "@num": "L441-1-2", "#text": "Code de la construction et de l'habitation. - art. L441-1-2 (M)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000006825403", "@num": "L441-1-2", "#text": "Code de la construction et de l'habitation. - art. L441-1-2 (M)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000006825406", "@num": "L441-1-2", "#text": "Code de la construction et de l'habitation. - art. L441-1-2 (M)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000006825407", "@num": "L441-1-2", "#text": "Code de la construction et de l'habitation. - art. L441-1-2 (V)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000006825342", "@num": "L441-1-3", "#text": "Code de la construction et de l'habitation. - art. L441-1-3 (V)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000006825354", "@num": "L441-1-4", "#text": "Code de la construction et de l'habitation. - art. L441-1-4 (M)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000006825356", "@num": "L441-1-4", "#text": "Code de la construction et de l'habitation. - art. L441-1-4 (M)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000006825355", "@num": "L441-1-4", "#text": "Code de la construction et de l'habitation. - art. L441-1-4 (M)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000006825357", "@num": "L441-1-4", "#text": "Code de la construction et de l'habitation. - art. L441-1-4 (V)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000033971916", "@num": "L441-1-4", "#text": "Code de la construction et de l'habitation. - art. L441-1-4 (V)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000029945244", "@num": "L441-1-4", "#text": "Code de la construction et de l'habitation. - art. L441-1-4 (VD)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000006825359", "@num": "L441-1-5", "#text": "Code de la construction et de l'habitation. - art. L441-1-5 (Ab)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000006825358", "@num": "L441-1-5", "#text": "Code de la construction et de l'habitation. - art. L441-1-5 (M)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000028808363", "@num": "L441-1-5", "#text": "Code de la construction et de l'habitation. - art. L441-1-5 (M)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000033971898", "@num": "L441-1-5", "#text": "Code de la construction et de l'habitation. - art. L441-1-5 (M)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000037669916", "@num": "L441-1-5", "#text": "Code de la construction et de l'habitation. - art. L441-1-5 (M)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000045136844", "@num": "L441-1-5", "#text": "Code de la construction et de l'habitation. - art. L441-1-5 (V)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000006825361", "@num": "L441-1-6", "#text": "Code de la construction et de l'habitation. - art. L441-1-6 (Ab)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000006825360", "@num": "L441-1-6", "#text": "Code de la construction et de l'habitation. - art. L441-1-6 (M)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000033971894", "@num": "L441-1-6", "#text": "Code de la construction et de l'habitation. - art. L441-1-6 (M)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000037669908", "@num": "L441-1-6", "#text": "Code de la construction et de l'habitation. - art. L441-1-6 (M)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000045211549", "@num": "L441-1-6", "#text": "Code de la construction et de l'habitation. - art. L441-1-6 (V)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000006825372", "@num": "L441-10", "#text": "Code de la construction et de l'habitation. - art. L441-10 (M)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000006825373", "@num": "L441-10", "#text": "Code de la construction et de l'habitation. - art. L441-10 (V)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000006825374", "@num": "L441-11", "#text": "Code de la construction et de l'habitation. - art. L441-11 (V)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000036432651", "@num": "L441-11", "#text": "Code de la construction et de l'habitation. - art. L441-11 (V)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000028808505", "@num": "L441-11", "#text": "Code de la construction et de l'habitation. - art. L441-11 (VD)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000006825375", "@num": "L441-12", "#text": "Code de la construction et de l'habitation. - art. L441-12 (M)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000006825376", "@num": "L441-12", "#text": "Code de la construction et de l'habitation. - art. L441-12 (V)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000006825377", "@num": "L441-13", "#text": "Code de la construction et de l'habitation. - art. L441-13 (V)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000038834160", "@num": "L441-13", "#text": "Code de la construction et de l'habitation. - art. L441-13 (VD)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000006825378", "@num": "L441-14", "#text": "Code de la construction et de l'habitation. - art. L441-14 (M)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000006825379", "@num": "L441-14", "#text": "Code de la construction et de l'habitation. - art. L441-14 (V)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000006825380", "@num": "L441-15", "#text": "Code de la construction et de l'habitation. - art. L441-15 (V)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000006825513", "@num": "L441-2", "#text": "Code de la construction et de l'habitation. - art. L441-2 (M)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000006825515", "@num": "L441-2", "#text": "Code de la construction et de l'habitation. - art. L441-2 (M)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000006825514", "@num": "L441-2", "#text": "Code de la construction et de l'habitation. - art. L441-2 (M)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000006825512", "@num": "L441-2", "#text": "Code de la construction et de l'habitation. - art. L441-2 (M)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000006825509", "@num": "L441-2", "#text": "Code de la construction et de l'habitation. - art. L441-2 (M)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000006825510", "@num": "L441-2", "#text": "Code de la construction et de l'habitation. - art. L441-2 (M)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000006825511", "@num": "L441-2", "#text": "Code de la construction et de l'habitation. - art. L441-2 (M)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000006825516", "@num": "L441-2", "#text": "Code de la construction et de l'habitation. - art. L441-2 (V)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000006825362", "@num": "L441-2-1", "#text": "Code de la construction et de l'habitation. - art. L441-2-1 (M)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000006825364", "@num": "L441-2-1", "#text": "Code de la construction et de l'habitation. - art. L441-2-1 (M)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000006825363", "@num": "L441-2-1", "#text": "Code de la construction et de l'habitation. - art. L441-2-1 (M)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000006825365", "@num": "L441-2-1", "#text": "Code de la construction et de l'habitation. - art. L441-2-1 (V)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000006825343", "@num": "L441-2-2", "#text": "Code de la construction et de l'habitation. - art. L441-2-2 (V)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000006825344", "@num": "L441-2-3", "#text": "Code de la construction et de l'habitation. - art. L441-2-3 (M)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000006825345", "@num": "L441-2-3", "#text": "Code de la construction et de l'habitation. - art. L441-2-3 (M)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000006825346", "@num": "L441-2-3", "#text": "Code de la construction et de l'habitation. - art. L441-2-3 (V)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000006825347", "@num": "L441-2-3-1", "#text": "Code de la construction et de l'habitation. - art. L441-2-3-1 (V)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000006825348", "@num": "L441-2-3-2", "#text": "Code de la construction et de l'habitation. - art. L441-2-3-2 (V)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000006825349", "@num": "L441-2-4", "#text": "Code de la construction et de l'habitation. - art. L441-2-4 (V)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000006825351", "@num": "L441-2-5", "#text": "Code de la construction et de l'habitation. - art. L441-2-5 (M)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000006825350", "@num": "L441-2-5", "#text": "Code de la construction et de l'habitation. - art. L441-2-5 (M)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000006825352", "@num": "L441-2-5", "#text": "Code de la construction et de l'habitation. - art. L441-2-5 (V)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000028808348", "@num": "L441-2-6", "#text": "Code de la construction et de l'habitation. - art. L441-2-6 (M)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000006825353", "@num": "L441-2-6", "#text": "Code de la construction et de l'habitation. - art. L441-2-6 (V)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000033971828", "@num": "L441-2-6", "#text": "Code de la construction et de l'habitation. - art. L441-2-6 (V)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000006825410", "@num": "L441-3", "#text": "Code de la construction et de l'habitation. - art. L441-3 (M)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000006825411", "@num": "L441-3", "#text": "Code de la construction et de l'habitation. - art. L441-3 (M)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000006825408", "@num": "L441-3", "#text": "Code de la construction et de l'habitation. - art. L441-3 (M)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000006825413", "@num": "L441-3", "#text": "Code de la construction et de l'habitation. - art. L441-3 (M)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000006825409", "@num": "L441-3", "#text": "Code de la construction et de l'habitation. - art. L441-3 (M)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000006825412", "@num": "L441-3", "#text": "Code de la construction et de l'habitation. - art. L441-3 (M)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000033972454", "@num": "L441-3", "#text": "Code de la construction et de l'habitation. - art. L441-3 (M)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000037668675", "@num": "L441-3", "#text": "Code de la construction et de l'habitation. - art. L441-3 (M)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000006825414", "@num": "L441-3", "#text": "Code de la construction et de l'habitation. - art. L441-3 (V)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000028650764", "@num": "L441-3", "#text": "Code de la construction et de l'habitation. - art. L441-3 (VD)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000048827325", "@num": "L441-3", "#text": "Code de la construction et de l'habitation. - art. L441-3 (VT)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000006825366", "@num": "L441-3-1", "#text": "Code de la construction et de l'habitation. - art. L441-3-1 (V)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000006825367", "@num": "L441-4", "#text": "Code de la construction et de l'habitation. - art. L441-4 (M)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000006825368", "@num": "L441-4", "#text": "Code de la construction et de l'habitation. - art. L441-4 (V)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000006825382", "@num": "L441-5", "#text": "Code de la construction et de l'habitation. - art. L441-5 (Ab)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000006825381", "@num": "L441-5", "#text": "Code de la construction et de l'habitation. - art. L441-5 (M)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000006825384", "@num": "L441-6", "#text": "Code de la construction et de l'habitation. - art. L441-6 (Ab)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000006825383", "@num": "L441-6", "#text": "Code de la construction et de l'habitation. - art. L441-6 (M)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000006825369", "@num": "L441-7", "#text": "Code de la construction et de l'habitation. - art. L441-7 (Ab)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000006825370", "@num": "L441-8", "#text": "Code de la construction et de l'habitation. - art. L441-8 (M)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000006825371", "@num": "L441-8", "#text": "Code de la construction et de l'habitation. - art. L441-8 (V)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000006825386", "@num": "L441-9", "#text": "Code de la construction et de l'habitation. - art. L441-9 (M)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000006825385", "@num": "L441-9", "#text": "Code de la construction et de l'habitation. - art. L441-9 (M)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000006825387", "@num": "L441-9", "#text": "Code de la construction et de l'habitation. - art. L441-9 (M)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000037670643", "@num": "L441-9", "#text": "Code de la construction et de l'habitation. - art. L441-9 (V)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000038833818", "@num": "L441-9", "#text": "Code de la construction et de l'habitation. - art. L441-9 (VD)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000006825415", "@num": "L442-1", "#text": "Code de la construction et de l'habitation. - art. L442-1 (M)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000033972168", "@num": "L442-1", "#text": "Code de la construction et de l'habitation. - art. L442-1 (M)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000045211561", "@num": "L442-1", "#text": "Code de la construction et de l'habitation. - art. L442-1 (V)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000006825416", "@num": "L442-1-1", "#text": "Code de la construction et de l'habitation. - art. L442-1-1 (V)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000038834155", "@num": "L442-1-1", "#text": "Code de la construction et de l'habitation. - art. L442-1-1 (VD)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000006825418", "@num": "L442-1-2", "#text": "Code de la construction et de l'habitation. - art. L442-1-2 (M)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000006825417", "@num": "L442-1-2", "#text": "Code de la construction et de l'habitation. - art. L442-1-2 (M)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000006825419", "@num": "L442-1-2", "#text": "Code de la construction et de l'habitation. - art. L442-1-2 (V)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000006825759", "@num": "L442-10", "#text": "Code de la construction et de l'habitation. - art. L442-10 (M)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000006825756", "@num": "L442-10", "#text": "Code de la construction et de l'habitation. - art. L442-10 (M)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000006825757", "@num": "L442-10", "#text": "Code de la construction et de l'habitation. - art. L442-10 (M)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000006825758", "@num": "L442-10", "#text": "Code de la construction et de l'habitation. - art. L442-10 (M)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000006825760", "@num": "L442-10", "#text": "Code de la construction et de l'habitation. - art. L442-10 (V)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000006825447", "@num": "L442-11", "#text": "Code de la construction et de l'habitation. - art. L442-11 (V)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000006825420", "@num": "L442-2", "#text": "Code de la construction et de l'habitation. - art. L442-2 (V)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000006825660", "@num": "L442-3", "#text": "Code de la construction et de l'habitation. - art. L442-3 (M)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000006825658", "@num": "L442-3", "#text": "Code de la construction et de l'habitation. - art. L442-3 (M)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000006825661", "@num": "L442-3", "#text": "Code de la construction et de l'habitation. - art. L442-3 (M)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000006825659", "@num": "L442-3", "#text": "Code de la construction et de l'habitation. - art. L442-3 (M)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000006825662", "@num": "L442-3", "#text": "Code de la construction et de l'habitation. - art. L442-3 (V)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000006825421", "@num": "L442-4", "#text": "Code de la construction et de l'habitation. - art. L442-4 (M)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000006825422", "@num": "L442-4", "#text": "Code de la construction et de l'habitation. - art. L442-4 (V)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000006825423", "@num": "L442-4-1", "#text": "Code de la construction et de l'habitation. - art. L442-4-1 (V)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000006825424", "@num": "L442-4-2", "#text": "Code de la construction et de l'habitation. - art. L442-4-2 (V)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000006825663", "@num": "L442-5", "#text": "Code de la construction et de l'habitation. - art. L442-5 (Ab)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000006825664", "@num": "L442-5", "#text": "Code de la construction et de l'habitation. - art. L442-5 (M)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000006825665", "@num": "L442-5", "#text": "Code de la construction et de l'habitation. - art. L442-5 (M)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000006825666", "@num": "L442-5", "#text": "Code de la construction et de l'habitation. - art. L442-5 (V)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000006825425", "@num": "L442-6", "#text": "Code de la construction et de l'habitation. - art. L442-6 (M)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000006825427", "@num": "L442-6", "#text": "Code de la construction et de l'habitation. - art. L442-6 (M)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000006825426", "@num": "L442-6", "#text": "Code de la construction et de l'habitation. - art. L442-6 (M)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000006825428", "@num": "L442-6", "#text": "Code de la construction et de l'habitation. - art. L442-6 (V)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000006825431", "@num": "L442-6-1", "#text": "Code de la construction et de l'habitation. - art. L442-6-1 (Ab)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000006825430", "@num": "L442-6-1", "#text": "Code de la construction et de l'habitation. - art. L442-6-1 (M)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000006825429", "@num": "L442-6-1", "#text": "Code de la construction et de l'habitation. - art. L442-6-1 (M)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000006825432", "@num": "L442-6-2", "#text": "Code de la construction et de l'habitation. - art. L442-6-2 (V)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000006825433", "@num": "L442-6-3", "#text": "Code de la construction et de l'habitation. - art. L442-6-3 (V)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000028808951", "@num": "L442-6-4", "#text": "Code de la construction et de l'habitation. - art. L442-6-4 (M)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000006825434", "@num": "L442-6-4", "#text": "Code de la construction et de l'habitation. - art. L442-6-4 (V)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000039784760", "@num": "L442-6-4", "#text": "Code de la construction et de l'habitation. - art. L442-6-4 (V)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000028807061", "@num": "L442-6-5", "#text": "Code de la construction et de l'habitation. - art. L442-6-5 (M)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000006825435", "@num": "L442-6-5", "#text": "Code de la construction et de l'habitation. - art. L442-6-5 (V)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000006825667", "@num": "L442-7", "#text": "Code de la construction et de l'habitation. - art. L442-7 (M)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000006825668", "@num": "L442-7", "#text": "Code de la construction et de l'habitation. - art. L442-7 (V)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000006825436", "@num": "L442-8", "#text": "Code de la construction et de l'habitation. - art. L442-8 (M)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000006825437", "@num": "L442-8", "#text": "Code de la construction et de l'habitation. - art. L442-8 (M)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000006825438", "@num": "L442-8", "#text": "Code de la construction et de l'habitation. - art. L442-8 (M)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000006825439", "@num": "L442-8", "#text": "Code de la construction et de l'habitation. - art. L442-8 (M)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000006825440", "@num": "L442-8", "#text": "Code de la construction et de l'habitation. - art. L442-8 (V)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000006825711", "@num": "L442-8-1", "#text": "Code de la construction et de l'habitation. - art. L442-8-1 (M)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000006825714", "@num": "L442-8-1", "#text": "Code de la construction et de l'habitation. - art. L442-8-1 (M)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000006825713", "@num": "L442-8-1", "#text": "Code de la construction et de l'habitation. - art. L442-8-1 (M)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000006825715", "@num": "L442-8-1", "#text": "Code de la construction et de l'habitation. - art. L442-8-1 (M)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000006825712", "@num": "L442-8-1", "#text": "Code de la construction et de l'habitation. - art. L442-8-1 (M)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000006825716", "@num": "L442-8-1", "#text": "Code de la construction et de l'habitation. - art. L442-8-1 (V)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000006825720", "@num": "L442-8-2", "#text": "Code de la construction et de l'habitation. - art. L442-8-2 (M)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000006825717", "@num": "L442-8-2", "#text": "Code de la construction et de l'habitation. - art. L442-8-2 (M)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000006825718", "@num": "L442-8-2", "#text": "Code de la construction et de l'habitation. - art. L442-8-2 (M)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000006825719", "@num": "L442-8-2", "#text": "Code de la construction et de l'habitation. - art. L442-8-2 (M)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000006825721", "@num": "L442-8-2", "#text": "Code de la construction et de l'habitation. - art. L442-8-2 (V)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000006825441", "@num": "L442-8-3", "#text": "Code de la construction et de l'habitation. - art. L442-8-3 (V)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000006825442", "@num": "L442-8-3-1", "#text": "Code de la construction et de l'habitation. - art. L442-8-3-1 (V)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000006825443", "@num": "L442-8-4", "#text": "Code de la construction et de l'habitation. - art. L442-8-4 (V)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000006825445", "@num": "L442-9", "#text": "Code de la construction et de l'habitation. - art. L442-9 (M)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000006825444", "@num": "L442-9", "#text": "Code de la construction et de l'habitation. - art. L442-9 (M)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000006825446", "@num": "L442-9", "#text": "Code de la construction et de l'habitation. - art. L442-9 (V)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000006825448", "@num": "L443-1", "#text": "Code de la construction et de l'habitation. - art. L443-1 (V)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000006825690", "@num": "L443-10", "#text": "Code de la construction et de l'habitation. - art. L443-10 (M)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000006825691", "@num": "L443-10", "#text": "Code de la construction et de l'habitation. - art. L443-10 (M)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000006825688", "@num": "L443-10", "#text": "Code de la construction et de l'habitation. - art. L443-10 (M)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000006825689", "@num": "L443-10", "#text": "Code de la construction et de l'habitation. - art. L443-10 (M)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000006825692", "@num": "L443-10", "#text": "Code de la construction et de l'habitation. - art. L443-10 (M)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000037669181", "@num": "L443-10", "#text": "Code de la construction et de l'habitation. - art. L443-10 (V)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000006825480", "@num": "L443-10-1", "#text": "Code de la construction et de l'habitation. - art. L443-10-1 (Ab)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000006825481", "@num": "L443-10-2", "#text": "Code de la construction et de l'habitation. - art. L443-10-2 (Ab)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000006825697", "@num": "L443-11", "#text": "Code de la construction et de l'habitation. - art. L443-11 (M)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000006825695", "@num": "L443-11", "#text": "Code de la construction et de l'habitation. - art. L443-11 (M)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000006825694", "@num": "L443-11", "#text": "Code de la construction et de l'habitation. - art. L443-11 (M)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000006825696", "@num": "L443-11", "#text": "Code de la construction et de l'habitation. - art. L443-11 (M)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000006825693", "@num": "L443-11", "#text": "Code de la construction et de l'habitation. - art. L443-11 (M)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000006825699", "@num": "L443-11", "#text": "Code de la construction et de l'habitation. - art. L443-11 (M)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000006825698", "@num": "L443-11", "#text": "Code de la construction et de l'habitation. - art. L443-11 (M)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000006825700", "@num": "L443-11", "#text": "Code de la construction et de l'habitation. - art. L443-11 (V)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000006825702", "@num": "L443-12", "#text": "Code de la construction et de l'habitation. - art. L443-12 (M)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000006825704", "@num": "L443-12", "#text": "Code de la construction et de l'habitation. - art. L443-12 (M)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000006825701", "@num": "L443-12", "#text": "Code de la construction et de l'habitation. - art. L443-12 (M)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000006825703", "@num": "L443-12", "#text": "Code de la construction et de l'habitation. - art. L443-12 (M)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000028808897", "@num": "L443-12", "#text": "Code de la construction et de l'habitation. - art. L443-12 (M)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000033974631", "@num": "L443-12", "#text": "Code de la construction et de l'habitation. - art. L443-12 (M)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000006825705", "@num": "L443-12", "#text": "Code de la construction et de l'habitation. - art. L443-12 (V)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000024040945", "@num": "L443-12", "#text": "Code de la construction et de l'habitation. - art. L443-12 (V)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000037669143", "@num": "L443-12", "#text": "Code de la construction et de l'habitation. - art. L443-12 (V)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000006825470", "@num": "L443-12-1", "#text": "Code de la construction et de l'habitation. - art. L443-12-1 (M)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000006825471", "@num": "L443-12-1", "#text": "Code de la construction et de l'habitation. - art. L443-12-1 (V)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000006825707", "@num": "L443-13", "#text": "Code de la construction et de l'habitation. - art. L443-13 (M)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000006825709", "@num": "L443-13", "#text": "Code de la construction et de l'habitation. - art. L443-13 (M)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000006825706", "@num": "L443-13", "#text": "Code de la construction et de l'habitation. - art. L443-13 (M)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000006825708", "@num": "L443-13", "#text": "Code de la construction et de l'habitation. - art. L443-13 (M)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000006825710", "@num": "L443-13", "#text": "Code de la construction et de l'habitation. - art. L443-13 (V)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000006825482", "@num": "L443-14", "#text": "Code de la construction et de l'habitation. - art. L443-14 (M)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000006825483", "@num": "L443-14", "#text": "Code de la construction et de l'habitation. - art. L443-14 (M)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000006825484", "@num": "L443-14", "#text": "Code de la construction et de l'habitation. - art. L443-14 (M)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000006825485", "@num": "L443-14", "#text": "Code de la construction et de l'habitation. - art. L443-14 (M)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000037669119", "@num": "L443-14", "#text": "Code de la construction et de l'habitation. - art. L443-14 (V)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000006825488", "@num": "L443-15", "#text": "Code de la construction et de l'habitation. - art. L443-15 (M)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000006825487", "@num": "L443-15", "#text": "Code de la construction et de l'habitation. - art. L443-15 (M)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000006825486", "@num": "L443-15", "#text": "Code de la construction et de l'habitation. - art. L443-15 (M)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000006825489", "@num": "L443-15", "#text": "Code de la construction et de l'habitation. - art. L443-15 (V)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000006825722", "@num": "L443-15-1", "#text": "Code de la construction et de l'habitation. - art. L443-15-1 (M)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000006825723", "@num": "L443-15-1", "#text": "Code de la construction et de l'habitation. - art. L443-15-1 (M)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000006825725", "@num": "L443-15-1", "#text": "Code de la construction et de l'habitation. - art. L443-15-1 (V)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000006825728", "@num": "L443-15-2", "#text": "Code de la construction et de l'habitation. - art. L443-15-2 (M)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000006825726", "@num": "L443-15-2", "#text": "Code de la construction et de l'habitation. - art. L443-15-2 (M)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000006825727", "@num": "L443-15-2", "#text": "Code de la construction et de l'habitation. - art. L443-15-2 (M)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000006825729", "@num": "L443-15-2", "#text": "Code de la construction et de l'habitation. - art. L443-15-2 (M)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000028808902", "@num": "L443-15-2", "#text": "Code de la construction et de l'habitation. - art. L443-15-2 (M)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000006825730", "@num": "L443-15-2", "#text": "Code de la construction et de l'habitation. - art. L443-15-2 (V)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000025577126", "@num": "L443-15-2", "#text": "Code de la construction et de l'habitation. - art. L443-15-2 (V)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000037669077", "@num": "L443-15-2", "#text": "Code de la construction et de l'habitation. - art. L443-15-2 (V)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000038451466", "@num": "L443-15-2", "#text": "Code de la construction et de l'habitation. - art. L443-15-2 (VD)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000038834048", "@num": "L443-15-2", "#text": "Code de la construction et de l'habitation. - art. L443-15-2 (VD)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000006825478", "@num": "L443-15-2-1", "#text": "Code de la construction et de l'habitation. - art. L443-15-2-1 (M)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000036432749", "@num": "L443-15-2-1", "#text": "Code de la construction et de l'habitation. - art. L443-15-2-1 (M)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000037669062", "@num": "L443-15-2-1", "#text": "Code de la construction et de l'habitation. - art. L443-15-2-1 (V)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000041466705", "@num": "L443-15-2-1", "#text": "Code de la construction et de l'habitation. - art. L443-15-2-1 (V)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000038451458", "@num": "L443-15-2-1", "#text": "Code de la construction et de l'habitation. - art. L443-15-2-1 (VD)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000006825472", "@num": "L443-15-3", "#text": "Code de la construction et de l'habitation. - art. L443-15-3 (M)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000006825473", "@num": "L443-15-3", "#text": "Code de la construction et de l'habitation. - art. L443-15-3 (M)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000037669022", "@num": "L443-15-3", "#text": "Code de la construction et de l'habitation. - art. L443-15-3 (V)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000006825474", "@num": "L443-15-4", "#text": "Code de la construction et de l'habitation. - art. L443-15-4 (M)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000006825475", "@num": "L443-15-4", "#text": "Code de la construction et de l'habitation. - art. L443-15-4 (V)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000006825476", "@num": "L443-15-5", "#text": "Code de la construction et de l'habitation. - art. L443-15-5 (M)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000006825477", "@num": "L443-15-5", "#text": "Code de la construction et de l'habitation. - art. L443-15-5 (V)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000006825479", "@num": "L443-15-6", "#text": "Code de la construction et de l'habitation. - art. L443-15-6 (V)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000006825490", "@num": "L443-15-7", "#text": "Code de la construction et de l'habitation. - art. L443-15-7 (V)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000037670555", "@num": "L443-15-7", "#text": "Code de la construction et de l'habitation. - art. L443-15-7 (V)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000027645810", "@num": "L443-15-7", "#text": "Code de la construction et de l'habitation. - art. L443-15-7 (VD)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000006825491", "@num": "L443-16", "#text": "Code de la construction et de l'habitation. - art. L443-16 (V)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000006825455", "@num": "L443-17", "#text": "Code de la construction et de l'habitation. - art. L443-17 (M)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000006825456", "@num": "L443-17", "#text": "Code de la construction et de l'habitation. - art. L443-17 (V)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000045293481", "@num": "L443-17", "#text": "Code de la construction et de l'habitation. - art. L443-17 (VD)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000006825492", "@num": "L443-18", "#text": "Code de la construction et de l'habitation. - art. L443-18 (V)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CREATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000006825492", "@num": "L443-18", "#text": "Code de la construction et de l'habitation. - art. L443-18 (V)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000006825452", "@num": "L443-2", "#text": "Code de la construction et de l'habitation. - art. L443-2 (M)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000006825453", "@num": "L443-2", "#text": "Code de la construction et de l'habitation. - art. L443-2 (V)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000006825454", "@num": "L443-3", "#text": "Code de la construction et de l'habitation. - art. L443-3 (Ab)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000006825449", "@num": "L443-4", "#text": "Code de la construction et de l'habitation. - art. L443-4 (V)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000006825669", "@num": "L443-5", "#text": "Code de la construction et de l'habitation. - art. L443-5 (Ab)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000006825450", "@num": "L443-6", "#text": "Code de la construction et de l'habitation. - art. L443-6 (V)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000006825451", "@num": "L443-6-1", "#text": "Code de la construction et de l'habitation. - art. L443-6-1 (V)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000006825465", "@num": "L443-6-10", "#text": "Code de la construction et de l'habitation. - art. L443-6-10 (V)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000006825466", "@num": "L443-6-11", "#text": "Code de la construction et de l'habitation. - art. L443-6-11 (V)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000006825467", "@num": "L443-6-12", "#text": "Code de la construction et de l'habitation. - art. L443-6-12 (V)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000006825468", "@num": "L443-6-13", "#text": "Code de la construction et de l'habitation. - art. L443-6-13 (V)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000006825457", "@num": "L443-6-2", "#text": "Code de la construction et de l'habitation. - art. L443-6-2 (V)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000006825458", "@num": "L443-6-3", "#text": "Code de la construction et de l'habitation. - art. L443-6-3 (V)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000006825459", "@num": "L443-6-4", "#text": "Code de la construction et de l'habitation. - art. L443-6-4 (V)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000006825460", "@num": "L443-6-5", "#text": "Code de la construction et de l'habitation. - art. L443-6-5 (V)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000006825461", "@num": "L443-6-6", "#text": "Code de la construction et de l'habitation. - art. L443-6-6 (V)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000006825462", "@num": "L443-6-7", "#text": "Code de la construction et de l'habitation. - art. L443-6-7 (V)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000006825463", "@num": "L443-6-8", "#text": "Code de la construction et de l'habitation. - art. L443-6-8 (V)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000006825464", "@num": "L443-6-9", "#text": "Code de la construction et de l'habitation. - art. L443-6-9 (V)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000006825674", "@num": "L443-7", "#text": "Code de la construction et de l'habitation. - art. L443-7 (M)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000006825671", "@num": "L443-7", "#text": "Code de la construction et de l'habitation. - art. L443-7 (M)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000006825672", "@num": "L443-7", "#text": "Code de la construction et de l'habitation. - art. L443-7 (M)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000006825675", "@num": "L443-7", "#text": "Code de la construction et de l'habitation. - art. L443-7 (M)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000006825670", "@num": "L443-7", "#text": "Code de la construction et de l'habitation. - art. L443-7 (M)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000006825673", "@num": "L443-7", "#text": "Code de la construction et de l'habitation. - art. L443-7 (M)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000006825676", "@num": "L443-7", "#text": "Code de la construction et de l'habitation. - art. L443-7 (V)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000006825469", "@num": "L443-7-1", "#text": "Code de la construction et de l'habitation. - art. L443-7-1 (Ab)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000006825679", "@num": "L443-8", "#text": "Code de la construction et de l'habitation. - art. L443-8 (M)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000006825680", "@num": "L443-8", "#text": "Code de la construction et de l'habitation. - art. L443-8 (M)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000006825678", "@num": "L443-8", "#text": "Code de la construction et de l'habitation. - art. L443-8 (M)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000006825677", "@num": "L443-8", "#text": "Code de la construction et de l'habitation. - art. L443-8 (M)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000028808926", "@num": "L443-8", "#text": "Code de la construction et de l'habitation. - art. L443-8 (M)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000033972485", "@num": "L443-8", "#text": "Code de la construction et de l'habitation. - art. L443-8 (M)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000006825681", "@num": "L443-8", "#text": "Code de la construction et de l'habitation. - art. L443-8 (V)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000037669202", "@num": "L443-8", "#text": "Code de la construction et de l'habitation. - art. L443-8 (V)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000006825683", "@num": "L443-9", "#text": "Code de la construction et de l'habitation. - art. L443-9 (M)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000006825684", "@num": "L443-9", "#text": "Code de la construction et de l'habitation. - art. L443-9 (M)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000006825682", "@num": "L443-9", "#text": "Code de la construction et de l'habitation. - art. L443-9 (M)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000006825686", "@num": "L443-9", "#text": "Code de la construction et de l'habitation. - art. L443-9 (M)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000006825685", "@num": "L443-9", "#text": "Code de la construction et de l'habitation. - art. L443-9 (M)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000006825687", "@num": "L443-9", "#text": "Code de la construction et de l'habitation. - art. L443-9 (M)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000037669192", "@num": "L443-9", "#text": "Code de la construction et de l'habitation. - art. L443-9 (V)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000006825493", "@num": "L444-1", "#text": "Code de la construction et de l'habitation. - art. L444-1 (M)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000006825494", "@num": "L444-1", "#text": "Code de la construction et de l'habitation. - art. L444-1 (V)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000006825495", "@num": "L444-2", "#text": "Code de la construction et de l'habitation. - art. L444-2 (M)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000006825496", "@num": "L444-2", "#text": "Code de la construction et de l'habitation. - art. L444-2 (V)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000006825497", "@num": "L444-3", "#text": "Code de la construction et de l'habitation. - art. L444-3 (V)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000006825498", "@num": "L444-4", "#text": "Code de la construction et de l'habitation. - art. L444-4 (V)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000006825499", "@num": "L444-5", "#text": "Code de la construction et de l'habitation. - art. L444-5 (V)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000006825500", "@num": "L444-6", "#text": "Code de la construction et de l'habitation. - art. L444-6 (V)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000006825501", "@num": "L445-1", "#text": "Code de la construction et de l'habitation. - art. L445-1 (V)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000006825502", "@num": "L445-2", "#text": "Code de la construction et de l'habitation. - art. L445-2 (V)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000006825503", "@num": "L445-3", "#text": "Code de la construction et de l'habitation. - art. L445-3 (V)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000006825504", "@num": "L445-4", "#text": "Code de la construction et de l'habitation. - art. L445-4 (V)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000006825505", "@num": "L445-5", "#text": "Code de la construction et de l'habitation. - art. L445-5 (VT)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000006825506", "@num": "L445-6", "#text": "Code de la construction et de l'habitation. - art. L445-6 (V)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000006825507", "@num": "L445-7", "#text": "Code de la construction et de l'habitation. - art. L445-7 (V)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000006825508", "@num": "L445-8", "#text": "Code de la construction et de l'habitation. - art. L445-8 (Ab)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000006825734", "@num": "L451-1", "#text": "Code de la construction et de l'habitation. - art. L451-1 (AbD)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000006825731", "@num": "L451-1", "#text": "Code de la construction et de l'habitation. - art. L451-1 (M)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000006825733", "@num": "L451-1", "#text": "Code de la construction et de l'habitation. - art. L451-1 (M)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000006825732", "@num": "L451-1", "#text": "Code de la construction et de l'habitation. - art. L451-1 (M)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000006825735", "@num": "L451-1", "#text": "Code de la construction et de l'habitation. - art. L451-1 (VD)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000006825517", "@num": "L451-1-1", "#text": "Code de la construction et de l'habitation. - art. L451-1-1 (VT)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000006825546", "@num": "L451-2", "#text": "Code de la construction et de l'habitation. - art. L451-2 (M)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000006825544", "@num": "L451-2", "#text": "Code de la construction et de l'habitation. - art. L451-2 (M)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000006825545", "@num": "L451-2", "#text": "Code de la construction et de l'habitation. - art. L451-2 (M)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000006825547", "@num": "L451-2", "#text": "Code de la construction et de l'habitation. - art. L451-2 (VT)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000006825518", "@num": "L451-2-1", "#text": "Code de la construction et de l'habitation. - art. L451-2-1 (M)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000006825519", "@num": "L451-2-1", "#text": "Code de la construction et de l'habitation. - art. L451-2-1 (VT)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000006825738", "@num": "L451-3", "#text": "Code de la construction et de l'habitation. - art. L451-3 (Ab)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000006825736", "@num": "L451-3", "#text": "Code de la construction et de l'habitation. - art. L451-3 (M)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000006825737", "@num": "L451-3", "#text": "Code de la construction et de l'habitation. - art. L451-3 (M)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000006825739", "@num": "L451-3", "#text": "Code de la construction et de l'habitation. - art. L451-3 (VT)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000006825742", "@num": "L451-4", "#text": "Code de la construction et de l'habitation. - art. L451-4 (Ab)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000006825740", "@num": "L451-4", "#text": "Code de la construction et de l'habitation. - art. L451-4 (M)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CREATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000006825740", "@num": "L451-4", "#text": "Code de la construction et de l'habitation. - art. L451-4 (M)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000006825741", "@num": "L451-4", "#text": "Code de la construction et de l'habitation. - art. L451-4 (M)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000006825743", "@num": "L451-5", "#text": "Code de la construction et de l'habitation. - art. L451-5 (Ab)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000006825745", "@num": "L451-5", "#text": "Code de la construction et de l'habitation. - art. L451-5 (M)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000006825744", "@num": "L451-5", "#text": "Code de la construction et de l'habitation. - art. L451-5 (M)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000024040949", "@num": "L451-5", "#text": "Code de la construction et de l'habitation. - art. L451-5 (M)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000006825746", "@num": "L451-5", "#text": "Code de la construction et de l'habitation. - art. L451-5 (V)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000037668155", "@num": "L451-5", "#text": "Code de la construction et de l'habitation. - art. L451-5 (V)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000006825548", "@num": "L451-6", "#text": "Code de la construction et de l'habitation. - art. L451-6 (M)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000006825549", "@num": "L451-6", "#text": "Code de la construction et de l'habitation. - art. L451-6 (V)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000006825550", "@num": "L451-7", "#text": "Code de la construction et de l'habitation. - art. L451-7 (M)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000006825551", "@num": "L451-7", "#text": "Code de la construction et de l'habitation. - art. L451-7 (VT)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000006825520", "@num": "L452-1", "#text": "Code de la construction et de l'habitation. - art. L452-1 (M)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000006825521", "@num": "L452-1", "#text": "Code de la construction et de l'habitation. - art. L452-1 (M)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000006825522", "@num": "L452-1", "#text": "Code de la construction et de l'habitation. - art. L452-1 (V)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000006825523", "@num": "L452-2", "#text": "Code de la construction et de l'habitation. - art. L452-2 (M)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000006825524", "@num": "L452-2", "#text": "Code de la construction et de l'habitation. - art. L452-2 (V)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000028808976", "@num": "L452-2", "#text": "Code de la construction et de l'habitation. - art. L452-2 (V)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000006825525", "@num": "L452-2-1", "#text": "Code de la construction et de l'habitation. - art. L452-2-1 (M)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000028808973", "@num": "L452-2-1", "#text": "Code de la construction et de l'habitation. - art. L452-2-1 (M)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000036432620", "@num": "L452-2-1", "#text": "Code de la construction et de l'habitation. - art. L452-2-1 (M)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000006825526", "@num": "L452-2-1", "#text": "Code de la construction et de l'habitation. - art. L452-2-1 (V)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000024435657", "@num": "L452-2-1", "#text": "Code de la construction et de l'habitation. - art. L452-2-1 (V)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000037668036", "@num": "L452-2-1", "#text": "Code de la construction et de l'habitation. - art. L452-2-1 (V)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000006825527", "@num": "L452-3", "#text": "Code de la construction et de l'habitation. - art. L452-3 (M)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000006825528", "@num": "L452-3", "#text": "Code de la construction et de l'habitation. - art. L452-3 (V)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000006825531", "@num": "L452-4", "#text": "Code de la construction et de l'habitation. - art. L452-4 (M)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000006825530", "@num": "L452-4", "#text": "Code de la construction et de l'habitation. - art. L452-4 (M)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000006825529", "@num": "L452-4", "#text": "Code de la construction et de l'habitation. - art. L452-4 (MMN)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000006825532", "@num": "L452-4", "#text": "Code de la construction et de l'habitation. - art. L452-4 (V)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000006825533", "@num": "L452-4-1", "#text": "Code de la construction et de l'habitation. - art. L452-4-1 (M)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000006825534", "@num": "L452-4-1", "#text": "Code de la construction et de l'habitation. - art. L452-4-1 (V)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000006825535", "@num": "L452-5", "#text": "Code de la construction et de l'habitation. - art. L452-5 (V)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000006825536", "@num": "L452-6", "#text": "Code de la construction et de l'habitation. - art. L452-6 (M)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000006825537", "@num": "L452-6", "#text": "Code de la construction et de l'habitation. - art. L452-6 (M)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000033974451", "@num": "L452-6", "#text": "Code de la construction et de l'habitation. - art. L452-6 (V)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000006825538", "@num": "L452-7", "#text": "Code de la construction et de l'habitation. - art. L452-7 (M)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000006825539", "@num": "L452-7", "#text": "Code de la construction et de l'habitation. - art. L452-7 (V)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000006825540", "@num": "L453-1", "#text": "Code de la construction et de l'habitation. - art. L453-1 (M)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000006825541", "@num": "L453-1", "#text": "Code de la construction et de l'habitation. - art. L453-1 (V)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000006825542", "@num": "L453-2", "#text": "Code de la construction et de l'habitation. - art. L453-2 (V)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000006825543", "@num": "L453-3", "#text": "Code de la construction et de l'habitation. - art. L453-3 (V)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000006825749", "@num": "L461-1", "#text": "Code de la construction et de l'habitation. - art. L461-1 (Ab)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000006825747", "@num": "L461-2", "#text": "Code de la construction et de l'habitation. - art. L461-2 (M)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000006825748", "@num": "L461-2", "#text": "Code de la construction et de l'habitation. - art. L461-2 (VT)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000006825552", "@num": "L471-1", "#text": "Code de la construction et de l'habitation. - art. L471-1 (V)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000006825553", "@num": "L472-1", "#text": "Code de la construction et de l'habitation. - art. L472-1 (V)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000025760581", "@num": "L472-1", "#text": "Code de la construction et de l'habitation. - art. L472-1 (V)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000006825750", "@num": "L472-1-1", "#text": "Code de la construction et de l'habitation. - art. L472-1-1 (M)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000006825751", "@num": "L472-1-1", "#text": "Code de la construction et de l'habitation. - art. L472-1-1 (V)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000006825555", "@num": "L472-1-2", "#text": "Code de la construction et de l'habitation. - art. L472-1-2 (M)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000006825557", "@num": "L472-1-2", "#text": "Code de la construction et de l'habitation. - art. L472-1-2 (M)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000006825558", "@num": "L472-1-2", "#text": "Code de la construction et de l'habitation. - art. L472-1-2 (M)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000006825554", "@num": "L472-1-2", "#text": "Code de la construction et de l'habitation. - art. L472-1-2 (M)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000006825556", "@num": "L472-1-2", "#text": "Code de la construction et de l'habitation. - art. L472-1-2 (M)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000006825559", "@num": "L472-1-2", "#text": "Code de la construction et de l'habitation. - art. L472-1-2 (V)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000025760567", "@num": "L472-1-2", "#text": "Code de la construction et de l'habitation. - art. L472-1-2 (V)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000028808495", "@num": "L472-1-2", "#text": "Code de la construction et de l'habitation. - art. L472-1-2 (VD)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000006825560", "@num": "L472-1-3", "#text": "Code de la construction et de l'habitation. - art. L472-1-3 (V)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000025760561", "@num": "L472-1-3", "#text": "Code de la construction et de l'habitation. - art. L472-1-3 (V)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000006825561", "@num": "L472-1-4", "#text": "Code de la construction et de l'habitation. - art. L472-1-4 (V)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000025760555", "@num": "L472-1-4", "#text": "Code de la construction et de l'habitation. - art. L472-1-4 (V)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000006825562", "@num": "L472-1-5", "#text": "Code de la construction et de l'habitation. - art. L472-1-5 (V)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000025760549", "@num": "L472-1-6", "#text": "Code de la construction et de l'habitation. - art. L472-1-6 (M)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000006825563", "@num": "L472-1-6", "#text": "Code de la construction et de l'habitation. - art. L472-1-6 (V)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000033972350", "@num": "L472-1-6", "#text": "Code de la construction et de l'habitation. - art. L472-1-6 (V)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000006825564", "@num": "L472-1-7", "#text": "Code de la construction et de l'habitation. - art. L472-1-7 (V)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000025760539", "@num": "L472-1-7", "#text": "Code de la construction et de l'habitation. - art. L472-1-7 (V)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000006825752", "@num": "L472-2", "#text": "Code de la construction et de l'habitation. - art. L472-2 (M)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000006825753", "@num": "L472-2", "#text": "Code de la construction et de l'habitation. - art. L472-2 (V)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000025760529", "@num": "L472-2", "#text": "Code de la construction et de l'habitation. - art. L472-2 (V)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000006825755", "@num": "L481-1", "#text": "Code de la construction et de l'habitation. - art. L481-1 (Ab)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000006825754", "@num": "L481-1", "#text": "Code de la construction et de l'habitation. - art. L481-1 (M)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000006825565", "@num": "L481-1-1", "#text": "Code de la construction et de l'habitation. - art. L481-1-1 (M)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000006825566", "@num": "L481-1-1", "#text": "Code de la construction et de l'habitation. - art. L481-1-1 (V)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000006825567", "@num": "L481-2", "#text": "Code de la construction et de l'habitation. - art. L481-2 (Ab)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000006825568", "@num": "L481-3", "#text": "Code de la construction et de l'habitation. - art. L481-3 (M)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000006825569", "@num": "L481-3", "#text": "Code de la construction et de l'habitation. - art. L481-3 (M)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000006825570", "@num": "L481-3", "#text": "Code de la construction et de l'habitation. - art. L481-3 (V)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000006825571", "@num": "L481-4", "#text": "Code de la construction et de l'habitation. - art. L481-4 (M)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000006825572", "@num": "L481-4", "#text": "Code de la construction et de l'habitation. - art. L481-4 (V)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000006825573", "@num": "L481-5", "#text": "Code de la construction et de l'habitation. - art. L481-5 (M)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000006825574", "@num": "L481-5", "#text": "Code de la construction et de l'habitation. - art. L481-5 (V)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000006825575", "@num": "L481-6", "#text": "Code de la construction et de l'habitation. - art. L481-6 (V)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000006825761", "@num": "L511-1", "#text": "Code de la construction et de l'habitation. - art. L511-1 (M)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000006825762", "@num": "L511-1", "#text": "Code de la construction et de l'habitation. - art. L511-1 (V)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000042342695", "@num": "L511-1", "#text": "Code de la construction et de l'habitation. - art. L511-1 (V)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000006825763", "@num": "L511-1-1", "#text": "Code de la construction et de l'habitation. - art. L511-1-1 (M)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000006825764", "@num": "L511-1-1", "#text": "Code de la construction et de l'habitation. - art. L511-1-1 (V)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000006825805", "@num": "L511-2", "#text": "Code de la construction et de l'habitation. - art. L511-2 (M)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000006825804", "@num": "L511-2", "#text": "Code de la construction et de l'habitation. - art. L511-2 (M)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000006825803", "@num": "L511-2", "#text": "Code de la construction et de l'habitation. - art. L511-2 (M)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000006825806", "@num": "L511-2", "#text": "Code de la construction et de l'habitation. - art. L511-2 (V)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000006825766", "@num": "L511-3", "#text": "Code de la construction et de l'habitation. - art. L511-3 (M)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000006825765", "@num": "L511-3", "#text": "Code de la construction et de l'habitation. - art. L511-3 (M)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000006825767", "@num": "L511-3", "#text": "Code de la construction et de l'habitation. - art. L511-3 (V)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000042342679", "@num": "L511-3", "#text": "Code de la construction et de l'habitation. - art. L511-3 (V)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000006825768", "@num": "L511-4", "#text": "Code de la construction et de l'habitation. - art. L511-4 (M)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000006825769", "@num": "L511-4", "#text": "Code de la construction et de l'habitation. - art. L511-4 (M)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000006825770", "@num": "L511-4", "#text": "Code de la construction et de l'habitation. - art. L511-4 (V)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000006825771", "@num": "L511-5", "#text": "Code de la construction et de l'habitation. - art. L511-5 (M)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000006825772", "@num": "L511-5", "#text": "Code de la construction et de l'habitation. - art. L511-5 (V)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000042342667", "@num": "L511-5", "#text": "Code de la construction et de l'habitation. - art. L511-5 (V)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000006825774", "@num": "L511-6", "#text": "Code de la construction et de l'habitation. - art. L511-6 (M)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000006825773", "@num": "L511-6", "#text": "Code de la construction et de l'habitation. - art. L511-6 (M)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000006825775", "@num": "L511-6", "#text": "Code de la construction et de l'habitation. - art. L511-6 (V)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000006825778", "@num": "L521-1", "#text": "Code de la construction et de l'habitation. - art. L521-1 (M)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000006825777", "@num": "L521-1", "#text": "Code de la construction et de l'habitation. - art. L521-1 (M)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000006825776", "@num": "L521-1", "#text": "Code de la construction et de l'habitation. - art. L521-1 (M)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000006825779", "@num": "L521-1", "#text": "Code de la construction et de l'habitation. - art. L521-1 (V)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000049398958", "@num": "L521-1", "#text": "Code de la construction et de l'habitation. - art. L521-1 (V)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000041586711", "@num": "L521-1", "#text": "Code de la construction et de l'habitation. - art. L521-1 (VD)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000042343009", "@num": "L521-1", "#text": "Code de la construction et de l'habitation. - art. L521-1 (VD)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000006825781", "@num": "L521-2", "#text": "Code de la construction et de l'habitation. - art. L521-2 (M)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000006825780", "@num": "L521-2", "#text": "Code de la construction et de l'habitation. - art. L521-2 (M)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000006825782", "@num": "L521-2", "#text": "Code de la construction et de l'habitation. - art. L521-2 (M)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000006825783", "@num": "L521-3", "#text": "Code de la construction et de l'habitation. - art. L521-3 (T)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000028808242", "@num": "L521-3-1", "#text": "Code de la construction et de l'habitation. - art. L521-3-1 (M)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000006825784", "@num": "L521-3-1", "#text": "Code de la construction et de l'habitation. - art. L521-3-1 (V)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000033973493", "@num": "L521-3-1", "#text": "Code de la construction et de l'habitation. - art. L521-3-1 (V)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000049397643", "@num": "L521-3-1", "#text": "Code de la construction et de l'habitation. - art. L521-3-1 (V)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000042342978", "@num": "L521-3-1", "#text": "Code de la construction et de l'habitation. - art. L521-3-1 (VD)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000006825785", "@num": "L521-3-2", "#text": "Code de la construction et de l'habitation. - art. L521-3-2 (M)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000006825786", "@num": "L521-3-2", "#text": "Code de la construction et de l'habitation. - art. L521-3-2 (M)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000028808250", "@num": "L521-3-2", "#text": "Code de la construction et de l'habitation. - art. L521-3-2 (M)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000006825787", "@num": "L521-3-2", "#text": "Code de la construction et de l'habitation. - art. L521-3-2 (V)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000033973464", "@num": "L521-3-2", "#text": "Code de la construction et de l'habitation. - art. L521-3-2 (V)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000049398947", "@num": "L521-3-2", "#text": "Code de la construction et de l'habitation. - art. L521-3-2 (V)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000041586681", "@num": "L521-3-2", "#text": "Code de la construction et de l'habitation. - art. L521-3-2 (VD)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000042342962", "@num": "L521-3-2", "#text": "Code de la construction et de l'habitation. - art. L521-3-2 (VD)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000006825789", "@num": "L521-4", "#text": "Code de la construction et de l'habitation. - art. L521-4 (M)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000006825788", "@num": "L521-4", "#text": "Code de la construction et de l'habitation. - art. L521-4 (M)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000006825790", "@num": "L521-4", "#text": "Code de la construction et de l'habitation. - art. L521-4 (V)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000006825791", "@num": "L522-1", "#text": "Code de la construction et de l'habitation. - art. L522-1 (V)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000006825792", "@num": "L522-2", "#text": "Code de la construction et de l'habitation. - art. L522-2 (V)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000006825793", "@num": "L531-1", "#text": "Code de la construction et de l'habitation. - art. L531-1 (M)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000006825794", "@num": "L531-1", "#text": "Code de la construction et de l'habitation. - art. L531-1 (V)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000025760590", "@num": "L531-1", "#text": "Code de la construction et de l'habitation. - art. L531-1 (V)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000006825795", "@num": "L531-2", "#text": "Code de la construction et de l'habitation. - art. L531-2 (M)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000006825796", "@num": "L531-2", "#text": "Code de la construction et de l'habitation. - art. L531-2 (V)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000025760586", "@num": "L531-2", "#text": "Code de la construction et de l'habitation. - art. L531-2 (V)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000039119650", "@num": "L531-2", "#text": "Code de la construction et de l'habitation. - art. L531-2 (VD)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000042342958", "@num": "L531-2", "#text": "Code de la construction et de l'habitation. - art. L531-2 (VD)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000006825797", "@num": "L541-1", "#text": "Code de la construction et de l'habitation. - art. L541-1 (M)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000033973435", "@num": "L541-1", "#text": "Code de la construction et de l'habitation. - art. L541-1 (V)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000037671643", "@num": "L541-1", "#text": "Code de la construction et de l'habitation. - art. L541-1 (VD)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000041586672", "@num": "L541-1", "#text": "Code de la construction et de l'habitation. - art. L541-1 (VD)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000042342925", "@num": "L541-1", "#text": "Code de la construction et de l'habitation. - art. L541-1 (VD)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000006825798", "@num": "L541-2", "#text": "Code de la construction et de l'habitation. - art. L541-2 (V)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000006825799", "@num": "L541-3", "#text": "Code de la construction et de l'habitation. - art. L541-3 (V)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000006825800", "@num": "L541-4", "#text": "Code de la construction et de l'habitation. - art. L541-4 (V)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000006825801", "@num": "L541-5", "#text": "Code de la construction et de l'habitation. - art. L541-5 (V)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000006825802", "@num": "L541-6", "#text": "Code de la construction et de l'habitation. - art. L541-6 (V)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000041586641", "@num": "L541-6", "#text": "Code de la construction et de l'habitation. - art. L541-6 (VD)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000042342887", "@num": "L541-6", "#text": "Code de la construction et de l'habitation. - art. L541-6 (VD)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000006825807", "@num": "L611-1", "#text": "Code de la construction et de l'habitation. - art. L611-1 (V)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000006825808", "@num": "L612-1", "#text": "Code de la construction et de l'habitation. - art. L612-1 (M)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000030902232", "@num": "L612-1", "#text": "Code de la construction et de l'habitation. - art. L612-1 (V)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000006825973", "@num": "L613-1", "#text": "Code de la construction et de l'habitation. - art. L613-1 (M)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000006825974", "@num": "L613-1", "#text": "Code de la construction et de l'habitation. - art. L613-1 (M)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000006825972", "@num": "L613-1", "#text": "Code de la construction et de l'habitation. - art. L613-1 (M)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000006825975", "@num": "L613-1", "#text": "Code de la construction et de l'habitation. - art. L613-1 (M)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000006825976", "@num": "L613-1", "#text": "Code de la construction et de l'habitation. - art. L613-1 (V)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000006825809", "@num": "L613-2", "#text": "Code de la construction et de l'habitation. - art. L613-2 (V)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000006825810", "@num": "L613-2-1", "#text": "Code de la construction et de l'habitation. - art. L613-2-1 (M)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000006825811", "@num": "L613-2-1", "#text": "Code de la construction et de l'habitation. - art. L613-2-1 (VT)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000006825827", "@num": "L613-3", "#text": "Code de la construction et de l'habitation. - art. L613-3 (M)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000006825828", "@num": "L613-3", "#text": "Code de la construction et de l'habitation. - art. L613-3 (M)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000006825829", "@num": "L613-3", "#text": "Code de la construction et de l'habitation. - art. L613-3 (VT)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000006825812", "@num": "L613-4", "#text": "Code de la construction et de l'habitation. - art. L613-4 (VT)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000006825813", "@num": "L613-5", "#text": "Code de la construction et de l'habitation. - art. L613-5 (VT)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000006825814", "@num": "L614-1", "#text": "Code de la construction et de l'habitation. - art. L614-1 (VT)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000006825815", "@num": "L615-1", "#text": "Code de la construction et de l'habitation. - art. L615-1 (M)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000006825816", "@num": "L615-1", "#text": "Code de la construction et de l'habitation. - art. L615-1 (V)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000028807845", "@num": "L615-1", "#text": "Code de la construction et de l'habitation. - art. L615-1 (VT)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000006825817", "@num": "L615-2", "#text": "Code de la construction et de l'habitation. - art. L615-2 (M)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000006825818", "@num": "L615-2", "#text": "Code de la construction et de l'habitation. - art. L615-2 (V)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000028807839", "@num": "L615-2", "#text": "Code de la construction et de l'habitation. - art. L615-2 (V)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000006825819", "@num": "L615-3", "#text": "Code de la construction et de l'habitation. - art. L615-3 (V)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000027573558", "@num": "L615-3", "#text": "Code de la construction et de l'habitation. - art. L615-3 (VD)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000028807857", "@num": "L615-3", "#text": "Code de la construction et de l'habitation. - art. L615-3 (VT)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000006825820", "@num": "L615-4", "#text": "Code de la construction et de l'habitation. - art. L615-4 (V)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000006825821", "@num": "L615-4-1", "#text": "Code de la construction et de l'habitation. - art. L615-4-1 (V)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000006825822", "@num": "L615-5", "#text": "Code de la construction et de l'habitation. - art. L615-5 (V)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000028807853", "@num": "L615-5", "#text": "Code de la construction et de l'habitation. - art. L615-5 (V)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000006825823", "@num": "L615-6", "#text": "Code de la construction et de l'habitation. - art. L615-6 (V)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000006825824", "@num": "L615-7", "#text": "Code de la construction et de l'habitation. - art. L615-7 (V)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000006825825", "@num": "L616", "#text": "Code de la construction et de l'habitation. - art. L616 (M)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000006825826", "@num": "L616", "#text": "Code de la construction et de l'habitation. - art. L616 (V)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000006825830", "@num": "L621-1", "#text": "Code de la construction et de l'habitation. - art. L621-1 (V)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000006825831", "@num": "L621-2", "#text": "Code de la construction et de l'habitation. - art. L621-2 (M)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000033972854", "@num": "L621-2", "#text": "Code de la construction et de l'habitation. - art. L621-2 (M)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000037669855", "@num": "L621-2", "#text": "Code de la construction et de l'habitation. - art. L621-2 (V)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000006825977", "@num": "L621-3", "#text": "Code de la construction et de l'habitation. - art. L621-3 (M)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000006825978", "@num": "L621-3", "#text": "Code de la construction et de l'habitation. - art. L621-3 (V)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000006825979", "@num": "L621-4", "#text": "Code de la construction et de l'habitation. - art. L621-4 (M)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000006825980", "@num": "L621-4", "#text": "Code de la construction et de l'habitation. - art. L621-4 (V)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000028806840", "@num": "L621-4", "#text": "Code de la construction et de l'habitation. - art. L621-4 (V)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000006825832", "@num": "L621-5", "#text": "Code de la construction et de l'habitation. - art. L621-5 (V)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000006825833", "@num": "L621-6", "#text": "Code de la construction et de l'habitation. - art. L621-6 (V)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000039279909", "@num": "L621-6", "#text": "Code de la construction et de l'habitation. - art. L621-6 (VD)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000006825834", "@num": "L622-1", "#text": "Code de la construction et de l'habitation. - art. L622-1 (V)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000006825835", "@num": "L631-1", "#text": "Code de la construction et de l'habitation. - art. L631-1 (M)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CONCORDANCE", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000006825835", "@num": "L631-1", "#text": "Code de la construction et de l'habitation. - art. L631-1 (M)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000006825836", "@num": "L631-1", "#text": "Code de la construction et de l'habitation. - art. L631-1 (V)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CONCORDANCE", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000006825836", "@num": "L631-1", "#text": "Code de la construction et de l'habitation. - art. L631-1 (V)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000006825865", "@num": "L631-10", "#text": "Code de la construction et de l'habitation. - art. L631-10 (M)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000006825866", "@num": "L631-10", "#text": "Code de la construction et de l'habitation. - art. L631-10 (V)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000006825867", "@num": "L631-11", "#text": "Code de la construction et de l'habitation. - art. L631-11 (V)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000006825837", "@num": "L631-2", "#text": "Code de la construction et de l'habitation. - art. L631-2 (M)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000006825838", "@num": "L631-2", "#text": "Code de la construction et de l'habitation. - art. L631-2 (V)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000006825839", "@num": "L631-3", "#text": "Code de la construction et de l'habitation. - art. L631-3 (M)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000006825840", "@num": "L631-3", "#text": "Code de la construction et de l'habitation. - art. L631-3 (V)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000006825841", "@num": "L631-4", "#text": "Code de la construction et de l'habitation. - art. L631-4 (M)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000006825842", "@num": "L631-4", "#text": "Code de la construction et de l'habitation. - art. L631-4 (V)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000006825843", "@num": "L631-5", "#text": "Code de la construction et de l'habitation. - art. L631-5 (M)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000006825844", "@num": "L631-5", "#text": "Code de la construction et de l'habitation. - art. L631-5 (M)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000006825845", "@num": "L631-5", "#text": "Code de la construction et de l'habitation. - art. L631-5 (V)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000006825846", "@num": "L631-6", "#text": "Code de la construction et de l'habitation. - art. L631-6 (M)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000006825847", "@num": "L631-6", "#text": "Code de la construction et de l'habitation. - art. L631-6 (V)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000006825984", "@num": "L631-7", "#text": "Code de la construction et de l'habitation. - art. L631-7 (M)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000006825985", "@num": "L631-7", "#text": "Code de la construction et de l'habitation. - art. L631-7 (M)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000006825981", "@num": "L631-7", "#text": "Code de la construction et de l'habitation. - art. L631-7 (M)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000006825983", "@num": "L631-7", "#text": "Code de la construction et de l'habitation. - art. L631-7 (M)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000006825982", "@num": "L631-7", "#text": "Code de la construction et de l'habitation. - art. L631-7 (M)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000006825986", "@num": "L631-7", "#text": "Code de la construction et de l'habitation. - art. L631-7 (V)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000006825849", "@num": "L631-7-1", "#text": "Code de la construction et de l'habitation. - art. L631-7-1 (M)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000006825848", "@num": "L631-7-1", "#text": "Code de la construction et de l'habitation. - art. L631-7-1 (M)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000006825850", "@num": "L631-7-1", "#text": "Code de la construction et de l'habitation. - art. L631-7-1 (V)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000006825851", "@num": "L631-7-2", "#text": "Code de la construction et de l'habitation. - art. L631-7-2 (M)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000006825852", "@num": "L631-7-2", "#text": "Code de la construction et de l'habitation. - art. L631-7-2 (M)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000006825853", "@num": "L631-7-2", "#text": "Code de la construction et de l'habitation. - art. L631-7-2 (V)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000006825854", "@num": "L631-7-3", "#text": "Code de la construction et de l'habitation. - art. L631-7-3 (M)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000006825855", "@num": "L631-7-3", "#text": "Code de la construction et de l'habitation. - art. L631-7-3 (M)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000006825856", "@num": "L631-7-3", "#text": "Code de la construction et de l'habitation. - art. L631-7-3 (M)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000006825857", "@num": "L631-7-3", "#text": "Code de la construction et de l'habitation. - art. L631-7-3 (V)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000006825860", "@num": "L631-8", "#text": "Code de la construction et de l'habitation. - art. L631-8 (M)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000006825859", "@num": "L631-8", "#text": "Code de la construction et de l'habitation. - art. L631-8 (M)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000006825858", "@num": "L631-8", "#text": "Code de la construction et de l'habitation. - art. L631-8 (M)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000006825861", "@num": "L631-8", "#text": "Code de la construction et de l'habitation. - art. L631-8 (V)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000006825862", "@num": "L631-9", "#text": "Code de la construction et de l'habitation. - art. L631-9 (M)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000006825863", "@num": "L631-9", "#text": "Code de la construction et de l'habitation. - art. L631-9 (M)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000006825864", "@num": "L631-9", "#text": "Code de la construction et de l'habitation. - art. L631-9 (V)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000006825870", "@num": "L632-1", "#text": "Code de la construction et de l'habitation. - art. L632-1 (M)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000006825869", "@num": "L632-1", "#text": "Code de la construction et de l'habitation. - art. L632-1 (M)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000006825868", "@num": "L632-1", "#text": "Code de la construction et de l'habitation. - art. L632-1 (M)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000006825871", "@num": "L632-1", "#text": "Code de la construction et de l'habitation. - art. L632-1 (V)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000006825872", "@num": "L632-2", "#text": "Code de la construction et de l'habitation. - art. L632-2 (M)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000006825873", "@num": "L632-2", "#text": "Code de la construction et de l'habitation. - art. L632-2 (V)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000006825874", "@num": "L632-3", "#text": "Code de la construction et de l'habitation. - art. L632-3 (V)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000006825875", "@num": "L633-1", "#text": "Code de la construction et de l'habitation. - art. L633-1 (M)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000006825876", "@num": "L633-1", "#text": "Code de la construction et de l'habitation. - art. L633-1 (V)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000006825877", "@num": "L633-2", "#text": "Code de la construction et de l'habitation. - art. L633-2 (V)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000028807441", "@num": "L633-2", "#text": "Code de la construction et de l'habitation. - art. L633-2 (V)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000006825878", "@num": "L633-3", "#text": "Code de la construction et de l'habitation. - art. L633-3 (M)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000031726860", "@num": "L633-3", "#text": "Code de la construction et de l'habitation. - art. L633-3 (V)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000006825880", "@num": "L633-4", "#text": "Code de la construction et de l'habitation. - art. L633-4 (M)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000006825879", "@num": "L633-4", "#text": "Code de la construction et de l'habitation. - art. L633-4 (M)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000006825881", "@num": "L633-4", "#text": "Code de la construction et de l'habitation. - art. L633-4 (V)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000028807445", "@num": "L633-4", "#text": "Code de la construction et de l'habitation. - art. L633-4 (V)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000006825882", "@num": "L633-4-1", "#text": "Code de la construction et de l'habitation. - art. L633-4-1 (V)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000006825883", "@num": "L633-5", "#text": "Code de la construction et de l'habitation. - art. L633-5 (M)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000006825884", "@num": "L633-5", "#text": "Code de la construction et de l'habitation. - art. L633-5 (M)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000037669844", "@num": "L633-5", "#text": "Code de la construction et de l'habitation. - art. L633-5 (V)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000006825885", "@num": "L641-1", "#text": "Code de la construction et de l'habitation. - art. L641-1 (M)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000006825886", "@num": "L641-1", "#text": "Code de la construction et de l'habitation. - art. L641-1 (M)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000006825887", "@num": "L641-1", "#text": "Code de la construction et de l'habitation. - art. L641-1 (M)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000037667255", "@num": "L641-1", "#text": "Code de la construction et de l'habitation. - art. L641-1 (V)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000006825905", "@num": "L641-10", "#text": "Code de la construction et de l'habitation. - art. L641-10 (M)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000006825906", "@num": "L641-10", "#text": "Code de la construction et de l'habitation. - art. L641-10 (V)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000006825907", "@num": "L641-11", "#text": "Code de la construction et de l'habitation. - art. L641-11 (M)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000006825908", "@num": "L641-11", "#text": "Code de la construction et de l'habitation. - art. L641-11 (V)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000006825909", "@num": "L641-12", "#text": "Code de la construction et de l'habitation. - art. L641-12 (M)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000006825910", "@num": "L641-12", "#text": "Code de la construction et de l'habitation. - art. L641-12 (V)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000006825911", "@num": "L641-13", "#text": "Code de la construction et de l'habitation. - art. L641-13 (M)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000006825912", "@num": "L641-13", "#text": "Code de la construction et de l'habitation. - art. L641-13 (V)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000006825913", "@num": "L641-14", "#text": "Code de la construction et de l'habitation. - art. L641-14 (M)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000006825914", "@num": "L641-14", "#text": "Code de la construction et de l'habitation. - art. L641-14 (V)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000006825888", "@num": "L641-2", "#text": "Code de la construction et de l'habitation. - art. L641-2 (M)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000006825889", "@num": "L641-2", "#text": "Code de la construction et de l'habitation. - art. L641-2 (V)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000006825890", "@num": "L641-3", "#text": "Code de la construction et de l'habitation. - art. L641-3 (M)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000006825891", "@num": "L641-3", "#text": "Code de la construction et de l'habitation. - art. L641-3 (M)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000037667247", "@num": "L641-3", "#text": "Code de la construction et de l'habitation. - art. L641-3 (V)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000006825892", "@num": "L641-4", "#text": "Code de la construction et de l'habitation. - art. L641-4 (M)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000006825893", "@num": "L641-4", "#text": "Code de la construction et de l'habitation. - art. L641-4 (V)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000029336866", "@num": "L641-4", "#text": "Code de la construction et de l'habitation. - art. L641-4 (V)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000006825894", "@num": "L641-5", "#text": "Code de la construction et de l'habitation. - art. L641-5 (M)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000006825895", "@num": "L641-5", "#text": "Code de la construction et de l'habitation. - art. L641-5 (M)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000037667239", "@num": "L641-5", "#text": "Code de la construction et de l'habitation. - art. L641-5 (V)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000006825896", "@num": "L641-6", "#text": "Code de la construction et de l'habitation. - art. L641-6 (M)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000006825897", "@num": "L641-6", "#text": "Code de la construction et de l'habitation. - art. L641-6 (V)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000006825898", "@num": "L641-7", "#text": "Code de la construction et de l'habitation. - art. L641-7 (M)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000006825900", "@num": "L641-7", "#text": "Code de la construction et de l'habitation. - art. L641-7 (M)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000006825899", "@num": "L641-7", "#text": "Code de la construction et de l'habitation. - art. L641-7 (V)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000037667229", "@num": "L641-7", "#text": "Code de la construction et de l'habitation. - art. L641-7 (V)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000006825901", "@num": "L641-8", "#text": "Code de la construction et de l'habitation. - art. L641-8 (M)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CONCORDANCE", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000006825901", "@num": "L641-8", "#text": "Code de la construction et de l'habitation. - art. L641-8 (M)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000006825902", "@num": "L641-8", "#text": "Code de la construction et de l'habitation. - art. L641-8 (V)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000006825902", "@num": "L641-8", "#text": "Code de la construction et de l'habitation. - art. L641-8 (V)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CONCORDANCE", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000006825903", "@num": "L641-9", "#text": "Code de la construction et de l'habitation. - art. L641-9 (M)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000006825904", "@num": "L641-9", "#text": "Code de la construction et de l'habitation. - art. L641-9 (V)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000039279903", "@num": "L641-9", "#text": "Code de la construction et de l'habitation. - art. L641-9 (VD)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000026968771", "@num": "L642-1", "#text": "Code de la construction et de l'habitation. - art. L642-1 (M)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000006825915", "@num": "L642-1", "#text": "Code de la construction et de l'habitation. - art. L642-1 (V)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000037667221", "@num": "L642-1", "#text": "Code de la construction et de l'habitation. - art. L642-1 (V)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000006825924", "@num": "L642-10", "#text": "Code de la construction et de l'habitation. - art. L642-10 (V)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000026968775", "@num": "L642-10", "#text": "Code de la construction et de l'habitation. - art. L642-10 (V)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000006825925", "@num": "L642-11", "#text": "Code de la construction et de l'habitation. - art. L642-11 (V)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000006825926", "@num": "L642-12", "#text": "Code de la construction et de l'habitation. - art. L642-12 (V)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000026968778", "@num": "L642-12", "#text": "Code de la construction et de l'habitation. - art. L642-12 (V)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000006825927", "@num": "L642-13", "#text": "Code de la construction et de l'habitation. - art. L642-13 (V)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000006825928", "@num": "L642-14", "#text": "Code de la construction et de l'habitation. - art. L642-14 (V)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000006825929", "@num": "L642-15", "#text": "Code de la construction et de l'habitation. - art. L642-15 (M)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000037667188", "@num": "L642-15", "#text": "Code de la construction et de l'habitation. - art. L642-15 (V)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000006825930", "@num": "L642-16", "#text": "Code de la construction et de l'habitation. - art. L642-16 (V)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000006825931", "@num": "L642-17", "#text": "Code de la construction et de l'habitation. - art. L642-17 (V)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000006825932", "@num": "L642-18", "#text": "Code de la construction et de l'habitation. - art. L642-18 (V)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000006825933", "@num": "L642-19", "#text": "Code de la construction et de l'habitation. - art. L642-19 (V)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000006825916", "@num": "L642-2", "#text": "Code de la construction et de l'habitation. - art. L642-2 (V)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000006825934", "@num": "L642-20", "#text": "Code de la construction et de l'habitation. - art. L642-20 (V)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000006825935", "@num": "L642-21", "#text": "Code de la construction et de l'habitation. - art. L642-21 (V)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000006825936", "@num": "L642-22", "#text": "Code de la construction et de l'habitation. - art. L642-22 (V)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000006825937", "@num": "L642-23", "#text": "Code de la construction et de l'habitation. - art. L642-23 (M)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000037667183", "@num": "L642-23", "#text": "Code de la construction et de l'habitation. - art. L642-23 (V)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000006825938", "@num": "L642-24", "#text": "Code de la construction et de l'habitation. - art. L642-24 (V)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000006825939", "@num": "L642-25", "#text": "Code de la construction et de l'habitation. - art. L642-25 (V)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000006825940", "@num": "L642-26", "#text": "Code de la construction et de l'habitation. - art. L642-26 (V)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000006825941", "@num": "L642-27", "#text": "Code de la construction et de l'habitation. - art. L642-27 (V)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000006825942", "@num": "L642-28", "#text": "Code de la construction et de l'habitation. - art. L642-28 (M)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000006825943", "@num": "L642-28", "#text": "Code de la construction et de l'habitation. - art. L642-28 (V)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000006825917", "@num": "L642-3", "#text": "Code de la construction et de l'habitation. - art. L642-3 (V)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000006825918", "@num": "L642-4", "#text": "Code de la construction et de l'habitation. - art. L642-4 (M)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000037667206", "@num": "L642-4", "#text": "Code de la construction et de l'habitation. - art. L642-4 (V)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000006825919", "@num": "L642-5", "#text": "Code de la construction et de l'habitation. - art. L642-5 (M)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000037667200", "@num": "L642-5", "#text": "Code de la construction et de l'habitation. - art. L642-5 (V)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000006825920", "@num": "L642-6", "#text": "Code de la construction et de l'habitation. - art. L642-6 (V)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000006825921", "@num": "L642-7", "#text": "Code de la construction et de l'habitation. - art. L642-7 (V)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000006825922", "@num": "L642-8", "#text": "Code de la construction et de l'habitation. - art. L642-8 (V)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000006825923", "@num": "L642-9", "#text": "Code de la construction et de l'habitation. - art. L642-9 (M)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000037667195", "@num": "L642-9", "#text": "Code de la construction et de l'habitation. - art. L642-9 (V)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000006825944", "@num": "L651-1", "#text": "Code de la construction et de l'habitation. - art. L651-1 (M)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000006825945", "@num": "L651-1", "#text": "Code de la construction et de l'habitation. - art. L651-1 (V)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000006825961", "@num": "L651-10", "#text": "Code de la construction et de l'habitation. - art. L651-10 (M)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000006825962", "@num": "L651-10", "#text": "Code de la construction et de l'habitation. - art. L651-10 (V)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000006825947", "@num": "L651-2", "#text": "Code de la construction et de l'habitation. - art. L651-2 (M)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000006825946", "@num": "L651-2", "#text": "Code de la construction et de l'habitation. - art. L651-2 (M)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000028806855", "@num": "L651-2", "#text": "Code de la construction et de l'habitation. - art. L651-2 (M)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000033461416", "@num": "L651-2", "#text": "Code de la construction et de l'habitation. - art. L651-2 (M)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000037670756", "@num": "L651-2", "#text": "Code de la construction et de l'habitation. - art. L651-2 (M)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000006825948", "@num": "L651-2", "#text": "Code de la construction et de l'habitation. - art. L651-2 (V)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000038310711", "@num": "L651-2", "#text": "Code de la construction et de l'habitation. - art. L651-2 (V)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000050623451", "@num": "L651-2", "#text": "Code de la construction et de l'habitation. - art. L651-2 (V)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000038791019", "@num": "L651-2", "#text": "Code de la construction et de l'habitation. - art. L651-2 (VD)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000006825951", "@num": "L651-3", "#text": "Code de la construction et de l'habitation. - art. L651-3 (M)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000006825949", "@num": "L651-3", "#text": "Code de la construction et de l'habitation. - art. L651-3 (M)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000006825950", "@num": "L651-3", "#text": "Code de la construction et de l'habitation. - art. L651-3 (M)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000006825952", "@num": "L651-3", "#text": "Code de la construction et de l'habitation. - art. L651-3 (V)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000006825953", "@num": "L651-4", "#text": "Code de la construction et de l'habitation. - art. L651-4 (M)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000006825954", "@num": "L651-4", "#text": "Code de la construction et de l'habitation. - art. L651-4 (V)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000039279900", "@num": "L651-4", "#text": "Code de la construction et de l'habitation. - art. L651-4 (VD)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000006825956", "@num": "L651-5", "#text": "Code de la construction et de l'habitation. - art. L651-5 (M)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000006825955", "@num": "L651-5", "#text": "Code de la construction et de l'habitation. - art. L651-5 (M)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000006825957", "@num": "L651-5", "#text": "Code de la construction et de l'habitation. - art. L651-5 (V)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000006825987", "@num": "L651-6", "#text": "Code de la construction et de l'habitation. - art. L651-6 (M)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000006825988", "@num": "L651-6", "#text": "Code de la construction et de l'habitation. - art. L651-6 (M)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000006825958", "@num": "L651-7", "#text": "Code de la construction et de l'habitation. - art. L651-7 (M)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000049397737", "@num": "L651-7", "#text": "Code de la construction et de l'habitation. - art. L651-7 (V)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000006825959", "@num": "L651-8", "#text": "Code de la construction et de l'habitation. - art. L651-8 (V)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000006825960", "@num": "L651-9", "#text": "Code de la construction et de l'habitation. - art. L651-9 (V)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000006825963", "@num": "L661-1", "#text": "Code de la construction et de l'habitation. - art. L661-1 (M)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000006825964", "@num": "L661-1", "#text": "Code de la construction et de l'habitation. - art. L661-1 (M)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000006825965", "@num": "L661-1", "#text": "Code de la construction et de l'habitation. - art. L661-1 (V)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000006825966", "@num": "L661-2", "#text": "Code de la construction et de l'habitation. - art. L661-2 (M)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000006825967", "@num": "L661-2", "#text": "Code de la construction et de l'habitation. - art. L661-2 (VT)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000006825968", "@num": "L662-1", "#text": "Code de la construction et de l'habitation. - art. L662-1 (M)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000006825969", "@num": "L662-1", "#text": "Code de la construction et de l'habitation. - art. L662-1 (M)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000006825970", "@num": "L662-1", "#text": "Code de la construction et de l'habitation. - art. L662-1 (V)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000006825971", "@num": "L662-2", "#text": "Code de la construction et de l'habitation. - art. L662-2 (V)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000028574433", "@num": "L662-2", "#text": "Code de la construction et de l'habitation. - art. L662-2 (V)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000006899857", "@num": "R*481-1", "#text": "Code de la construction et de l'habitation. - art. R*481-1 (M)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000006899858", "@num": "R*481-1", "#text": "Code de la construction et de l'habitation. - art. R*481-1 (T)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000006899859", "@num": "R*481-2", "#text": "Code de la construction et de l'habitation. - art. R*481-2 (V)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000006899848", "@num": "R*481-3", "#text": "Code de la construction et de l'habitation. - art. R*481-3 (V)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000006899850", "@num": "R*481-5", "#text": "Code de la construction et de l'habitation. - art. R*481-5 (V)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000006899851", "@num": "R*481-5-1", "#text": "Code de la construction et de l'habitation. - art. R*481-5-1 (M)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000034685149", "@num": "R*481-5-1", "#text": "Code de la construction et de l'habitation. - art. R*481-5-1 (M)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000038688744", "@num": "R*481-5-1", "#text": "Code de la construction et de l'habitation. - art. R*481-5-1 (V)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000006899852", "@num": "R*481-6", "#text": "Code de la construction et de l'habitation. - art. R*481-6 (M)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000006899853", "@num": "R*481-6", "#text": "Code de la construction et de l'habitation. - art. R*481-6 (V)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000028424442", "@num": "R*481-6", "#text": "Code de la construction et de l'habitation. - art. R*481-6 (V)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000006900404", "@num": "R*491-1", "#text": "Code de la construction et de l'habitation. - art. R*491-1 (V)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000006900406", "@num": "R*491-2", "#text": "Code de la construction et de l'habitation. - art. R*491-2 (V)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000006900407", "@num": "R*491-3", "#text": "Code de la construction et de l'habitation. - art. R*491-3 (V)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000006900408", "@num": "R*491-4", "#text": "Code de la construction et de l'habitation. - art. R*491-4 (V)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000006900409", "@num": "R*491-5", "#text": "Code de la construction et de l'habitation. - art. R*491-5 (V)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000006900410", "@num": "R*491-6", "#text": "Code de la construction et de l'habitation. - art. R*491-6 (V)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000006895994", "@num": "R112-1", "#text": "Code de la construction et de l'habitation. - art. R112-1 (Ab)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000006895993", "@num": "R112-1", "#text": "Code de la construction et de l'habitation. - art. R112-1 (M)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000006895995", "@num": "R112-2", "#text": "Code de la construction et de l'habitation. - art. R112-2 (Ab)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000029826808", "@num": "R112-3", "#text": "Code de la construction et de l'habitation. - art. R112-3 (Ab)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000006895996", "@num": "R112-3", "#text": "Code de la construction et de l'habitation. - art. R112-3 (M)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000029826800", "@num": "R112-4", "#text": "Code de la construction et de l'habitation. - art. R112-4 (Ab)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000028424390", "@num": "R112-4", "#text": "Code de la construction et de l'habitation. - art. R112-4 (M)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000006895997", "@num": "R112-4", "#text": "Code de la construction et de l'habitation. - art. R112-4 (V)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000025832232", "@num": "R125-1", "#text": "Code de la construction et de l'habitation. - art. R125-1 (Ab)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000006896166", "@num": "R125-1", "#text": "Code de la construction et de l'habitation. - art. R125-1 (V)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000032499003", "@num": "R125-1-1", "#text": "Code de la construction et de l'habitation. - art. R125-1-1 (Ab)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000006896167", "@num": "R125-1-1", "#text": "Code de la construction et de l'habitation. - art. R125-1-1 (M)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000006896168", "@num": "R125-1-2", "#text": "Code de la construction et de l'habitation. - art. R125-1-2 (V)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000006896169", "@num": "R125-1-3", "#text": "Code de la construction et de l'habitation. - art. R125-1-3 (Ab)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000006896170", "@num": "R125-1-4", "#text": "Code de la construction et de l'habitation. - art. R125-1-4 (Ab)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000032499029", "@num": "R125-2", "#text": "Code de la construction et de l'habitation. - art. R125-2 (Ab)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000006896171", "@num": "R125-2", "#text": "Code de la construction et de l'habitation. - art. R125-2 (M)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000025832238", "@num": "R125-2-1", "#text": "Code de la construction et de l'habitation. - art. R125-2-1 (Ab)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000006896172", "@num": "R125-2-1", "#text": "Code de la construction et de l'habitation. - art. R125-2-1 (V)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000006896173", "@num": "R125-2-2", "#text": "Code de la construction et de l'habitation. - art. R125-2-2 (Ab)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000006896174", "@num": "R125-2-3", "#text": "Code de la construction et de l'habitation. - art. R125-2-3 (Ab)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000032499015", "@num": "R125-2-4", "#text": "Code de la construction et de l'habitation. - art. R125-2-4 (Ab)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000006896175", "@num": "R125-2-4", "#text": "Code de la construction et de l'habitation. - art. R125-2-4 (M)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000032499039", "@num": "R125-2-5", "#text": "Code de la construction et de l'habitation. - art. R125-2-5 (Ab)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000006896176", "@num": "R125-2-5", "#text": "Code de la construction et de l'habitation. - art. R125-2-5 (V)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000025832253", "@num": "R125-2-5", "#text": "Code de la construction et de l'habitation. - art. R125-2-5 (VD)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000032499124", "@num": "R125-2-6", "#text": "Code de la construction et de l'habitation. - art. R125-2-6 (Ab)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000006896177", "@num": "R125-2-6", "#text": "Code de la construction et de l'habitation. - art. R125-2-6 (V)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000025832250", "@num": "R125-2-6", "#text": "Code de la construction et de l'habitation. - art. R125-2-6 (VD)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000006896178", "@num": "R125-2-7", "#text": "Code de la construction et de l'habitation. - art. R125-2-7 (Ab)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000039344356", "@num": "R125-2-8", "#text": "Code de la construction et de l'habitation. - art. R125-2-8 (Ab)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000006896179", "@num": "R125-2-8", "#text": "Code de la construction et de l'habitation. - art. R125-2-8 (V)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000025832261", "@num": "R125-2-8", "#text": "Code de la construction et de l'habitation. - art. R125-2-8 (VD)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000006897384", "@num": "R331-78", "#text": "Code de la construction et de l'habitation. - art. R331-78 (M)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000006897385", "@num": "R331-78", "#text": "Code de la construction et de l'habitation. - art. R331-78 (M)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000006897386", "@num": "R331-78", "#text": "Code de la construction et de l'habitation. - art. R331-78 (T)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000006897387", "@num": "R331-79", "#text": "Code de la construction et de l'habitation. - art. R331-79 (M)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000006897388", "@num": "R331-79", "#text": "Code de la construction et de l'habitation. - art. R331-79 (T)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000006897389", "@num": "R331-80", "#text": "Code de la construction et de l'habitation. - art. R331-80 (M)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000006897390", "@num": "R331-80", "#text": "Code de la construction et de l'habitation. - art. R331-80 (T)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000006897391", "@num": "R331-81", "#text": "Code de la construction et de l'habitation. - art. R331-81 (M)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000006897392", "@num": "R331-81", "#text": "Code de la construction et de l'habitation. - art. R331-81 (T)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000006897394", "@num": "R331-82", "#text": "Code de la construction et de l'habitation. - art. R331-82 (Ab)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000006897393", "@num": "R331-82", "#text": "Code de la construction et de l'habitation. - art. R331-82 (M)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000006897395", "@num": "R331-83", "#text": "Code de la construction et de l'habitation. - art. R331-83 (M)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000006897396", "@num": "R331-83", "#text": "Code de la construction et de l'habitation. - art. R331-83 (T)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000006897399", "@num": "R331-84", "#text": "Code de la construction et de l'habitation. - art. R331-84 (M)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000006897400", "@num": "R331-84", "#text": "Code de la construction et de l'habitation. - art. R331-84 (T)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000006899845", "@num": "R472-1", "#text": "Code de la construction et de l'habitation. - art. R472-1 (V)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000039042839", "@num": "R481-2", "#text": "Code de la construction et de l'habitation. - art. R481-2 (VD)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000039042835", "@num": "R481-3", "#text": "Code de la construction et de l'habitation. - art. R481-3 (VD)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000006899849", "@num": "R481-4", "#text": "Code de la construction et de l'habitation. - art. R481-4 (V)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000039042829", "@num": "R481-5-1", "#text": "Code de la construction et de l'habitation. - art. R481-5-1 (VD)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000044636907", "@num": "R481-5-1", "#text": "Code de la construction et de l'habitation. - art. R481-5-1 (VD)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000045646946", "@num": "R481-6", "#text": "Code de la construction et de l'habitation. - art. R481-6 (V)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000039042824", "@num": "R481-6", "#text": "Code de la construction et de l'habitation. - art. R481-6 (VD)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000039042803", "@num": "R491-1", "#text": "Code de la construction et de l'habitation. - art. R491-1 (VD)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000039042797", "@num": "R491-2", "#text": "Code de la construction et de l'habitation. - art. R491-2 (VD)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000044636893", "@num": "R491-2", "#text": "Code de la construction et de l'habitation. - art. R491-2 (VD)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000039042792", "@num": "R491-3", "#text": "Code de la construction et de l'habitation. - art. R491-3 (VD)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000044636888", "@num": "R491-3", "#text": "Code de la construction et de l'habitation. - art. R491-3 (VD)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000039042786", "@num": "R491-4", "#text": "Code de la construction et de l'habitation. - art. R491-4 (VD)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000044636883", "@num": "R491-4", "#text": "Code de la construction et de l'habitation. - art. R491-4 (VD)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000039042775", "@num": "R491-6", "#text": "Code de la construction et de l'habitation. - art. R491-6 (VD)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "CODIFICATION", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000006315879", "@num": "L160", "#text": "Livre des procédures fiscales - art. L160 (M)", "@sens": "cible", "@cidtexte": "LEGITEXT000006069583", "@typelien": "CONCORDANCE", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" } ] }, "TITRE": "Décret n° 78-621 du 31 mai 1978", "MCS_TXT": { "MC": [ "CODE DE LA CONSTRUCTION ET L'HABITATION‎", "CCH", "HLM", "ACCESSION A LA PROPRIETE", "CODIFICATION", "FORCE DE LOI" ] }, "TITREFULL": "Décret n° 78-621 du 31 mai 1978 portant codification des textes concernant la construction et ‎l'habitation (première partie: Législative)‎" }, "META_TEXTE_CHRONICLE": { "CID": "JORFTEXT000000516442", "NUM": "78-621", "DATE_PUBLI": "1978-06-08", "DATE_TEXTE": "1978-05-31", "ORIGINE_PUBLI": "JORF du 8 juin 1978", "PAGE_DEB_PUBLI": 2295, "PAGE_FIN_PUBLI": 2297 } }, "META_COMMUN": { "ID": "JORFTEXT000000516442", "URL": "texte/version/JORF/TEXT/00/00/00/51/64/JORFTEXT000000516442.xml", "NATURE": "DECRET", "ORIGINE": "JORF", "ANCIEN_ID": "1DX978621" } }, "ENTREPRISE": { "@texte_entreprise": "non" } }, "JORFTEXT000000709335": { "SM": { "CONTENU": "Modification du code de la construction et de l'habitation, du code civil." }, "TP": { "CONTENU": "(1) Travaux préparatoires: loi no 90-1129.
\n
Sénat:
\n
Projet de loi no 298 (1989-1990);
Rapport de M. Robert Laucournet, au nom de la commission des affaires économiques, no 480 (1989-1990);
Discussion et adoption le 10 octobre 1990.
\n
Assemblée nationale:
\n
Projet, adopté par le Sénat, no 1644;
Rapport de M. Roger Léron, au nom de la commission de la production, no 1697;
Discussion et adoption le 20 novembre 1990.
\n
Sénat:
Projet de loi, modifié par l'Assemblée nationale, no 92 (1990-1991);
Rapport de M. Robert Laucournet, au nom de la commission des affaires économiques, no 133 (1990-1991);
Discussion et adoption le 11 décembre 1990.
" }, "META": { "META_SPEC": { "META_TEXTE_VERSION": { "LIENS": { "LIEN": [ { "@id": "JORFTEXT000000522423", "#text": "LOI n° 77-2 du 3 janvier 1977", "@sens": "source", "@cidtexte": "JORFTEXT000000522423", "@numtexte": "77-2", "@typelien": "APPLICATION", "@naturetexte": "LOI", "@datesignatexte": "1977-01-03" }, { "@id": "JORFTEXT000000333548", "#text": "Ordonnance n°86-1243 du 1 décembre 1986", "@sens": "source", "@cidtexte": "JORFTEXT000000333548", "@numtexte": "86-1243", "@typelien": "APPLICATION", "@naturetexte": "ORDONNANCE", "@datesignatexte": "1986-12-01" }, { "@id": "JORFTEXT000000343019", "#text": "Loi n° 89-1010 du 31 décembre 1989", "@sens": "source", "@cidtexte": "JORFTEXT000000343019", "@nortexte": "ECOX8900100L", "@numtexte": "89-1010", "@typelien": "APPLICATION", "@naturetexte": "LOI", "@datesignatexte": "1989-12-31" }, { "@id": "JORFTEXT000000344731", "#text": "DECRET91-1201", "@sens": "cible", "@cidtexte": "JORFTEXT000000344731", "@nortexte": "EQUC9101565D", "@numtexte": "91-1201", "@typelien": "APPLICATION", "@naturetexte": "DECRET", "@datesignatexte": "1991-11-27" }, { "@id": "JORFTEXT000000710038", "#text": "DECRET91-1202", "@sens": "cible", "@cidtexte": "JORFTEXT000000710038", "@nortexte": "EQUC9101566D", "@numtexte": "91-1202", "@typelien": "APPLICATION", "@naturetexte": "DECRET", "@datesignatexte": "1991-11-27" }, { "@id": "JORFTEXT000000710552", "#text": "ARRETE", "@sens": "cible", "@cidtexte": "JORFTEXT000000710552", "@nortexte": "EQUC9101700A", "@typelien": "APPLICATION", "@naturetexte": "ARRETE", "@datesignatexte": "1991-11-28" }, { "@id": "LEGIARTI000006830655", "@num": "ANNEXE", "#text": "Arrêté du 28 novembre 1991 - art. ANNEXE (M)", "@sens": "cible", "@cidtexte": "JORFTEXT000000710552", "@nortexte": "EQUC9101700A", "@typelien": "CITATION", "@naturetexte": "ARRETE", "@datesignatexte": "1991-11-28" }, { "@id": "LEGIARTI000006830654", "@num": "ANNEXE", "#text": "Arrêté du 28 novembre 1991 - art. ANNEXE (M)", "@sens": "cible", "@cidtexte": "JORFTEXT000000710552", "@nortexte": "EQUC9101700A", "@typelien": "CITATION", "@naturetexte": "ARRETE", "@datesignatexte": "1991-11-28" }, { "@id": "LEGIARTI000034138784", "@num": "ANNEXE", "#text": "Arrêté du 28 novembre 1991 - art. ANNEXE (V)", "@sens": "cible", "@cidtexte": "JORFTEXT000000710552", "@nortexte": "EQUC9101700A", "@typelien": "CITATION", "@naturetexte": "ARRETE", "@datesignatexte": "1991-11-28" }, { "@id": "LEGIARTI000034138799", "@num": "ANNEXE", "#text": "Arrêté du 28 novembre 1991 - art. ANNEXE (V)", "@sens": "cible", "@cidtexte": "JORFTEXT000000710552", "@nortexte": "EQUC9101700A", "@typelien": "CITATION", "@naturetexte": "ARRETE", "@datesignatexte": "1991-11-28" }, { "@id": "JORFARTI000038431580", "#text": "Rapport - art., v. init.", "@sens": "cible", "@cidtexte": "JORFTEXT000038431579", "@nortexte": "TERL1908590P", "@typelien": "CITATION", "@naturetexte": "RAPPORT", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000006443652", "@num": "1792-5", "#text": "Code civil - art. 1792-5 (V)", "@sens": "cible", "@cidtexte": "LEGITEXT000006070721", "@typelien": "SPEC_APPLI", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000006824493", "@num": "L230-1", "#text": "Code de la construction et de l'habitation. - art. L230-1 (V)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "SPEC_APPLI", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000006824509", "@num": "L231-1", "#text": "Code de la construction et de l'habitation. - art. L231-1 (V)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "SPEC_APPLI", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000006824511", "@num": "L231-1-2", "#text": "Code de la construction et de l'habitation. - art. L231-1-2 (Ab)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "SPEC_APPLI", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000006824501", "@num": "L231-10", "#text": "Code de la construction et de l'habitation. - art. L231-10 (V)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "SPEC_APPLI", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000006824502", "@num": "L231-11", "#text": "Code de la construction et de l'habitation. - art. L231-11 (V)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "SPEC_APPLI", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000006824503", "@num": "L231-12", "#text": "Code de la construction et de l'habitation. - art. L231-12 (M)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "SPEC_APPLI", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000006824504", "@num": "L231-13", "#text": "Code de la construction et de l'habitation. - art. L231-13 (M)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "SPEC_APPLI", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000006824659", "@num": "L231-2", "#text": "Code de la construction et de l'habitation. - art. L231-2 (M)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "SPEC_APPLI", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000006824513", "@num": "L231-3", "#text": "Code de la construction et de l'habitation. - art. L231-3 (V)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "SPEC_APPLI", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000006824494", "@num": "L231-4", "#text": "Code de la construction et de l'habitation. - art. L231-4 (V)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "SPEC_APPLI", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000006824495", "@num": "L231-5", "#text": "Code de la construction et de l'habitation. - art. L231-5 (V)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "SPEC_APPLI", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000006824496", "@num": "L231-6", "#text": "Code de la construction et de l'habitation. - art. L231-6 (M)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "SPEC_APPLI", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000006824497", "@num": "L231-6", "#text": "Code de la construction et de l'habitation. - art. L231-6 (V)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "SPEC_APPLI", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000006824499", "@num": "L231-8", "#text": "Code de la construction et de l'habitation. - art. L231-8 (V)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "SPEC_APPLI", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000006824500", "@num": "L231-9", "#text": "Code de la construction et de l'habitation. - art. L231-9 (V)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "SPEC_APPLI", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000006824506", "@num": "L232-1", "#text": "Code de la construction et de l'habitation. - art. L232-1 (V)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "SPEC_APPLI", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000006824507", "@num": "L232-2", "#text": "Code de la construction et de l'habitation. - art. L232-2 (V)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "SPEC_APPLI", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000006824529", "@num": "L241-8", "#text": "Code de la construction et de l'habitation. - art. L241-8 (M)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "SPEC_APPLI", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000006824532", "@num": "L241-9", "#text": "Code de la construction et de l'habitation. - art. L241-9 (M)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "SPEC_APPLI", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000006824637", "@num": "L271-1", "#text": "Code de la construction et de l'habitation. - art. L271-1 (M)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "SPEC_APPLI", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000006824653", "@num": "L281-1", "#text": "Code de la construction et de l'habitation. - art. L281-1 (MMN)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "SPEC_APPLI", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" }, { "@id": "LEGIARTI000006824654", "@num": "L281-1", "#text": "Code de la construction et de l'habitation. - art. L281-1 (V)", "@sens": "cible", "@cidtexte": "LEGITEXT000006074096", "@typelien": "SPEC_APPLI", "@naturetexte": "CODE", "@datesignatexte": "2999-01-01" } ] }, "TITRE": "LOI n° 90-1129 du 19 décembre 1990", "MCS_TXT": { "MC": [ "EQUIPEMENT", "CODE DE LA CONSTRUCTION ET DE L'HABITATION", "CCH", "CODE CIVIL", "CONTRAT", "CONTRAT DE CONSTRUCTION", "MAISON", "MAISON INDIVIDUELLE", "URBANISME", "VENTE", "PLAN", "MAITRE D'OEUVRE", "CONSTRUCTEUR", "GARANTIE", "LIVRAISON", "LOUAGE D'OUVRAGE", "CONTRAT DE LOUAGE D'OUVRAGE", "PROJET DE LOI" ] }, "TITREFULL": "LOI n° 90-1129 du 19 décembre 1990 relative au contrat de construction d'une maison individuelle (1)" }, "META_TEXTE_CHRONICLE": { "CID": "JORFTEXT000000709335", "NOR": "EQUX9000054L", "NUM": "90-1129", "DATE_PUBLI": "1990-12-22", "DATE_TEXTE": "1990-12-19", "NUM_PARUTION": 297, "ORIGINE_PUBLI": "JORF n°297 du 22 décembre 1990", "PAGE_DEB_PUBLI": 15855, "PAGE_FIN_PUBLI": 15859 } }, "META_COMMUN": { "ID": "JORFTEXT000000709335", "URL": "texte/version/JORF/TEXT/00/00/00/70/93/JORFTEXT000000709335.xml", "NATURE": "LOI", "ORIGINE": "JORF", "ANCIEN_ID": "1LX9901129" } }, "VISAS": { "CONTENU": "L'Assemblée nationale et le Sénat ont adopté,
Le Président de la République promulgue la loi dont la teneur suit:
\n
\n
" }, "ENTREPRISE": { "@texte_entreprise": "non" }, "SIGNATAIRES": { "CONTENU": "Fait à Paris, le 19 décembre 1990.
\n

FRANCOIS MITTERRAND

\n
\n

Par le Président de la République:

Le Premier ministre,
MICHEL ROCARD

Le ministre d'Etat, ministre de l'économie,

des finances et du budget,

PIERRE BEREGOVOY

Le garde des sceaux, ministre de la justice,
HENRI NALLET

Le ministre de l'industrie

et de l'aménagement du territoire,

ROGER FAUROUX

Le ministre de l'équipement, du logement,
des transports et de la mer,
\n
MICHEL DELEBARRE

Le ministre délégué au commerce et à l'artisanat,

FRANCOIS DOUBIN

Le ministre délégué au logement,
LOUIS BESSON

Le secrétaire d'Etat à la consommation,

VERONIQUE NEIERTZ

" } } }, "texte_version_lien": [ { "texte_version_id": "JORFTEXT000000709335", "cible": true, "cidtexte": "LEGITEXT000006074096", "id": "LEGIARTI000006824507", "typelien": "SPEC_APPLI" }, { "texte_version_id": "JORFTEXT000000516442", "cible": true, "cidtexte": "LEGITEXT000006074096", "id": "LEGIARTI000006824507", "typelien": "CODIFICATION" } ], "follow": [ "LIENS.LIEN[@sens=cible,@typelien=CREATION].@id" ], "id": "LEGIARTI000006824507", "liens_entrants": true }

Article L232-2 AUTONOME VIGUEUR, en vigueur depuis le 01/12/1991 (Code de la construction et de l'habitation)